CDRLS Brakes.pdf

DD FORM 1423-1, FEB 2001 PREVIOUS EDITION MAY BE USED.

17. PRICE GROUP

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

ADMN

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A001

2. TITLE OF DATA ITEM

CONFERENCE AGENDA

3. SUBTITLE

Briefings/Minutes

4. AUTHORITY (Data Acquisition Document No.)

DI-ADMN-81249A

5. CONTRACT REFERENCE

SOW PARA. 3.5.3, 3.5.4

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

NO

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

ASREQ (See Block 16)

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

N/A

D 11. AS OF DATE

412010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLOCK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The meeting minutes shall include new issues or concerns, potential risk mitigation strategies for each problem or concern, what was covered in the meeting or conference, and new action items for both Contractor and Government personnel. The Government will let the Contractor know to what POC to send the meeting minutes and agenda.

BLOCKS 10, 12, and 13: Final minutes/briefing packages NLT 10 days after each meeting.The Conference agenda shall be delivered to the Government 10 days before each formal meeting or conference, with the exception of the first kick-off meeting.

BLOCK 4: Contractor format is acceptable.

BLOCK 9: Use Distribution Statement D, Attachment (2).

BLOCK 14: The deliverable shall be in digital format using Microsoft Office.

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

Mary Ann Foran

H. DATE

10/6/2009

I. APPROVED BY J. DATE

2/18/2010

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

GDRQ

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A002

2. TITLE OF DATA ITEM

DESIGN REVIEW #1 REPORT

3. SUBTITLE

Design Requirements

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE

SOW PARA. 3.2.2.1

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

ONCE

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLOCK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall attend a Design Review #1 (DR#1).

Block 15: 2

BLOCK 4: The DR#1 shall serve as a review of the Contractor's preliminary technical design concepts as well as for the Contractor and the Government to coordinate on program issues and contract requirements. The document shall be provided in Microsoft Word 2003 and in Contractor format.

The DR#1 shall have clear entry and exit criteria.

BLOCK 12: The Contractor shall deliver the minutes, action items, and the report from the DR#1 within 15 days after completion of the

DR#1.

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

GDRQ

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A003

2. TITLE OF DATA ITEM

PERFORMANCE SPECIFICATION

DOCUMENTS

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SDMP-81465A

5. CONTRACT REFERENCE

SOW PARA 3.2.2.1, 3.13.1

6. REQUIRING OFFICE

E-6B FST Jacksonville

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

2TIMES/R (See Block 16)

12. DATE OF FIRST

SUBMISSION

SEE BLK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLOCK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

A system-level description shall be delivered.

BLOCKS 10, 12 and 13: The system-level description shall be completed 10 days prior to Design Review #1. The final system-level description shall be completed 10 days prior to Final Design Review.

Revisions shall be delivered as required.

Block 15: 2

BLOCK 4: The system-level description shall be completed in a Microsoft Office 2003-compatible or older and contractor format.

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

SESS

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A004

2. TITLE OF DATA ITEM

DID PARTS LIST

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SESS-81359B

5. CONTRACT REFERENCE

SOW PARA 3.2.2.1.1-2

6. REQUIRING OFFICE

E-6B FST Jacksonville

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

2TIMES/R (See Block 16)

12. DATE OF FIRST

SUBMISSION

SEE BLK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLOCK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

BLOCK 4: The Bill Of Materials (BOM) shall include the part number (either manufacturer or contractor part numbers), part description, required quantities, and replacement cost in an indented-grouping format.

The Contractor shall use the indented-grouping format to the lowest level possible to develop the Preliminary BOM, down to the part number level.

The final BOM shall include any and all changes to the preliminary BOM after installation of the first retrofit and component kits on the test aircraft.

The Contractor shall deliver a Bill of Materials (BOM) in a Microsoft Word version 2003 or Microsoft Excel version 2003 or older format.

BLOCKs 10, 12 and 13: The preliminary BOM shall be delivered 10 days prior to Design Review #1.The final BOM shall be completed no later than 20 days after retrofit installation on the test aircraft and further updates as required.

BLOCK 15: 2

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

ILSS

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A005

2. TITLE OF DATA ITEM

FAILURE MODES, EFFECTS, AND

CRITICALITY ANALYSIS (FMECA)

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-ILSS-81495

5. CONTRACT REFERENCE

SOW PARA 3.2.2.1, 3.4,

3.8.3.1.5

6. REQUIRING OFFICE

E-6B FST Jacksonville

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

2TIMES

12. DATE OF FIRST

SUBMISSION

SEE BLK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall deliver a preliminary, updated (as needed), and final Failure Modes, Effects, and Criticality Analysis (FMECA).

BLOCK 15: 2

BLOCK 4: The FMECA shall be delivered in electronic format and shall be compatible with the latest Navy Marine Corps Intranet (NMCI)-compatible version of Integrated Reliability-Centered Maintenance Software (IRCMS)-compatible format.

If there are changes to the preliminary FMECA or there are new items to be added, then an updated FMECA shall be delivered. The second (updated as needed) FMECA shall include any and all items that were not included in the preliminary FMECA.

BLOCK 12: The preliminary FMECA shall be completed 15 days before Design Review #1.

BLOCK 13: The Final (updated) FMECA shall be delivered to the Government no later than 15 days before Final Design Review.

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

SESS

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A006

2. TITLE OF DATA ITEM

PROVISIONING PARTS LIST

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SESS-81715 (removed/replaced items only)

5. CONTRACT REFERENCE

SOW PARA 3.2.2.1

6. REQUIRING OFFICE

E-6B FST Jacksonville

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

3TIME/R

12. DATE OF FIRST

SUBMISSION

SEE BLK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

ASREQ

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

BLOCK 4: The Contractor shall develop and deliver one (1) list of all parts and components needing replacement and another list of all parts needing modification (and will still remain on the aircraft).

BLOCK 12: The preliminary list shall be submitted 10 days prior to Design Review #1.The updated list shall be submitted 10 days prior to Final Design Review . The final list(s) of modified and/or replaced parts shall be completed 10 days after final installation of retrofit and component parts on the test aircraft.

BLOCK 15: 2

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

SDMP

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A007

2. TITLE OF DATA ITEM

PERFORMANCE SPECIFICATION

DOCUMENTS

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SDMP-81465A

5. CONTRACT REFERENCE

SOW PARA 3.2.2.1, 3.2.3

6. REQUIRING OFFICE

E-6B FST Jacksonville

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

ONCE

12. DATE OF FIRST

SUBMISSION

SEE BLK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

N/A

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall deliver an estimate of the E-6B aircraft brake stopping performance based on analysis and simulation results.

BLOCK 15: 2

BLOCK 4: The landing distance estimations shall be delivered to the Government in an electronic format compatible with Microsoft Word 2003 and older and in contractor format.

BLOCK 12: This landing distance estimation shall be completed 10 days before Design Review #1 (DR#1).

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

GDRQ

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A008

2. TITLE OF DATA ITEM

PRODUCT BASE LINE INDEX

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-CMAN-81218

5. CONTRACT REFERENCE

SOW PARA 3.2.2.1, 3.13.4

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

ONCE

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

N/A

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

BLOCK 4: The report shall be in Microsoft Word version 2003 or older and in Contractor format.

BLOCK 12: The Contractor shall deliver the meeting minutes, action items, and the report to the Government in Microsoft Word-compatible format within 15 days after completion of Final Design Review.

BLOCK 15: 2

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

10/6/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

MNTY

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A009

2. TITLE OF DATA ITEM

PERFORMANCE SPECIFICATION

DOCUMENTS

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SDMP-81465A

5. CONTRACT REFERENCE

SOW PARA. 3.8.3.3

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

1TIME

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

N/A

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall deliver to the Government a Maintainability Demonstration Report (MDR).

BLOCK 15: 2.

BLOCK 4: The Maintainability Demonstration Report shall be delivered to the Government in Microsoft Word version 2003 or older format.

BLOCK 12: The Maintainability Demonstration shall be performed no later than 15 days after installation on the Test aircraft. The report must be submitted NLT 15 days after the Demonstration.

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

10/6/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

TDP

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A010

2. TITLE OF DATA ITEM

ENGINEERING DOCUMENTATION

PRODUCT DRAWINGS

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-DRPR-81681

5. CONTRACT REFERENCE

SOW PARA 3.2.2.1

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

See Block 16

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLOCK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall create and deliver to the Government preliminary and final Level 3 manufacturing and installation drawings of the brake assembly, including all associated drawings with the brake effort. Engineering data file representations of engineering drawings from 3-D Solid Modeling Software (Pro-E, Solid Works, etc.) shall be delivered in AutoCAD *DXF format. Each drawing shall list the part number, dimensions of the component, and component material. The engineering drawings shall reflect the end product and shall be sufficiently complete to produce and maintain quality training and maintenance publications without resorting to additional product design effort, or additional design data. Engineering drawings shall include performance ratings, dimensional data, input and output characteristics, diagrams, mechanical, hydraulic, and electrical connections (if applicable), physical characteristics, and interface control information.

BLOCKs 12 and 13: The preliminary brake drawings shall be delivered 10 days before Design Review #1 (DR#1). The final brake drawings shall be completed and submitted to the Government 30 days after completion of the installation of the brakes onto the flight test aircraft.

BLOCK 15: 2

BLOCK 10: The Contractor shall deliver any updates, as required, to the drawings and associated lists that happen as a result of any of the production aircraft installations.

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

SESS

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A011

2. TITLE OF DATA ITEM

WEIGHT AND BALANCE ANALYSIS

REPORT

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SESS-81002E

5. CONTRACT REFERENCE

SOW PARA. 3.2.2.1, 3.8.8.7

6. REQUIRING OFFICE

E-6B FST Jacksonville

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

3TIME/R

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLOCK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall deliver to the Government a preliminary and final (updated) detailed weight and balance reports.

BLOCK 15: 3

BLOCK 4: The format of the report shall be in both the standard format (DD-365 - series forms) and in the latest version of the Automated Weight and Balance System (AWBS) at the time of submittal. Change pages to the weight report and the Chart "A" should be submitted to the Government as required.

BLOCK 12: The preliminary weight and balance report shall be completed and submitted 10 days before the Design Review #1 (DR#1). The updated weight and balance report shall be delivered 10 days before Final Design Review.

BLOCK 13: The Chart "A" shall be completed and submitted 30 days after installation of the wheels, brakes, and tires on the test aircraft.

E-6B ISS IPT

Jacksonville

PMA-271-E6

LIBRARY

AIR 4.1.7

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

MGMT

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A012

2. TITLE OF DATA ITEM

INTEGRATED MASTER SCHEDULE

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-MGMT-81650

5. CONTRACT REFERENCE

SOW PARA 3.2.2.1, 3.5.5.1,

3.5.6

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

See Block 16

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

N/A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLOCK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall deliver a Risk Management Plan, IMP, and an IMS for the E-6 brake upgrade program.

The Contractor shall provide the IMP/IMS per DID DI-MGMT-81650 except or as modified by the following:

BLOCK 4: Modify paragraph 2.4.1.23 to read: "The Contractor shall submit Schedule Risk Assessments (SRA) and be prepared to actively participate in quarterly SRAs to identify and quantify milestone/event and task/activity level schedule risk. The contractor shall report optimistic, pessimistic, and most likely remaining durations for each Critical Path and Near Critical Path task/activity. The SRA will be performed on the Program Critical Path and the Critical Path and Near Critical Paths to selected critical milestones. The rationale used to establish the remaining durations should be documented.

a. Test Program Critical Path longest path through entire program

b. Test Critical Path to next major milestone(s)

c. Test Near Critical Paths to next major milestone(s)"

Modify paragraph 2.5 with "The first narrative submission is to provide the Basis and Assumptions (B&A) of the Integrated Master Schedule (IMS). The B&A will outline all major program milestones and/or Integrated Master Plan (IMP) events and document all associated programmatic schedule assumptions that were utilized in the development of the baseline plan. At a minimum, all monthly submissions will include a written schedule analysis to identify, document, and communicate changes of five (5) working days or greater to Program Critical Path and Near Critical Path task/activity actual start and/or actual finish date variances from submission to submission as well as IMP and/or major program milestone impacts or other major schedule risk areas. Work around and/or recovery schedules/plans, and associated impacts due to program changes shall also be provided. The schedule narrative shall address progress to date and discuss any significant schedule changes (i.e., added/deleted tasks, any significant logistics revisions, and any/all programmatic schedule assumption change etc.)."

BLOCK 9: Use Distribution Statement D, Attachment (2).

BLOCK 10: Reports are due monthly.

BLOCK 12: The first submission is due within 15 working days after the end of the month.

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

10/6/2009

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

MGMT

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A012

2. TITLE OF DATA ITEM

INTEGRATED MASTER SCHEDULE

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-MGMT-81650

5. CONTRACT REFERENCE

SOW PARA 3.2.2.1, 3.5.5.1,

3.5.6

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

See Block 16

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

N/A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLOCK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

BLOCK 13: Subsequent submittals are due within 15 working days after the close of the month.

BLOCK 14: Data shall be delivered in Microsoft Project 2003.

G. PREPARED BY

James Humbert

H. DATE

10/6/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

SDMP

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A013

2. TITLE OF DATA ITEM

PERFORMANCE SPECIFICATION

DOCUMENTS

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SDMP-81465A

5. CONTRACT REFERENCE

SOW PARA 3.2.2.2

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

ONCE

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

NA

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall deliver to the Government a qualification plan that demonstrates how the Contractor intends to comply with the Performance Specification.

BLOCK 15: 2

BLOCK 4: The brake qualification plan shall be in Microsoft Word 2003-compatible and contractor format.

BLOCK 12: The brake qualification plan shall be completed 10 days prior to Design Review #1 (DR#1).

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

SDMP

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A016

2. TITLE OF DATA ITEM

PERFORMANCE SPECIFICATION

DOCUMENTS

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SDMP-81465A

5. CONTRACT REFERENCE

SOW PARA. 3.10

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

ONCE

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

NA

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall deliver to the Government a Brake Temperature Monitoring System (BTMS) report.

BLOCK 15: 2

BLOCK 4: The BTMS report shall be in a Microsoft Word version 2003 and in Contractor format.

BLOCK 12: The BTMS proposal shall be delivered to the Government no later than 10 days before Design Review #1 (DR#1).

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

SAFT

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A019

2. TITLE OF DATA ITEM

SYSTEM SAFETY HAZARDOUS ANALYSIS

REPORT

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SAFT-80101B

5. CONTRACT REFERENCE

SOW PARA. 3.2.2.2

6. REQUIRING OFFICE

E-6B FST Jacksonville

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

ONCE

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

NA

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall deliver to the Government a System Safety Evaluation (SSE) that shows compliance with NAVAIRINST 4200.25D.

BLOCK 15: 2

BLOCK 4: The system safety evaluation report shall be in a Microsoft Word 2003-compatible and in Contractor format.

BLOCK 12: The brake system safety evaluation report shall be completed 10 days prior to the Final Design Review.

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

TDP

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A020

2. TITLE OF DATA ITEM

INSTALLATION SPECIFICATION

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-QCIC-80510

5. CONTRACT REFERENCE

SOW PARA. 3.11

6. REQUIRING OFFICE

E-6B FST Jacksonville

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

2TIMES/R

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

2/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLOCK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

BLOCK 4: The Contractor shall deliver to the Government a preliminary and final (updated, see below) list of detailed installation instructions of how to install the brakes, wheels, and radial tires on the aircraft, along with any other ancillary equipment needed to make the brakes, wheels, and radial tires safely work on the production aircraft.

BLOCK 12: The preliminary detailed installation instructions shall be delivered to the Government in electronic format no later than 10 days days before Final Design Review.

BLOCK 13: The final (updated) installation instructions shall be delivered in electronic format no later than 15 days after the istallation on the test aircraft.

BLOCK 15: 2

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

James Humbert

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

SESS

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A021

2. TITLE OF DATA ITEM

INTERNAL CONTRACTOR TECHNICAL

DATA REPORT

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SESS-81309A

5. CONTRACT REFERENCE

SOW PARA. 3.2.2.1

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

ONE/R

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

N/A

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

BLOCK 4: The Brake Comparison Performance Data (BCPD) shall be delivered to the Government in Microsoft Word 2003-compatible and Contractor format.

BLOCKs 12: Delivery no later than 10 days prior to Design Review #1.

BLOCK 15: 2

E-6B ISS IPT

Jacksonville

PMA-271-E6

LIBRARY

15. TOTAL

G. PREPARED BY

JAMES HUMBERT

H. DATE

10/6/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

OTHER

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A022

2. TITLE OF DATA ITEM

PERFORMANCE SPECIFICATION

DOCUMENTS

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-SDMP-81465A

5. CONTRACT REFERENCE

SOW PARA. 3.3

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

1TIME

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

N/A

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

BLOCK 4: The Contractor shall provide BTCD to the Government in Microsoft Word 2003 or older and in contractor format.

BLOCK 12: The report shall be submitted 10 days prior to Design Review #1 (DR#1).

BLOCK 15: 2

E-6B ISS IPT

Jacksonville

PMA-271-E6

LIBRARY

15. TOTAL

G. PREPARED BY

JAMES HUMBERT

H. DATE

9/18/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

CMAN

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A023

2. TITLE OF DATA ITEM

CONFIGURATION MANAGEMENT PLAN

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-CMAN-80858B

5. CONTRACT REFERENCE

SOW PARA. 3.8.8, 3.8.8.1,

3.8.8.2,

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

2TIMES/R

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

SEE BLOCK 16

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall develop and deliver to the Government a Configuration Management (CM) Plan.

BLOCK 15: 2

BLOCKs 12 and 13: The preliminary CM plan shall be submitted 10 days before Final Design Review. The final CM plan shall be submitted 30 days after final flight test.

BLOCK 4: The CM plan shall be submitted in Microsoft Word version 3 or older and contractor format.

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

JAMES HUMBERT

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

CMAN

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A024

2. TITLE OF DATA ITEM

CONFIGURATION AUDIT SUMMARY

REPORT

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-CMAN-81022C

5. CONTRACT REFERENCE

SOW PARA. 3.8.8.6.1

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

ONCE

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

NA

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

BLOCK 4: The Contractor shall deliver a Functional Configuration Audit (FCA) to the Government. The FCA is a formal examination of the "as-tested" physical and performance characteristics of a configuration item where the focus is on design and performance suitability.

BLOCK 12: The FCA shall be performed at the Contractor's facility no later than 30 days after Final Design Review.

The FCA minutes (if needed or requested by the Government) shall be delivered in Microsoft Word version 2003 or older in contractor format no later than 10 days after the completion of the FCA.

BLOCK 15: 2

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

JAMES HUMBERT

H. DATE

9/29/2009

18. ESTIMATED

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302 and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY

CMAN

D. SYSTEM/ITEM

E-6B Brakes

E. CONTRACT/PR NO.

N00019-09-R-0296

F. CONTRACTOR

1. DATA ITEM NO.

A025

2. TITLE OF DATA ITEM

CONFIGURATION AUDIT SUMMARY

REPORT

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-CMAN-81022C

5. CONTRACT REFERENCE

SOW PARA. 3.8.8.6.2

6. REQUIRING OFFICE

PMA-271

7. DD 250

REQ

LT

9. DIST STATEMENT

REQUIRED

10. FREQUENCY

ONCE

12. DATE OF FIRST

SUBMISSION

SEE BLOCK 16

8. APP CODE

A

D 11. AS OF DATE

4/1/2010

13. DATE OF SUBSEQUENT

SUBMISSION

NA

14. DISTRIBUTION

b. COPIES

a. ADDRESSEE Final

Draft Reg. Repro

16. REMARKS

The Contractor shall deliver a Physical Configuration Audit (PCA) to the Government.

BLOCK 15: 2.

BLOCK 4: The Contractor shall submit a report in Contractor format with Government acknowledgement that the PCA was a success and that the brakes meet the requirements of their technical documentation.

BLOCK 12: This report shall be due 10 days after successful completion of the PCA.

PMA-271-E6

LIBRARY

E-6B ISS IPT

Jacksonville

15. TOTAL

G. PREPARED BY

JAMES HUMBERT

H. DATE

10/6/2009

TOTAL PRICE

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No.