RFQ_1332KP26Q0033 Boilers Replacement.pdf

WOMEN-OWNED SMALL

BUSINESS (WOSB)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NUMBER 3.AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NUMBER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

REQUEST

FOR QUOTE

(RFQ)

INVITATION

FOR BID

(IFB)

REQUEST

FOR

PROPOSAL

(RFP)

SEE ADDENDUM

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN 29. AWARD OF CONTRACT: REFERENCE

. YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NORTH AMERICAN

INDUSTRY CLASSIFICATION

STANDARD (NAICS):

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

THE DEFENSE PRIORITIES

AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FREE ON

BOARD (FOB) DESTINATION

UNLESS BLOCK IS MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4.

FAR 52.212-3 AND 52.212-5 ARE ATTACHED.

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED.

8(A)

ECONOMICALLY

DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH

AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND

ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS

SPECIFIED

DATED.

OFFER

ADDENDA

ADDENDA

1332KP26Q0033

USDOC/NOAA/NESDIS/FCDAS

1300 EISELE ROAD

FAIRBANKS AK 99712

SIAD-RED

1325 EAST WEST HWY

SSMC2, 11th FLOOR

SILVER SPRING MD 20910

05/28/2026 1500 ED

SIAD-RED 100.00

238220

$19

05/13/2026

EB300031

This is a combined synopsis/solicitation for commercial products or commercial services prepared in accordance with part 12. This announcement constitutes the only solicitation.

Offers are being requested and a separate

Continued...

STOCK RECORD (S/R)

STANDARD FORM 1449 (REV. 11/2021) BACK

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED:

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE RECEIVED (MM/DD/YYYY) 42d. TOTAL CONTAINERS

40. PAID BY

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32g. EMAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

33. SHIP NUMBER 34. VOUCHER NUMBER 35. AMOUNT VERIFIED

CORRECT FOR

PARTIAL FINAL

37. CHECK NUMBER

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER

36. PAYMENT

COMPLETE PARTIAL FINAL

ACCEPTED,

written solicitation will not be issued.

Solicitation number 1332KP26Q0033 is issued as a Request for Quotation (RFQ) for the replacement of two (2) non-operational boilers.

This acquisition is set-aside for small business concerns. This solicitation incorporates provisions and clauses by reference. The full text of provisions and clauses may be accessed electronically at www.acquisition.gov.

Delivery: 05/31/2027

Period of Performance: 06/01/2026 to

05/31/2027

0001 FCDAS Boiler Replacement Project

Contractor shall provide all labor, materials, and equipment to replace two (2) failed boilers at the Fairbanks Command and Data Acquisition

Station (FCDAS) in accordance with the attached

Performance Work Statement (PWS).

Period of Performance: Twelve (12) months from the Date of Award.

Place of Performance: FCDAS, Fairbanks, AK.

Continued...

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGES

NAME OF OFFEROR OR CONTRACTOR

SUPPLIES/SERVICES

(B)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

OPTIONAL FORM 336 (4-86)

Sponsored by GSA FAR (48 CFR) 53.110

ITEM NO.

(A)

QUANTITY

(C)

NSN 7540-01-152-8067

1332KP26Q0033

Inspection/Acceptance: Destination.

Product/Service Code: 4410

1332KP26Q0033 BASE

Section B - Supplies or Services/Prices Section C - Description/Specifications Section I - Contract Clauses Section J - List of Documents, Exhibits and Other Attachments Section L - Instructions, Conditions, and Notices to Bidders Section M - Evaluation Factors for Award

Section B - Supplies or Services/Prices

Item Number Description Quantity Unit Unit Price Amount

FCDAS Boiler Replacement Project

Contractor shall provide all labor, materials, and equipment to replace two (2) failed boilers at the Fairbanks Command and Data Acquisition Station (FCDAS) in accordance with the attached Performance Work Statement (PWS).

Period of Performance: Twelve (12) months from the Date of Award.

Place of Performance: FCDAS, Fairbanks, AK.

Inspection/Acceptance: Destination.

Award Type: Firm-fixed-price Product/Service Code: 4410

B.1 PRICE SCHEDULE

The Offeror shall provide a firm-fixed-price for the following requirement. Prices shall be all-inclusive of labor, materials, equipment, mobilization, travel to Fairbanks, AK, and Building Automation System (BAS) integration.

B.2 PRICE BREAKOUT (For Evaluation Purposes) In accordance with the instructions in this solicitation, Offerors shall provide a detailed price breakout as an attachment to their quote. This breakout is for the purpose of evaluating price reasonableness and realism. This is a Firm-Fixed-Price contract; the Government will not pay for travel or mobilization as a separate line item. All costs for travel and mobilization must be included in the total firm-fixed-price for CLIN 0001. At a minimum, this breakout must identify the following components of the total price:

1. Equipment: Cost of two (2) new boilers and associated hardware.

2. Installation: Mechanical, electrical, and plumbing labor.

3. Integration/Testing: BAS programming, lead/lag configuration, and startup/commissioning.

4. Mobilization/Travel: All costs for personnel and material transport to Fairbanks, AK, included in the total fixed price.

Section C - Description/Specifications

C.1 STATEMENT OF WORK

The Contractor shall provide all labor, management, supervision, tools, materials, equipment, and transportation necessary to replace two (2) non-operational boilers at the Fairbanks Command and Data Acquisition Station (FCDAS) in accordance with the Performance Work Statement (PWS) titled "FCDAS Boilers Replacement" dated February 23, 2026, which is incorporated herein by reference and included in Section J.

C.2 CORE TECHNICAL REQUIREMENTS

In accordance with the PWS, the work includes, but is not limited to:

1. Mechanical/Plumbing: Demolition of failed units and installation of two (2) new Burnham commercial boilers (or Government-approved equal).

2. Building Automation: Integration into the existing BAS and configuration for lead/lag operation to ensure system redundancy.

3. Operational Continuity: All work must be phased to ensure that the primary operational boilers in the Facilities Building and Powerhouse remain functional 24/7/365.

Section I - Contract Clauses

Clauses Incorporated by Reference Clause Number Clause Title

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. (JAN 2017)

52.204-7 System for Award Management-Registration. (NOV 2024) (Deviation JAN 2026)

52.204-13 System for Award Management-Maintenance. (OCT 2018) (Deviation JAN 2026)

52.204-91 Contractor Identification. (Deviation JAN 2026)

52.212-4 Terms and Conditions-Commercial Products and Commercial Services. (NOV 2023) (Deviation JAN 2026)

52.219-6 Notice of Total Small Business Set-Aside. (NOV 2020) (Deviation JAN 2026)

52.219-14 Limitations on Subcontracting. (OCT 2022) (Deviation JAN 2026)

52.219-33 Nonmanufacturer Rule. (SEP 2021) (Deviation JAN 2026)

52.222-6 Construction Wage Rate Requirements. (AUG 2018) (Deviation JAN 2026)

52.222-7 Withholding of Funds. (MAY 2014) 52.222-8 Payrolls and Basic Records. (JUL 2021)

52.222-10 Compliance With Copeland Act Requirements. (FEB 1988)

52.222-11 Subcontracts (Labor Standards). (MAY 2014) (Deviation

JAN 2026)

52.223-3 Hazardous Material Identification and Safety Data. (FEB 2021) (Deviation JAN 2026)

52.223-5 Pollution Prevention and Right-to-Know Information.

(MAY 2024)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors. (MAR 2023)

52.237-1 Site Visit. (APR 1984)

52.237-2 Protection of Government Buildings, Equipment, and Vegetation. (APR 1984)

52.240-91 Security Prohibitions and Exclusions. (Deviation JAN 2026)

1352.201-70 Contracting Officer's Authority. (MAR 2010) 1352.209-73 Compliance with the laws. (APR 2010) 1352.209-74 Organizational conflict of interest. (APR 2010) 1352.233-71 GAO and Court of Federal Claims protests. (APR 2010)

1352.237-70 Security processing requirements-high or moderate risk contracts. (APR 2010)

ADDENDUM TO FAR 52.212-4

(a) Inspection/Acceptance: The Government will perform inspection and acceptance at Destination (FCDAS, Fairbanks, AK). Acceptance is contingent upon successful Building Automation System (BAS) integration and lead/lag operational testing as defined in the PWS.

(f) Excusable Delays: (Tailored) The Contractor is responsible for anticipating and planning for sub-arctic weather conditions typical for Fairbanks, AK. Only 'unusually severe' weather—defined as weather that statistically exceeds the average conditions for the month of performance and directly impacts the critical path—will be considered for an excusable delay. Documentation from the National Weather Service (NWS) must be provided with any request for extension.

Full Text Clauses

CAR 1352.201-72 Contracting Officer's Representative (COR). (APR 2010)

(a) COR TBD AT TIME OF AWARD is hereby designated as the Contracting Officer's Representative (COR). The COR may be changed at any time by the Government without prior notice to the contractor by a unilateral modification to the contract. The COR is located at:

Phone Number: [ ]

E-mail: [ ]

(b) The responsibilities and limitations of the COR are as follows:

(1) The COR is responsible for the technical aspects of the contract and serves as technical liaison with the contractor. The COR is also responsible for the final inspection and acceptance of all deliverables and such other responsibilities as may be specified in the contract.

(2) The COR is not authorized to make any commitments or otherwise obligate the Government or authorize any changes which affect the contract price, terms or conditions. Any contractor request for changes shall be referred to the Contracting Officer directly or through the COR. No such changes shall be made without the express written prior authorization of the Contracting Officer. The Contracting Officer may designate assistant or alternate COR(s) to act for the COR by naming such assistant/alternate(s) in writing and transmitting a copy of such designation to the contractor.

(End of clause)

CAR 1352.233-70 Agency protests. (APR 2010)

(a) An agency protest may be filed with either: (1) The contracting officer, or (2) at a level above the contracting officer, with the appropriate agency Protest Decision Authority. See 64 FR 16,651 (April 6, 1999).

(b) Agency protests filed with the Contracting Officer shall be sent to the following address:

mark.a.sullivan@noaa.gov

(c) Agency protests filed with the agency Protest Decision Authority shall be sent to the following address: keith.long@noaa.gov

(d) A complete copy of all agency protests, including all attachments, shall be served upon the Contract Law Division of the Office of the General Counsel within one day of filing a protest with either the Contracting Officer or the Protest Decision Authority.

(e) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce, Office of the General Counsel, Chief, Contract Law Division, Room 5893, Herbert C.

Hoover Building, 14th Street and Constitution Avenue, NW., Washington, DC 20230. FAX: (202) 482-5858.

(End of clause)

CAR 1352.246-70 Place of acceptance. (APR 2010)

(a) The Contracting Officer or the duly authorized representative will accept supplies and services to be provided under this contract.

(b) The place of acceptance will be:

NESDIS Fairbanks CDA Station (FCDAS) 1300 Eisele Road Fairbanks, AK 99712

(End of clause)

CAR 1352.270-70 Period of performance. (APR 2010)

(a) The base period of performance of this contract is from DATE OF AWARD through 12 MONTHS. If an option is exercised, the period of performance shall be extended through the end of that option period.

(b) The option periods that may be exercised are as follows:

N/A - NO OPTION PERIODS ARE PLANNED FOR THIS REQUIREMENT AND IS THEREFORE NOT

INCLUDED.

(c) The notice requirements for unilateral exercise of option periods are set out in FAR 52.217-9.

(End of clause)

NOAA Acquisition Manual 1330-52.222-70 NOAA SEXUAL ASSAULT AND SEXUAL HARASSMENT

PREVENTION AND RESPONSE POLICY (MAY 2018)

In accordance with NOAA Administrative Order (NAO) 202-1106, NOAA Sexual Assault and Sexual Harassment Prevention and Response Policy, it is the policy of NOAA to maintain a work environment free from sexual assault and sexual harassment. NOAA prohibits sexual assault and sexual harassment by or of any employee, supervisor, manager, contractor, vendor, affiliate, or other individual with whom NOAA employees come into contact by the virtue of their work for NOAA.

(a) Definitions.

Contractor Employees - The term “contractor employees,” as used in this solicitation and contract language, refers to employees of the prime contractor or its subcontractors, affiliates, consultants, or team members.

Sexual Assault - The term sexual assault, as used in this solicitation and contract language, means any conduct proscribed by state or federal sexual abuse laws, including, but not limited to, those defined in chapter 109A of title 18 of the U.S. Code (sexual abuse), and assaults committed both by offenders who are strangers to the victim and by offenders who are known or related by blood or marriage to the victim.

Sexual Harassment - As defined by the Equal Employment Opportunity Commission, sexual harassment is a form of sex discrimination that violates Title VII of the Civil Rights Act of 1964. It includes unwelcome sexual advances, requests for sexual favors, and other verbal, non-verbal, or physical conduct of a sexual nature when any of the following are true:

● Submission to such conduct is made either explicitly or implicitly as a term or condition of an individual's employment;

● Submission to or rejection of such conduct by an individual is used as the basis for employment decisions affecting such individual;

● The conduct unreasonably interferes with an individual's work performance or creates an intimidating, hostile, or offensive working environment.

The main characteristics of sexual harassment are that the harasser's conduct is targeted against the recipient’s sex, gender identity, or sexual orientation, and is unwelcome to the recipient. It may include, but is not limited to: offensive jokes, slurs, epithets or name calling, undue attention, physical assaults or threats, unwelcome touching or contact, intimidation, ridicule or mockery, insults or put-downs, constant or unwelcome questions about an individual's identity, and offensive objects or pictures.

(b) Requirements.

1. It is the responsibility of the contractor to ensure that contractor employees maintain the highest degree of conduct and standards in performance of the contract. In support of this, NOAA urges its contractors to develop and enforce comprehensive company policy addressing sexual assault and sexual harassment.

2. The contractor shall include wording substantially the same as this solicitation and contract language in every subcontract so that it is binding upon each subcontractor.

3. If a contractor employee observes or is the object of sexual assault or sexual harassment, he or she is highly encouraged to report the matter, as soon as possible, to their immediate supervisor, the COR, subset of the COR (e.g. Task Manager or Assistant COR), or contracting officer (CO) if a COR is not assigned to the contract. The contract employee may also contact the NOAA Civil Rights Office to obtain guidance on reporting instances of sexual assault or sexual harassment. If deemed necessary, the contractor employee may also report such instances to local law enforcement. In the case where the incident occurs while performing at a remote location, such as at sea or in the field (at a field camp or other isolated location) where the above referenced individuals are unavailable, the contractor employee should follow the reporting procedure set forth in NAO 202-1106, Section 6.07, Reporting from Remote Locations.

4. Swift reporting allows NOAA and the contractor to take the appropriate measures to ensure that offensive behavior stops and the complainants’ needs are addressed.

5. The COR (if assigned), CO, and contractor, where applicable, will work together to ensure appropriate action is taken in accordance with applicable laws and regulations, contract terms and conditions, and the contractor’s written policy (where applicable).

6. The contractor shall provide all contractor employees assigned to perform under this contract with mandatory sexual assault and sexual harassment prevention and response training in compliance with the requirements of NAO 202-1106, Section 5, Prevention Training and Awareness, as part of their initial in-processing and on an annual basis thereafter. The initial training shall be completed within [ ] business days (30 unless a different number is inserted) of contract award or the date a contractor employee is assigned to perform under the contract, as applicable.

Evidence of initial training by name and date completed for each contractor employee, shall be submitted to the COR or contracting officer (if no COR assigned) within 10 business days of completion.

Evidence of annual training by name and date completed for each contractor employee shall be submitted to the COR or contracting officer (if no COR assigned) no later than March 1st of each calendar year of contract performance.

7. The mandatory sexual assault and sexual harassment training provided by the contractor shall include the required elements set forth by NOAA’s Workplace Violence Program Manager. A link to the website including the required elements of the training is provided at https://www.noaa.gov/organization/acquisition-grants/noaa-workplace-harassment-training-for-contractors-and-financial. The website will also provide training materials and resources to assist the contractor in conducting the training. The contractor may provide training that solely addresses the NOAA required elements or may supplement existing company sexual assault and sexual harassment training in a manner that ensures all of the elements are adequately addressed.

8. The required elements of the training and resources available to the contractor for the training may be updated by NOAA periodically. The contractor is responsible for monitoring the website and incorporating any changes to the NOAA required elements into the contractor provided training.

9. NOAA’s Workplace Violence Program Manager, COR, or CO may periodically review the contractor’s training outline to ensure all required elements are included and, if necessary, any appropriate adjustments are made to the training by the contractor.

10. Contractor employees performing on assignments in a remote location, such as at a field camp or other isolated locations, are subject to receiving the same briefing on the parameters of the order provided to NOAA employees as set forth in Section 6 of NAO 202-1106.

11. The contractor shall provide a copy of this solicitation and contract language and NAO 202-1106 to contractor employees.

(c) Sexual Assault/Sexual Harassment (SASH) Helpline.

For NOAA employees, affiliates, and contractors who have experienced sexual assault or sexual harassment, NOAA has established the NOAA Sexual Assault/Sexual Harassment (SASH) helpline. This helpline is designed to provide crisis intervention, referrals, and emotional support to those who are victims and/or survivors of sexual harassment or sexual assault within the workplace. Contractor employees may use the helpline to receive live, confidential, one-on-one support in an occurrence of sexual harassment or assault by a Federal Government employee.

All services are anonymous, secure, and available worldwide, 24 hours a day, seven days a week. The NOAA SASH helpline is accessible through a variety of channels, including:

● Phone: 1-866-288-6558

● Website & Online Chat: https://www.noaasashhelpline.org/

● Mobile App: NOAA SASH Helpline (available via iOS and Android App Stores)

● Text: (202) 335-0265

(d) Confidentiality.

Any party receiving information from the filing of a complaint alleging sexual assault or sexual harassment, or while performing an investigation into such a complaint, shall keep the information confidential. “Confidentiality” means that the information shall only be shared with others who have a need to know the information to conduct their official duties.

(e) Remedies.

In addition to other remedies available to the Government, contractor employee violations of Federal requirements (e.g., law, statutes, executive orders, code, rules, regulations) applicable to sexual assault and sexual harassment and/or failure to complete the mandatory training set forth in this solicitation and contract language, may result in:

1. Requiring the contractor to remove a contractor employee or employees from the performance of the contract;

2. Requiring the contractor to terminate a subcontract;

3. Suspension of contract payments until the Contractor has taken appropriate remedial action;

4. Termination of the contract for default or cause, in accordance with the termination clause of this contract;

5. Suspension or debarment; or

6. Other appropriate action.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.232-71 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (FEB 2023)

The Contractor must submit payment requests electronically through the U.S. Department of the Treasury's Invoice Processing Platform System (IPP). The Contractor must use the IPP website to register, access, and submit payment requests. The IPP website address is https://www.ipp.gov.

"Payment request" means any request for contract financing payment or invoice payment to the Contractor. To be considered proper, invoices must be prepared in accordance with, and contain all elements specified in, the contract payment clause (e.g., FAR 52.212-4(g), FAR 52.232-25(a)(3), FAR 52.232-26(a)(2), FAR 52.232-27(a)(2)).

The Contractor must include the following documents as attachments to payment requests submitted through the IPP: NA.

If the Contractor is unable to comply with the requirement to submit payment requests through the IPP due to a threat to national security; a matter of unusual or compelling urgency; or because the political, financial, or communications infrastructure of a foreign country does not support access to the IPP, the Contractor must request an exception in writing. Contact the Contracting Officer for more information about requesting an exception.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.237-70 CONTRACTOR COMMUNICATIONS

(a) A contractor employee shall be identified both by the individual’s name and the contractor’s name when:

● Included in NOAA’s locator, and

● When submitting any type of electronic correspondence to any NOAA employee or stakeholder.

(b) Any written correspondence from a contractor or any contractor employee shall be printed on company/organization letterhead or otherwise clearly identify the sender as an employee of the company or organization and shall identify the contract number.

(c) Contractors and/or contractor employees shall clearly identify themselves as such in any verbal communications, whether in informal discussion or a formal meeting.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.237-71 NOAA GOVERNMENT-CONTRACTOR RELATIONS - NON-

PERSONAL SERVICES CONTRACT (SEPT 2017)

(a) The Government and the contractor understand and agree that the services to be delivered under this contract by the contractor to the Government are non-personal services as defined in FAR Part 37, Service Contracting, and the parties recognize and agree that no employer-employee relationship exists or will exist under the contract between the Government and the contractor’s personnel. It is, therefore, in the best interest of the Government to afford both parties an understanding of their respective obligations.

(b) Contractor personnel under this contract shall not:

1. Be placed in a position where they are under relatively continuous supervision and control of a Government employee.

2. Be placed in a position of command, supervision, administration, or control over Government personnel or over personnel of other contractors performing under other NOAA contracts.

(c) The services to be performed under this contract do not require the contractor or the contractor’s personnel to exercise personal judgment and discretion on behalf of the Government. Rather, the contractor’s personnel will act and exercise personal judgment and discretion on behalf of the contractor.

(d) Rules, regulations, directives, and requirements that are issued by the Department of Commerce and NOAA under its responsibility for good order, administration, and security are applicable to all personnel who enter the Government installation and facilities, who are provided access to Government systems, or who travel on Government transportation. This is not to be construed or interpreted to establish any degree of Government control that is inconsistent with a non-personal services contract.

(e) Both parties are responsible for monitoring contract activities for indications of improper employee-employer relationships during performance. In the event a situation or occurrence takes place inconsistent with this contract language, the following applies:

1. The contractor shall notify the contracting officer in writing within 5 business days from the date of any situation or occurrence where the contractor considers specific contract activity to be inconsistent with the intent of this contract language. The notice must include the date, nature and circumstance of the situation or occurrence, the name, function and activity of each Government employee or contractor employee involved or knowledgeable about the situation or occurrence, provide any documents or the substance of any oral communications related to the activity, and an estimated date by which the Government is recommended to respond to the notice in order to minimize cost, delay, or disruption of performance.

2. The contracting officer will review the information provided by the contractor, obtain additional information (if needed), and respond in writing as soon as practicable after receipt of the notification from the contractor. The contracting officer’s response will provide a decision on whether the contracting officer determines the situation or occurrence to be inconsistent with the intent of this contract language and, if deemed necessary, will specify any corrective action(s) to be taken in order to resolve the issue.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.237-72 CONTRACTOR ACCESS TO NOAA FACILITIES (SEPT 2017)

(a)

1. The performance of this contract requires employees of the prime contractor or its subcontractors, affiliates, consultants, or team members (“contractor employees”) to have access to and to the extent authorized, mobility within, a NOAA facility.

2. NOAA may close and or otherwise deny contractor employees access to a NOAA facility for a portion of a business day or longer for various reasons including, but not limited, to the following events:

i. Federal public holidays for Federal employees in accordance with 5 U.S.C. 6103;

ii. Fires, floods, earthquakes, and unusually severe weather, including but not limited to snow storms, tornadoes, and hurricanes;

iii. Occupational safety or health hazards;

iv. Lapse in Appropriations; or

v. Federal Statute, Executive Order, Presidential Proclamation, or any other unforeseen reason.

3. In such events, the contractor employees may be denied access to a NOAA facility that is ordinarily available for the contractor to perform work or make delivery, as required by the contract.

(b) In all instances where contractors are denied access or required to vacate a NOAA facility, in part or in whole, the contractor shall be responsible to ensure contractor personnel working under the contract comply. If the circumstances permit, the contracting officer will provide direction to the contractor, either directly or through the COR, which could include continuing on-site performance during the NOAA facility closure period; however, if Government oversight is required and is not available, on-site performance shall not be allowed. In the absence of such direction, the contractor shall exercise sound judgment to minimize unnecessary contract costs and performance impacts, for example, performing required work off- site if possible or reassigning personnel to other activities if appropriate.

(c) The contractor shall be responsible for monitoring the Office of Personnel Management at opm.gov, the local radio, television stations, NOAA web sites, and other communication channels. Once the facility is accessible, the contractor shall resume contract performance as required by the contract.

(d) For the period that NOAA facilities were not accessible to contractors who required access in order to perform the services, the contracting officer may—

1. Adjust the contract performance or delivery schedule for a period equivalent to the period the NOAA facility was not accessible;

2. Forego the work; or

3. Reschedule the work by mutual agreement of the parties.

(e) Notification procedures of a NOAA facility closure, including contractor denial of access, are as follows:

1. The contractor shall be responsible for notification of its employees of the NOAA facility closure to include denial of access to the NOAA facility. The dismissal of NOAA employees in accordance with statute and regulations providing for such dismissals shall not, in itself, equate to a NOAA facility closure in which contractors are denied access. Moreover, the leave status of NOAA employees shall not be conveyed or imputed to contractor personnel. Accordingly, unless a NOAA facility is closed and the contractor is denied access to the facility, the contractor shall continue performance in accordance with the contract.

2. Access to Government facilities and resources, including equipment and systems, will be limited and personnel necessary to administer contract performance may not be available. Generally, supply and service contracts that are funded beyond the date of the lapse in appropriation and do not require access to Government facilities, active administration by Government personnel or the use of Government resources in a manner that would cause the Government to incur additional obligations during the lapse in appropriation may continue. If a delivery date for a contract falls during the period of a lapse in appropriations, Government personnel may not be available to receive delivery. Contractors are directed to consult with a contracting officer before attempting to make a delivery. Contracting officers will be available throughout the lapse in appropriation period to provide guidance.

Once OMB guidance is given, CORs, in consultation with the contracting officer, will notify those contractors that are deemed by the Program Office to be performing excepted work and identify the contractor personnel requiring access to NOAA facilities. CORs will also coordinate directly with facility management or physical security personnel at respective locations to ensure that the names of contractor personnel requiring access to Government facilities during the lapse in appropriations are provided to physical security personnel.

Contractors who are not designated as performing excepted work are not allowed access to Government facilities or to utilize Government resources in a manner that would incur any additional obligation of funding on behalf of the Government during the lapse in appropriation.

3. Unless otherwise specified within the contract award, contractors requiring access to NOAA facilities outside normal business hours or outside the normal workweek shall submit a written request in writing through the COR to the contracting officer. The written request shall provide justification supporting the required access and be submitted 24 HOURS hours/days (contracting officer insert number of days. If blank, 72 hours applies) before access to the NOAA facility is needed.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.243-70 REQUESTS FOR EQUITABLE ADJUSTMENT (OCT 2017)

(a) The amount of any request for equitable adjustment to contract terms shall accurately reflect the contract adjustment for which the contractor believes the Government is liable. The request shall include only costs for performing the change. All indirect costs included in the request shall be properly allocable to the change in accordance with applicable acquisition regulations.

(b) Any request for equitable adjustment to contract terms that exceeds the simplified acquisition threshold shall bear, at the time of submission, the following certificate executed by an individual authorized to certify the request on behalf of the contractor:

I certify that the request is made in good faith, and that the supporting data are accurate and complete to the best of my knowledge and belief.

(Official’s Name)

(Title)

(c) The certification in paragraph (b) of this solicitation and contract language requires full disclosure of all relevant facts, including:

1. Certified cost or pricing data, if required, in accordance with subsection 15.403-4 of the Federal Acquisition Regulation (FAR); and

2. Data other than certified cost or pricing data, in accordance with subsection 15.403-3 of the FAR, including actual cost data and data to support any estimated costs, even if certified cost or pricing data are not required.

(d) The certification requirement in paragraph (b) of this solicitation and contract language does not apply to:

1. Requests for routine contract payments; for example, requests for payment for accepted supplies and services, routine vouchers under a cost-reimbursement type contract, or progress payment invoices; or

2. Final adjustments under an incentive provision of the contract.

(End of solicitation and contract language)

RFO 52.225-2 Buy American Certificate. (OCT 2022)

(a)(1) The Offeror certifies that each end product, except those listed in paragraph (b) of this provision, is a domestic end product and that each domestic end product listed in paragraph (c) of this provision contains a critical component.

(2) The Offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products. For those foreign end products that do not consist wholly or predominantly of iron or steel or a combination of both, the Offeror shall also indicate whether these foreign end products exceed 55 percent domestic content, except for those that are COTS items. If the percentage of the domestic content is unknown, select "no".

(3) The Offeror shall separately list the line item numbers of domestic end products that contain a critical component (see FAR 25.105).

(4) The terms "commercially available off-the-shelf (COTS) item," "critical component," "domestic end product," "end product," and "foreign end product" are defined in the clause of this solicitation entitled "Buy American-Supplies."

(b) Foreign End Products:

Line item No. Country of origin Exceeds 55% domestic content (yes/no)

(b) [List as necessary]

(c) Domestic end products containing a critical component:

Line Item No. ____________

[List as necessary]

(d) The Government will evaluate offers in accordance with the policies and procedures of part 25 of the Federal Acquisition Regulation.

(End of provision)

RFO 52.240-90 Security Prohibitions and Exclusions Representations and Certifications. (Deviation JAN 2026)

(a) Definitions. As used in this provision--

Backhaul, covered article, covered telecommunications equipment or services, critical technology, FASCSA order, Intelligence community, interconnection arrangements, national security system, roaming, sensitive compartmented information, sensitive compartmented information system, source, and substantial or essential component have the meanings provided in the clause 52.240-91, Security Prohibitions and Exclusions.

Business operations means engaging in commerce in any form, including by acquiring, developing, maintaining, owning, selling, possessing, leasing, or operating equipment, facilities, personnel, products, services, personal property, real property, or any other apparatus of business or commerce.

Marginalized populations of Sudan means-

(1) Adversely affected groups in regions authorized to receive assistance under section 8(c) of the Darfur Peace and Accountability Act (Pub. L. 109-344) (50 U.S.C. 1701 note);

and

(2) Marginalized areas in Northern Sudan described in section 4(9) of such Act.

Restricted business operations means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate-

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted under specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology-

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically-

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

(b) Procedures.

(1) Covered telecommunications and video surveillance. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) at https://www.sam.gov for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(2) FASCSA Orders.

(i) The Offeror shall search in SAM for the phrase "FASCSA order" for any covered article, or any products or services produced or provided by a source, if there is an applicable FASCSA order described in paragraph (e) of FAR 52.240- 91, Security Prohibitions and Exclusions.

(ii) The Offeror shall review the solicitation for any FASCSA orders that are not in SAM but are effective and apply to the solicitation and resultant contract (see FAR 40.204-1(c)(2)).

(iii) FASCSA orders issued after the date of solicitation do not apply unless added by an amendment to the solicitation.

(c) Covered telecommunications equipment or services representations. By submission of its offer, the Offeror represents that, after conducting a reasonable inquiry (that looks at any information in the Offeror's possession but does not need to include an internal or third-party audit)-

(1) It will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation, except as waived by the solicitation, or as disclosed in paragraph (g); and

(2) It does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services, except as waived by the solicitation, or as disclosed in paragraph (g).

(d) FASCSA Representation. By submission of this offer, the offeror represents that it has conducted a reasonable inquiry, and that the offeror does not propose to provide or use in response to this solicitation any covered article, or any products or services produced or provided by a source, if the covered article or the source is prohibited by an applicable FASCSA order in effect on the date the solicitation was issued, except as waived by the solicitation, or as disclosed in paragraph (g). A reasonable inquiry will look at any information in the offeror's possession but does not need to include an internal or third-party audit.

(e) Sudan certification. By submission of its offer, the offeror certifies, after conducting a reasonable inquiry (that looks at any information in the offeror's possession but does not need to include an internal or third-party audit), that the offeror does not conduct any restricted business operations in Sudan.

(f) Iran Representation and Certifications.

(1) Except as provided in paragraph (f)(2) of this provision or if a waiver has been granted in accordance with FAR 40.203-3, the offeror, after conducting a reasonable inquiry (that looks at any information in the offeror's possession but does not need to include an internal or third-party audit), by submission of its offer-

(i) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran;

(ii) Certifies that the offeror, or any person (as defined at section 15 of the Iran Sanctions Act of 1996, Pub. L. 104-172, 50 U.S.C. 1701 note) owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Act. These sanctioned activities are in the areas of development of the petroleum resources of Iran, production of refined petroleum products in Iran, sale and provision of refined petroleum products to Iran, and contributing to Iran's ability to acquire or develop certain weapons or technologies; and

(iii) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds $15,000 with Iran's Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50 U.S.C. 1701 et seq.) (see OFAC's Specially Designated Nationals and Blocked Persons List at https://www.treasury.gov/resource-center/sanctions/SDN- List/Pages/default.aspx)

(2) Exception for trade agreements. The representation and certification requirements of paragraph (f)(1) of this provision do not apply if-

(i) This solicitation includes a trade agreements notice or certification (e.g., 52.225-6, Trade Agreements Certificate); and

(ii) The offeror has certified that all the offered products to be supplied are designated country end products or designated country construction material.

(iii) The offeror shall email questions concerning sensitive technology to the Department of State at CISADA106@state.gov.

(g) Disclosure.

(1) If the Offeror is not able to represent compliance with the prohibitions in paragraphs

(c) or (d), then the Offeror shall disclose within 72 hours to the contracting office identified in paragraph (g)(2) the following information for each product or service not compliant:

(i) Contract number and order number, if applicable;

(ii) Identification of whether this disclosure relates to paragraph (c) on covered telecommunication equipment or services, or to paragraph (d) on FASCSA orders;

(iii) A description of the products or services that the Contractor identifies or has reason to suspect is prohibited (include brand; model number, such as the original equipment manufacturer (OEM) number, manufacturer part number, or wholesaler number; and item description, as applicable);

(iv) The entity that produced the product or service (include entity name, unique entity identifier, Contractor and Government Entity (CAGE) code, facilities responsible for design, fabrication, assembly, packaging, and test of the product, and whether the entity was the OEM or a distributor (provide manufacturer codes and distributor codes used for the product));

(v) Description of the functionality of the product or service and how that functionality impacts the risk to the product or service;

(vi) An explanation of any factors relevant to determining if the product or service should be permitted by an applicable exception, exemption, or waiver (if the offeror would like the Government to consider a waiver);

(vii) Whether alternative products or services are available that would be compliant with the prohibition;

(viii) If the product or service is related to item maintenance, include the following information on the item being maintained:

(A) Brand;

(B) Model number, OEM number, manufacturer part number, or wholesaler number; and

(C) Item description, as applicable.

(ix) Any readily available information about mitigation actions undertaken or recommended.

(2) If a disclosure is required to be submitted to a contracting office, the offeror shall submit the disclosure as follows:

(i) If a Department of Defense contracting office, the offeror shall submit the disclosure to the website at https://dibnet.dod.mil.

(ii) For all other contracting offices, the Offeror shall submit the disclosure to the Contracting Officer.

(3) If the disclosure provided does not contain any of the information required by paragraph (1), and the Offeror later discovers new information that is required by paragraph (1), then the Offeror shall submit a subsequent disclosure within 72 hours of discovering the new information.

(h) Executive agency review of disclosures. The Contracting Officer will review disclosures provided in paragraph (g) to determine if any applicable waiver may be sought. The Contracting Officer may choose not to pursue a waiver and may instead make an award to an Offeror that does not require a waiver.

(End of provision)

RFO 52.252-1 Solicitation Provisions Incorporated by Reference. (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): https://www.acquisition.gov/browse/index/far

(End of provision)

RFO 52.252-2 Clauses Incorporated by Reference. (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/browse/index/far

(End of clause)

RFO 52.252-6 Authorized Deviations in Clauses. (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter

1) clause with an authorized deviation is indicated by the addition of (DEVIATION) after the date of the clause.

(b) The use in this solicitation or contract of any FEDERAL ACQUISITION REGULATIONS (48 CFR [ ]) clause with an authorized deviation is indicated by the addition of (DEVIATION) after the name of the regulation.

(End of clause)

Section J - List of Documents, Exhibits and Other Attachments

Attachment Number Title

1 FCDAS…