N00024-20-R-4456_A0007.pdf

SOUTHWEST REGIONAL MAINTENANCE CENTER

CODE 400 3755 BRINSER STREET, STE 1

SAN DIEGO CA 92136-5205

N0002420FR62044

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this Amendment is to: (1) Provide responses to Bidder Question Nos. 96 - 107; and (2) Update Section B, Note F.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 23-Nov-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N0002421R4456

X 9B. DATED (SEE ITEM 11)

20-Oct-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

23-Nov-2020

CODE

NAVAL SEA SYSTEMS COMMAND (HQ)

1333 ISAAC HULL AVE SE

WASHINGTON NAVY YARD DC 20376-2030

N00024 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE N55236

FACILITY CODECODE

EMAIL:TEL:

N0002421R4456

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION B - SUPPLIES OR SERVICES AND PRICES

The following have been modified:

NOTE F: AVAILABILITY SCHEDULE PERFORMANCE

1. The Contractor shall schedule the performance of all Base and Option items in the work package, so as to permit a contract scope increase up to the following:

For the USS RUSSELL FY21 SRA:

Total contract wide number of labor hours and material dollars to complete growth work as described in

NOTE A: LEVEL OF EFFORT TO COMPLETION –SHIP REPAIR, paragraph 1(a).

Total contract wide number of Small Value Dollar Growth occurrences as described in NOTE E:

SPECIAL AGREEMENT FOR GROWTH WITH A PRICE OF $25,000 OR LESS, paragraph 2(a).

For the USS SOMERSET FY21 SRA:

Total contract wide number of labor hours and material dollars to complete growth work as described in

NOTE A: LEVEL OF EFFORT TO COMPLETION –SHIP REPAIR, paragraph 1(b).

Total contract wide number of Small Value Dollar Growth occurrences as described in NOTE E:

SPECIAL AGREEMENT FOR GROWTH WITH A PRICE OF $25,000 OR LESS, paragraph 2(b).

2. The Contractor agrees that the growth work identified in Section B, Note F, Paragraph 1, above, if tasked, shall be performed, purchased and installed concurrently with the work items, without impacting, accelerating, or causing delay or disruption to the work required by the base and option work items, to any other Government contract, or to any other work in progress for the Government.

3. The growth work described above, if required, shall be tasked during the contract period of performance, as may be modified, on the following schedule phasing:

No more than 50% of the hours or material following the 50% schedule point of the availability (as measured in days between the “Availability Start” and “Contract Complete” milestones in Attachment J-3 / J-13), adjusted for delay to delivery date.

No more than 25% of the hours or material following the 75% schedule point of the availability (as measured in days between the “Availability Start” and “Contract Complete” milestones in Attachment J-3 / J-13), adjusted for delay to delivery date.

(End of Summary of Changes)