S02 EXHIBIT A - Statement of Prior Experience.pdf
PDF 172 KB Posted
- Solicitation number
- 36C24426R0035
About this file
This is a template form for Statement of Prior Experience (Exhibit A) used in federal construction contract solicitations to evaluate offeror qualifications based on past performance.
Part 1 requires offerors to submit no more than three (3) prior projects or contracts completed within the five years preceding the solicitation issue date. For each project, offerors must provide: company name, project/contract title, description of effort as prime or subcontractor, contract number, original and current/final contract values with explanation of any variance, original completion date and current schedule with estimated/final completion date, and primary cause for any contract modifications. Offerors must include detailed descriptions of work performed, specific elements performed by their firm, identification of major subcontractors with indication of whether they will be used on the current solicitation, technical areas uniquely relevant to the solicitation, and contact information (phone and email) for the government Contracting Officer and/or Contracting Officer's Representative for reference purposes.
Part 2 requires offerors to identify all subcontractors and teaming partners to be utilized on the contract, with a maximum of three (3) subcontractors permitted per discipline. Specialty trades must identify major subcontractors or teaming partners specific to their trade. Upon completion of Part 1, offerors must prepare and send Exhibit C Package to references for each of the three construction projects or specialty trades identified in Part 1.
View the file
Other files
Show all 16
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
EXHIBIT A STATEMENT OF PRIOR EXPERIENCE
PART 1: Prepare no more than three (3) Part 1 forms:
Provide the following information requested in this format for each of the projects/contracts being described. Projects may be on going and cannot have been completed any later than 5 years prior to the solicitation issue date. Provide frank, concise comments regarding YOUR PERFORMANCE on the contracts you identify. Use additional space as required.
A. Offeror (Your) Name (Company/Division):
B. Project/Contract Title:
C. Contract Specifics:
1. Description of Effort as Prime or _Subcontractor
2. Contract Number
3. Original Contract $ Value Current/Final Contract $ Value
4. If amounts in 3 above are different, provide a brief description of the reason:
5. Completion Date:
1. Original Date:
2. Current Schedule: _____________________
3. Estimate/Final Completion Date:
4. Primary cause for Contract Modifications
D. Provide detailed description of the work performed under the contract and describe why you believe the work is very relevant, relevant or semi-relevant to this solicited project.
(Use as much space as necessary)
In addition, address the following
1. Describe the specific elements of the work performed by your firm.
2. Indicate what elements of work were performed by your major subcontractors and indicate if those same subcontractors will be used on projects awarded under this solicitation. Should you intend to use these same subcontractors, please list their company names and described their principal areas of work that they will perform.
3. Address any technical areas about this project you consider uniquely relevant to this solicitation.
E. Point of Contact for Owner/Government agency Contracting Officer and or inspector (COR); include a current phone number and email address for each.
End of Part 1- Questionnaire Requirements – Prepare and send Exhibit C Package to the reference(s) for each of the no more than three Construction Projects, or Specialty Trade if applicable provided in Exhibit A, Part 1. See below for Exhibit A, Part 2.
Part 2 - Additional offeror information required.
A. Name subcontractors and/or Teaming Partners to be utilized on this contract. Multiple subcontractors may be named for the same discipline but are limited to a maximum of three (3) subcontractors per discipline. As a minimum, provide the name(s) of subcontractors to be utilized in the following areas:
(Specialty Trades will address their specific trade for any major subcontractor or Teaming partner)
| PART 1: Prepare no more than three (3) Part 1 forms: |
| End of Part 1- Questionnaire Requirements – Prepare and send Exhibit C Package to the reference(s) for each of the no more than three Construction Projects, or Specialty Trade if applicable provided in Exhibit A, Part 1. See below for Exhibit A, Part 2. |
File details come from the government source that posted it. Updated .