CONTINUATION_OF_SYNOPSIS-CLAUSES-PROVISIONS_-SPAR.docx

REQUEST FOR QUOTATION

SOLICITATION NO. HSCG85-15-Q-P45P58

UNPLANNED DRY DOCK REPAIRS –CGC SPAR (WLM 206)

CONTINUATION OF COMBINED SYNOPSIS/SOLICITATION

CONTRACT CLAUSES

This solicitation incorporates by reference 52.212-4, and the addenda.

(1) FAR 52.212-4 CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS (MAY 2015)

ADDENDUM

(2) FAR 52.209-7 Information Regarding Responsibility Matters (Jul 2013)

(a) Definitions. As used in this provision— “Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceeding at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [_] has [_] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c) (1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c) (1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(3) FAR 52.217-7 Option for Increased Quantity – Separately Priced Line Item (Mar 1989)

The Government may require the performance of the numbered line items, identified in the Schedule as option items, at the unit prices stated in the Schedule. The option quantities shown in the Schedule are estimates only. The Government has the right to require performance of these items at the quantities deemed necessary. Therefore, the Government may exercise an option item on more than one occasion during the contract performance period. The Contracting Officer will provide initial notification of the exercise of an option either verbally, by email, or both. When time is of essence initial notification will be provided verbally followed within 24 hours by an email of confirmation. A contract modification will be executed shortly thereafter to include those options wherein exercise notification was provided. Such options may be exercised at any phase during the contract performance period as stated herein, or any extension of the performance period. To maintain the contract performance period the Contractor shall commence performance of an option item immediately upon receiving initial notification; but, not later than 24 hours thereafter, unless proper sequencing of the work requires a delay in beginning performance of the option. In that case, the option item shall be commenced as soon as proper sequencing permits. The exercise of any option item listed in the Schedule will not normally extend the contract performance period. However, the Contracting Officer may consider a request by the Contractor for contract extension if an option is exercised after 50% of the contract performance period has expired.

(4) FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.arnet.gov/far/index.html or http://www.dhs.gov/publication/hsar

APR 2014

DEC 2013

(APR 2012)

APR 2012

JUN 2003

JUL 2003

SEP 2012

DEC 2003

DEC 2003

JUN 2006

(5) HSAR 3052.212-70 CONTRACT TERMS AND CONDITIONS APPLICABLE TO DHS ACQUISITION OF COMMERCIAL ITEMS (SEP 2012) The Contractor agrees to comply with any provision or clause that is incorporated herein by reference to implement agency policy applicable to acquisition of commercial items or components. The provision or clause in effect based on the applicable regulation cited on the date the solicitation is issued applies unless otherwise stated herein. The following provisions and clauses are incorporated by reference:

(a) Provisions.

____3052.209-72 Organizational Conflicts of Interest.

____3052.216-70 Evaluation of Offers Subject to An Economic Price Adjustment Clause.

____3052.219-72 Evaluation of Prime Contractor Participation in the DHS Mentor Protégé Program.

(b) Clauses.

____3052.203-70 Instructions for Contractor Disclosure of Violations.

____3052.204-70 Security Requirements for Unclassified Information Technology Resources.

____3052.204-71 Contractor Employee Access.

____Alternate I ____3052.205-70 Advertisement, Publicizing Awards, and Releases.

____3052.209-73 Limitation on Future Contracting.

_X___3052.215-70 Key Personnel or Facilities.

____3052.216-71 Determination of Award Fee.

____3052.216-72 Performance Evaluation Plan.

____3052.216-73 Distribution of Award Fee.

_X___3052.217-91 Performance. (USCG) _X___3052.217-92 Inspection and Manner of Doing Work. (USCG) _X___3052.217-93 Subcontracts. (USCG) _X___3052.217-94 Lay Days. (USCG) _X___3052.217-95 Liability and Insurance. (USCG) _X___3052.217-96 Title. (USCG) _X___3052.217-97 Discharge of Liens. (USCG) _X___3052.217-98 Delays. (USCG) _X___3052.217-99 Department of Labor Safety and Health Regulations for Ship Repair. (USCG) _X___3052.217-100 Guarantee. (USCG) ____3052.219-70 Small Business Subcontracting Plan Reporting.

____3052.219-71 DHS Mentor Protégé Program.

_X___3052.228-70 Insurance.

____3052.228-90 Notification of Miller Act Payment Bond Protection. (USCG) ____3052.228-91 Loss of or Damage to Leased Aircraft. (USCG) ____3052.228-92 Fair Market Value of Aircraft. (USCG) ____3052.228-93 Risk and Indemnities. (USCG) ____3052.236-70 Special Provisions for Work at Operating Airports.

_X___3052.242-72 Contracting Officer’s Technical Representative.

____3052.247-70 F.o.B. Origin Information.

____Alternate I ____Alternate II ____3052.247-71 F.o.B. Origin Only.

_X___3052.247-72 F.o.B. Destination Only.

(6) HSAR 3052.223-70 REMOVAL OR DISPOSAL OF HAZARDOUS SUBSTANCES – APPLICABLE LICENSES AND PERMITS (JUN 2006)

The Contractor shall have all licenses and permits required by Federal, state, and local laws to perform hazardous substance(s) removal or disposal services. If the Contractor does not currently possess these documents, it shall obtain all requisite licenses and permits within 30 days after date of award. The Contractor shall provide evidence of said documents to the Contracting Officer or designated Government representative prior to commencement of work under the contract.

(7) VOLATILE ORGANIC COMPOUNDS (VOC) REGULATIONS

(a) Contractors are required to comply with federal, state and local VOC compliance laws and regulations. Among other requirements, certain Contractors may also be required to operate pursuant to a Title V permit. The need for such a permit will depend on the provisions of the applicable state’s “State Implementation Plan” (SIP) and the type/quantity of the Contractor’s regulated emissions, including VOCs. Certain SIPs may also mandate certain Contractors to operate under the terms of a compliance plan intended to reduce VOC emissions.

(b) Contractors, therefore, must submit the following to the designated Port Engineer not later than two weeks after contract award:

1) Copies of any federal, state or local permits required and applicable to the use or application of VOCs at Contractor’s facility or offsite work places;

2) Copies of any compliance plans required and applicable to the use or application of VOCs at Contractor’s facility or offsite work places.

(c) If no federal, state or local permits or compliance plans are required and applicable to the use or application of VOCs at Contractor’s facility or offsite workplaces, then Contractor shall submit to the designated Port Engineer a letter, notarized under oath, that such documents are not required.

(d) Contractors will submit the following to the designated Port Engineer not later than two weeks after contract award: Data Sheets (MSDS) documents, certificates, specifications or any other manufacturing data verifying the VOC ratings of paints to be applied to the Cutter in accordance with MLCA Standard Spec 63000N, Section 5.3.1.

(8) FAR 52.223-11 Ozone-Depleting Substances (May 2001)

(a) Definition. “Ozone-depleting substance,” as used in this clause, means any substance the Environmental Protection Agency designates in 40 CFR Part 82 as--

(1) Class I, including, but not limited to, chlorofluorocarbons, halons, carbon tetrachloride, and methyl chloroform; or

(2) Class II , including, but not limited to hydrochlorofluorocarbons.

(b) The Contractor shall label products which contain or are manufactured with ozone-depleting substances in the manner and to the extent required by 42 U.S.C. 7671j (b), (c), and (d) and 40 CFR Part 82, Subpart E, as follows:

Warning Contains (or manufactured with, if applicable) *_______, a substance(s) which harm(s) public health and environment by destroying ozone in the upper atmosphere.

* The Contractor shall insert the name of the substance(s).

(9) REQUIRED INSURANCE

The Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.228-70, Insurance (DEC 2003), the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including:

3. Full insurance coverage in accordance with the United States’ Longshoremen's and Harbor Worker's Act.

4. Full insurance coverage in accordance with the State's Workmen's Compensation Law (or its equivalent) for all places of performance under this contract.

The insurance certificate must provide the name of the US Coast Guard vessel and the contract and/or solicitation number as specifically insured.

(10) ACCESS TO VESSEL

(a) A reasonable number of officers, employees, and associates of the Government, or other Prime Contractors with the Government, and their Sub Contractors, shall, as authorized by the Contracting Officer, have, at all reasonable times, admission to the plant, and access to vessel(s) to perform and fulfill their respective obligations to the Government on a noninterference basis.

The Contractor shall make reasonable arrangements with the Government or Contractors of the Government, as shall have been identified and authorized by the Contracting Officer, to be given admission to the Contractor's facilities and access to the vessel(s) and to office space, work areas, storage or shop areas, or other facilities and services, necessary for the performance of their respective responsibilities and reasonable to their performance. All such above personnel shall be required to comply with all Contractor rules and regulations governing personnel at its shipyard, including those relative to safety and security.

(b) The Contractor further agrees, as authorized by the Contracting Officer, to afford to a reasonable number of officers, employees, and associates of bidders on other contemplated work, the same privileges of admission to the Contractor's plant and access to the vessel(s) on a noninterference basis subject to all Contractor rules and regulations governing personnel in its shipyard, including those relative to safety and security.

(11) INDEMNIFICATION FOR ACCESS TO VESSELS

Notwithstanding any provision in the "Access to Vessels" clause, or any other clause of the contract, the Contractor agrees to allow officers, employees, and associates of the Government, or other Prime Contractors with the Government and their Sub Contractors, and officers, employees, and associates of quoters on other contemplated work, admission to the Contractor's facilities and access to the vessel without any further request for indemnification from any party, which has not been previously included in the contract price.

(12) INSPECTIONS

Except as specified elsewhere, the U.S. Coast Guard shall rely on the Contractor to accomplish all inspection and testing needed to ensure that the work conforms to contract quality requirements.

Records of all inspection work by the Contractor shall be kept complete and available to the Government during the term of this contract and for such longer period as may be specified elsewhere in this contract.

The name and telephone number of the U.S. Coast Guard Inspector will be provided after the award of a contract resulting from this solicitation.

(13) GROWTH WORK

(a) The Contractor shall not perform growth work without the Contracting Officer's authorization. Growth work is work within the scope of the contract, which has not been previously priced as a pre-priced CLIN. The Contracting Officer reserves the right to contract for growth work on the basis of a negotiated, firm, fixed price, when it is in the best interest of the Government. If a firm-fixed price contract is awarded, and during the performance period a repair within scope is identified but the Contracting Officer and Contractor are unable to agree on the cost of the work, a bilateral modification may be incorporated into the contract using a Time and Materials modification for this specific repair. In this situation, FAR 52.212-4, Alternate I, will be incorporated.

(b) The Contractor shall furnish a price breakdown directly to the Contracting Officer, itemized as required by the Contracting Officer, of any proposal submitted for a contract modification. Unless otherwise directed, the breakdown shall be submitted on an SFLC 002 proposal form provided at the arrival conference permitting an analysis of all materials, labor, equipment, subcontract, overhead costs, and profit covering all work involved in the change/modification whether such work was deleted, added or changed. Any amount claimed for subcontracts shall be supported by a separate, similar price breakdown. If the proposal includes a request for a time extension, justification shall be furnished with the proposal.

(c) This clause is to be used in conjunction with the clause COMPOSITE LABOR RATE incorporated into this solicitation. The Contractor is required to have and/or furnish all tools and equipment incidental to each bench trade. Supplies such as wiping rags, hacksaw blades, sandpaper, welding wire, helium, etc., are also to be furnished by the Contractor and shall be included in the Composite Labor Rate. Other materials are to be charged at regular rates and prices currently in effect and as agreed to by the Contracting Officer. Material shall be best commercial quality available except where a precise specification is indicated in which case the specification shall apply, e.g., MILSPEC, FEDERAL SPEC.

(14) DISCOVERIES AND CHANGES TO CONTRACT:

Work requests can be transmitted electronically by using email. The bullets below display the process of how work requests are to be followed during the availability:

Work Request Process will occur in the following order:

1. Condition Found Report (CFR)-Generated by the Contractor and provided to COR

2. Condition Report Reply(CRR)-Generated by the COR and provided to Contractor

3. Work Request- WR and IGE are generated by the COR and forwarded to KO

4. COR provides copy of Work Request to the Contractor

5. Contractor’s Proposal- Provided to the KO for the identified tasking on WR

6. Negotiations- If needed, take place to establish pricing

7. Approved Work Request- Forwarded to Contractor and COR by the KO

8. Modification to Contract- The KS/KO will issue a modification covering all WRs

In order to determine price reasonableness: All change requests that list sub-contracting and/or material must have a written proposal from the sub-contractor or the company providing the material with complete, detailed information (listing number of hours/price per hour; each part/component & associated cost; and an estimated shipping cost).

Condition Found Report, Change Orders and Quick Chits will be transmitted electronically by using email. The bullets below display the process of how these documents are to be followed for the duration of the contract performance period:

(a) Condition Found Report (CFR) - All readings and inspections are to be taken within 24 hours after the machinery or system is opened. All reports of reading and inspections required by the specifications shall be submitted to the COR in writing using a "Condition Found Report (CFR)" form, within 24 hours after the readings and/or inspections are made.

Promptness in taking and reporting readings is particularly important for underbody work items such as shaft bearing or rudder bearing clearances. Often during the progress of a work item, conditions are discovered by the contractor which is considered abnormal for reasons of safety, expected reliability, health, or habitability. These conditions must be brought to the attention of the Coast Guard using a CFR. Details provided by the Contractor in a CFR are important because the CFR may result in a contract change. To speed the contract change progress, the Contractor should include in his/her CFR the following details as a minimum:

Contracting Officer’s Representative (COR) will respond to the Contractor’s within 24 hours of receiving a Condition Found Report. A copy of ALL condition found reports shall be retained in the Cutter’s file.

(b) Change Request Process will occur when the contemplated change is above $3,000.00 in the following order:

9. Condition Found Report-Generated by the contractor and provided to COR .

10. Condition Report Reply-Generated by the COR and provided to Contractor

11. Change Request- CR and IGE are generated by the COR and entered in the Contract Workbook. COR will assign the Change request number.

12. COR provides copy of Change Request to the Contractor

13. Contractor’s Proposal- Provided to the KO for the identified tasking on CR

14. Negotiations- If needed, take place to establish pricing

15. Approved Change Request- Forwarded to Contractor and COR by the KO

Change Request must be submitted by the COR to the contractor within 24 hours after responding to the CFR. Contractor must submit proposal to the Contracting Officer within 72 hours receipt of the Change Request.

(15) COMPOSITE LABOR RATE:

The composite labor rate offered shall be the sole labor hour rate used to price the Prime Contractor's direct labor hours for contract changes, i.e. growth work. The Contractor shall not receive any compensation in addition to this rate for the Prime Contractor's direct labor associated with such changes under this contract.

(a) The composite labor hour rate shall represent total compensation for the following:

(1) direct labor wages and salaries;

(2) all employee benefits including, but not limited to, paid leave, supplemental pay, insurance, retirement, savings, and legally required benefits;

(3) other direct costs associated with transit time, delay, disruption, expendable supplies, and equipment;

(4) all indirect costs such as overhead and general and administrative expense;

(5) any port or association fees, rents, or other levies;

(6) profit (fee);

(7) all direct and indirect costs and profit associated with the following support functions:

(8) all consumables;

(b) The composite labor hour rate will be applied to production labor hours only. Production labor hours include only those hours necessary and reasonable to perform direct production functions and do not include the hours expended on the support functions listed above. This exclusion of support function hours applies whether such support functions are normally charged directly or indirectly by the Contractor's accounting system. These support functions are to be priced into the composite labor rate quoted and shall not be separately compensated.

(c) The Quantity of Composite Labor hours indicated in the Schedule of Supplies/Services, is only an estimate and is an Optional Item pursuant to this solicitation. The Estimated Quantity represents the Government’s best estimate of the total number of additional hours that may be required throughout the contract. The Government may elect to exceed this value at the prices stated in the schedule and its discretion during performance of the contract. The inclusion of this item does not obligate the Government to exercise the item nor entitle the Contractor to compensation if not exercised.

(16) MAINTAINING, REPORTING, AND DISPOSING OF GOVERNMENT PROPERTY IN THE PERFORMANCE OF A SHIP REPAIR CONTRACT

)1. The Government Property Clause incorporated by reference delineates the Contractor's overall responsibility when taking possession of government property in performance of a contract. In performance of this contract the Contractor will be required to properly identify, track and control property within its possession. This includes, a) property furnished by the government (GFP) to the Contractor in conjunction with specific CLIN Items. These items and their values are listed in the specification, b) property that is pre-existing in a location that during the course of performance will be replaced or renewed.

2. The items listed in the specification, as government furnished property will be provided in the quantities designated. Government furnished property may be provided in person by an official Coast Guard employee, shipment via commercial carrier, etc. The Contractor shall sign for all government furnished property using either a DD Form 1149, entitled, “Requisition and Invoice/Shipping Document” or a DD Form 1348, entitled, “Issue Release/Receipt Document”. A copy of the DD 1149 or DD 1348 must be sent within 48 hours of receipt of property, to the designated Government Property Administrator. The name of the individual assigned as Property Administrator will be furnished to the Contractor at time of award. The Contractor shall not take receipt of property that is not listed in the specification, has not been previously identified as becoming part of the contract (via contract modification) or which otherwise cannot be identified. Such irregularities shall be immediately reported to the Property Administrator.

3. The Contractor shall complete the report provided herein, entitled, “Government Property Report”. This report is intended as a living document whereby relevant fields shall be filled in, maintained and kept current at all times. All property described in paragraph 1 (a and b) above shall be reported on the report. At contract completion the Contractor and the Property Administrator shall ensure that all fields are appropriately completed. A signature block is provided at the end of the report for both parties to attest to the report's accuracy and completeness. The Government Property Report shall clearly delineate the complete track that all Government property took over the course of the contract. This completed report must accompany the Contractor's final invoice. Final payment may be delayed, without penalty of interest, until such time as the report is received. A separate copy of the completed report and any final DD 1149s or DD 1348s executed, as a result of carrying out disposition instructions shall be provided to the Property Administrator.

)4. Pursuant to the Government Property Clause the authority to render disposition instructions of Government property associated with this contract is delegated to the Property Administrator. The Contractor shall comply with all instructions in the contract for the return of government property to the Coast Guard. This includes government property taken off the vessel (shafts, propellers, etc.), government property returned to the vessel (special tools, etc.) or surplus government property not used during performance of the contract.

(17) CONTRACTING OFFICER’S AUTHORITY

No oral or written statement of any person other than the Contracting Officer will in any manner or degree modify or otherwise affect the terms of this contract. The Contracting Officer is the only person authorized to approve changes in any of the requirements under this contract, and, notwithstanding any provisions contained elsewhere in this contract, said authority remains solely with the Contracting Officer. In the event the Contractor effects any such change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in cost incurred as a result thereof.

(18) CONTRACTOR PERFORMANCE EVALUATION

(a) GENERAL: The U.S. Coast Guard Surface Forces Logistic Center (SFLC) will monitor and evaluate the successful offeror’s past performance of this contract and prepare a Contractor Performance Assessment Report (CPAR) in accordance with FAR Part 42.15. All information contained in this assessment may be used, within the limitations of FAR 42.15, by the government for future source selections and in accordance with FAR 15.304, when past performance is an evaluation factor for award.

(b) NOTIFICATION: Upon completion of the contract, the Contractor will be notified of the assessment. The Contractor will be allowed 30 days to respond to the SLFC’s assessment of its performance entered into CPARS. The Contractor’s response, if any, will be made part of the CPAR system at https://www.cpars.csd.disa.mil.

(c) INFORMATION: Information included in the CPAR may include, but is not limited to, the Contractor’s record of conforming to contract requirements and to standards of good workmanship; the Contractor’s record of forecasting and controlling costs; the Contractor’s adherence to contract schedules, including the administrative aspects of performance; the Contractor’s history of reasonable and cooperative behavior and commitment to customer satisfaction; the Contractor’s record of integrity and business ethics, and generally, the Contractor’s business-like concern for the interest of the customer.

(d) RELEASE OF DATA: CPARS information is considered business sensitive and will not be released except: (1) to other Federal procurement activities which request it; (2) when SFLC must release pursuant to a Freedom of Information Act (FOIA) request; or (3) when prior written consent is requested and obtained from the Contractor.

(19) CONTRACT DEFICIENCY REPORT

The Contracting Officer or Contracting Officer’s Representative (COR) may issue a Contract Deficiency Report (CDR), SFLC Form 005. The Contractor shall respond in writing within 24 hours of receipt, unless otherwise approved by the Contracting Officer, to the COR. The COR will comment on the Contractor's response and will forward the Deficiency Report and comments to the Contracting Officer, with a copy to the Contractor and Availability Program Manager. The Contracting Officer will render a final determination and provide it to the Contractor and COR in writing.

(20) INVOICE SUBMISSION PROCESS:

1. The Contractor shall prepare a proper invoice IAW FAR clause 52.212-4, and in addition to the information required by FAR 52.212-4(g) as cited in the contract. All invoices shall be itemized to correlate to the Schedule of Supplies/Services.

(A) The Government will make payment under this contract based on a percentage or stage of completion. The Contractor may invoice each contract line item (CLIN) as work progresses. The amount invoiced shall be calculated based on those prices stipulated in the contract Schedule of Supplies/Services as follows:

(B) A CLIN may not be invoiced until the percentage complete reaches 25 percent. Future invoices for that CLIN have no limitation as to the percentage of completion required before invoicing. (The minimum percentage of completion (25%) to be reached prior to billing each CLIN may be waived by the Contracting Officer on a case by case basis for large dollar CLINS.)

(C) In addition to the information required by FAR 52.212-4 (g) Invoices shall include:

1) Contract Number, Delivery Order/Task Order Number, DOC Number

2) Name and Address of the Contractor

3) Invoice Number and Invoice Date

4) DUNS Number

5) Name of the Contract Specialist and Contracting Officer’s

6) Invoice Routing Code (IRC): SFLC-2

7) Indicate Small Business Status

8) Indicate if Final Invoice, the Contractor’s final invoice submitted under the contract must be marked as follows: THIS INVOICE CONSTITUTES THE FINAL INVOICE – UPON PAYMENT OF THIS INVOICE NO OTHER MONIES ARE DUE UNDER CONTRACT NUMBER (to be assigned upon contract award).

9) The percentage of completion for each CLIN identified;

10) Vessel name

11) The overall percentage and dollar amount previously billed, currently billed and unbilled,

12) Shipping and Payment Terms

13) Name, title, phone number, and mailing address of person to be notified in the event of a defective invoice.

All information must be included in an invoice for it to constitute a proper invoice. All improper invoices will be rejected which could delay payment.

1. The Contractor shall forward invoices to the contracting Officer’s Technical Representative (COR), who shall review, verify and sign the invoice and then return it to the Contractor.

2. The Contractor shall complete the Contractor Invoice Submission Form (listed below).

3. The Contractor shall submit the Contractor Invoice Submission Form, a PDF file of the invoice, and any necessary documents for supplies or services via the U.S. Coast Guard Finance Center website at:

http://www.fincen.uscg.mil/centralinv/central_inv_contr.cfm Contractor Invoice Submission Form Directions: Please complete as much information as possible. All blocks in red text are required entries.

Note: Web-Invoices are accepted only for Coast Guard Contracts over the Simplified Acquisition Threshold (Document Type 24).

THIS WEB FORM IS NOT AN OFFICIAL INVOICE. THE OFFICIAL INVOICE MUST BE ATTACHED

Invoice Information

Discount Days: Net Days: (help)

Company Name: (help)

DUNS: Plus 4: (help)

Point of Contact Name: (help)

Point of Contact Email: (help)

Phone: (help) Fax: (help)

Please verify your entry on the next page. Attach invoice and any supporting documentation after verification.

· Attachment must be a single PDF file no larger than 3 MB. Grey-scale PDFs are not compatible. This will be our official invoice. Supporting documentation must be combined in the single PDF file or submitted to your contracting office separately via email.

· Need help creating a PDF file? Click here for instructions.

Bottom of Form

6. The Contractor must select the correct Invoice Routing Code for timely invoice processing. The Invoice Routing Code for this contract is SFLC-2.

7. Visit the U.S. Coast Guard Finance Center Website for instructions regarding invoice attachments. http://www.fincen.uscg.mil/centralinv/central_inv_contr.cfm

8. A copy of the invoice and any supporting documentation shall also be e-mailed to the following individuals:

Natalie J. Rodriguez Contracting Officer Natalie.j.rodriguez@uscg.mil

CWO John Brummett Contracting Officer Representative John.t.brummett@uscg.mil

Shari A. Jackson-Humphrey Contract Specialist-Contractor Shari.a.jackson-humphrey@uscg.mil

Additional work verbally agreed to by the parties that has not yet been incorporated into the contract by modification shall not be included in an invoice. Payments will not be made for any work to which a modification has not been properly executed. Invoices submitted for payment that includes such a request will be reduced by the unmodified amount.

NOTE: 10% OF THE TOTAL CONTRACT PRICE WILL BE WITHHELD UNTIL ALL DELIVERABLES, REQUIRED BY THE CONTRACT, ARE RECEIVED AND ACCEPTED.

FURTHER CONSIDERATIONS WITH INVOICING:

In accordance with the Prompt Payment Act, for the purposes of determining a payment due date and the date on which interest will begin to accrue if a payment is late, a proper invoice shall be deemed to have been received:

(1) On the later of:

(i) For invoices that are mailed the date a proper invoice is actually received by the designated billing office and annotates the invoice with date of receipt at the time of receipt.

(ii) For invoices electronically transmitted by the Contractor via web based submission, the date a transmission is received by the designated billing office, and receipt confirmation is provided to the designated recipient; or

(iii) The seventh day after the date on which the property is actually delivered or performance of the services is actually completed; unless—

a) The agency has actually accepted the property or services before the seventh day in which case the acceptance date shall substitute for the seventh day after the delivery date; or

b) A longer acceptance period is specified in the contract, in which case the date of actual acceptance or the date on which such longer acceptance period ends shall substitute for the seventh day after the delivery date;

(2) On the date placed on the invoice by the Contractor, when the agency fails to annotate the invoice with date of receipt of the invoice at the time of receipt (such invoice must be a proper invoice); or

(3) On the date of delivery, when the contract specifies that the delivery ticket may serve as an invoice.

(4) Web based submission by the Contractor and receipt confirmation does not reflect Government review or acceptance of the invoice.

(5) For inquiries and payment status please visit: https://fincen.uscg.mil/secure/payment.htm

The Data Universal Numbering System (DUNS) number is the primary identifier in System for Award Management (SAM), formally known as Central Contractor Registration (CCR), (see FAR 52.232-33, Payment by Electronic Funds Transfer – Central Contractor Registration (OCT 2003)). Contractors are located and identified in SAM by their DUNS number. Therefore, to facilitate payment, the DUNS number shall be recorded on every invoice submitted to the U.S. Coast Guard.

All payments for partial performance rendered by the Government under this contract are based on the assumption that the Contractor will, in good faith, execute and honor all payment terms entered into between it, the Prime Contractor, and any subcontractor thereof in the performance of this contract. The Contractor hereby acknowledges the Government’s right to reduce or suspend progress payments based on non-payment in accordance with any payment terms of the subcontract agreement.

Any amount deemed not payable will be deducted from the Contractor’s invoice. Deducted amounts may be resubmitted on the next invoice for reconsideration.

(21) FAR 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS-COMMERCIAL ITEMS (MAY 2015)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Dec 2014)

(2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004)(Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

_X_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

_X_ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jul 2013) (Pub. L. 109-282) (31 U.S.C. 6101 note).

__ (5) [Reserved].

__ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div. C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014) (Pub. L. 111-117, section 743 of Div. C).

_X_ (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Aug 2013) (31 U.S.C. 6101 note).

__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313).

__ (10) [Reserved].

__ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).

__ (ii) Alternate I (Nov 2011) of 52.219-3.

__ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__ (ii) Alternate I (JAN 2011) of 52.219-4.

__ (13) [Reserved] _X_ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C. 644).

__ (ii) Alternate I (Nov 2011).

__ (iii) Alternate II (Nov 2011).

__ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

__ (ii) Alternate I (Oct 1995) of 52.219-7.

__ (iii) Alternate II (Mar 2004) of 52.219-7.

_X_ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)).

__ (17)(i) 52.219-9, Small Business Subcontracting Plan (Oct 2014) (15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Oct 2001) of 52.219-9.

__ (iii) Alternate II (Oct 2001) of 52.219-9.

__ (iv) Alternate III (Oct 2014) of 52.219-9.

__ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011)(15 U.S.C. 644(r)).

_X_ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)).

__ (20) 52.219-16, Liquidated Damages-Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657 f).

_X_ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)).

__ (23) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (Jul 2013) (15 U.S.C. 637(m)).

__ (24) 52.219-30, Notice of Set-Aside for Women-Owned Small Business (WOSB) Concerns Eligible Under the WOSB Program (Jul 2013) (15 U.S.C. 637(m)).

_X_ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

_X_ (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2014) (E.O. 13126).

_X_ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

_X_ (28) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

_X_ (29) 52.222-35, Equal Opportunity for Veterans (Jul 2014)(38 U.S.C. 4212).

_X_ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

_X_ (31) 52.222-37, Employment Reports on Veterans (JUL 2014) (38 U.S.C. 4212).

_X_ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

__ (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

__ (34) 52.222-54, Employment Eligibility Verification (AUG 2013). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

__ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (36)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-13.

__ (37)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (JUN 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-14.

__ (38) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b).

__ (39)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (JUN 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-16.

_X_ (40) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (AUG 2011) (E.O. 13513).

_X_ (41) 52.225-1, Buy American-Supplies (May 2014) (41 U.S.C. chapter 83).

__ (42)(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I (May 2014) of 52.225-3.

__ (iii) Alternate II (May 2014) of 52.225-3.

__ (iv) Alternate III (May 2014) of 52.225-3.

__ (43) 52.225-5, Trade Agreements (NOV 2013) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_X_ (44) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (45) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

__ (46) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

__ (47) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

__ (48) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

__ (49) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

_X_ (50) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (51) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (52) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

__ (53) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

__ (54)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

__ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

__ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495).

__ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67).

__ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

__ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

__ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2014)(E.O. 13658).

__ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792).

__ (10) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract.