Amendment 0004.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

N40080-23-R-0010, DESIGN-BUILD STEAM BOILER REPLACEMENT, NAVAL SUPPORT FACILITY, INDIAN HEAD MD

SEE SF30 BLOCK 14 CONTINUATION PAGE

1. CONTRACT ID CODE PAGE OF PAGES

J 1 14

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 02-Jun-2023

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N4008023R0010

X 9B. DATED (SEE ITEM 11)

28-Feb-2023

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

02-Jun-2023

CODE

NAVAL FACILITIES ENGINEERING SYS COMMAND

1314 HARWOOD STREET SE

WASHINGTON DC 20374

N40080 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N4008023R0010

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0004

The purpose of this amendment is to:

1. Provide Responses to Pre-Proposal Inquiries (PPIs)

2. Provide New Wage Determination - General Decision Number: MD20230041 05/05/2023

All other terms and conditions remain unchanged.

Question No.

Date Received

REFERENCE QUESTION GOVERNMENT RESPONSE Posted on Amend No.

Page Section Para.

1 Phase II

RFP

Please provide drawings of the existing Buildings 814 and 815 and the hazardous material inspection report for each.

Structures 814 and 815 are not buildings. They are above ground fuel oil storage tanks and their associated structure, as stated in the RFP Part 3 Chapter 3 and shown in the photos in RFP Part 6.

Hazardous material inspection reports for these structures are not available.

Fuel tanks 814 & 815 had a layer(s) of lead paint since it was constructed before 1950. The secondary containment (lined basin) was repaired (concrete side and a new rubber liner) around 2005‐2006. The tanks held originally No.6 Oil Fuel, and later on No.2 Oil Fuel.

2 Phase II

RFP

It seems that there should be drawings that go with this RFP. We are to demolish an existing building which we would also need the hazardous material inspection report for the building. Please provide these documents for Building 712.

Drawings for Bldg 712 are located on page 1183 of the Final RFP. Hazardous material inspection report for Bldg 712 is not available.

Bldg 712 just like fuel tanks 814 & 815 has multiples layers of lead paint on the metal structure.

Bldg 712 had an large asbestos abatement project 23 years ago. They removed asbestos from boilers and distribution lines, Leaving only the corrugated siding and the mastic of the window panels. The “asbestos free” stickers are still attached on the steam lines.

3 RFP The liquidated damages is listed as “TBD” in the Phase I RFP. Please provide the liquidated damage per day information.

Liquidated Damages: $2594.79/per day 0004

"General Decision Number: MD20230041 05/05/2023

Superseded General Decision Number: MD20220041

State: Maryland

Construction Type: Building

County: Charles County in Maryland.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60).

|If the contract is entered |. Executive Order 14026 | |into on or after January 30, | generally applies to the | |2022, or the contract is | contract. | |renewed or extended (e.g., an |. The contractor must pay | |option is exercised) on or | all covered workers at | |after January 30, 2022: | least $16.20 per hour (or | | | the applicable wage rate | | | listed on this wage | | | determination, if it is | | | higher) for all hours | | | spent performing on the | | | contract in 2023. | |If the contract was awarded on|. Executive Order 13658 | |or between January 1, 2015 and| generally applies to the | |January 29, 2022, and the | contract. | |contract is not renewed or |. The contractor must pay all| |extended on or after January | covered workers at least | |30, 2022: | $12.15 per hour (or the | | | applicable wage rate listed| | | on this wage determination,| | | if it is higher) for all | | | hours spent performing on | | | that contract in 2023. |

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at http://www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/06/2023 1 01/13/2023 2 03/24/2023 3 04/07/2023 4 05/05/2023

ASBE0024-007 04/01/2021

Rates Fringes

ASBESTOS WORKER/HEAT & FROST

INSULATOR........................$ 39.27 18.67+a

Includes the application of all insulating materials, protective coverings, coatings and finishes to all types of mechanical systems

a. PAID HOLIDAYS: New Year's Day, Martin Luther King Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day,the day after Thanksgiving and Christmas Day provided the employee works the regular work day before and after the paid holiday.

ASBE0024-010 04/01/2021

Rates Fringes

ASBESTOS WORKER: HAZARDOUS

MATERIAL HANDLER (Removal of hazardous material from ceilings, floors, mechanical systems, and walls)..............$ 24.46 8.69+a

a. PAID HOLIDAYS: New Year's Day, Martin Luther King Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day,the day after Thanksgiving and Christmas Day provided the employee works the regular work day before and after the paid holiday.

* BRMD0001-006 04/30/2023

Rates Fringes

TILE SETTER......................$ 33.41 12.67

* BRMD0001-009 04/30/2023

Rates Fringes

TILE FINISHER....................$ 27.68 11.63

* BRMD0001-011 04/30/2023

Rates Fringes

BRICKLAYER (Excluding Pointing, Caulking and Cleaning)........................$ 36.50 13.47

* BRMD0001-012 04/30/2023

Rates Fringes

MASON - STONE....................$ 43.16 20.28

* BRMD0001-013 04/30/2023

Rates Fringes

TERRAZZO WORKER/SETTER...........$ 33.41 12.67

CARP0197-001 05/01/2022

Rates Fringes

CARPENTER (Including Acoustical Ceiling Installation, Drywall Hanging, Metal Stud Installation and Form Work)......$ 31.40 13.86

CARP0219-001 05/01/2022

Rates Fringes

MILLWRIGHT.......................$ 36.00 14.07

ELEC0026-021 09/07/2020

Rates Fringes

ELECTRICIAN (Communication and Sound Equipment).............$ 29.05 11.39

ELEC0026-022 12/06/2021

Rates Fringes

ELECTRICIAN (Including low voltage wiring for and installation of alarms, HVAC controls)........................$ 50.00 20.49+a a.PAID HOLIDAYS: New Year's Day, Inauguration Day, Martin

Luther King Jr.'s Birthday, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day, the day after Thanksgiving Day and Christmas Day.

ELEV0010-001 01/01/2023

Rates Fringes

ELEVATOR MECHANIC................$ 52.49 37.335+a+b

a. PAID HOLIDAYS: New Year's Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day, Christmas Day and the Friday after Thanksgiving.

b. VACATIONS: Employer contributes 8% of basic hourly rate for 5 years or more of service; 6% of basic hourly rate for 6 months to 5 years of service as vacation pay credit.

ENGI0077-017 05/01/2022

Rates Fringes

POWER EQUIPMENT OPERATOR:

Backhoe.....................$ 33.98 11.07+a Bulldozer...................$ 33.98 11.07+a

a. PAID HOLIDAYS: New Year's Day, Inaugural Day, Decoration Day, Independence Day, Labor Day, Martin Luther King's Birthday, Veterans' Day, Thanksgiving Day, Friday after Thanksgiving and Christmas Day.

IRON0005-005 06/01/2022

Rates Fringes

IRONWORKER, STRUCTURAL AND

ORNAMENTAL.......................$ 34.85 24.95

IRON0005-014 05/01/2022

Rates Fringes

IRONWORKER, REINFORCING..........$ 29.85 23.18

LABO0011-013 06/15/2020

Rates Fringes

LABORER: Mason Tender - Cement/Concrete..................$ 25.88 8.63 LABORER: Pipelayer..............$ 25.88 8.63

PAIN0051-014 06/01/2022

GLAZIER

Glazing Contracts $2 million and under...........$ 29.92 13.35 Glazing Contracts over $2 million.....................$ 34.16 13.35

PAIN0051-019 06/01/2022

Rates Fringes

PAINTER

Brush, Roller, Spray and Drywall Finisher/Taper......$ 26.61 11.41 Industrial..................$ 33.05 13.22

PLAS0891-005 07/01/2021

Rates Fringes

PLASTERER (Including Fireproofing)....................$ 30.53 7.93

PLAS0891-006 02/01/2020

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 28.82 11.68

PLUM0005-010 08/01/2022

Rates Fringes

PLUMBER..........................$ 48.00 20.75+a

a. PAID HOLIDAYS: Labor Day, Veterans' Day, Thanksgiving Day and the day after Thanksgiving, Christmas Day, New Year's Day, Martin Luther King's Birthday, Memorial Day and the Fourth of July.

PLUM0602-013 08/01/2022

Rates Fringes

PIPEFITTER (HVAC Pipe and System Installation Only)........$ 47.98 23.12+a

a. PAID HOLIDAYS: New Year's Day, Martin Luther King's Birthday, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day and the day after Thanksgiving and Christmas Day.

ROOF0030-016 07/01/2022

ROOFER...........................$ 32.26 14.71

SFMD0669-001 04/01/2023

Rates Fringes

SPRINKLER FITTER (Fire Sprinklers)......................$ 40.46 25.22

SHEE0100-015 11/01/2021

Rates Fringes

SHEET METAL WORKER (Including HVAC Duct Installation)..........$ 44.37 21.33+a

a. PAID HOLIDAYS: New Year's Day, Martin Luther King's Birthday, Memorial Day, Independence Day, Labor Day, Veterans Day, Thanksgiving Day and Christmas Day

* SUMD2010-089 08/20/2010

Rates Fringes

LABORERS

Common or General...........$ 11.38 ** Grade Checker...............$ 16.00 ** 2.90 Landscape...................$ 9.23 ** Mason Tender - Brick........$ 13.00 ** Mason Tender - Stone........$ 14.03 ** Mason Tender for Pointing, Caulking and Cleaning.......$ 13.25 ** Mortar Mixer................$ 16.61 9.09

PIPEFITTER (Excluding HVAC Pipe and System Installation)....$ 28.96 11.35

POINTER, CAULKER, CLEANER,

Includes pointing, caulking, cleaning of existing masonry, brick, stone and cement structures (restoration work); excludes pointing, caulking, cleaning of new or replacement masonry, brick, stone or cement...........................$ 19.17

POWER EQUIPMENT OPERATOR:

Asphalt Roller..............$ 21.35 5.38 Bobcat/Skid Loader..........$ 18.05 8.78

Boom........................$ 21.44 8.29 Crane.......................$ 20.95 6.18 Excavator...................$ 20.00 Forklift....................$ 16.00 ** 5.12 Gradall.....................$ 20.50 8.42 Grader/Blade................$ 14.50 ** 5.18 Loader......................$ 22.75 4.91 Paver.......................$ 17.47 6.36 Roller excluding Asphalt....$ 17.60 3.88

TRUCK DRIVER

Dump Truck..................$ 15.90 ** 1.12 Tractor Haul Truck..........$ 17.87 9.98

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

** Workers in this classification may be entitled to a higher minimum wage under Executive Order 14026 ($16.20) or 13658 ($12.15). Please see the Note at the top of the wage determination for more information.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour National Office because National Office has responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative

Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISIO"

SECTION 00700 - CONTRACT CLAUSES

The following have been modified:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,594.79 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)