Amendment 0003.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to provide responses to Pre-Proposal Inquiries, provide the site visit log, and extend the proposal due date to 19 January 2021.

See SF30 Block 14 Continuation Page.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 18-Dec-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X N4008521R1215

X 9B. DATED (SEE ITEM 11)

02-Dec-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

18-Dec-2020

CODE

NAVFACSYSCOM MID-ATLANTIC

ACQUISITION CORE

9324 VIRGINIA AVENUE

NORFOLK VA 23511-3095

N40085 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N4008521R1215

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

AMENDMENT 0003

The purpose of this amendment is to provide responses to Pre-Proposal Inquiries, provide the site visit log, and extend the proposal due date to 19 January 2021.

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 05-Jan-2021 02:00 PM to 19-Jan-

2021 02:00 PM.

SECTION 01 00 00 - GENERAL REQUIREMENTS

The following have been modified:

GENERAL REQUIREMENTS SEED PROJ

GENERAL REQUIREMENTS

NAVFAC Solicitation No.: N4008521R1215 NAVFAC Specification Work Order No.: 05-17-0075 NAVFAC Drawings Nos.: 60024409-60024442

Title: Interior/Exterior Repairs, Bldg. AS124

Location of the Work: Marine Corps Air Station New River, NC

Description of Work: This project, Interior/Exterior Repairs, Bldg. AS124, will include new finishes, roof and wall panels, roofing, plumbing, HVAC, electrical, doors, windows, masonry work, painting, and incidental related work.

*See drawings and specifications for full description.

Estimated Budget Amount or Price Range: In accordance with DFARS 236.204 Disclosure of the Magnitude of Construction Projects, the estimated price range for this project is between $1,000,000 and $5,000,000.

Time for Completion: In accordance with FAR 52.211-10 Commencement, Prosecution, and Completion of Work, the Government desires completion of construction within 465 calendar days after award (includes 15 calendar days for submission and approval of bonds and insurance).

Wage Determination: Department of Labor (DoL) General Decision Number NC20200038 08/14/2020 NC38 Mod 01 applies to this work. Should this wage determination be modified by DoL prior to award, the most current wage determination will be incorporated at the time of award.

Liquidated Damages: In accordance with FAR 52.211-12 Liquidated Damages – Construction, liquidated damages, at the time of award, will be based upon the liquidated damages for the base price, plus any option or combination of options exercised. If an option(s) is exercised within the timeframe allowed after award, the liquidated damages will be increased based upon the liquidated damages for that option.

Base plus all options: $155/Calendar Day

Utilities: In accordance with FAC 5252.236-9305 Availability of Utilities, when available, the Government will provide reasonable amounts of electric, water and compressed air for the work to be performed under this contract at no cost to the contractor.

Record Shop Drawings: In accordance with FAR 52.236.21 Specifications and Drawings for Construction and FAC 5252.236-9310 Record Drawings, record shop drawings are required. Reproducible copies of these record drawings are also required.

Bond Requirements: In accordance with FAC 5252.228-9302 Bid Guarantee, each offeror shall submit with its offer a guarantee bond (Standard Form 24) in a penal sum equal to at least 20 percent of the largest amount for which award can be made under the offer submitted, but in no case to exceed $3,000,000. In accordance with FAC 5252.228-9305 Notice of Bonding Requirements, Performance and Payment Bonds are required from the awardee ten (10) calendar days after date of award.

Proposal Acceptance Period: Proposal acceptance period shall be 120 days from receipt of offers.

Pursuant to FAR 52.232-18, Availability of Funds, the Government's obligation under this solicitation, or any task order or contract that might result from the solicitation is entirely subject to, and contingent upon, the availability of appropriated funds. Should the Government be unable to award the seed project, the Government guarantees an award in the amount of $5,000.00 to each successful offeror upon award of the Multiple Award Construction Contracts. This minimum guarantee is over the full term of the contract, including option years. No legal liability on the part of the Government shall arise until funds are made available to the Contracting Officer and a task order or contract is awarded by the Contracting Officer. Any offeror proposing on this solicitation does so at its own cost and with the full knowledge that a task order for the seed project, might not result from this solicitation.

Site Visit:

A site visit is scheduled for Wednesday, December 16, 2020. Participants shall meet at the MCAS New River Visitors Center no later than 9:00AM Local Time. All participants shall submit a list of attendees to Lauren Loconto via email at lauren.loconto@navy.mil no later than close of business on Friday, December 11, 2020.

Participants without current DBIDS access to MCAS New River will require sponsorship. Participants shall submit the current version of the SECNAV form 5512/1 (version expiring January 31, 2021, one per attendee), a scanned copy of the photo identification(s) that will be presented at the Visitors Center, and scanned copies of the vehicle registration(s) and insurance(s). Participants requiring sponsorship but planning to use rental vehicles shall submit participant names exactly as they appear on the identification to be presented at the Visitors Center and will need to present the photo identification(s), SECNAV form 5512/1, and rental agreement at the Visitors Center on the date of the site visit. The sponsor information for the SECNAV form 5512/1 is Lauren F. Loconto, Supervisory Contract Specialist. Participants should be aware that wait times at the Visitor’s Center vary, but can be as long as one hour.

The site visit will begin promptly at 9:00AM without delay. Information regarding the Visitors Center, can be found at https://www.newriver.marines.mil/Welcome-Aboard/Pass-Registration/.

Pre-Proposal Inquiries (PPIs): Submit in accordance with Section 00 21 13 – Bidding Schedule Instructions to Bidders of the SF1442, Instruction to Offerors, 5.3 Pre-Proposal Inquiries (PPIs).

Proposal Due Date: 19 January 2021 no later than 2:00 PM Eastern. LATE PROPOSALS WILL NOT BE

CONSIDERED.

Please submit in accordance with Section 00 21 13 – Bidding Schedule/Instructions to Bidders of the SF1442, Instructions to Offerors, 5.2 PROPOSAL SUBMISSION INSTRUCTIONS.

Proposal Delivery Information: Proposals may arrive via U. S. mail or express mail carrier to the following address:

ATTN: John Bishop Naval Facilities Engineering Command, Mid-Atlantic

ACQ21

9324 Virginia Avenue Building Z-140, Room 225 Norfolk, Virginia 23511

Evaluation Factors for Award: Refer to Section 00 21 13 - Bidding Schedule/Instructions to Bidders of the SF1442, Instruction to Offerors, 4. Evaluation Factors for Award.

ATTACHMENTS:

(D) AS124 Dwgs_Part1of2

(E) AS124 Dwgs_Part2of2

(F) AS124 Specs

All attachments will be provided under the “Attachments” link on Beta SAM.

(End of Summary of Changes)