_Exhibit F. Notification of Compliance with Contract Insurance Requirements.pdf
PDF 2 MB Posted
- Solicitation number
- W50S6X-23-R-0006
- Issued by
-
Department of the Army National Guard
About this file
This document is a notification of compliance with contract insurance requirements for a federal contract opportunity for asphalt paving repair services at the Delaware Air National Guard. The contractor acknowledges they understand and will maintain the required insurance types and amounts specified in FAR 28.307-2 for the duration of the contract and any extensions. Insurance policies will contain endorsements stating any cancellation or material changes adversely affecting the government's interests will not be effective for the period prescribed by Delaware law or 30 calendar days after notice is given to the contracting officer, whichever is longer. Delaware workers' compensation insurance or a letter of reciprocal agreement must also be maintained for the entire performance period of the contract and any extensions. Copies of subcontractor proofs of required insurance will be maintained and made available to the contracting officer upon request.
The related federal contract opportunity is solicitation number W50S6X-23-R-0006 from the Department of the Army National Guard for asphalt paving repair including full replacement base course aggregate and bituminous, mill and overlay hot mix, drainage, sealant and striping for approximately 7,600 square yards in 13 contiguous areas at the Delaware Air National Guard. The estimated price range for the work if all options are exercised through September 2023 is $500,000 to $1,000,000. Bidders must submit a bid bond with their proposal and payment and performance bonds will be required within 10 days of award.
View the file
Other files
Show all 17
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Notification of Compliance with Contract Insurance Requirements
Contract No.:
The undersigned Contractor hereby acknowledges that it understands the insurance requirements specified in this contract and hereby provides notification (1) that such insurance shall be maintained in at least the amounts and types as stated in FAR 28.307-2 and during any modifications and/or time extensions granted thereto; (2) that the required insurance policies shall contain an endorsement to the effect that any cancellation of material changes adversely affecting the Government's interest shall not be effective for such period as the laws of the State in which this contract is to be performed prescribe, or until thirty (30) calendar days after the insurer or contractor gives written notice to the Contracting Officer, whichever period is longer; (3) that Delaware Workers' Compensation Insurance, or letter of reciprocal agreement with another state, shall be maintained on this contract for and during the entire performance period and for any modifications and/or time extensions granted thereto; and (4) that a copy of all subcontractors' proofs of required insurance shall be maintained and shall be made available to the Contracting Officer upon request. This agreement shall be a part of subject contract and shall be legally binding and enforceable at law.
INSURANCE COMPANY(S):
Name
Address
Policy No.
Telephone No.
CONTRACTOR:
Name
Address
Telephone No.
Typed Name and Title
Authorized Signature Date:
NGB May 2022 D-19
File details come from the government source that posted it. Updated .