CDRL A0001 Project Time Chart.docx
DOCX document 30 KB Posted
- Attached to
- Computer Numerical Control (CNC) with Live Tooling Federal contract opportunity
- Solicitation number
- W911RQ-23-R-9999
About this file
This document contains a Contract Data Requirements List (CDRL) and details of a related federal contract opportunity. The CDRL requires the submission of a project time chart showing milestones for the installation of a CNC lathe with live tooling within 12 months of award. The time chart must include adequate safety factors for potential delays and any extensions must be approved by the Contracting Officer.
The related federal contract opportunity is a solicitation issued by the Red River Army Depot seeking quotes for the purchase of one HAAS ST-40L CNC lathe with live tooling or equal, including installation, software, startup and training. Quotes are due by the date specified in the solicitation. The requirement is set aside for small businesses with a size standard of 500 employees. The required delivery date and other contractual terms will be determined upon award.
View the file
Other files for this federal contract opportunity
| File | Type | Posted |
|---|---|---|
| CDRL A0004 Final Acceptance Testing.docx | DOCX document | |
| (SUPPLY) LOCAL TERMS AND CONDITIONS updated 1-13-22.docx | DOCX document | |
| CDRL A0005 Training.docx | DOCX document | |
| CDRL A0002 Installation Schedule.docx | DOCX document | |
| CDRL A0003 Lockout Tagout.docx | DOCX document | |
| CDRL A0006 Manuals.docx | DOCX document | |
| COMBINED SYNOPSIS CNC Lathe.docx | DOCX document |
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
OCONTRACT DATA REQUIREMENTS LIST (CDRL)
(1 Data Item) Form Approved OMB No. 0704-0188
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services Directorate (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
| A. CONTRACT LINE ITEM NO. |
| B. EXHIBIT |
| C. CATEGORY: |
| TDP ____ |
| TM _____ |
| OTHER X |
| D. SYSTEM/ITEM |
| E. CONTRACT/PR NO. |
| F. CONTRACTOR |
| CNC Lathe with live tooling |
| 1. DATA ITEM NO. |
| 2. TITLE OF DATA ITEM |
| 3. SUBTITLE |
17. PRICE GROUP
| 0001 |
| Project Time Chart |
| 4. AUTHORITY (Data Acquisition Document No.) |
| 5. CONTRACT REFERENCE |
| 6. REQUIRING OFFICE |
18. ESTIMATED
TOTAL PRICE
| PD 3.0 |
| RRAD, Contracting |
| 7. DD 250 REQ |
| 9. DIST STATEMENT |
| 10. FREQUENCY |
| 12. DATE OF FIRST SUBMISSION |
| 14. DISTRIBUTION |
| DD |
| REQUIRED |
| ASRE Q |
| SEE BLOCK 16, ASREQ |
| a. ADDRESSEE |
| b. COPIES |
| 8. APP CODE |
| B |
| 11. AS OF DATE |
| 13. DATE IF SUBSEQUENT SUBM. |
| Draft |
| Final |
A
| SEE BLOCK 16 |
| SEE BLOCK 16 |
| Reg |
| Repro |
| 16. REMARKS |
| RRAD, Contracting |
Per block 5. The Contractor shall be submit a detailed project time chart that shows milestones for a completed machine installation within 12 months. The chart must reflect adequate safety factors for delays. Any modifications or extensions shall be requested through the Contracting Officer for this contract. Reference PD 3.0
Per block 8. POC will review projected time chart IAW with PD and will inform contracting on necessary changes to be made if any within seven (7) working days.
Per block 9. For administrative and operational use only. (See DoDI 5230.24)
Per block 10. Project Time Chart will be required one time only prior to work start.
Per block 11. Project Time Chart will be required one time only prior to work start.
Per block 12. . Project Time Chart will be required one time only prior to work start.
Distribution addresses:
POC – Jay Oliver, Production Engineering Division Luke Leitschuck, RRAD, Contracting
Repro = electronic delivery
| PED, POC |
| 1 |
| 1 |
| 15. TOTAL ▬▬▬▬► |
| 1 |
| 2 |
| 0 |
| G. PREPARED BY |
| H. DATE |
| I. APPROVED BY |
| J. DATE |
| Jay Oliver |
| 12 Dec 2022 |
| Andy Graves, Chief Facilitization Team |
| 12 Dec 2022 |
File details come from the government source that posted it. Updated .