NNC_Bid Documents_Specs_865CM3031.pdf

NCA MASTER SPECIFICATIONS

BID DOCUMENTS

NASHVILLE NATIONAL CEMETERY

NASHVILLE, DAVIDSON COUNTY, TENNESSEE

PROJECT NO. 865CM3031

REPAIR ROADS

Prepared for:

United States Department of Veterans Affairs

July 24, 2023

NASHVILLE NATIONAL CEMETERY PROJECT NO. 865CM3031

REPAIR ROADS JULY 24, 2023

BID DOCUMENTS

PROFESSIONAL SEALS & SIGNATURES

00 01 07-1

PROFESSIONAL SEALS & SIGNATURES

Section 00 01 07

RYAN P. PERKS

CIVIL ENGINEER

INTEGRITY FEDERAL SERVICES

BID DOCUMENTS

PROFESSIONAL SEALS & SIGNATURES

00 01 07-2

THIS PAGE LEFT BLANK INTENTIONALLY

TABLE OF CONTENTS

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

NCA MASTER SPECIFICATIONS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 15 List of Drawing Sheets 05-10

00 01 07 Professional Seals and Signatures

DIVISION 01 - GENERAL REQUIREMENTS

01 00 02 General Requirements (Minor NCA Projects) 06-14

01 32 17 Network Analysis Schedules (Microsoft Project Gantt

Chart)

10-10

01 33 23 Shop Drawings, Product Data, and Samples 06-14

01 42 19 Reference Standards 06-14

01 45 29 Testing Laboratory Services 06-14

01 57 19 Temporary Environmental Controls 06-14

01 74 19 Construction Waste Management 06-14

01 81 13 Sustainable Construction Requirements 08-16

DIVISION 02 – EXISTING CONDITIONS

02 41 10 Demolition and Site Clearing 06-14

DIVISION 03 – CONCRETE

03 30 53 Cast-in-Place Concrete (Short-Form) 06-14

DIVISION 31 – EARTHWORK

31 20 11 Earth Moving (Short Form) 11-16

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 05 23 Cement and Concrete for Exterior Improvements 11-16

32 12 16 Asphalt Paving 11-16

32 17 23 Pavement Markings 11-16

32 90 00 Planting 11-16

DIVISION 33 – UTILITIES

33 40 00 Storm Sewer Utilities 11-16

00 01 10-2

BID DOCUMENTS

LIST OF DRAWING SHEETS

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

Drawings listed below accompanying this specification form a part of the contract.

Drawing No. Drawing Drawing Title

1. GI001 COVER SHEET

2. GI002 GENERAL NOTES, SYMBOLS AND ABBREVIATIONS

3. VL100 OVERALL EXISTING CONDITIONS AND BORING PLAN

4. VL101 EXISTING TREE AND UTILITY TABLES AND BORING LOGS

5. VL102 EXISTING CONDITIONS AND BORING PLAN

6. VL103 EXISTING CONDITIONS AND BORING PLAN

7. VL104 EXISTING CONDITIONS AND BORING PLAN

8. VL105 EXISTING CONDITIONS AND BORING PLAN

9. VL106 EXISTING CONDITIONS AND BORING PLAN

10. VL107 EXISTING CONDITIONS AND BORING PLAN

11. GC100 CONSTRUCTION SEQUENCE PLAN

12. GC101 EROSION AND SEDIMENT CONTROL PLAN

13. GC102 EROSION AND SEDIMENT CONTROL PLAN

14. GC103 EROSION AND SEDIMENT CONTROL PLAN

15. GC104 EROSION AND SEDIMENT CONTROL PLAN

16. GC105 EROSION AND SEDIMENT CONTROL PLAN

17. GC106 EROSION AND SEDIMENT CONTROL PLAN

18. GC501 EROSION AND SEDIMENT CONTROL NOTES & DETAILS

19. GC502 EROSION AND SEDIMENT CONTROL NOTES & DETAILS

20. CD101 SITE DEMOLITION PLAN

21. CD102 SITE DEMOLITION PLAN

22. CD103 SITE DEMOLITION PLAN

23. CD104 SITE DEMOLITION PLAN

24. CD105 SITE DEMOLITION PLAN

25. CD106 SITE DEMOLITION PLAN

26. CS101 SITE PLAN

27. CS102 SITE PLAN

28. CS103 SITE PLAN

29. CS104 SITE PLAN

30. CS105 SITE PLAN

31. CS106 SITE PLAN

32. CS5O1 SITE DETAILS

BID DOCUMENTS

LIST OF DRAWING SHEETS

00 01 15 - 2

33. CS502 SITE DETAILS

34. CS503 SITE DETAILS

35. CS504 SITE DETAILS

36. CS505 SITE DETAILS

- - - END - - -

GENERAL REQUIREMENTS

01 00 02 - 1

SECTION 01 00 02

GENERAL REQUIREMENTS (MINOR NCA PROJECTS)

1.1 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor, materials, equipment and services and perform and complete all work for Nashville National Cemetery Repair Roads as required by drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the

Cemetery Director.

C. Offices of Integrity Federal Services Inc, as Architect-Engineers

(A/E), may render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the

Government without affirmations by Contracting Officers Representative

(COR) or his duly authorized representative.

D. All employees of general contractor and subcontractors shall comply with security requirements as established by the COR, be identified by name and employer. They shall be restricted from unauthorized access.

E. Prior to commencing work, general contractor shall provide proof that a

OSHA certified “competent person” (CP) (29 CFR 1926.20(b)(2) will maintain a presence at the work site whenever the general or subcontractors are present.

F. Training:

1. All employees of general contractor or subcontractors shall, at the minimum, have successfully completed the 30-hour OSHA certified

Construction Safety course and/or other relevant competency training, as determined by VA CP.

2. Submit OSHA training records of all employees for approval before the start of work.

1.2 STATEMENT OF BID ITEM(S)

A. Installation of all work shown on the plans and described in the specifications including but not limited to: Construction of storm drainage improvements, pavement/curb repair and pavement overlay.

1.3 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. AFTER AWARD OF CONTRACT, 2 bond paper set(s) of specifications and drawings will be furnished.

01 00 02 - 2

B. Additional sets of drawings may be made by the Contractor, at

Contractor's expense, from digital files furnished by the Issuing

Office.

1.4 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the site without following the procedures approved by the COR. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. For working outside the “regular hours” as defined in the contract, The General Contractor shall give 3 days’ notice to the COR so that appropriate arrangements can be provided for the Cemetery employees.

This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the COR.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the COR.

C. Guards:

1. The General Contractor shall provide unarmed guards at the project site when theft or vandalism warrants.

D. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the COR for the purpose of security inspections of every area of project including tool boxes and parked machines, and to take any necessary emergency action.

01 00 02 - 3

1.5 FIRE SAFETY

A. Applicable Publications: Publications listed below form part of this

Article to the extent referenced. Publications are referenced in text by basic designations only.

1. American Society for Testing and Materials (ASTM):

E84-2009a Surface Burning Characteristics of Building

Materials

2. National Fire Protection Association (NFPA):

10-2010 Standard for Portable Fire Extinguishers

30-2008 Flammable and Combustible Liquids Code

51B-2009 Standard for Fire Prevention During Welding, Cutting and Other Hot Work

70-2008 National Electrical Code

241-2009 Standard for Safeguarding Construction, Alteration, and Demolition Operations

3. Occupational Safety and Health Administration (OSHA):

29 CFR 1926 Safety and Health Regulations for Construction

B. Fire Safety Plan: Establish and maintain a fire protection program in accordance with 29 CFR 1926. Prior to start of work, prepare a plan detailing project-specific fire safety measures, including periodic status reports, and submit to COR/Cemetery Director for review for compliance with contract requirements in accordance with Section 01 33

23, SHOP DRAWINGS, PRODUCT DATA AND SAMPLES. Prior to any worker for the contractor or subcontractor’s beginning work, they shall undergo a safety briefing provided by the General Contractor’s competent person per OSHA requirements. This briefing shall include information on the construction limits, safety guidelines, means of egress, break areas, work hours, locations of restrooms, use of NCA equipment, etc.

Documentation shall be provided to the COR that individuals have undergone the Contractor’s safety briefing.

C. Site and Building Access: Maintain free and unobstructed access to emergency services and for fire, police and other emergency response forces in accordance with NFPA 241.

D. Separate temporary facilities, such as trailers, storage sheds, and dumpsters, from existing buildings and new construction by distances in accordance with NFPA 241. For small facilities with less than 20 feet exposing overall length, separate by 10 feet.

01 00 02 - 4

E. Egress Routes for Construction Workers: Maintain free and unobstructed egress. Inspect daily. Report findings and corrective actions weekly to

COR.

F. Fire Extinguishers: Provide and maintain extinguishers in construction areas and temporary storage areas in accordance with 29 CFR 1926, NFPA

241 and NFPA 10.

G. Flammable and Combustible Liquids: Store, dispense and use liquids in accordance with 29 CFR 1926, NFPA 241 and NFPA 30.

H. Fire Hazard Prevention and Safety Inspections: Inspect entire construction areas weekly. Coordinate with, and report findings and corrective actions weekly to COR.

I. Dispose of waste and debris in accordance with NFPA 241. Remove from site weekly.

J. Perform other construction, alteration and demolition operations in accordance with 29 CFR 1926.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the COR. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Temporary buildings (e.g., storage trailers, office trailers) and utilities may be erected by the Contractor only with the approval of the COR and shall be built with labor and materials furnished by the

Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the Contractor and shall be removed by the Contractor at its expense upon completion of the work.

C. The Contractor shall, under regulations prescribed by the COR, use only established roadways, or use temporary roadways constructed by the

Contractor when and as authorized by the COR. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the

Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

01 00 02 - 5

D. Working space and space available for storing materials shall be as determined by the COR with agreement of the Cemetery. Contractor parking will be only in areas and on roadways designated and agreed to by the COR in agreement of the Cemetery.

E. Workmen are subject to rules of the Cemetery applicable to their conduct.

F. Execute work so as to interfere as little as possible with normal functioning of Cemetery as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others.

1. Do not store materials and equipment in other than assigned areas.

2. Provide unobstructed access to the Cemetery areas required to remain in operation.

G. Phasing: To ensure such executions, the Contractor shall furnish the

COR with a schedule of approximate dates on which the Contractor intends to accomplish work in each specific area of site, or portion thereof. In addition, the Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, or portion thereof. Arrange such dates to ensure accomplishment of this work in successive phases mutually agreeable to the Cemetery

Director, COR and Contractor, as follows:

H. Construction Fence: Before construction operations begin, the

Contractor shall provide a chain link construction fence, six feet minimum height, around the construction. Provide gates as required for access with necessary hardware, including hasps and padlocks. Fasten fence fabric to terminal posts with tension bands and to line posts and top and bottom rails with tie wires spaced at maximum 15 inches. Bottom of fences shall extend to one inch above grade. The temporary fencing shall encompass the construction work area(s) to serve as a pedestrian barrier to alert cemetery patrons of the construction site. Remove the fence when directed by COR.

I. Utilities Services: Maintain existing utility services for the Cemetery at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

Where necessary to cut existing water, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and

01 00 02 - 6 capped at suitable places where shown; or, in absence of such indication, where directed by COR. All such actions shall be coordinated with the Utility Company involved.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR. Electrical work shall be accomplished with all affected circuits or equipment de-energized.

When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without the COR, and Cemetery Director’s prior knowledge and written approval.

2. The Contractor shall submit a request to interrupt any such services to both COR and the Cemetery Director in writing, 48 hours in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. The Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of the Cemetery. Interruption time approved by the Cemetery and COR may occur at other than

Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

J. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged-in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

01 00 02 - 7

K. To minimize interference of construction activities with flow of

Cemetery traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles. Wherever excavation for new utility lines cross existing roads, at least one lane must be open to traffic at all times.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances must be approved by the COR.

L. Coordinate the work for this contract with other construction operations as directed by COR. This includes the scheduling of traffic and the use of roadways.

M. Coordination of Construction with Cemetery Director: The burial activities at a National Cemetery shall take precedence over construction activities. The Contractor must cooperate and coordinate with the Cemetery Director, through the COR, in arranging construction schedule to cause the least possible interference with Cemetery activities in actual burial areas. Construction noise during the committal services shall not disturb the service. Trucks and workmen shall not pass through the service area during this period.

1. The Contractor is required to discontinue work sufficiently in advance of Easter Sunday, Mother's Day, Father's Day, Memorial Day, Veteran's Day and/or Federal holidays, to permit the Contractor to clean up all areas of operation adjacent to existing burial plots before these dates.

2. Cleaning up shall include the removal of all equipment, tools, materials and debris and leaving the areas in a clean, neat condition.

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR of areas in which alterations occur and furnish a signed report, to the Contracting Officer. This report shall list:

1. Existing condition and types of surfaces not required to be altered throughout affected areas.

2. Shall note any discrepancies between drawings and existing conditions at site.

01 00 02 - 8

3. Shall designate areas for working space, materials storage and routes of access to areas where alterations occur and which have been agreed upon by Contractor and COR.

B. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas involved. They shall furnish a report on conditions then existing surfaces as compared with conditions of same as noted in first condition survey report.

1. Re-survey report shall also list any damage caused by the Contractor to such surfaces, despite protection measures; and will form the basis for determining extent of repair work required of the

Contractor to restore damage caused by the Contractor's workmen in executing work of this contract.

C. Protection: Provide the following protective measures:

1. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled and equipment moved and/or relocated.

1.8 ENVIRONMENTAL CONTROLS

A. In general, following preventive measures shall be adopted during construction to keep down dust.

1. Dampen debris to keep down dust where directed by COR.

B. Final Cleanup:

1. Upon completion of the project, or as work progresses, remove all construction debris from site.

1.9 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from the Cemetery.

01 00 02 - 9

1.10 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS

A. The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so, and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workmen, the Contractor shall trim those limbs or branches with a clean cut and paint the cut with a tree-pruning compound as directed by the COR.

B. The Contractor shall protect from damage all existing improvements and utilities at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the

Contractor fails or refuses to repair the damage promptly, the COR may have the necessary work performed and charge the cost to the

Contractor.

(FAR 52.236-9)

C. Refer to Section 01 57 19, TEMPORARY ENVIRONMENTAL CONTROLS, for additional requirements on protecting vegetation, soils and the environment. Refer to Articles, "Alterations", "Restoration", and

"Operations and Storage Areas" for additional instructions concerning repair of damage to structures and site improvements.

1.11 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any water/irrigation or electric work without approval of the COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality

01 00 02 - 10 to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, landscape stone, lawns, paving, roads, walks, etc.)

disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At the Contractor's own expense, the Contractor shall immediately restore to service and repair any damage caused by the Contractor's workmen to existing piping and conduits, wires, cables, etc., of utility services, irrigation system control, and power which are indicated on drawings and which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES"

(FAR 52.243-4 and VAAR 852.236-88) and "DIFFERING SITE CONDITIONS" (FAR

52.236-2).

1.12 PHYSICAL DATA

A. Data and information furnished or referred to below is for the

Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

1. The indications of physical conditions on the drawings and in the specifications are the result of site investigations by the A/E.

(FAR 52.236-4)

B. Subsurface conditions have been developed by core borings and test pits. Logs of subsurface exploration conducted by ECS Southwest, LLP are shown in the “Summary of Pavement Coring Activities”.

C. A copy of the Summary is an Appendix to specification 31 20 11 Earth

Moving (Short Form) and shall be considered part of the contract documents.

D. The Government does not guarantee that other materials will not be encountered nor that proportions, conditions or character of several materials will not vary from those indicated by explorations. Bidders

01 00 02 - 11 are expected to examine the site of work and logs of borings and, after investigation, decide for themselves the character of materials and make their bids accordingly. Upon proper application to the Department of Veterans Affairs, including approved scheduling bidders will be permitted to make subsurface explorations of their own at site.

1.13 PROFESSIONAL SURVEYING SERVICES

A registered professional land surveyor or registered civil engineer whose services are retained and paid for by the Contractor shall perform services specified herein and in other specification sections.

The Contractor shall certify that the land surveyor or civil engineer is not one who is a regular employee of the Contractor, and that the land surveyor or civil engineer has no financial interest in this contract.

1.14 LAYOUT OF WORK

A. The Contractor shall lay out the work and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at the Contractor's own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the COR. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the COR until authorized to remove them. If such marks are destroyed by the

Contractor or through Contractor's negligence before their removal is authorized, the COR may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor.

(FAR 52.236-17)

B. Establish and plainly mark center lines for lines and grades that are reasonably necessary to properly assure that location, orientation, and elevations established for roads, parking lots, are in accordance with lines and elevations shown on contract drawings.

C. Following completion of general mass excavation and before any other permanent work is performed, establish and plainly mark (through use of appropriate batter boards or other means) sufficient additional survey control points or system of points as may be necessary to assure proper alignment, orientation, and grade of all major features of work.

01 00 02 - 12

1. Such additional survey control points or system of points thus established shall be checked and certified by a registered land surveyor or registered civil engineer. Furnish such certification to the COR before any work (such as footings, floor slabs, columns, walls, utilities and other major controlling features) is placed.

D. During progress of work, the Contractor shall have lines, grades, locations and plumbness of all major form work checked and certified by a registered land surveyor or registered civil engineer as meeting requirements of contract drawings. Furnish such certification to the

COR before any major items of concrete work are placed. In addition, furnish to the COR certificates from a registered land surveyor or registered civil engineer that the following work is complete in every respect as required by contract drawings.

1. Lines and elevations of sewers and of all outside distribution systems.

2. Lines and elevations of roads, streets and parking lots.

3. Northing/Easting coordinate locations and elevation of all water, sanitary, storm, gas and irrigation structures, directional fittings, control wire and lines.

E. Upon completion of the work, the Contractor shall furnish the COR with reproducible drawings, in AutoCAD form, at the scale of the contract drawings, showing the finished grade on the grid developed for constructing the work. These drawings shall bear the seal of the registered land surveyor or registered civil engineer.

F. The Contractor shall perform the surveying and layout work of this and other articles and specifications in accordance with the provisions of

Article "Professional Surveying Services".

1.15 AS-BUILT DRAWINGS

A. The Contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, which will include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To ensure compliance, as-built drawings shall be made available for the COR's review, as often as requested.

C. The Contractor shall deliver two approved completed sets of as-built drawings to the COR within 15 calendar days after acceptance of the project by the COR.

01 00 02 - 13

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.16 USE OF ROADWAYS

A. For hauling, use only established public roads and permanent roads on

Cemetery property. When necessary to cross curbing, sidewalks, or similar construction, they must be protected by well-constructed bridges.

1.17 TEMPORARY TOILETS

A. Provide where directed, (for use of all Contractor's workers) ample temporary sanitary toilet accommodations with suitable sewer and water connections, or when approved by COR provide suitable dry closets where directed. Keep such places clean and free from flies, and all connections and appliances connected therewith are to be removed prior to completion of contract, and premises left perfectly clean.

1.18 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract. The amount to be paid by the Contractor for chargeable electrical services shall be the prevailing rates charged to the Government. The Contractor shall carefully conserve any utilities furnished without charge.

B. The Contractor, at Contractor's expense and in a workmanlike manner satisfactory to the COR, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to measure the amount of electricity used for the purpose of determining charges. Before final acceptance of the work by the

Government, the Contractor shall remove all the temporary connections, distribution lines, meters, and associated paraphernalia.

C. The Contractor shall install meters at the Contractor's expense and furnish the Cemetery a monthly record of the Contractor's usage of electricity as hereinafter specified.

D. Heat: Furnish temporary heat necessary to prevent injury to work and materials through dampness and cold. Use of open salamanders or any temporary heating devices which may be fire hazards or may smoke and damage finished work, will not be permitted. Maintain minimum temperatures as specified for various materials:

E. Electricity (for Construction and Testing): Furnish all temporary electric services.

01 00 02 - 14

1. Obtain electricity by connecting to the Cemetery electrical distribution system. The Contractor shall meter and pay for electricity required for electric cranes and hoisting devices, electrical welding devices and any electrical heating devices providing temporary heat. Where not available or not convenient to connect to the Cemetery distribution system, the contractor shall supply power via portable generators at own expense. Generators shall be acoustically screened so as not to disturb committal services and/or visitation to the adjacent columbarium.

F. Water (for Construction and Testing): Furnish temporary water service.

1. Obtain water by connecting to the Cemetery irrigation distribution system. Backflow preventer may not be required at connections to the irrigation system. Water is available at no cost to the Contractor.

2. If potable water is required and convenient connection is available the contractor may connect to the Cemetery potable water distribution system. The contractor shall install reduced pressure backflow preventer at each connection at own expense.

3. Maintain connections, pipe, fittings and fixtures and conserve water-use so none is wasted. Failure to stop leakage or other wastes will be cause for revocation (at COR's discretion) of use of water from the Cemetery's system.

4. Where not available or not convenient to connect to the Cemetery distribution system, the Contractor shall supply water via portable/temporary means at his own expense.

1.19 HISTORIC PRESERVATION

A. Where the Contractor or any of the Contractor's employees, prior to, or during the construction work, are advised of or discover any possible archeological, historical and/or cultural resources, the Contractor shall immediately notify the COR verbally, and then with a written follow up.

1.20 PROJECT HEALTH AND SAFETY PLAN

A. Prior to commencing any construction, the Contractor shall submit a site-specific Project Health and Safety Plan (PHSP). At a minimum, the

PHSP shall cover the following topics:

1. Organizational structure (including Responsible Persons)

2. Site Characterization and Job Hazard Identification

3. Site Control and Security

01 00 02 - 15

4. Training

5. PPE

6. Heat Stress

7. Spill Containment

8. Decontamination

9. Emergency Response

10. Trench Safety

- - - E N D - - -

01 00 02 - 16

NETWORK ANALYSIS SCHEDULE

01 32 17-1

SECTION 01 32 17

NETWORK ANALYSIS SCHEDULES

(MICROSOFT PROJECT GANTT CHART)

PART 1 - GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Microsoft Project 2003 (or later) Gantt

Chart (bar chart) schedule demonstrating fulfillment of the contract requirements. The Contractor shall keep the network up-to-date in accordance with the requirements of this section. The Contractor shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). The Gantt Chart will be utilized to satisfy time applications.

1.2 CONTRACTOR’S REPRESENTATIVE:

A. The Contractor shall designate an in-house representative who will be responsible to prepare the schedule, review the schedule and report progress of the project to the Contracting Officer's Representative.

B. The Contractor's in-house representative shall be given authority to act on behalf of the Contractor in fulfilling the requirements of this specification section. Such authority shall not be interrupted throughout the duration of the project.

1.3 COMPUTER PRODUCED SCHEDULES:

A. The contractor shall provide to VA monthly computer processing of all computer produced schedules generated from monthly project updates. The

Contractor shall provide to VA two (2) copies of the updated Microsoft

Project Gantt Chart and an electronic copy of this data. This must be submitted with and substantively support the contractor’s monthly payment request.

B. The Contractor is responsible for the correctness and timeliness of the computer-produced reports. The Contractor is also responsible for the accurate and timely submittal of the updated project schedule.

C. VA shall report errors in computer-produced reports to the Contractor’s representative within ten (10) calendar days from receipt of reports.

The Contractor shall reprocess the Gantt Chart and associated CDs, when requested by the Contracting Officers Representative, to correct errors that affect the schedule for the project.

01 32 17-2

1.4 THE COMPLETE PROJECT GANTT CHART SUBMITTAL:

A. The Complete Project Microsoft Project Gantt Chart will contain sufficient work activities/events as necessary to fully detail the project schedule.

B. Within ten (10) calendar days after receipt of the Notice to Proceed, the Contractor shall submit for the Contracting Officer's review, a

Microsoft Project Gantt Chart and digital file. Each activity/event on the Gantt Chart schedule shall contain as a minimum, but not limited to, activity/event description, duration, start dates and finish dates.

Activity constraints, not required by the contract, will not be accepted. Logic events (non-work) will be permitted where necessary to reflect proper sequence among work events, but must have zero duration.

C. The complete working Gantt Chart shall reflect the Contractor's approach to scheduling the complete project. The final Gantt Chart in its original form shall contain no contract changes or delays that may have been incurred during the final Gantt Chart development period. It shall reflect the Contractors “AS BID” or “DAY 1” schedule. Changes and /or delays shall be entered at the first monthly update after the final Gantt Chart has been approved. The Contractor should provide their requests for time and supporting time extension analysis for contract time as a result of contract changes/delays, after this update, and in accordance with Article, ADJUSTMENT OF CONTRACT

COMPLETION.

D. Within ten (10) calendar days after receipt of the complete project

Gantt Chart, the Contracting Officer or his representative, will do one or both of the following:

1. Notify the Contractor concerning his actions, opinions, and objections.

2. Schedule a meeting with the Contractor at, or near the job site, for joint review, correction or adjustment of the proposed plan. Within ten (10) calendar days after the joint review, the Contractor shall revise and shall submit two (2) copies of the revised Gantt Chart and a revised digital file as specified to the Contracting Officer.

The revised submission will be reviewed by the Contracting Officer and, if found to be as previously agreed upon, will be approved.

01 32 17-3

1.5 WORK ACTIVITY/EVENT AND COST DATA INFORMATION:

A. The Contractor shall not be required to “cost load” the computerized

Microsoft Project Gantt Chart. As part of this submission, the

Contractor shall provide a separate Schedule of Costs on AIA document

G703. This Schedule of Costs shall reflect and contain all the same activities/events identified on the Gantt Chart.

B. The Contractor and the Contracting Officer shall use this Schedule of

Costs for monthly payment purposes as referenced in the General

Conditions of this agreement.

C. The Contractor and Contracting Officer shall agree on percentages for monthly work accomplished. The cumulative total amount of all cost loaded activities/events (including alternates) shall equal the total contract price.

D. Prorate overhead, profit and general conditions on all work activities/events for the entire project. Negative work activity/event cost data will not be acceptable, except on VA issued contract changes.

1.6 GANTT CHART REQUIREMENTS:

A. Show on the Gantt Chart the sequence and interdependence of work activities/events required for complete performance of all items of work. In preparing the Gantt Chart, the Contractor shall:

1. Show the following on each work activity/event:

a. Concise description of the work represented by the activity/event.

b. Duration (in work days.)

2. Show activities/events as:

a. Contractor's time required for submittal of shop drawings, templates, fabrication, delivery and similar pre-construction work.

b. Contracting Officer Representative's and Architect-Engineer's review and approval of shop drawings, equipment schedules, samples, template, or similar items.

c. Interruption of VA Cemetery utilities, delivery of Government furnished equipment, project phasing and any other specification requirements.

d. Test, balance and adjust various systems and pieces of equipment.

e. VA inspection and acceptance activity/event with a minimum duration of five (5) work days at the end of each phase and

01 32 17-4 immediately preceding any VA move activity/event required by the contract phasing for that phase.

3. Break up the work into activities/events of durations no longer than thirty (30) work days each, except as to non-construction activities/events (i.e., procurement of materials, delivery of equipment, concrete and asphalt curing) and any other activities/events for which the Contracting Officer may approve the showing of a longer duration. [The duration for VA approval of any required submittal, shop drawing, or other submittals shall not be less than ten (10) workdays.] The construction time as determined by the Gantt Chart schedule from start to finish for any sub-phase, phase or the entire project shall not exceed the total contract duration. Describe work activities/events clearly, so the work is readily identifiable for assessment of completion.

Activities/events labeled "start," "continue," or "completion," are not specific and will not be allowed. Lead and lag time activities will not be acceptable.

1.7 PAYMENT TO THE CONTRACTOR:

A. Monthly, the contractor shall submit the Gantt Chart updated for remaining activity durations and a Schedule of Costs updated for costs.

AIA application and certification for payment documents G702 and G703 will be used. The payment request should reflect and be in accordance with the provisions of the following Article, PAYMENT AND PROGRESS

REPORTING, as the basis upon which progress payments will be made pursuant to Article, PAYMENT UNDER FIXED-PRICE CONSTRUCTION CONTRACTS of Section GENERAL CONDITIONS. The Contractor is entitled to a monthly progress payment upon approval of estimates as determined from the currently approved updated Schedule of Costs unless, in special situations, the Contracting Officer permits an exception to this requirement. Monthly payment requests shall include: two (2) copies of the updated Microsoft Project Gantt Chart, a listing of all project schedule changes, and associated data, made at the update. These must be submitted with and substantively support the contractor’s monthly application and certificate for payment request documents.

B. When the Contractor fails or refuses to furnish to the Contracting

Officer the information and the associated updated Gantt Chart data, which, in the sole judgment of the Contracting Officer, are necessary

01 32 17-5 for validating the monthly progress payment, the Contractor shall not be deemed to have provided supporting schedule data upon which progress payment may be reasonably determined.

1.8 PAYMENT AND PROGRESS REPORTING:

A. Monthly job site progress meetings shall be held on dates mutually agreed to by the Contracting Officer (or Contracting Officer's

Representative) and the Contractor. Presence of subcontractors during the progress meeting is optional unless required by the Contracting

Officer (or Contracting Officer's Representative). Job progress will be reviewed to verify:

1. Actual start and/or finish dates for updated/completed activities/events.

2. Remaining duration, required to complete each activity/event started, or scheduled to start, but not completed.

3. Time and cost data for change orders, and supplemental agreements that are to be incorporated into the Gantt Chart.

4. Percentage for completed and partially completed activities/events.

5. Logic and duration revisions required by this section of the specifications.

6. Activity/event duration and percent complete shall be updated independently.

B. The Contractor shall submit a narrative report as a part of his monthly review and update, in a form agreed upon by the Contracting Officer.

The narrative report shall include a description of problem areas;

current and anticipated delaying factors and their estimated impact on performance of other activities/events and completion dates; and an explanation of corrective action taken or proposed. This report is in addition to the daily reports pursuant to the provisions of Article, DAILY REPORT OF WORKERS AND MATERIALS in the GENERAL CONDITIONS.

C. As part of the monthly jobsite progress meeting, the General

Contractor, specifically requested subcontractors and the Contracting

Officers Representative shall meet to discuss the monthly updated schedule. The main emphasis shall be to address work activities to avoid slippage of project schedule and to identify any necessary actions required to maintain project schedule during the reporting period.

01 32 17-6

1.9 RESPONSIBILITY FOR COMPLETION:

A. Whenever it becomes apparent from the monthly progress review meeting or the monthly computer-produced Gantt Chart schedule that phasing or contract completion dates will not be met, the Contractor shall execute some or all of the following remedial actions:

1. Increase construction manpower in such quantities and crafts as necessary to eliminate the backlog of work.

2. Increase the number of working hours per shift, shifts per working day, working days per week, the amount of construction equipment, or any combination of the foregoing to eliminate the backlog of work.

3. Reschedule the work in conformance with the specification requirements.

B. Prior to proceeding with any of the above actions, the Contractor shall notify and obtain approval from the Contracting Officer for the proposed schedule changes. If such actions are approved, the revisions shall be incorporated by the Contractor into the Gantt Chart before the next update, at no additional cost to the Government.

1.10 CHANGES TO GANTT CHART SCHEDULE:

A. Within ten (10) calendar days after VA acceptance and approval of any updated computer-produced schedule, the Contractor shall submit a revised Gantt Chart, the associated digital files, and a list of any activity/event changes including predecessors and successors for any of the following reasons:

1. Delay in completion of any activity/event or group of activities/events, which indicate an extension of the project completion by twenty (20) working days or 10 percent of the remaining project duration, whichever is less. Such delays which may be involved with contract changes, strikes, unusual weather, and other delays will not relieve the Contractor from the requirements specified unless the conditions are shown on the Gantt Chart as the direct cause for delaying the project beyond the acceptable limits.

2. Delays in submittals, or deliveries, or work stoppage are encountered which make rescheduling of the work necessary.

3. The schedule does not represent the actual prosecution and progress of the project.

01 32 17-7

4. When there is, or has been, a substantial revision to the activity/event costs of the network diagram regardless of the cause for these revisions.

B. Revisions made under this paragraph, which affect the previously approved computer-produced schedules for Government furnished equipment, contract phase(s) and sub phase(s), utilities furnished by the Government to the Contractor, or any other previously contracted item, must be furnished in writing to the Contracting Officer for approval.

C. Contracting Officer's approval for the revised Gantt Chart and all relevant data is contingent upon compliance with all other paragraphs of this section and any other previous agreements by the Contracting

Officer or the Contracting Officer’s Representative.

D. The cost of revisions to the Gantt Chart resulting from contract changes will be included in the cost of the change.

E. The cost of revisions to the Gantt Chart not resulting from contract changes is the responsibility of the Contractor.

1.11 ADJUSTMENT OF CONTRACT COMPLETION:

A. The contract completion time will be adjusted only for causes specified in this contract. Request for an extension of the contract completion date by the Contractor shall be supported with a justification, Gantt

Chart data and supporting evidence as the Contracting Officer may deem necessary for determination as to whether or not the Contractor is entitled to an extension of time under the provisions of the contract.

Submission of proof based on revised activity/event logic, durations

(in work days) and costs is obligatory to any approvals.

B. The Contracting Officer's determination as to the total number of days of contract extension will be based upon the current computer-produced

Gantt Chart schedule for the time period when the change took place and all other relevant information. The Contracting Officer will, within thirty (30) calendar days after receipt of such justification and supporting evidence, advise the Contractor in writing of his decision on the matter.

C. The Contractor shall submit each request for a change in the contract completion date to the Contracting Officer in accordance with the provisions specified under Article, CHANGES, in the Section, GENERAL

CONDITIONS. The Contractor shall include, as a part of each change

01 32 17-8 order proposal, a sketch showing all revisions, duration (in work days) changes, and cost changes, for work in question and its relationship to other activities on the approved network diagram.

D. All delays due to non-work activities/events such as RFI’s, WEATHER, STRIKES, and similar non-work activities/events shall be analyzed on a month-by-month basis.

SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES

01 33 23 - 1

SECTION 01 33 23

SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES

1-1. Refer to Articles titled SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION

(FAR 52.236-21) and, SPECIAL NOTES (VAAR 852.236-91), in GENERAL

CONDITIONS.

1-2. For the purposes of this contract, samples, test reports, certificates, and manufacturers' literature and data shall also be subject to the previously referenced requirements. The following text refers to all items collectively as SUBMITTALS.

1-3. Submit for approval, all of the items specifically mentioned under the separate sections of the specification, with information sufficient to evidence full compliance with contract requirements. Materials, fabricated articles and the like to be installed in permanent work shall equal those of approved submittals. After an item has been approved, no change in brand or make will be permitted unless:

A. Satisfactory written evidence is presented to, and approved by

Contracting Officer, that manufacturer cannot make scheduled delivery of approved item or;

B. Item delivered has been rejected and substitution of a suitable item is an urgent necessity or;

C. Other conditions become apparent which indicates approval of such substitute item to be in best interest of the Government.

1-4. Forward submittals in sufficient time to permit proper consideration and approval action by Government.