County_LD_Schedule_(for_Purchasing_only)_.xlsx
XLSX spreadsheet 26 KB Posted
- Attached to
- FY 2026 Pavement Preservation Package 1-STEP 2
- Solicitation number
- 25-0070-ITB-C STEP 2
- Issued by
- Pinellas County, Clewiston City, Florida
About this file
This document is a Liquidated Damages Calculator spreadsheet for Pinellas County's FY 2026 Pavement Preservation Package 1 (Project ID 25-0070), involving a roadway improvement project. The project encompasses approximately 34.98 lane miles, including one arterial and four local neighborhood projects, with a planned construction duration of 210 calendar days. The Engineer's estimated probable construction cost is $5,606,585.30, and the project aims to promote traffic safety and efficiency within the county's roadway network.
The liquidated damages for this project are calculated at $1,434.66 per day of delay, based on various factors including construction administration fees, project overhead, and potential daily administrative costs. The calculation methodology considers elements such as construction administration fees, project manager time, and potential indirect costs associated with project delays. The document provides a detailed framework for determining and documenting liquidated damages, emphasizing the importance of creating a transparent and justifiable approach to calculating potential financial penalties for project timeline deviations.
View the file
Other files
Show all 26
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Table
| LIQUIDATED DAMAGES CALCULATOR |
| Project Name: FY 26 Pavement Preservation Package 1 |
| PID No.: 25-0070- REQ |
| Enter Design Consultant's total post design fee | $ - 0 |
| Enter Construction Administrator's total Fee | N/A |
| Duration of Construction (calendar days) | 210 |
| Enter Total Project Enclosed Square Footage (if applicable) | N/A |
| Enter Total Daily Department PM/APM Full time Equivalents | N/A |
| Engineer's Estimate of probable construction cost | $ 5,606,585.30 |
| Elements for Liquidated Damages Determination: | ||
| Design Consultant Fees | $ - 0 | Total post design fee divided by construction duration *3% |
| Construction Administration/Inspection | $ 1,356.00 | Daily combined burdened rate for CA staff + Consultant CEI |
| Project Manager/Assistant Project Manager | $ 78.66 | (1 hour/day burdened rate) |
| Department Project Overhead | LD Schedule | |
| Agency Administrative Costs | $ - 0 | |
| Temporary Heat/Cooling/Electric | $ - 0 | |
| Temporary Storage of Owner Provided FFE | $ - 0 | |
| Rental/Lease of Facilites for Staff, and/or Clients | $ - 0 | |
| Lost revenues | $ - 0 | |
| Lost grant revenues | $ - 0 | |
| Interest | $ - 0 | |
| Rental / moving expenses | $ - 0 | |
| Cost for Insurance | ||
| Other | ||
| Total Liquidated Damages Amount per day | $ 1,434.66 | |
| Prepared by: | ||
| Edit Highlighted Areas |
Definitions
| A. LIQUIDATED DAMAGES: |
| Liquidated damages are a specific sum (or a sum readily determinable) of money, stipulated by the contracting parties, as the amount to be recovered for each day of delay in delivery of the product. |
| Typically, the actual damage amount is unknown or difficult to estimate and is liquidated by the mutual agreement to the rate. Liquidated damages must be based on a reference to a definite standard, such as market value, established experience, or direct inference from known circumstances. |
| Liquidated damages can not be speculative or a penalty. |
| B. RATE DETERMINATION: |
| The amount of liquidated damages must be reasonable to ensure that the damages will not be held to be unenforceable. Therefore, the rate of liquidated damages, also, must be reasonable and is figured on a project-by-project basis. |
| On the other hand, you do not want to set the liquidated damages at too low an amount. Once liquidated damages are included in a contract, you will be unable to recover actual damages in excess of the specified amount. |
| C. HOW TO DETERMINE THE AMOUNT OF ANTICIPATED ACTUAL DAMAGES IN ORDER TO ESTABLISH AN APPROPRIATE AMOUNT FOR LIQUIDATED DAMAGES: |
| Examples of Elements of Rate Determination are listed below (All rates to be based on daily cost). The following list of criteria should be considered when determining anticipated damages that may be caused by a delay in the completion of a project. |
| Some of these are hard costs; others are based upon nonquantifiable factors. |
*Design Consultant Fees – calculated as the construction administration portion of the consultant fee divided by the construction duration multiplied by 3% per year based on duration. If not known, use estimate.
| *Construction Administration Fee - Generally calculated by the Construction Division; however, if Construction Division is not inspecting, cost can be based on the total cost for CA divided by the construction duration (multiplied by 3%/year). |
| FDOT grant funded projects will use the FDOT LD Schedule. |
| *Project Manager/Assistant Project Manager Time – Hourly burdened rate of PM or APM. |
| *DPW Project Overhead - based upon daily rate for DPW administrative overhead costs not recovered in PM billing rate. |
| *Agency Administrative Costs – based upon daily rate for agency personnel assigned to work on project or agency personnel required to spend a portion of their time should be included at that percentage of the daily rate. |
| *Temporary Heat/Cooling/Electric, Owner provided – Per S.F. of project area/day. |
| *Temporary Storage of Owner provided FFE – Costs for storage of Furniture, Fixtures, and Equipment, or other storage of products or materials caused by the delayed turn over of the facility. |
| *Rental/Lease of Facilities for Staff, and/or Clients – calculated in coordination with the agency representative based upon specific needs and available alternatives. |
| *Loss of revenue - Loss of potential revenue from a facility not opening as scheduled. |
| *Loss of grant - Loss of grant funding should the project not be completed on time. |
| *Interest (on borrowed funds) during unexcused delays in completion or periods of non-use. |
| *Rental/moving or other expenses for alternate space. |
| *Costs for insurance, utilities, or equipment. |
| D. HOW TO DOCUMENT THE MEANS BY WHICH LIQUIDATED DAMAGES ARE ESTABLISHED: |
| 1. Determine your anticipated actual per diem damages using criteria such as those listed above. |
| 2. Determine the appropriateness of the figure arrived at in Step 1. The anticipated figure may be used, or a percentage of that figure may be determined to be more appropriate for liquidated damages. |
| 3. Create a typewritten document of the criteria, calculations, and judgments used above. |
| 4. Place the documentation with the Contracts Unit project file for future reference. It is essential to keep all of the records used to determine the per diem liquidated damages amount. |
| This documentation is important to resolve possible future claims, for audit purposes, and for reference in developing future liquidated damages clauses. |
Sheet3
File details come from the government source that posted it. Updated .