RFP - 1305M221RNMAN01155_RHB Mid-Life.pdf

REQUEST FOR PROPOSAL (RFP)

1305M221RNMAN01155

NOAA Ship RONALD H. BROWN

Mid-Life Refit

U.S. Department of Commerce

National Oceanic and Atmospheric Administration

Office of Marine and Aviation Operations

Eastern Acquisition Division

200 Granby Street, Suite 405

Norfolk, VA 23510

April 29, 2021

2 | P a g e

Part I – The Schedule

Section A – Solicitation / Contract Form (SF-33)

3 | P a g e

Section B – Supplies and Prices

This acquisition will be competed on a full and open basis utilizing FAR Part 12, Acquisition of

Commercial Items, in conjunction with FAR Part 15, Contracting by Negotiation.

A firm fixed price (FFP), single award contract is anticipated.

The North American Industry Classification System (NAICS) code for this acquisition is

336611. The small business size standard is 1250 employees.

Homeport for the NOAA Ship RONALD H. BROWN is:

Charleston Marine Support Facility

1050 Register Street

Charleston, SC 29405-2421

United States

Solicitation Inquiries shall be received no later than 12:00 PM ET, June 28, 2021 and must be sent to Andrew.Northcutt@noaa.gov; Jessica.Loftus@noaa.gov; Jamie.A.LeCompte@noaa.gov;

and Andrew.Mackay@noaa.gov and include the following subject description:

1305M221RNMAN01155: Mid-Life Refit Inquiry (Name of contractor)

Proposals shall be submitted to both the Contracting Officer, Andrew Northcutt and the Contract

Specialist, Jessica Loftus, via email at Andrew.Northcutt@noaa.gov and

Jessica.Loftus@noaa.gov no later than 12:00 PM ET, August 6, 2021.

Pricing shall be submitted using Attachement J.2, Section B, Supplies and Prices (Excel

Spreadsheet).

END OF SECTION B

mailto:Andrew.Northcutt@noaa.gov mailto:Jessica.Loftus@noaa.gov mailto:Jamie.A.LeCompte@noaa.gov mailto:Andrew.Mackay@noaa.gov

4 | P a g e

Section C – Specification

C1. The Contractor shall furnish the necessary personnel, material, equipment, services and facilities (except as otherwise specified) to perform the Specifications referenced as an attachment in Part III – List of Documents, Exhibits, and Other Attachments, Section J, List of

Attachments.

Please see Attachment J.3, Specification. The Specification is a combination of 37 Work

Packages.

END OF SECTION C

5 | P a g e

Section E – Inspection and Acceptance

E.1 FAR 52.246-16 RESPONSIBILITY FOR SUPPLIES (APR 1984)

E.2 CAR 1352.246-70 PLACE OF ACCEPTANCE (APR 2010)

(a) The Contracting Officer or the duly authorized representative will accept supplies and services to be provided under this contract.

(b) The place of acceptance will be at the contractor’s facility.

(End of clause)

E.3 CAR 1352.271-70 INSPECTION AND MANNER OF DOING WORK (APR 2010)

END OF SECTION E

6 | P a g e

Section F – Deliveries or Performance

F.1 FAR 52.242-15 STOP-WORK ORDER (AUG 1989)

F.2 FAR 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

F.3 FAR 52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH

AND DEVELOPMENT (SEP 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $15,609.13 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price

Supply and Service clause, the Contractor is liable for liquidated damages accruing until the

Government reasonably obtains delivery or performance of similar supplies or services.

These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

F.4 CAR 1352.270-70 PERIOD OF PERFORMANCE (APR 2010)

(a) The period of performance for work to be conducted on board NOAA Ship RONALD H.

BROWN will be 24 months, beginning on or about May 2022 through May 2024, not including the ship’s transit time from its homeport in Charleston, SC to and from the contractor’s facility. The period of performance can start no sooner than May 2022.

(b) The option periods are not applicable to this acquisition.

(c) Deleted

7 | P a g e

F.5 NAM 1330-52.215-70 SCHEDULE OF DELIVERABLES (SEPT 2005)

Following is a schedule of all deliverables, including administrative deliverables, required during the period of performance of this contract:

Item Description Qty Due Date Deliver To Reference

1 Insurance Certificate 1 Within 5 days of award

Contract

Specialist

CAR clause 1352.271-79 and CAR clause 1352.271-

2 Performance and

Payment Bonds

1 Within 10 days of award

Contract

Specialist

FAR clause 52.228-16, SF-1418, and SF-1416

3 Specification

Deliverables

(List Not Inclusive)

Various See

Specification

COR Specification

4 Subcontractor List (per

H.6 of this solicitation)

1 Within 5 days of award

COR and

Contract

Specialist

CAR clause 1352.228-77

5 Sexual Assault and

Sexual Harassment

Training Certificates

1 each Within 5 days of award and due annually by 1 March thereafter

COR and

Contract

Specialist

NAM contract language

1330-52.222-70

6 Critical Personnel resumes, each position

1 30 days before the employees start date on this project

COR and

Contract

Specialist

Specification

END OF SECTION F

8 | P a g e

Section G – Contract Administration Data

G.1 FAR 52.245-1 GOVERNMENT PROPERTY (JAN 2017)

G.2 CAR 1352.201-70 CONTRACTING OFFICER'S AUTHORITY (APR 2010)

The Contracting Officer is the only person authorized to make or approve any changes in any of the requirements of this contract, and, notwithstanding any provisions contained elsewhere in this contract, the said authority remains solely in the Contracting Officer. In the event the contractor makes any changes at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract terms and conditions, including price.

(End of clause)

G.3 CAR 1352.201-72 CONTRACTING OFFICER'S REPRESENTATIVE (COR) (APR 2010)

(a) Mr. Jamie LeCompte will be designated as the Contracting Officer's Representative (COR).

The COR may be changed at any time by the Government without prior notice to the contractor by a unilateral modification to the contract. The COR is located at:

Jamie LeCompte

Jamie.A.LeCompte@noaa.gov

(b) The responsibilities and limitations of the COR are as follows:

(1) The COR is responsible for the technical aspects of the contract and serves as technical liaison with the contractor. The COR is also responsible for the final inspection and acceptance of all deliverables and such other responsibilities as may be specified in the contract.

(2) The COR is not authorized to make any commitments or otherwise obligate the

Government or authorize any changes which affect the contract price, terms or conditions. Any contractor request for changes shall be referred to the Contracting

Officer directly or through the COR. No such changes shall be made without the express written prior authorization of the Contracting Officer. The Contracting Officer may designate assistant or alternate COR(s) to act for the COR by naming such assistant/alternate(s) in writing and transmitting a copy of such designation to the contractor.

END OF SECTION G

mailto:Jamie.A.LeCompte@noaa.gov

9 | P a g e

Section H – Special Contract Requirements

H.1 DEPARTMENT OF COMMERCE (DOC) ACQUISITION REGULATION (CAR) 48 CFR

CHAPTER 13 CLAUSES

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address:

http://www.gpo.gov

(End of Clause)

H.2 CAR 1352.208-70 RESTRICTIONS ON PRINTING AND DUPLICATING (APR 2010)

H.3 CAR 1352.209-73 COMPLIANCE WITH THE LAWS (APR 2010)

H.4 CAR 1352.209-74 ORGANIZATIONAL CONFLICT OF INTEREST (APR 2010)

H.5 CAR 1352.237-73 FOREIGN NATIONAL VISITOR AND GUEST ACCESS TO

DEPARTMENTAL RESOURCES (APR 2010)

H.6 CAR 1352.271-71 METHOD OF PAYMENT AND INVOICING INSTRUCTIONS FOR

SHIP REPAIR (APR 2010)

(a) The Government will make payment under this contract based on a percentage of completion. The contractor may invoice for the percentage completed for each work item as work progresses. The amount invoiced shall be calculated based on prices stated in the

Schedule, as follows: A work item may not be invoiced until the percentage complete reaches 25 percent. Future invoices for that work item have no limitation as to the percentage of completion required before invoicing, but in no event may invoices be submitted more frequently than every 2 weeks, or for amounts less than $10,000, unless it is the final payment. The minimum percentage of completion (25%) to be reached prior to billing each work item may be waived by the Contracting Officer for large dollar work items on a case-by-case basis.

(b) Invoices submitted by the contractor which are deemed not proper, in accordance with FAR

52.232-25, will be returned. Invoices shall include:

(1) Name and Address of the contractor;

(2) DUNS Number;

(3) Invoice Date;

(4) Contract Number/Modification Number;

(5) CLIN/Work Item Number, to include: Description, Quantity, Unit of Measure, Unit

Price and Extended Price;

(6) Shipping and Payment Terms; and,

(7) Contractor Point of Contact, including: Name, Title, Phone Number, and Mailing

Address;

10 | P a g e

(8) The percentage of completion for each CLIN/work item identified;

(9) Name of the Contracting Officer ;

(10) Ship name;

(11) The overall percentage and dollar amount previously billed, currently billed and unbilled.

(c) When invoicing for changed work, the contractor shall identify it as a contract change and shall identify the modification authorizing the change, and the CLIN/Work Item associated with the change.

(d) All items of work invoiced under this contract will be verified and confirmed by the

Contracting Officer's Representative as accurate and complete and approved by the designated billing office before payment will be made.

(e) Invoices shall be submitted electronically to the COR at Jamie.A.LeCompte@noaa.gov and

Invoices.moc-p@noaa.gov.

A copy of all invoices shall be sent by electronic mail to the contract administration office as follows:

Andrew.Northcutt@noaa.gov

Jessica.Loftus@noaa.gov

Payment will be made by the Department of Commerce/NOAA Finance Systems Admin

Branch/Rm. 1204, 20020 Century Blvd., Germantown, MD 20874.

(f) The contractor's final invoice submitted under the contract must be marked as follows:

“THIS INVOICE CONSTITUTES THE FINAL INVOICE - UPON PAYMENT OF THIS

INVOICE NO OTHER MONIES ARE DUE UNDER CONTRACT NUMBER

1305M222CNMANXXXX."

(Award Number will be given at time of award.)

Note: Electronic submission of invoices and associated documentation via e-mail and/or fax is authorized and encouraged.

H.7 CAR 1352.271-72 ADDITIONAL ITEM REQUIREMENTS (AIR) - GROWTH WORK

(APR 2010)

(a) This clause applies to Additional Item Requirements (AIR), also known as growth and emergent work ordered by the Contracting Officer pursuant to the Changes - Ship Repair clause or mutually agreed upon by the parties. The contractor shall perform AIR at the labor billing rates designated in the Schedule, as described in paragraph (c) of this clause. The

AIR handling fee designated in the Schedule shall be the sole fee used for direct material purchases and subcontractor handling. The estimated quantity of labor hours and handling fees represent the Government's best estimate for growth that may be required throughout the contract performance period. All growth work shall be paid at the prices stated in the

Schedule.

mailto:Jamie.A.LeCompte@noaa.gov mailto:Invoices.moc-p@noaa.gov

11 | P a g e

(b) The contractor shall take into account the potential for ordering all estimated AIR quantities in developing the Production Schedule. The ordering of any portion of the AIR quantities does not in itself warrant an extension to the original contract completion date; however, for planning purposes, the Government anticipates ordering AIR in accordance with the following schedule:

(1) No more than 75% of the hours during the first half of the contract period of performance.

(2) No more than 50% of the hours during the third quarter of the contract period of performance.

(3) No more than 30% of the hours during the fourth quarter of the contract period of performance.

(c) The AIR labor rate shall be a flat, hourly rate to cover the entire effort and shall be burdened to include:

(1) Direct production labor hour functions only. Direct production labor hours are hours of skilled labor at the journeyman level expended in direct production. Direct production is defined as work performed by a qualified craftsman that is directly related to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. The following functions are identified as direct production:

Abrasive Cleaning/Water Blasting, Tank Cleaning, Welding, Burning, Brazing, Blacksmithing, Machining (inside and outside), Carpentry, Electrical/Electronic Work, Crane Operation, Shipfitting, Lagging/Insulating, Painting, Boilermaking, Pipe Fitting, Engineering (Production), Sheetmetal Work, Staging/Scaffolding, and Rigging.

(2) Non-production labor hours (whether charged directly or indirectly by contractor's accounting system) shall be for labor in support of production functions. For purposes of this clause, support functions are defined as functions that do not directly contribute to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. Necessary support functions should be priced into the burdened rate for production labor hours. Examples of support functions include:

Testing, Quality Assurance (inspection), Engineering (support), Planning (including involvement of craft foreman/journeyman in planning a task), Estimating (including determination of necessary materials and equipment needed to perform a task), Material

Handling, Set-up (moving tools and equipment from shop to ship to perform a task), Fire

Watch, General Labor (including general support of journeyman tasks), Cleaning

(including debris pickup and removal), Surveying, Security, Transportation, Supervision, and Lofting (sail/pattern making).

(d) Additional Item Requirements do not include replacement work performed pursuant to the

Inspection and Manner of Doing Work or Guarantees clauses.

(e) It is the Government's intention to award any growth work identified during the repair to the contractor, if a fair and reasonable price can be negotiated for such work, based upon

Schedule rates. If a fair and reasonable price cannot be negotiated, the Government may, at its discretion, obtain services outside of the contract. Such services may be performed while the ship is undergoing repair in the contractor's facility pursuant to the Access to Vessels clause.

(f) The contractor shall submit to the Contracting Officer the following information in all AIR proposals:

(1) Number of labor hours estimated; broken down by specific direct production labor category.

12 | P a g e

(2) Material estimates, individually broken out and priced. When requested by the

Contracting Officer, material quotes shall be provided.

(3) Subcontractor estimates, individually broken out and priced along with the actual subcontractor quotes. The requirement to submit subcontractor quotes may be waived if deemed appropriate by the Contracting Officer.

(4) Material/subcontractor handling fee and the basis for the fee.

(g) The contractor shall not be entitled to payment for any hours ordered pursuant to this clause until such time as a written contract modification is executed.

H.8 CAR 1352.271-73 SCHEDULE OF WORK (APR 2010)

(a) Notwithstanding other requirements specified in this contract, the contractor shall provide to the Contracting Officer and COR the following documents within five (5) working days of the vessel's arrival at the contractor's facility:

(1) Production Schedule

(2) Work Package Network

(3) Total Manpower Loading Curve

(4) Trade Manning Curves

(5) Subcontracting List

(b) The Production Schedule shall list the earliest, latest, and scheduled start and completion date for each work item awarded and shall identify the critical path. The Work Package Network shall show the work items, milestones, key events, and activities and shall clearly identify the critical path. The Total Manpower Loading Curve shall show the required manning for the duration of the contract. The Trade Manning Curves shall show the required manning for each trade for the duration of the contract. The Subcontracting List shall show work items, milestones, key events, and activities to be accomplished by subcontractors.

(c) Additional Item Requirements ordered and agreed upon, whether or not yet formalized via a change order (contract modification), shall be added to the Production Schedule, Trade

Manning Curves, and Subcontracting List and submitted to the Contracting Officer and COR at each weekly Progress Meeting. Any anticipated or unanticipated deviation (greater than five (5) calendar days) from the Production Schedule shall be immediately brought to the attention of the Contracting Officer and COR.

(d) Any unauthorized deviation in the Production Schedule which results in a delay in the completion of work on a vessel past the established performance period completion date may entitle the Government to remedies for late performance, including, but not limited to, liquidated damages.

H.9 CAR 1352.271-75 DELIVERY AND SHIFTING OF THE VESSEL (APR 2010)

H.10 CAR 1352.271-76 PERFORMANCE (APR 2010)

(a) The contractor shall not commence work until a notice to proceed has been issued by the

Contracting Officer.

13 | P a g e

(b) The Government shall deliver the vessel described in the contract at such time and location as may be specified in the contract. Upon completion of the work, the Government shall accept delivery of the vessel at such time and location as may be specified in the contract.

(c) Without additional charge to the Government, and without specific requirement in the contract, the contractor shall:

(1) Make available, at the facility, to personnel of the vessel while in drydock or on a marine railway, sanitary facilities adequate for the number of personnel using them and acceptable to the Contracting Officer;

(2) Supply and maintain, in such condition as the Contracting Officer may reasonably require, suitable brows and gangways from the pier, drydock or marine railway to the vessel;

(3) Perform, or pay the cost of, any repair, reconditioning or replacement made necessary as the result of the use by the contractor of any of the vessel's machinery, equipment or fittings, including, but not limited to, winches, pumps, riggings, or pipe lines; and

(4) Furnish suitable offices, office equipment and telephones at or near the site of the work as the Contracting Officer reasonably requires for personnel designated by the Government.

(d) Except as otherwise provided in the contract, the contractor shall furnish all necessary material, labor, supervision, services, equipment, tools, supplies, power, accessories, facilities, and other things and services necessary for accomplishing the work.

(e) The contractor shall conduct dock and sea trials of the vessel as required by the contract.

Unless otherwise expressly provided in the contract, during the conduct of these trials the vessel shall be under the control of the vessel's commander and crew with representatives of the contractor and the Government on board to determine whether the work provided by the contractor has been satisfactorily performed. Dock and sea trials not specified which the contractor requires for its own benefit shall not be undertaken by the contractor without prior notice to and approval of the Contracting Officer; any such dock or sea trial shall be conducted at the risk and expense of the contractor. The contractor shall provide and install all fittings and appliances which may be necessary for the dock and sea trials to enable the representatives of the Government to determine whether the requirements of the contract plans and specifications have been met. The contractor shall also be responsible for the care, installation and removal of any instruments and apparatus furnished by the Government for such trials.

H.11 CAR 1352.271-77 DELAYS (APR 2010)

H.12 CAR 1352.271-78 MINIMIZATION OF DELAY DUE TO GOVERNMENT

FURNISHED PROPERTY (APR 2010)

H.13 CAR 1352.271-79 LIABILITY AND INSURANCE (APR 2010)

H.14 CAR 1352.271-80 TITLE (APR 2010)

H.15 CAR 1352.271-81 DISCHARGE OF LIENS (APR 2010)

14 | P a g e

H.16 CAR 1352.271-82 DEPARTMENT OF LABOR OCCUPATIONAL SAFETY AND

HEALTH STANDARDS FOR SHIP REPAIR (APR 2010)

H.17 CAR 1352.271-83 GOVERNMENT REVIEW, COMMENT, ACCEPTANCE AND

APPROVAL (APR 2010)

H.18 CAR 1352.271-84 ACCESS TO THE VESSEL (APR 2010)

H.19 CAR 1352.271-85 DOCUMENTATION OF REQUESTS FOR EQUITABLE

ADJUSTMENT (APR 2010)

H.20 CAR 1352.271-86 LAY DAYS (APR 2010)

H.21 CAR 1352.271-87 CHANGES – SHIP REPAIR (APR 2010)

H.22 CAR 1352.271-88 GUARANTEES (APR 2010)

(a) In the event any work performed or materials furnished by the contractor under this contract prove defective or deficient within 90 days from the date of redelivery of the vessel, the contractor, as directed by the Contracting Officer and at its own expense, shall correct and repair the deficiency to the satisfaction of the Contracting Officer.

(b) The Government shall be entitled to rely upon any guarantee secured by the contractor or any sub-contractor covering work done or materials furnished which exceeds the 90-day period until its expiration.

(c) With respect to any individual work item identified and listed as incomplete at the redelivery of the vessel, the guarantee period shall run from the date of completion of such item.

(d) If and when practicable, the Government shall afford the contractor an opportunity to effect such corrections and repairs.

(1) If the Contracting Officer determines it is impracticable or is otherwise not advisable to return the vessel to the contractor, or the contractor fails to proceed promptly with any such repairs as directed by the Contracting Officer, the

Contracting Officer may direct that the repairs be performed elsewhere, at the contractor's expense.

(2) Where corrections and repairs are to be made by other than the contractor due to nonreturn of the vessel to the contractor, the contractor's liability may be discharged by an equitable deduction in the price of the contract.

(e) The contractor's liability shall only extend for an additional 90-day guarantee period on those defects or deficiencies which it corrected. However, this clause does not limit the responsibility or relieve the liability of the contractor under the Liability and

Insurance clause.

(f) At the Contracting Officer's option, defects and deficiencies may be left in their uncorrected condition. In that event, the contractor and the Contracting Officer shall agree on an equitable deduction in the contract price. Failure to agree upon an equitable reduction shall constitute a dispute under the Disputes clause of this contract.

(g) The rights and remedies of the Government provided in this clause are in addition to and do not limit any rights afforded to the Government by any other clause of the

15 | P a g e contract. If a defect or deficiency that exists at the time of redelivery of the vessel was not discovered by a reasonable inspection and is discovered after the expiration of the time frame stated in this clause, it is not subject to the time limitations stated in this clause.

H.23 CAR 1352.271-89 TEMPORARY SERVICES (APR 2010)

H.24 CAR 1352.271-90 INSURANCE REQUIREMENTS (APR 2010)

(a) The contractor shall procure and thereafter maintain the following insurance:

(1) Ship contractor's legal liability insurance to insure the risks described in paragraph (b) of clause 1352.271-79. This insurance shall be for $1,000,000.00.

(2) Comprehensive general liability insurance and automobile insurance to insure the risks described in paragraph (c) of clause 1352.271-79. This insurance shall be for $1,000,000.00 on account of any one accident or occurrence with respect to each vessel, boat, and/or barge upon which work is performed. The contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies.

(3) Full coverage in accordance with the State Worker's Compensation law; and

(4) Full coverage in accordance with the United States Longshoremen's and

Harbor Worker's Act.

(b) As evidence that it has obtained the insurance specified in paragraph (a) of this clause, the contractor shall furnish the Contracting Officer with a certificate or certificates executed by an agent of the insurer authorized to execute such certificates.

Such certificates shall be furnished prior to commencement of the work. Each certificate shall state that (name of insurer) has insured (name of contractor) awarded contract number (to be provided at the time of award) for repair/alteration of NOAA SHIP

RONALD H. BROWN in accordance with the Liability and Insurance clause and the

Insurance Requirements clause contained herein. Each certificate shall set forth that each policy of insurance represented thereby will expire on (date) and that each such policy contains the following clause:

"It is agreed that in the event of cancellation or any material change in the policy adversely affecting the interest of the Government in this insurance, 30 days prior written notice will be given to the Contracting Officer."

16 | P a g e

H.25 FAR 52.228-1 BID GUARANTEE (SEPT 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier’s check, irrevocable letter of credit, or, under Treasury

Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds

(including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000.00, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

H.26 FAR 52.228-16 PERFORMANCE AND PAYMENT BONDS-OTHER THAN

CONSTRUCTION (NOV 2006)

(a) Definitions. As used in this clause-

"Original contract price" means the award price of the contract or, for requirements contracts, the price payable for the estimated quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity. Original contract price does not include the price of any options, except those options exercised at the time of contract award.

(b) The Contractor shall furnish a performance bond (Standard Form 1418) for the protection of the Government in an amount equal to 100 percent of the original contract price and a payment bond (Standard Form 1416) in an amount equal to 100 percent of the original contract price.

(c) The Contractor shall furnish all executed bonds, including any necessary reinsurance agreements, to the Contracting Officer, within 10 days of award, but in any event, before starting work.

(d) The Government may require additional performance and payment bond protection if the contract price is increased. The Government may secure the additional protection by directing the Contractor to increase the penal amount of the existing bonds or to obtain additional bonds.

(e) The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual https://www.gsa.gov/forms-library/performance-bond-other-construction-contracts https://www.gsa.gov/forms-library/payment-bond-other-construction-contracts

17 | P a g e sureties, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal

Register, or may be obtained from the:

U.S. Department of the Treasury, Financial Management Service, Surety Bond Branch, 3700 East West Highway, Room 6 F01

Hyattsville, MD 20782.

Or via the internet at http://www.fms.treas.gov/c570/.

END OF SECTION H

http://www.fms.treas.gov/c570/

18 | P a g e

Part II – Contract Clauses

Section I – Contract Clauses

I.1 FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the

Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/Far/ and http://www.gpo.gov

I.2 FAR 52.202-1 DEFINITIONS (JUN 2020)

I.3 FAR 52.203-3 GRATUITIES (APR 1984)

I.4 FAR 52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE

GOVERNMENT (JUN 2020)

I.5 FAR 52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

I.6 FAR 52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR

ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

I.7 FAR 52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER

ACTIVITY (MAY 2014)

I.8 FAR 52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (JUN 2020)

I.9 FAR 52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND

REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER

RIGHTS (JUN 2020)

I.10 FAR 52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON POSTCONSUMER

FIBER CONTENT PAPER (MAY 2011)

I.11 FAR 52.204-13 SYSTEM FOR AWARD MAINTENANCE (OCT 2018)

I.12 FAR 52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE

MAINTENANCE (AUG 2020)

I.13 FAR 52.211-5 MATERIAL REQUIREMENTS (AUG 2000)

http://www.gpo.gov/

19 | P a g e

I.14 FAR 52.212-4 CONTRACT TERMS AND CONDITIONS-COMMERCIAL ITEMS

(OCT 2018)

I.15 FAR 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO

IMPLEMENT STATUTES OR EXECUTIVE ORDERS-COMMERCIAL

ITEMS (JAN 2021)

(a) The Contractor shall comply with the following Federal Acquisition Regulation

(FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or

Statements (Jan 2017) (section 743 of Division E, Title VII, of the

Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts

(and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services

Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul

2018) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video

Surveillance Services or Equipment. (Aug 2020) (Section 889(a)(1)(A) of

Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov

2015).

(5) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(6) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-

77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the

Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

X (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (June 2020), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

X (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Jun

2020) (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment

Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of

2009.)

X (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun

2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

__ (5) [Reserved].

__ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery

Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

https://www.acquisition.gov/far/52.203-19#FAR_52_203_19 https://www.acquisition.gov/far/52.204-23#FAR_52_204_23 https://www.acquisition.gov/far/52.204-25#FAR_52_204_25 https://www.acquisition.gov/far/52.209-10#FAR_52_209_10 https://www.acquisition.gov/far/52.233-3#FAR_52_233_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.233-4#FAR_52_233_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.203-6#FAR_52_203_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.203-13#FAR_52_203_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.203-15#FAR_52_203_15 https://www.acquisition.gov/far/52.204-10#FAR_52_204_10 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/52.204-14#FAR_52_204_14 https://www.acquisition.gov/far/52.204-15#FAR_52_204_15

20 | P a g e

X (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors

Debarred, Suspended, or Proposed for Debarment. (Jun

2020) (31 U.S.C. 6101 note).

X (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility

Matters (Oct 2018) (41 U.S.C. 2313).

__ (10) [Reserved].

__ (11)

(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Mar

2020) (15 U.S.C. 657a).

__ (ii) Alternate I (Mar 2020) of 52.219-3.

__ (12)

(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business

Concerns (Mar 2020) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__ (ii) Alternate I (Mar 2020) of 52.219-4.

__ (13) [Reserved]

__ (14)

(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-6.

__ (15)

(i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-7.

X (16) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)).

__ (17)

(i) 52.219-9, Small Business Subcontracting Plan (Jun 2020) (15 U.S.C. 637(d)(4)).

X (ii) Alternate I (Nov 2016) of 52.219-9.

__ (iii) Alternate II (Nov 2016) of 52.219-9.

__ (iv) Alternate III (Jun 2020) of 52.219-9.

__ (v) Alternate IV (Jun 2020) of 52.219-9

__ (18)

(i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

__ (ii) Alternate I (Mar 2020) of 52.219-13.

__ (19) 52.219-14, Limitations on Subcontracting (Mar 2020) (15 U.S.C. 637(a)(14)).

X (20) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan

1999) (15 U.S.C. 637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Mar

2020) (15 U.S.C. 657f).

X (22)

(i) 52.219-28, Post Award Small Business Program Rerepresentation (Nov

2020) (15 U.S.C. 632(a)(2)).

__ (ii) Alternate I (MAR 2020) of 52.219-28.

__ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically

Disadvantaged Women-Owned Small Business Concerns (Mar

2020) (15 U.S.C. 637(m)).

https://www.acquisition.gov/far/52.209-6#FAR_52_209_6 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/52.209-9#FAR_52_209_9 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section2313&num=0&edition=prelim https://www.acquisition.gov/far/52.219-3#FAR_52_219_3 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637a&num=0&edition=prelim https://www.acquisition.gov/far/52.219-3#FAR_52_219_3 https://www.acquisition.gov/far/52.219-4#FAR_52_219_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-4#FAR_52_219_4 https://www.acquisition.gov/far/52.219-6#FAR_52_219_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-6#FAR_52_219_6 https://www.acquisition.gov/far/52.219-7#FAR_52_219_7 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-7#FAR_52_219_7 https://www.acquisition.gov/far/52.219-8#FAR_52_219_8 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-13#FAR_52_219_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-13#FAR_52_219_13 https://www.acquisition.gov/far/52.219-14#FAR_52_219_14 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-16#FAR_52_219_16 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-27#FAR_52_219_27 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-28#FAR_52_219_28 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-28#FAR_52_219_28 https://www.acquisition.gov/far/52.219-29#FAR_52_219_29 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3

21 | P a g e

__ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small

Business Concerns Eligible Under the Women-Owned Small Business

Program (Mar2020) (15 U.S.C. 637(m)).

__ (25) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar

2020) (15 U.S.C. 644(r)).

__ (26) 52.219-33, Nonmanufacturer Rule (Mar 2020) (15U.S.C. 637(a)(17)).

X (27) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

X (28) 52.222-19, Child Labor-Cooperation with Authorities and

Remedies (Jan2020) (E.O.13126).

X (29) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

X (30)

(i) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

__ (ii) Alternate I (Feb 1999) of 52.222-26.

X (31)

(i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

__ (ii) Alternate I (Jul 2014) of 52.222-35.

X (32)

(i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C. 793).

__ (ii) Alternate I (Jul 2014) of 52.222-36.

X (33) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

X (34) 52.222-40, Notification of Employee Rights Under the National Labor Relations

Act (Dec 2010) (E.O. 13496).

X (35)

(i) 52.222-50, Combating Trafficking in Persons (Oct 2020) (22 U.S.C. chapter 78 and E.O.

13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

X (36) 52.222-54, Employment Eligibility Verification (Oct 2015). (Executive Order 12989).

(Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

__ (37)

(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated

Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

X (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential

Hydrofluorocarbons (Jun 2016) (E.O. 13693).

X (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and

Air Conditioners (Jun 2016) (E.O. 13693).

__ (40)

(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s

13423 and 13514).

__ (ii) Alternate I (Oct 2015) of 52.223-13.

__ (41)

(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and

13514).

__ (ii) Alternate I (Jun2014) of 52.223-14.

https://www.acquisition.gov/far/52.219-30#FAR_52_219_30 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-32#FAR_52_219_32 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec644.htm https://www.acquisition.gov/far/52.219-33#FAR_52_219_33 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec637.htm https://www.acquisition.gov/far/52.222-3#FAR_52_222_3 https://www.acquisition.gov/far/52.222-19#FAR_52_222_19 https://www.acquisition.gov/far/52.222-21#FAR_52_222_21 https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.222-35#FAR_52_222_35 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/52.222-35#FAR_52_222_35 https://www.acquisition.gov/far/52.222-36#FAR_52_222_36 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title29-section793&num=0&edition=prelim https://www.acquisition.gov/far/52.222-36#FAR_52_222_36 https://www.acquisition.gov/far/52.222-37#FAR_52_222_37 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/52.222-40#FAR_52_222_40 https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-54#FAR_52_222_54 https://www.acquisition.gov/far/22.1803#FAR_22_1803 https://www.acquisition.gov/far/52.223-9#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.223-9#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.223-11#FAR_52_223_11 https://www.acquisition.gov/far/52.223-12#FAR_52_223_12 https://www.acquisition.gov/far/52.223-13#FAR_52_223_13 https://www.acquisition.gov/far/52.223-13#FAR_52_223_13 https://www.acquisition.gov/far/52.223-14#FAR_52_223_14 https://www.acquisition.gov/far/52.223-14#FAR_52_223_14

22 | P a g e

__ (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (May

2020) (42 U.S.C. 8259b).

__ (43)

(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct

2015) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-16.

X (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Jun

2020) (E.O. 13513).

__ (45) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

__ (46) 52.223-21, Foams (Jun2016) (E.O. 13693).

__ (47)

(i) 52.224-3 Privacy Training (Jan 2017) (5 U.S.C. 552 a).

__ (ii) Alternate I (Jan 2017) of 52.224-3.

X (48) 52.225-1, Buy American-Supplies (Jan2021) (41 U.S.C. chapter 83).

__ (49)

(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act

(Jan 2021)(41 U.S.C.chapter83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note

, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-

78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-

42, and 112-43.

__ (ii) Alternate I (Jan 2021) of 52.225-3.

__ (iii) Alternate II (Jan 2021) of 52.225-3.

__ (iv) Alternate III (Jan 2021) of 52.225-3.

__ (50) 52.225-5, Trade Agreements (Oct 2019) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

X (51) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the

Department of the Treasury).

__ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States

(Oct 2016) (Section 862, as amended, of the National Defense

Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302Note).

__ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov2007) (42 U.S.C. 5150).

__ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area

(Nov2007) (42 U.S.C. 5150).

__ (55) 52.229-12, Tax on Certain Foreign Procurements (Jun 2020).

__ (56) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb

2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

__ (57) 52.232-30, Installment Payments for Commercial Items (Jan 2017)

(41 U.S.C. 4505, 10 U.S.C. 2307(f)).

X (58) 52.232-33, Payment by Electronic Funds Transfer-System for Award

Management (Oct2018) (31 U.S.C. 3332).

__ (59) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award

Management (Jul 2013) (31 U.S.C. 3332).

__ (60) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

__ (61) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

X (62) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(13)).

__ (63) https://www.acquisition.gov/far/52.223-15#FAR_52_223_15 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.223-16#FAR_52_223_16 https://www.acquisition.gov/far/52.223-16#FAR_52_223_16 https://www.acquisition.gov/far/52.223-18#FAR_52_223_18 https://www.acquisition.gov/far/52.223-20#FAR_52_223_20 https://www.acquisition.gov/far/52.223-21#FAR_52_223_21 https://www.acquisition.gov/far/52.224-3#FAR_52_224_3 https://www.acquisition.gov/far/52.224-3#FAR_52_224_3 https://www.acquisition.gov/far/52.225-1#FAR_52_225_1 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 https://www.acquisition.gov/far/52.225-5#FAR_52_225_5 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title19-section2501&num=0&edition=prelim http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title19-section3301&num=0&edition=prelim https://www.acquisition.gov/far/52.225-13#FAR_52_225_13 https://www.acquisition.gov/far/52.225-26#FAR_52_225_26 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.226-4#FAR_52_226_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.226-5#FAR_52_226_5 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.229-12#FAR_52_229_12 https://www.acquisition.gov/far/52.232-29#FAR_52_232_29 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.232-30#FAR_52_232_30 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.232-33#FAR_52_232_33 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section3332&num=0&edition=prelim https://www.acquisition.gov/far/52.232-34#FAR_52_232_34 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.232-36#FAR_52_232_36 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.239-1#FAR_52_239_1 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title5-section552a&num=0&edition=prelim https://www.acquisition.gov/far/52.242-5#FAR_52_242_5

23 | P a g e

(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb

2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

__ (ii) Alternate I (Apr 2003) of 52.247-64.

__ (iii) Alternate II (Feb 2006) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions…