Solicitation_Amendment_-_FA440719RA0020002.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

FA440719RA0020002

Section A - Solicitation/Contract Form

Section B - Supplies or Services and Prices/Cost

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

0001 Base Period - The Multiple Award Paving Contract (MAPC) program is a competitive, firm-fixed-price (FFP) Indefinite-Delivery Indefinite-Quantity (IDIQ) acquisition for general paving projects and related infrastructure work under the heavy highway construction category (NAICS 237310). Individual projects will be awarded via task orders under this program with defined requirements using a Statement of Work (SOW) and other attachments included in Section J of each task order.

Contractors shall provide all plant, labor, equipment, materials, transportation, supervision, and design (as required) to accomplish a wide variety of general bid-build and design-build paving work.

The minimum guarantee of $500.00 will be paid in the base period of the contract after attendance by the awardee of the post-award orientation conference.

Product Service Code: Z2LB Firm Fixed Price

100.0 Lot

Option Line Item

Option Period 1 - The Multiple Award Paving Contract (MAPC) program is a competitive, firm-fixed-price (FFP) Indefinite-Delivery Indefinite-Quantity (IDIQ) acquisition for general paving projects and related infrastructure work under the heavy highway construction category (NAICS 237310). Individual projects will be awarded via task orders under this program with defined requirements using a Statement of Work (SOW) and other attachments included in Section J of each task order.

Contractors shall provide all plant, labor, equipment, materials, transportation, supervision, and design (as required) to accomplish a wide variety of general bid-build and design-build paving work.

Product Service Code: Z2LB Firm Fixed Price

100.0 Lot

Option Line Item

Option Period 2 - The Multiple Award Paving Contract (MAPC) program is a competitive, firm-fixed-price (FFP) Indefinite-Delivery Indefinite-Quantity (IDIQ) acquisition for general paving projects and related infrastructure work under the heavy highway construction category (NAICS 237310). Individual projects will be awarded via task orders under this program with defined requirements using a Statement of

100.0 Lot

Work (SOW) and other attachments included in Section J of each task order.

Contractors shall provide all plant, labor, equipment, materials, transportation, supervision, and design (as required) to accomplish a wide variety of general bid-build and design-build paving work.

Product Service Code: Z2LB Firm Fixed Price

Option Line Item

Option Period 3 - The Multiple Award Paving Contract (MAPC) program is a competitive, firm-fixed-price (FFP) Indefinite-Delivery Indefinite-Quantity (IDIQ) acquisition for general paving projects and related infrastructure work under the heavy highway construction category (NAICS 237310). Individual projects will be awarded via task orders under this program with defined requirements using a Statement of Work (SOW) and other attachments included in Section J of each task order.

Contractors shall provide all plant, labor, equipment, materials, transportation, supervision, and design (as required) to accomplish a wide variety of general bid-build and design-build paving work.

Product Service Code: Z2LB Firm Fixed Price

100.0 Lot

Option Line Item

Option Period 4 - The Multiple Award Paving Contract (MAPC) program is a competitive, firm-fixed-price (FFP) Indefinite-Delivery Indefinite-Quantity (IDIQ) acquisition for general paving projects and related infrastructure work under the heavy highway construction category (NAICS 237310). Individual projects will be awarded via task orders under this program with defined requirements using a Statement of Work (SOW) and other attachments included in Section J of each task order.

Contractors shall provide all plant, labor, equipment, materials, transportation, supervision, and design (as required) to accomplish a wide variety of general bid-build and design-build paving work.

Product Service Code: Z2LB Firm Fixed Price

100.0 Lot

Section C - Description/Specifications/Statement of Work

Requirements Multiple Award Paving Contract

Section D - Packaging and Marking

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected at destination and inspected by the government. Supplies/services will be accepted at destination and accepted by the government. More specific inspection and acceptance terms may be incorporated on individual task orders.

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. 1996-08

Section F - Deliveries or Performance

This IDIQ will have a base period of one year (365 days) after date of award, and four option periods of one year (365 days) each that may be exercised consecutively. All performance will occur at Scott AFB, IL. Specific delivery information may be determined on individual task orders.

Option Line Item

Option Line Item

Option Line Item

Option Line Item

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.247-34 F.o.b. Destination. 1991-11 52.247-35 F.o.b. Destination, Within Consignee's Premises. 1984-04

Section G - Contract Administration Data

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.232-10 Payments under Fixed-Price Architect-Engineer Contracts. 2010-04

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.201-7000 Contracting Officer's Representative 1991-12 252.204-7006 Billing Instructions. 2005-10 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2018-12 252.236-7000 Modification Proposals--Price Breakdown. 1991-12

FAR Clauses Incorporated by Full Text

52.236-22 Design Within Funding Limitations. 1984-04 As prescribed in 36.609-1(c), insert the following clause:

Design Within Funding Limitations (Apr 1984)

(a) The Contractor shall accomplish the design services required under this contract so as to permit the award of a contract, using standard Federal Acquisition Regulation procedures for the construction of the facilities designed at a price that does not exceed the estimated construction contract price as set forth in paragraph (c) of this clause. When bids or proposals for the construction contract are received that exceed the estimated price, the contractor shall perform such redesign and other services as are necessary to permit contract award within the funding limitation. These additional services shall be performed at no increase in the price of this contract. However, the Contractor shall not be required to perform such additional services at no cost to the Government if the unfavorable bids or proposals are the result of conditions beyond its reasonable control.

(b) The Contractor will promptly advise the Contracting Officer if it finds that the project being designed will exceed or is likely to exceed the funding limitations and it is unable to design a usable facility within these limitations. Upon receipt of such information, the Contracting Officer will review the Contractor's revised estimate of construction cost. The Government may, if it determines that the estimated construction contract price set forth in this contract is so low that award of a construction contract not in excess of such estimate is improbable, authorize a change in scope or materials as required to reduce the estimated construction cost to an amount within the estimated construction contract price set forth in paragraph (c) of this clause, or the Government may adjust such estimated construction contract price. When bids or proposals are not solicited or are unreasonably delayed, the Government shall prepare an estimate of constructing the design submitted and such estimate shall be used in lieu of bids or proposals to determine compliance with the funding limitation.

(c) The estimated construction contract price for the project described in this contract is $__to be determined per task order__.

(End of clause)

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2018-12 As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause- Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow

(WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

Payment request and receiving report are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov;

and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the Web Based Training link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

__Invoice 2-in-1__ (Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

__Invoice 2-in-1__ (Contracting Officer: Insert either Invoice 2in1 or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF combo document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

| Field Name in WAWF || Data to be entered in WAWF | | Pay Official DoDAAC || __To be cited per task order__ | | Issue By DoDAAC || __FA4407__ | | Admin DoDAAC || __FA4407__ | | Inspect By DoDAAC || __To be cited per task order__ | | Ship To Code || ____ | | Ship From Code || ____ | | Mark For Code || ____ | | Service Approver (DoDAAC) || ____ | | Service Acceptor (DoDAAC) || __To be cited per task order__ | | Accept at Other DoDAAC || ____ | | LPO DoDAAC || ____ | | DCAA Auditor DoDAAC || ____ | | Other DoDAAC(s) || ____ |

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert See Schedule or Not applicable.)

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activitys WAWF point of contact.

__To be cited per task order__

(Contracting Officer: Insert applicable information or Not applicable.)

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section H - Special Contract Requirements

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.202-1 Definitions. 2013-11 52.203-3 Gratuities. 1984-04 52.203-6 Restrictions on Subcontractor Sales to the Government. 2006-09 52.203-7 Anti-Kickback Procedures. 2014-05 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper

Activity.

2014-05

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. 2014-05 52.203-11 Certification and Disclosure Regarding Payments to Influence Certain

Federal Transactions.

2007-09

52.203-12 Limitation on Payments to Influence Certain Federal Transactions. 2010-10 52.203-18 Prohibition on Contracting with Entities that Require Certain Internal

Confidentiality Agreements or Statements-Representation.

2017-01

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

2017-01

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper.2011-05 52.204-7 System for Award Management. 2018-10 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. 2018-10 52.204-16 Commercial and Government Entity Code Reporting. 2016-07 52.204-23 Prohibition on Contracting for Hardware, Software, and Services

Developed or Provided by Kaspersky Lab and Other Covered Entities.

2018-07

52.215-2 Audit and Records-Negotiation. 2010-10 52.215-8 Order of Precedence-Uniform Contract Format. 1997-10 52.215-11 Price Reduction for Defective Certified Cost or Pricing Data-

Modifications.

2011-08

52.215-13 Deviation 2018- O0015

Subcontractor Certified Cost or Pricing Data-Modifications (Deviation 2018-O0015)

2010-10

52.215-21 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data-Modifications.

2010-10

52.219-6 Deviation 2019- O0003

Notice of Total Small Business Set-Aside (DEVIATION 2019-O0003) 2011-11

52.219-8 Utilization of Small Business Concerns. 2018-10 52.219-14 Deviation 2019- O0003

Limitations on Subcontracting (DEVIATION 2019-O0003) 2017-01

52.222-1 Notice to the Government of Labor Disputes. 1997-02 52.222-3 Convict Labor. 2003-06 52.222-4 Contract Work Hours and Safety Standards -Overtime Compensation. 2018-03 52.222-6 Construction Wage Rate Requirements. 2018-08 52.222-7 Withholding of Funds. 2014-05 52.222-8 Payrolls and Basic Records. 2018-08 52.222-9 Apprentices and Trainees. 2005-07 52.222-10 Compliance with Copeland Act Requirements. 1988-02 52.222-11 Subcontracts (Labor Standards). 2014-05 52.222-12 Contract Termination-Debarment. 2014-05 52.222-13 Compliance with Construction Wage Rate Requirements and Related

Regulations.

2014-05

52.222-14 Disputes Concerning Labor Standards. 1988-02 52.222-15 Certification of Eligibility. 2014-05 52.222-21 Prohibition of Segregated Facilities. 2015-04 52.222-26 Equal Opportunity. 2016-09 52.222-27 Affirmative Action Compliance Requirements for Construction. 2015-04 52.222-30 Construction Wage Rate Requirements-Price Adjustment (None or

Separately Specified Method).

2018-08

52.222-37 Employment Reports on Veterans. 2016-02

52.222-40 Notification of Employee Rights Under the National Labor Relations Act.

2010-12

52.222-50 Combating Trafficking in Persons. 2019-01 52.222-54 Employment Eligibility Verification. 2015-10 52.222-55 Minimum Wages Under Executive Order 13658. 2015-12 52.222-62 Paid Sick Leave Under Executive Order 13706. 2017-01 52.223-2 Affirmative Procurement of Biobased Products Under Service and

Construction Contracts.

2013-09

52.223-5 Pollution Prevention and Right-to-Know Information. 2011-05 52.223-6 Drug-Free Workplace. 2001-05 52.223-11 Ozone-Depleting Substances and High Global Warming Potential

Hydrofluorocarbons.

2016-06

52.223-15 Energy Efficiency in Energy-Consuming Products. 2007-12 52.223-17 Affirmative Procurement of EPA-designated Items in Service and

Construction Contracts.

2018-08

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. 2011-08 52.223-21 Foams. 2016-06 52.225-13 Restrictions on Certain Foreign Purchases. 2008-06 52.227-1 Authorization and Consent. 2007-12 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement. 2007-12 52.228-2 Additional Bond Security. 1997-10 52.228-5 Insurance-Work on a Government Installation. 1997-01 52.228-11 Pledges of Assets. 2018-08 52.228-12 Prospective Subcontractor Requests for Bonds. 2014-05 52.228-14 Irrevocable Letter of Credit. 2014-11 52.228-15 Performance and Payment Bonds-Construction. 2010-10 52.229-3 Federal, State, and Local Taxes. 2013-02 52.232-8 Discounts for Prompt Payment. 2002-02 52.232-11 Extras. 1984-04 52.232-16 Alternate I Progress Payments. 2012-04 52.232-17 Interest. 2014-05 52.232-23 Assignment of Claims. 2014-05 52.232-26 Prompt Payment for Fixed-Price Architect-Engineer Contracts. 2017-01 52.232-27 Prompt Payment for Construction Contracts. 2017-01 52.232-33 Payment by Electronic Funds Transfer-System for Award Management.2018-10 52.232-39 Unenforceability of Unauthorized Obligations. 2013-06 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. 2013-12 52.233-1 Alternate I Disputes. 2014-05 52.233-3 Protest after Award. 1996-08 52.233-4 Applicable Law for Breach of Contract Claim. 2004-10 52.236-2 Differing Site Conditions. 1984-04 52.236-3 Site Investigation and Conditions Affecting the Work. 1984-04 52.236-5 Material and Workmanship. 1984-04 52.236-6 Superintendence by the Contractor. 1984-04 52.236-7 Permits and Responsibilities. 1991-11 52.236-8 Other Contracts. 1984-04 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and

Improvements.

1984-04

52.236-10 Operations and Storage Areas. 1984-04 52.236-11 Use and Possession Prior to Completion. 1984-04 52.236-12 Cleaning Up. 1984-04 52.236-13 Accident Prevention. 1991-11 52.236-13 Alternate I Accident Prevention. 1991-11 52.236-14 Availability and Use of Utility Services. 1984-04 52.236-15 Schedules for Construction Contracts. 1984-04 52.236-17 Layout of Work. 1984-04 52.236-23 Responsibility of the Architect-Engineer Contractor. 1984-04 52.236-24 Work Oversight in Architect-Engineer Contracts. 1984-04 52.242-13 Bankruptcy. 1995-07 52.242-14 Suspension of Work. 1984-04 52.243-1 Alternate III Changes-Fixed-Price. 1987-08 52.243-4 Changes. 2007-06 52.243-5 Changes and Changed Conditions. 1984-04

52.244-4 Subcontractors and Outside Associates and Consultants (Architect- Engineer Services).

1998-08

52.244-6 Subcontracts for Commercial Items. 2019-01 52.245-1 Alternate I Government Property. 2017-01 52.245-1 Government Property. 2017-01 52.245-9 Use and Charges. 2012-04 52.249-2 Alternate I Termination for Convenience of the Government (Fixed-Price). 2012-04 52.249-7 Termination (Fixed-Price Architect-Engineer). 1984-04 52.249-10 Default (Fixed-Price Construction). 1984-04 52.251-1 Government Supply Sources. 2012-04

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials 2011-09 252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-

Related Felonies.

2008-12

252.203-7002 Requirement to Inform Employees of Whistleblower Rights. 2013-09 252.203-7003 Agency Office of the Inspector General. As prescribed in 203.1004(a), use the following clause:

2012-12

252.204-7003 Control of Government Personnel Work Product. 1992-04 252.204-7004 Antiterrorism Awareness Training for Contractors. 2019-02 252.204-7008 Compliance with Safeguarding Covered Defense Information Controls. 2016-10 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident

Reporting.

2016-10

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. 2016-05 252.205-7000 Provision of Information to Cooperative Agreement Holders 1991-12 252.209-7004 Subcontracting with Firms that are Owned or Controlled by the

Government of a Country that is a State Sponsor of Terrorism.

2019-05

252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements. 2010-12 252.223-7004 Drug-Free Work Force. 1988-09 252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous

Materials.

2014-09

252.223-7008 Prohibition of Hexavalent Chromium. 2013-06 252.225-7048 Export-Controlled Items. 2013-06 252.227-7022 Government Rights (Unlimited). 1979-03 252.227-7023 Drawings and Other Data to Become Property of Government. 1979-03 252.227-7033 Rights in Shop Drawings. 1966-04 252.232-7004 DoD Progress Payment Rates. 2014-10 252.232-7010 Levies on Contract Payments. 2006-12 252.236-7005 Airfield Safety Precautions. 1991-12 252.236-7013 Requirement for Competition Opportunity for American Steel

Producers, Fabricators, and Manufacturers.

2013-06

252.243-7001 Pricing of Contract Modifications. 1991-12 252.243-7002 Requests for Equitable Adjustment. 2012-12 252.244-7000 Subcontracts for Commercial Items 2013-06 252.245-7000 Government-Furnished Mapping, Charting, and Geodesy Property 2012-04 252.245-7002 Reporting Loss of Government Property. 2017-12 252.245-7003 Contractor Property Management System Administration. 2012-04 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for Military

Operations.

2010-10

FAR Clauses Incorporated by Full Text

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights. 2014-04 As prescribed in 3.908-9 , insert the following clause:

Contractor Employee Whistleblower Rights and Requirement to Inform Employees of Whistleblower Rights (Apr 2014)

(a) This contract and employees working on this contract will be subject to the whistleblower rights and remedies in the pilot program on Contractor employee whistleblower protections established at 41 U.S.C. 4712 by section 828 of the National Defense Authorization Act for Fiscal Year 2013 (Pub. L. 112-239) and FAR 3.908.

(b) The Contractor shall inform its employees in writing, in the predominant language of the workforce, of employee whistleblower rights and protections under 41 U.S.C. 4712, as described in section 3.908 of the Federal Acquisition Regulation.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts over the simplified acquisition threshold.

(End of clause)

52.204-13 System for Award Management Maintenance. 2018-10 As prescribed in 4.1105(b), use the following clause:

System for Award Management Maintenance. (Oct 2018)

(a) Definitions. As used in this clause- "Electronic Funds Transfer (EFT) indicator" means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management (SAM) records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

"Registered in the System for Award Management (SAM)" means that-

(1) The Contractor has entered all mandatory information, including the unique entity identifier and the EFT indicator (if applicable), the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14), into SAM;

(2) The Contractor has completed the Core, Assertions, Representations and Certifications, and Points of Contact sections of the registration in SAM;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Contractor will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and

(4) The Government has marked the record "Active".

"System for Award Management (SAM)" means the primary Government repository for prospective Federal awardee and Federal awardee information and the centralized Government system for certain contracting, grants, and other assistance-related processes. It includes-

(1) Data collected from prospective Federal awardees required for the conduct of business with the Government;

(2) Prospective contractor-submitted annual representations and certifications in accordance with FAR subpart 4.12; and

(3) Identification of those parties excluded from receiving Federal contracts, certain subcontracts, and certain types of Federal financial and non-financial assistance and benefits.

"Unique entity identifier" means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b) If the solicitation for this contract contained the provision 52.204-7 with its Alternate I, and the Contractor was unable to register prior to award, the Contractor shall be registered in SAM within 30 days after award or before three days prior to submission of the first invoice, whichever occurs first.

(c) The Contractor shall maintain registration in SAM during contract performance and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement. The Contractor is responsible for the currency, accuracy and completeness of the data within SAM, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in SAM after the initial registration, the Contractor is required to review and update on an annual basis, from the date of initial registration or subsequent updates, its information in SAM to ensure it is current, accurate and complete. Updating information in SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(d) (1)

(i) If a Contractor has legally changed its business name or "doing business as" name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to-

(A) Change the name in SAM;

(B) Comply with the requirements of subpart 42.12 of the FAR; and

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor shall provide with the notification sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (d)(1)(i) of this clause, or fails to perform the agreement at paragraph (d)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in SAM record to reflect an assignee for the purpose of assignment of claims (see FAR subpart 32.8, Assignment of Claims).

Assignees shall be separately registered in the SAM. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the EFT clause of this contract.

(3) The Contractor shall ensure that the unique entity identifier is maintained with the entity designated at www.sam.gov for establishment of the unique entity identifier throughout the life of the contract. The Contractor shall communicate any change to the unique entity identifier to the Contracting Officer within 30 days after the change, so an appropriate modification can be issued to update the data on the contract. A change in the unique entity identifier does not necessarily require a novation be accomplished.

(e) Contractors may obtain additional information on registration and annual confirmation requirements at https:// www.sam.gov.

(End of clause)

52.204-21 Basic Safeguarding of Covered Contractor Information Systems. 2016-06 As prescribed in 4.1903 , insert the following clause:

Basic Safeguarding of Covered Contractor Information Systems (Jun 2016)

(a) Definitions. As used in this clause- "Covered contractor information system" means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

"Federal contract information" means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public websites) or simple transactional information, such as necessary to process payments.

"Information" means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009).

"Information system" means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502).

"Safeguarding" means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures.

(1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements.This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial items, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

(End of clause)

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. 2015-11 As prescribed in 9.108-5(b), insert the following clause:

Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(a) Definitions. As used in this clause- "Inverted domestic corporation" means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

"Subsidiary" means an entity in which more than 50 percent of the entity is owned-

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

(b) If the contractor reorganizes as an inverted domestic corporation or becomes a subsidiary of an inverted domestic corporation at any time during the period of performance of this contract, the Government may be prohibited from paying for Contractor activities performed after the date when it becomes an inverted domestic corporation or subsidiary. The Government may seek any available remedies in the event the Contractor fails to perform in accordance with the terms and conditions of the contract as a result of Government action under this clause.

(c) Exceptions to this prohibition are located at 9.108-2.

(d) In the event the Contractor becomes either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation during contract performance, the Contractor shall give written notice to the Contracting Officer within five business days from the date of the inversion event.

(End of clause)

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. 2016-02 As prescribed in 9.104-7 (d), insert the following provision:

Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law (Feb 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that-

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that-

(1) It is [_] is not [_] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [_] is not [_] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

(End of provision)

52.211-12 Liquidated Damages-Construction. 2000-09 As prescribed in 11.503(b), insert the following clause in solicitations and contracts:

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of __specified in each task order for each calendar day of delay until the work is completed or accepted.__ [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 Time Extensions. 2000-09 As prescribed in 11.503(c), insert the following clause:

Time Extensions (Sept 2000) Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

52.216-19 Order Limitations. 1995-10 As prescribed in 16.506(b), insert a clause substantially the same as follows:

Order Limitations (Oct 1995)

(a) Minimum order. When the Government requires supplies or services covered by this contract in an amount of less than __$500__ [insert dollar figure or quantity], the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those supplies or services under the contract.

(b) Maximum order. The Contractor is not obligated to honor-

(1) Any order for a single item in excess of __$5,000,000__ [insert dollar figure or quantity];

(2) Any order for a combination of items in excess of __$5,000,000__ [insert dollar figure or quantity]; or

(3) A series of orders from the same ordering office within __thirty (30) calendar__ days that together call for quantities exceeding the limitation in paragraph (b)(1) or (2) of this section.

(c) If this is a requirements contract (i.e.,includes the Requirements clause at subsection 52.216-21 of the Federal Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) of this section.

(d) Notwithstanding paragraphs(b) and (c) of this section, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within __five (5) calendar__ days after issuance, with written notice stating the Contractor's intent not to ship the item (or items) called for and the reasons.

Upon receiving this notice, the Government may acquire the supplies or services from another source.

(End of clause)

52.216-22 Indefinite Quantity. 1995-10 As prescribed in 16.506(e), insert the following clause:

Indefinite Quantity (Oct 1995)

(a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the maximum. The Government shall order at least the quantity of supplies or services designated in the Schedule as the minimum.

(c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period;

provided, that the Contractor shall not be required to make any deliveries under this contract after __completion of the last task order__ [insert date].

(End of clause)

52.217-8 Option to Extend Services. 1999-11 As prescribed in 17.208(f), insert a clause substantially the same as the following:

Option to Extend Services (Nov 1999) The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within __fifteen (15) calendar days of expiration of the current ordering period__ [insert the period of time within which the Contracting Officer may exercise the option].

(End of clause)

52.217-9 Option to Extend the Term of the Contract. 2000-03 As prescribed in 17.208(g), insert a clause substantially the same as the following:

Option to Extend the Term of the Contract (Mar 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within __five (5) calendar days of expiration of the current ordering period__ [insert the period of time within which the Contracting Officer may exercise the option]; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least __sixty (60)__ days [60days unless a different number of days is inserted] before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed __five (5) years__ (months) (years).

(End of clause)

52.219-13 Notice of Set-Aside of Orders. 2011-11 As prescribed in 19.508(f), insert the following clause:

Notice of Set-Aside of Orders (Nov 2011) The Contracting Officer will give notice of the order or orders, if any, to be set aside for small business concerns identified in 19.000(a)(3) and the applicable small business program. This notice, and its restrictions, will apply only to the specific orders that have been set aside for any of the small business concerns identified in 19.000(a)(3).

(End of clause)

52.219-28 Post-Award Small Business Program Rerepresentation. 2013-07 As prescribed in 19.309(c), insert the following clause:

Post-Award Small Business Program Rerepresentation (Jul 2013)

(a) Definitions. As used in this clause-

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.