Attachment A - 26R0219 - Steam Decentralization General Requirements.pdf

NAVAL FACILITIES ENGINEERING SYSTEM COMMAND, MID-ATLANTIC

9324 VIRGINIA AVE, BLDG Z-140, ROOM 216

NAVAL STATION NORFOLK, NORFOLK, VA 23511

POC: Stefan Nassaney, 401-841-4443, stefan.e.nassaney.civ@us.navy.mil

DESIGN-BUILD (DB)/DESIGN-BID-BUILD (DBB), INDEFINITE DELIVERY/INDEFINITE

QUANTITY (IDIQ) MULTIPLE AWARD CONSTRUCTION CONTRACT (MACC) FOR

FACILITIES IN THE NORTH AREA OF RESPONSIBILITY (AOR) TO INCLUDE

CONNECTICUT, DELAWARE, MAINE, MASSACHUSETTS, NEW HAMPSHIRE, NEW

JERSEY, NEW YORK, PENNSYLVANIA, RHODE ISLAND, AND VERMONT

MACC GROUP: ML-C00068

SOLICITATION NUMBER: N4008526R0219

Design Bid Build - Decentralize Steam - Provide Natural Gas Fired Boilers at Buildings 23A, 43, 44, 49 at Naval Health Care New England (NHCNE) Newport, RI

DATE OF SOLICITATION:

07 JULY 2026

NORTH AOR MACC CONTRACT HOLDERS:

N40085-21-D-0052 Benaka Inc.

7 Lawrence Street New Brunswick, New Jersey 08901 POC: C.N. Manjunath Phone: (732) 246-7060 Email: benaka@benakainc.com

N40085-21-D-0053 CCI Utility and Construction Services, LLC 111 W. 16th Avenue, Suite 402 Anchorage, AK 99501 POC: Jim Henebury Jeffrey Eaton Tim Nichols Phone: (207) 485-6701 Email: jhenebury@bbch-llc.com jeaton@bbch-llc.com Const-estimating@bbch-llc.com Const-proposals@bbch-llc.com

N40085-21-D-0054 Kunj Construction Corporation 163 B Paris Avenue Northvale, NJ 07647 POC: Neekunj Bhanderi Yatin Gajera Raghav Krish Phone: (201) 694-7617 Email: neekunjb@gmail.com Yatin@kunjcc.com Krish@kunjcc.com

N40085-21-D-0055 Ocean Construction Services 104 Aragona Boulevard, Suite 101 Virginia Beach, VA 23462 POC: Kara Laskowski Phone: (757) 200-9590 Email: bids@ocsinc.us

N40085-21-D-0056 PEM-Harkins Joint Venture 6161 Busch Boulevard, Suite 255 Columbus, OH 43229 POC: Radagodage Sumanaweera Phone: (614) 573-7299 Email: tsumanaweera@peminc.biz

N40085-21-D-0057 Tantara Corporation 54 Mason Street Worcester, MA 01610 POC: Dawn Dearborn Phone: (508) 752-5599 Email: DDearborn@tantaracorp.com mailto:stefan.e.nassaney.civ@us.navy.mil mailto:benaka@benakainc.com mailto:jhenebury@bbch-llc.com mailto:jeaton@bbch-llc.com mailto:Const-estimating@bbch-llc.com mailto:Const-proposals@bbch-llc.com mailto:neekunjb@gmail.com mailto:Yatin@kunjcc.com mailto:Krish@kunjcc.com mailto:bids@ocsinc.us mailto:tsumanaweera@peminc.biz mailto:DDearborn@tantaracorp.com

Decentralize Steam NHCNE Solicitation No.: N4008526R0219 Naval Station Newport, Newport, RI Work Order No.: 1929728

N40085-21-D-0066 J&J Contractors, Inc.

101 Billerica Avenue, Building 5, Suite 205 North Billerica, MA 01862 POC: Kamlesh Patel Phone: (978) 259-2454 Email: kamp@jjcontractor.com

GENERAL REQUIREMENTS

All terms and conditions of N4008521D0052/0053/0054/0055/0056/0057/0066 IDIQ Contract apply to this solicitation. Please review your MACC award document for guidance on contract clauses and requirements that may pertain to this order. You are responsible to adhere to all applicable clauses, even if they are not restated in this RFP package or the Task Order award document. For clarification on any clause or other contractual issue please contact Stefan Nassaney at stefan.e.nassaney.civ@us.navy.mil.

Amendments will be posted directly to PIEE, Sam.gov, and sent directly via email to MACC Holders. It is ultimately the responsibility of the MACC Holders to monitor SAM.gov for any updates.

NAVFAC Solicitation No.: N4008526R0219

NAVFAC Specification/Drawing: Work Order No. 1929728

Title: Design Bid Build - Decentralize Steam - Provide Natural Gas Fired Boilers at Buildings 23A, 43, 44, 49 at Naval Health Care New England (NHCNE) Newport, RI (eProjects#1929728)

Location of the work: Naval Station Newport, Newport, Rhode Island

Description of the work:

The work includes removal of (4) facilities from the building A6 steam supply system. The (4) buildings being taken off of steam service (23A, 43, 44, and 49) shall have their steam to heating hotwater exchangers removed and natural gas boilers provided in their place. Building B23A shall also have its domestic hot water heaters replaced.

Work includes the trenching and backfilling for the installation of gas piping to each of four buildings, restoration of paving due to gas piping installation, The contractor shall be responsible for connecting to the utility meter and provide gas distribution to the installed boilers.

NATURAL GAS LINE WORK:

Summary: Provision of natural gas to the buildings getting new boilers shall be accomplished as follows:

The construction contractor to whom this specification applies shall provide all site work (excavation, trench preparation, backfill, paving,site restoration, etc.) and Rhode Island Energy (RIE) will provide the gas line/piping installation up to and including the gas meters in the prepared trenches under a separate contract with the Navy. (Note 'National Grid' shall be interpreted as 'Rhode Island Energy' in all instances in this specification and on the drawings). As such, for bidding purposes, the construction contractor shall include costs for site work required for gas line installation, but shall not include costs related to the actual pipe installation. The trench shall be prepared in accordance with specifications provided by RIE.

mailto:kamp@jjcontractor.com mailto:stefan.e.nassaney.civ@us.navy.mil

NAVFAC will assist in coordination between the construction contractor and RIE, however the construction contractor shall establish working level communication with RIE to ensure proper site coordination and scheduling. The construction contractor shall not direct RIE to perform or not perform any work. The construction contractor shall immediately bring to the attention of the Contracting Officer any and all issues with gas line installation.

The construction contractor shall be responsible for providing all natural gas piping and appurtenances from the exterior meter through the exterior wall into the building up to the boilers.

Controls for each facility shall tie into the existing BACnet through the existing Johnson Controls MetaSYS controllers. Each boiler shall have its own factory furnished controller to manage internal functions. The MetaSYS shall perform supervisory control and accept all alarms from the boilers.

Work also includes pouring concrete housekeeping pads for new equipment along with removal of some interior building trenches no longer needed. They shall be filled in and have a new concrete slab poured.

Holes in foundations where pipes are removed shall be filled in with concrete. Additionally penetrations through roofs for piping shall be reinforced and flashing and roofing repairs shall be made along with incidental related work.

Estimated Budget Amount or Price Range: In accordance with FAR 36.204(f) Disclosure of the Magnitude of Construction Projects, the estimated price range for this project is between $1,000,000 and $5,000,000.

Time for completion: In accordance with FAR 52.211-10 Commencement, Prosecution, and Completion of Work, the deadline for completion of this task order (including Bid Options, if applicable) shall be 365 calendar days from date of award (includes 15 calendar days for submission and approval of bonds and insurance). Consistent with FAR 52.211-10, completion of the entire work ready for use must occur prior to the aforementioned date. The time stated for completion shall include final cleanup of the premises.

Wage Determination: Department of Labor (DoL) General Decision Number: RI20260001 05/18/2026 (Attachment E) applies to this work. Should this wage determination be modified by DoL prior to award, the most current wage determination will be incorporated in the award.

Liquidated damages: In accordance with FAR 52.211-12 Liquidated Damages, if the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government for each calendar day of delay until the work is completed or accepted. See associated liquidated damages below:

Estimate Number of Days Liquidated Damages 365 calendar days from date of award $576.25

Utilities: The Contractor shall be responsible for obtaining all utilities required for construction and testing.

The Contractor shall provide these utilities at his/her expense, paid for at the current utility rate delivered to the job site. The Contractor shall provide and maintain all temporary utility connections and distribution lines, and all meters required to measure the amount of each utility used.

Record Shop Drawings: In accordance with FAR 52.236.21, Specifications and Drawings for Construction, record shop drawings are required. Reproducible copies of these record drawings are not required.

Government Furnished Property: There is no Government Furnished Property.

Bond Requirements: In accordance with FAR 52.228-1, Bid Guarantees, each offeror shall submit with its offer a guarantee bond (Standard Form 24) in a penal sum equal to at least 20 percent of the offer price or $3,000,000, whichever is less.

Performance and Payment Bonds are required from the contract task order awardee ten (10) calendar days after date of award.

Proposal Acceptance Period: Proposal acceptance period shall be 120 days from receipt of offers.

Definitization Of Equitable Adjustments For Change Orders Under Construction Contracts: No data is available regarding the timely definitization of equitable adjustments for change orders under construction contracts. The REA definitization information referenced in Navy Marine Corps Acquisition Regulation Supplement (NMCARS) 5236.211(b)(2), should not be utilized. There are no agency-specific policies and procedures that apply to the definitization of equitable adjustments for change orders under construction contracts. This Contract contains rated order quantities certified for national defense use, and you are required to follow all the provisions of the DPAS regulation (DPAS Regulation - 15 CFR Part 700.12) only as it pertains to the rated quantities.

Pre-Proposal Inquiries (PPIs): Offerors who determine that the technical and or contractual requirements of this RFP require clarification(s) in order to permit submittal of a responsive proposal shall submit all questions in writing. All inquiries shall be submitted via email to Stefan Nassaney at stefan.e.nassaney.civ@us.navy.mil no later than, ten (10) calendar days prior to proposal due date.

Additionally, all inquiries shall be submitted using the Pre-Proposal Inquiry (PPI) form (Attachment F).

Do not submit the same inquiry more than once. Please verify that inquiries submitted by you on behalf of your subcontractors are not duplicates. A response will be published via an amendment by email to MACC holders.

Site Visit: All MACC holders are invited to attend the Site Visit for this project. Firms participating in the site visit will not be directly compensated for their participation.

Date: 22 July 2026 Time: 0830 AM Meeting Location: Naval Health Clinic Front Entrance on Naval Station Newport, Newport, RI

**** PLEASE BRING A HARD HAT ****

After following the necessary steps for obtaining base access, all attendees should meet at the Naval Health Clinic on base. Please refer to Attachments H, I, and J for more detailed site visit information.

Base Access Instructions: Refer to Attachments H, I, and J for Base Access.

***ALL BASE ACCESS FORMS ARE DUE NO LATER THAN NOON 15 JULY 2026.***

Site Visit Attachments:

ATTACHMENT H: NSN NHCNE SITE VISIT PROCEDURES

ATTACHMENT I: SECNAV 5512 FORM

mailto:stefan.e.nassaney.civ@us.navy.mil

ATTACHMENT J: SITE VISIT MAP

Site Visit POCs:

Stefan Nassaney, Contract Specialist, Office: 401-841-4443 Raymond Cournoyer, Project Manager, Office: 401-841-7625

Proposal Due Date: THURSDAY, 14 AUGUST 2026 AT 02:00PM EST. LATE PROPOSALS WILL BE HANDLED IN ACCORDANCE WITH FAR 15.208(b).

Proposal Submission Instructions: In response to this request for proposal, the complete proposal shall include the Price Proposal, submitted in accordance with the Basis of Evaluation and Submittal Requirements. The Offeror shall submit an electronic copy of the proposal in accordance with the instructions below by the proposal due date.

Electronic Copies: Only the PIEE Solicitation Module is authorized for the submission of electronic proposals in response to this solicitation. Electronic proposal submissions should be no larger than 1.9 GB per file. Offerors shall ensure that the Government has received the electronic proposal prior to the date and time specified. PIEE Solicitation Vendor Access Instructions are provided via Attachment E. Emailed, mailed, and hand-delivered submissions will not be accepted.

Offerors shall allow adequate time to upload files which may be slower for non-DoD users and to avoid other technical difficulties that may be encountered. Offerors are also responsible for submitting files in the format specified and consistent with requirements stated elsewhere in this solicitation. Files that cannot be opened or are otherwise missing the required content are the responsibility of the Offeror.

The PIEE system will record the date and time of package submittal. Upon successful receipt of the proposal through PIEE, the Offeror should receive an email confirmation. Please keep this for your records. The date and time of package receipt recorded in PIEE shall govern the timeliness of any proposal submission. Late responses will be handled in accordance with FAR 15.208(b).

Evaluation Factors for Award:

The proposed task order will be awarded to the responsible Offeror offering the best value to the Government. The lowest price source selection process is selected as appropriate for this acquisition because the best value is expected to result from selection of the proposal with the lowest evaluated price.

To make a determination of best value, the Government shall evaluate each Offeror on price only.

Basis of Evaluation and Submittal Requirements.

Price:

i. Solicitation Submittal Requirements:

Price shall be submitted on the Price Proposal Form included in the solicitation. The offeror shall submit one (1) electronic copy via The Procurement Integrated Enterprise Environment (PIEE), with the solicitation submittal requirements identified below:

a. Cover page with solicitation number, solicitation title, offeror name, address, phone number, Employer Identification Number (EIN), Unique Entity Identifier (UEI) in SAM, CAGE code, Federal Tax ID number, Point of Contact (POC), POC phone number, and

POC email address;

b. All amendments acknowledged;

c. Price Proposal Form (Attachment D);

d. Copy of Representation and Certifications and proof of registration in System for Award

Management (SAM);

e. Confirmation of filing of Veterans’ Employment and Training (VETS) VETS-4212 for the 2024/2025 filing cycle; and

f. Bid Guarantee in accordance with FAR Clause 52.228-1, Bid Guarantee. Amount shall be at least twenty percent (20%) of the proposed price, but shall not exceed $3 million

The Offeror is required to submit a complete Price Proposal Form that includes completion of all line-item numbers. All required proposal documents shall be submitted in accordance with FAR 15.208.

ii. Basis of Evaluation:

The Government will evaluate price based on the total lump sum price. Analysis will be performed by one or more of the following tecniques to ensure a fair and reasonable price:

a. Comparison of proposed prices received in response to the RFP.

b. Comparison of the proposed prices with the Independent Government Cost Estimate

(IGCE).

c. Comparison of proposed prices with available historical information.

d. Comparison of market survey results.

Evaluation:

1. The Government reserves the right to eliminate from consideration for award any or all offers at any time prior to award of the contract; to negotiate with offerors in the competitive range; and to award the contract to the Offeror submitting the lowest price proposal.

2. The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. In addition, if the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

ATTACHMENTS:

Attachment A - 26R0219 - Steam Decentralization General Requirements Attachment B - Decentralization_SPECIFICATION Attachment C - Decentralization_DRAWINGS Attachment D - Bid Schedule Attachment E - Wage Determination RI20260001 Attachment F - Pre-Proposal Inquiry (PPI) form Attachment G - PIEE Vendor Access Instructions Attachment H - NSN NHCNE SITE VISIT PROCEDURES Attachment I - SECNAV 5512 FORM Attachment J - SITE VISIT MAP

Attachment B - C

Specifications and Drawings

See separately attached PDF Files labeled as follows:

Specifications:

Attachment B - Decentralization_SPECIFICATION

Drawings:

Attachment C - Decentralization_DRAWINGS

Attachment D

Price Proposal Form

ATTACHMENT D: Price Proposal Form (PPF)

Attachment E

Wage Determination

"General Decision Number: RI20260001 05/18/2026

State: Rhode Island

Construction Types: Building, Heavy and Highway

Counties: Rhode Island Counties of Bristol, Kent, Newport, Providence and Washington

Includes Marine Construction Projects

Modification Number Publication Date 2 01/30/2026 3 05/18/2026

ASBE0006-006 09/01/2024

Rates Fringes

HAZARDOUS MATERIAL HANDLER (INCLUDES PREPARATION,

WETTING, STRIPPING, REMOVAL SCRAPPING, VACUUMING,

BAGGING & DISPOSING OF ALL INSULATION MATERIALS,

WHETHER THEY CONTAIN ASBESTOS OR NOT, FROM

MECHANICAL SYSTEMS).................................$ 49.91 36.63

ASBE0006-008 09/01/2024

Rates Fringes

ASBESTOS WORKER/INSULATOR (INCLUDES APPLICATION OF

ALL INSULATING MATERIALS, PROTECTIVE COVERINGS,

COATINGS & FINISHES TO ALL TYPES OF MECHANICAL

SYSTEMS)............................................$ 49.91 36.63

BOIL0029-001 01/01/2025

Rates Fringes

BOILERMAKER.........................................$ 50.62 28.82

BRRI0003-001 06/01/2022

Rates Fringes

BRICKLAYER, STONEMASON, POINTER, CAULKER & CLEANER..$ 46.86 29.14

BRRI0003-002 09/01/2022

Rates Fringes

MARBLE SETTER, TERRAZZO WORKER & TILE SETTER........$ 46.54 30.34

BRRI0003-003 09/01/2022

Rates Fringes

MARBLE, TILE & TERRAZZO FINISHER....................$ 38.78 29.61

CARP0330-001 01/01/2023

Rates Fringes

PILEDRIVER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 41.53 29.35

WELDER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER TENDER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 60.83 30.50

CARPENTER: INCLUDES SOFT FLOOR LAYER................$ 47.88 30.50

CARP0330-001 06/02/2025

Rates Fringes

PILEDRIVER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 41.53 29.35

WELDER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER TENDER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 60.83 30.50

CARPENTER: INCLUDES SOFT FLOOR LAYER................$ 47.88 30.50

CARP1121-002 04/21/2025

Rates Fringes

MILLWRIGHT..........................................$ 45.72 31.50

ELEC0099-002 06/01/2025

Rates Fringes

TELEDATA SYSTEM INSTALLER FOOTNOTES: WORK OF

A HAZARDOUS NATURE, OR WHERE THE WORK HEIGHT IS 30

FT. OR MORE FROM THE FLOOR, EXCEPT WHEN WORKING

OSHA-APPROVED LIFTS: 20% PER HOUR ADDITIONAL.

WORK IN TUNNELS BELOW GROUND LEVEL IN COMBINED

SEWER OUTFALL: 20% PER HOUR ADDITIONAL..............$ 42.09 19.71

ELECTRICIAN FOOTNOTES: WORK OF A HAZARDOUS

NATURE, OR WHERE THE WORK HEIGHT IS 30 FT. OR MORE

FROM THE FLOOR, EXCEPT WHEN WORKING OSHA-APPROVED

LIFTS: 20% PER HOUR ADDITIONAL. WORK IN TUNNELS

BELOW GROUND LEVEL IN COMBINED SEWER OUTFALL: 20%

PER HOUR ADDITIONAL.................................$ 56.11 24.74

ELEV0039-001 01/01/2025

Rates Fringes

ELEVATOR MECHANIC FOOTNOTES: A. PAID HOLIDAYS:

NEW YEARS DAY; MEMORIAL DAY; INDEPENDENCE DAY;

LABOR DAY; VETERANS' DAY; THANKSGIVING DAY; THE

FRIDAY AFTER THANKSGIVING DAY; AND CHRISTMAS DAY.

B. EMPLOYER CONTRIBUTES 8% BASIC HOURLY RATE FOR

5 YEARS OR MORE OF SERVICE OF 6% BASIC HOURLY RATE

FOR 6 MONTHS TO 5 YEARS OF SERVICE AS VACATION PAY

CREDIT..............................................$ 64.52 38.44

ENGI0057-001 12/01/2025

Rates Fringes

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 9 BOAT & TUG OPERATOR.

A. BOOM LENGTHS, INCLUDING JIBS: 150 FEET

AND OVER + $ 2.00 180 FEET AND OVER + $ 3.00 210

FEET AND OVER + $ 4.00 240 FEET AND OVER + $ 5.00

270 FEET AND OVER + $ 7.00 300 FEET AND OVER + $

8.00 350 FEET AND OVER + $ 9.00 400 FEET AND OVER

+ $10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 48.92 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 8 HEATER, CONCRETE MIXER, STONE

CRUSHER, WELDING MACHINE, GENERATOR AND LIGHT

PLANT, GAS AND ELECTRIC DRIVEN PUMP AND AIR

COMPRESSOR.

A. BOOM

LENGTHS, INCLUDING JIBS: 150 FEET AND OVER + $

2.00 180 FEET AND OVER + $ 3.00 210 FEET AND OVER

+ $ 4.00 240 FEET AND OVER + $ 5.00 270 FEET AND

OVER + $ 7.00 300 FEET AND OVER + $ 8.00 350 FEET

AND OVER + $ 9.00 400 FEET AND OVER + $10.00 A.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 45.00 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 7 UTILITY ENGINEERS AND SIGNAL PERSONS

A.

BOOM LENGTHS, INCLUDING JIBS: 150 FEET AND OVER +

$ 2.00 180 FEET AND OVER + $ 3.00 210 FEET AND

OVER + $ 4.00 240 FEET AND OVER + $ 5.00 270 FEET

AND OVER + $ 7.00 300 FEET AND OVER + $ 8.00 350

FEET AND OVER + $ 9.00 400 FEET AND OVER + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 33.15 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 6 WELL-POINT INSTALLATION CREW.

A. BOOM LENGTHS, INCLUDING JIBS: 150 FEET AND

OVER + $ 2.00 180 FEET AND OVER + $ 3.00 210 FEET

AND OVER + $ 4.00 240 FEET AND OVER + $ 5.00 270

FEET AND OVER + $ 7.00 300 FEET AND OVER + $ 8.00

350 FEET AND OVER + $ 9.00 400 FEET AND OVER +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 39.15 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 5 BULLDOZER, BOBCATS, SKID STEER

LOADER, TRACTOR, SCRAPER, COMBINATION LOADER

BACKHOE, ROLLER, FRONT END LOADER (LESS THAN 3

YDS.), STREET AND MOBILE-POWERED SWEEPER (3-YD.

CAPACITY), 8-FT. SWEEPER MINIMUM 65 HP).

A. BOOM LENGTHS, INCLUDING JIBS: 150

FEET AND OVER + $ 2.00 180 FEET AND OVER + $ 3.00

210 FEET AND OVER + $ 4.00 240 FEET AND OVER + $

5.00 270 FEET AND OVER + $ 7.00 300 FEET AND OVER

+ $ 8.00 350 FEET AND OVER + $ 9.00 400 FEET AND

OVER + $10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 48.35 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 4 OILER ON CRAWLER BACKHOE.

A. BOOM LENGTHS, INCLUDING JIBS: 150 FEET AND OVER

+ $ 2.00 180 FEET AND OVER + $ 3.00 210 FEET AND

OVER + $ 4.00 240 FEET AND OVER + $ 5.00 270 FEET

AND OVER + $ 7.00 300 FEET AND OVER + $ 8.00 350

FEET AND OVER + $ 9.00 400 FEET AND OVER + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 42.07 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 3 OILERS ON CRANES.

A. BOOM LENGTHS, INCLUDING JIBS: 150

FEET AND OVER + $ 2.00 180 FEET AND OVER + $ 3.00

210 FEET AND OVER + $ 4.00 240 FEET AND OVER + $

5.00 270 FEET AND OVER + $ 7.00 300 FEET AND OVER

+ $ 8.00 350 FEET AND OVER + $ 9.00 400 FEET AND

OVER + $10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 44.92 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 2 DIGGING MACHINE, ROSS CARRIER,

LOCOMOTIVE, HOIST, ELEVATOR, BIDWELL-TYPE MACHINE,

SHOT & WATER BLASTING MACHINE, PAVER, SPREADER,

GRADERS, FRONT END LOADER (3 YDS. AND OVER),

VIBRATORY HAMMER & VACUUM TRUCK, ROADHEADERS,

FORKLIFTS, ECONOMOBILE TYPE EQUIPMENT, TUNNEL

BORING MACHINES, CONCRETE PUMP AND ON SITE CONCRETE

PLANTS.

A. BOOM LENGTHS, INCLUDING

JIBS: 150 FEET AND OVER + $ 2.00 180 FEET AND

OVER + $ 3.00 210 FEET AND OVER + $ 4.00 240 FEET

AND OVER + $ 5.00 270 FEET AND OVER + $ 7.00 300

FEET AND OVER + $ 8.00 350 FEET AND OVER + $ 9.00

400 FEET AND OVER + $10.00 A. PAID HOLIDAYS: NEW

YEAR'S DAY, PRESIDENT'S DAY, MEMORIAL DAY, JULY

FOURTH, VICTORY DAY, LABOR DAY, COLUMBUS DAY,

VETERANS DAY, THANKSGIVING DAY, CHRISTMAS DAY. A:

ANY EMPLOYEE WHO WORKS 3 DAYS IN THE WEEK IN WHICH

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. A.

FOOTNOTES: HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL.......$ 49.30 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 1 CRANES, LIGHTERS, BOOM TRUCKS AND

DERRICKS

A. BOOM LENGTHS,

INCLUDING JIBS: 150 FEET AND OVER + $ 2.00 180

FEET AND OVER + $ 3.00 210 FEET AND OVER + $ 4.00

240 FEET AND OVER + $ 5.00 270 FEET AND OVER + $

7.00 300 FEET AND OVER + $ 8.00 350 FEET AND OVER

+ $ 9.00 400 FEET AND OVER + $10.00 A. PAID

HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 51.30 29.95

ENGI0057-003 12/01/2025

Rates Fringes

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 8 HEATER, CONCRETE MIXER, STONE CRUSHER,

WELDING MACHINE, GENERATOR FOR LIGHT PLANT, GAS AND

ELECTRIC DRIVEN PUMP & AIR COMPRESSOR

A. BOOM LENTHS, INCLUDING JIBS: 150 FT. AND OVER:

+ $ 2.00 180 FT. AND OVER: + $ 3.00 210 FT. AND

OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270 FT.

AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00 350

FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 44.54 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 7 WELL POINT INSTALLATION CREW

A. BOOM LENTHS,

INCLUDING JIBS: 150 FT. AND OVER: + $ 2.00 180

FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $ 4.00

240 FT. AND OVER: + $ 5.00 270 FT. AND OVER: + $

7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND OVER:

+ $ 9.00 400 FT. AND OVER: + $10.00 A.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 47.22 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 6 BULLDOZER,SKID STEER LOADERS,BOBCATS,

TRACTOR, GRADER, SCRAPER,COMBINATION LOADER

BACKHOE, ROLLER, FRONT END LOADER (LESS THAN 3

YDS.), STREET AND MOBILE POWERED SWEEPER (3 YDS.

CAPACITY), 8-FT. SWEEPER (MINIMUM 65 HP)

A. BOOM LENTHS, INCLUDING JIBS: 150 FT. AND OVER:

+ $ 2.00 180 FT. AND OVER: + $ 3.00 210 FT. AND

OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270 FT.

AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00 350

FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 47.65 29.95

GROUP 5 OILER ON CRAWLER BACKHOE

A. BOOM LENTHS, INCLUDING JIBS: 150 FT. AND

OVER: + $ 2.00 180 FT. AND OVER: + $ 3.00 210 FT.

AND OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270

FT. AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00

350 FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 41.50 29.95

GROUP 4 FIREMAN & OILER ON CRANES

LENTHS, INCLUDING JIBS: 150 FT. AND OVER: + $ 2.00

180 FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $

4.00 240 FT. AND OVER: + $ 5.00 270 FT. AND OVER:

+ $ 7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND

OVER: + $ 9.00 400 FT. AND OVER: + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 44.35 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 3 TELEHANDLER EQUIPMENT, FORKLIFT, CONCRETE

PUMP & ON-SITE CONCRETE PLANT

A. BOOM LENTHS, INCLUDING JIBS: 150 FT. AND OVER:

+ $ 2.00 180 FT. AND OVER: + $ 3.00 210 FT. AND

OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270 FT.

AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00 350

FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 48.35 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 2 DIGGING MACHINE, ROSS CARRIER, LOCOMOTIVE,

HOIST, ELEVATOR, BIDWELL-TYPE MACHINE, SHOT & WATER

BLASTING MACHINE, PAVER, SPREADER, FRONT END LOADER

(3 YDS. AND OVER), VIBRATORY HAMMER AND VACUUM

TRUCK

LENTHS, INCLUDING JIBS: 150 FT. AND OVER: + $ 2.00

180 FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $

4.00 240 FT. AND OVER: + $ 5.00 270 FT. AND OVER:

+ $ 7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND

OVER: + $ 9.00 400 FT. AND OVER: + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 48.57 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 1 CRANES, LIGHTERS, BOOM TRUCKS AND

DERRICKS.

A. BOOM

LENTHS, INCLUDING JIBS: 150 FT. AND OVER: + $ 2.00

180 FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $

4.00 240 FT. AND OVER: + $ 5.00 270 FT. AND OVER:

+ $ 7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND

OVER: + $ 9.00 400 FT. AND OVER: + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 50.57 29.95

ENGI0057-005 12/01/2025

Rates Fringes

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 8 GAS

AND ELECTRIC DRIVE HEATERS, CONCRETE MIXERS, LIGHT

PLANTS, WELDING MACHINES, PUMPS AND COMPRESSORS

A. FOOTNOTE: A. ANY

EMPLOYEE WHO WORKS THREE DAYS IN THE WEEK IN WHICH

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. B.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY.......................................$ 38.70 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 7

COMBINATION LOADER / BACKHOES, FRONT-END LOADERS

(LESS THAN 3 YDS.), FORKLIFT, BULLDOZERS, SCRAPERS,

BOATS, ROLLERS, SKID STEER LOADERS (REGARDLESS OF

ATTACHMENTS), STREET SWEEPERS, MECHANICS, WELDERS,

OPERATORS IN MATERIALS YARDS, SHOPS AND GARAGES

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. B.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY.......................................$ 43.43 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 6

OILERS ON CRANES AND DECKHANDS

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. B.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY.......................................$ 39.73 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 5

SIGNAL PERSONS

A.

FOOTNOTE: A. ANY EMPLOYEE WHO WORKS THREE DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 33.15 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 4

UTILITY ENGINEERS

A. FOOTNOTE:

A. ANY EMPLOYEE WHO WORKS THREE DAYS IN THE WEEK IN

WHICH A HOLIDAY FALLS SHALL BE PAID FOR THE

HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 25.75 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 3

WELLPOINT INSTALLATION AND DRILL/BORING MACHINE

ASSISTANTS

A. FOOTNOTE: A. ANY EMPLOYEE WHO WORKS THREE

DAYS IN THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE

PAID FOR THE HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S

DAY, PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH,

VICTORY DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 39.15 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 2

DIGGING MACHINES, EXCAVATORS, LOCOMOTIVES, JOHN

HENRY'S, DIRECTIONAL DRILLING MACHINES, COLD

PLANERS, RECLAIMERS, PAVERS, SPREADERS, GRADERS,

FRONT-END LOADERS (3YDS & OVER), VACUUM TRUCK,

DRILL/BORING MACHINE OPERATORS, VERMEER SAW, WATER

BLASTER, HYDRAULIC-DEMOLITION ROBOT, ROSS CARRIERS,

CONCRETE PUMP OPERATORS, ASPHALT/MATERIAL TRANSFER

MACHINES, ROTATING TELEHANDLERS, SPMT TYPE

EQUIPMENT

A. FOOTNOTE: A.

ANY EMPLOYEE WHO WORKS THREE DAYS IN THE WEEK IN

WHICH A HOLIDAY FALLS SHALL BE PAID FOR THE

HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 44.45 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 1

CRANES, PILE DRIVERS, LIGHTERS, BOOM TRUCKS,

HOISTS, DERRICKS

A. FOOTNOTE: A. ANY EMPLOYEE WHO WORKS THREE

DAYS IN THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE

PAID FOR THE HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S

DAY, PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH,

VICTORY DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 46.45 29.95

IRON0037-001 09/16/2025

Rates Fringes

IRONWORKER..........................................$ 43.03 33.53

LABO0271-001 12/03/2023

Rates Fringes

LABORER GROUP 5 (BUILDING CONSTRUCTION).............$ 39.00 26.90

LABORER GROUP 4 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABORER GROUP 3 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABORER GROUP 2 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABORER GROUP 1 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABO0271-002 11/27/2022

Rates Fringes

LABORER TEST BORING LABORER.........................$ 41.95 24.15

LABORER TEST BORING DRILLER.........................$ 41.95 24.15

LABORER OPEN AIR CAISSON, UNDERPINNING WORK AND

BORING CREW TOP MAN & LABORER...................$ 35.60 24.15

LABORER OPEN AIR CAISSON, UNDERPINNING WORK AND

BORING CREW BOTTOM MAN..............................$ 41.50 24.15

LABORER FREE AIR GROUP 3............................$ 42.45 24.15

LABORER FREE AIR GROUP 2............................$ 45.00 24.15

LABORER FREE AIR GROUP 1............................$ 46.00 24.15

LABORER COMPRESSED AIR GROUP 3......................$ 42.45 24.15

LABORER COMPRESSED AIR GROUP 2......................$ 52.93 24.15

LABORER COMPRESSED AIR GROUP 1......................$ 55.40 24.15

PAIN0011-005 06/01/2025

Rates Fringes

PAINTER (SPRAY, SAND & WATER BLASTING)..............$ 42.57 26.60

PAINTER (EPOXY, TANKS, TOWERS, SWING STAGE &

STRUCTURAL STEEL)...................................$ 41.57 26.60

PAINTER (BRUSH AND ROLLER)..........................$ 39.57 26.60

PAIN0011-006 06/01/2024

Rates Fringes

GLAZIER FOOTNOTES: SWING STAGE: $1.00 PER

HOUR ADDITIONAL. PAID HOLIDAYS: LABOR DAY &

CHRISTMAS DAY.......................................$ 41.63 26.15

PAIN0011-011 06/01/2024

Rates Fringes

PAINTER (BRIDGE WORK)...............................$ 57.85 26.40

PAIN0035-008 06/01/2011

Rates Fringes

SIGN PAINTER........................................$ 24.79 13.72

PLAS0040-001 01/01/2025

Rates Fringes

CEMENT MASON/CONCRETE FINISHER (BUILDING

CONSTRUCTION) FOOTNOTE: CEMENT MASON: WORK ON

FREE SWINGING SCAFFOLDS UNDER 3 PLANKS WIDTH AND

WHICH IS 20 OR MORE FEET ABOVE GROUND AND ANY

OFFSET STRUCTURE: $.30 PER HOUR ADDITIONAL..........$ 44.75 29.10

PLAS0040-002 01/01/2025

Rates Fringes

CEMENT MASON/CONCRETE FINISHER (HEAVY AND HIGHWAY

CONSTRUCTION).......................................$ 44.75 29.10

PLAS0040-003 01/01/2025

Rates Fringes

PLASTERER...........................................$ 45.52 29.43

PLUM0051-002 08/25/2025

Rates Fringes

PLUMBERS AND PIPEFITTERS............................$ 54.34 34.50

ROOF0033-004 12/01/2025

Rates Fringes

ROOFER..............................................$ 47.49 31.44

SFRI0669-001 04/01/2025

Rates Fringes

SPRINKLER FITTER....................................$ 53.76 33.44

SHEE0017-002 06/01/2025

Rates Fringes

SHEET METAL WORKER..................................$ 44.42 41.94

TEAM0251-001 05/01/2025

Rates Fringes

TRUCK DRIVER: HEAVY AND HIGHWAY CONSTRUCTION: GROUP

5 FOUR- AND FIVE-AXLE EQUIPMENT

FOOTNOTES:

A. PAID HOLIDAYS: NEW YEAR'S DAY, MEMORIAL DAY,

INDEPENDENCE DAY, LABOR DAY, THANKSGIVING DAY AND

CHRISTMAS DAY, PLUS PRESIDENTS' DAY, COLUMBUS DAY,

VETERAN'S DAY & V-J DAY, PROVIDING THE EMPLOYEE HAS

WORKED AT LEAST ONE DAY IN THE CALENDAR WEEK IN

WHICH THE HOLIDAY FALLS. B. EMPLOYEE WHO HAS

BEEN ON THE PAYROLL FOR 1 YEAR OR MORE BUT LESS

THAN 5 YEARS AND HAS WORKED 150 DAYS DURING THE

LAST YEAR OF EMPLOYMENT SHALL RECEIVE 1 WEEK'S PAID

VACATION; 5 TO 10 YEARS - 2 WEEKS' PAID VACATION;

10 OR MORE YEARS - 3 WEEK'S PAID VACATION. C.

EMPLOYEES ON THE SENIORITY LIST SHALL BE PAID A ONE

HUNDRED DOLLAR ($100.00) BONUS FOR EVERY FOUR

HUNDRED (400) HOURS WORKED, UP TO A MAXIMUM OF FIVE

HUNDRED DOLLARS ($500.00) ALL DRIVERS WORKING ON A

DEFINED HAZARD MATERIAL JOB SITE SHALL BE PAID A

PREMIUM OF $2.00 PER HOUR OVER APPLICABLE RATE.

........................................$ 32.21 34.51

10 TRACTOR TRAILER

FOOTNOTES: A. PAID HOLIDAYS: NEW YEAR'S DAY,

MEMORIAL DAY, INDEPENDENCE DAY, LABOR DAY,

THANKSGIVING DAY AND CHRISTMAS DAY, PLUS

PRESIDENTS' DAY, COLUMBUS DAY, VETERAN'S DAY & V-J

DAY, PROVIDING THE EMPLOYEE HAS WORKED AT LEAST ONE

DAY IN THE CALENDAR WEEK IN WHICH THE HOLIDAY

FALLS. B. EMPLOYEE WHO HAS BEEN ON THE PAYROLL

FOR 1 YEAR OR MORE BUT LESS THAN 5 YEARS AND HAS

WORKED 150 DAYS DURING THE LAST YEAR OF EMPLOYMENT

SHALL RECEIVE 1 WEEK'S PAID VACATION; 5 TO 10 YEARS

- 2 WEEKS' PAID VACATION; 10 OR MORE YEARS - 3

WEEK'S PAID VACATION. C. EMPLOYEES ON THE

SENIORITY LIST SHALL BE PAID A ONE HUNDRED DOLLAR

($100.00) BONUS FOR EVERY FOUR HUNDRED (400) HOURS

WORKED, UP TO A MAXIMUM OF FIVE HUNDRED DOLLARS

($500.00) ALL DRIVERS WORKING ON A DEFINED HAZARD

MATERIAL JOB SITE SHALL BE PAID A PREMIUM OF $2.00

PER HOUR OVER APPLICABLE RATE. .....$ 32.36 34.51

9 SPECIAL EARTH-MOVING EQUIPMENT, 35 TONS OR OVER

THANKSGIVING DAY AND CHRISTMAS DAY, PLUS

PRESIDENTS' DAY, COLUMBUS DAY, VETERAN'S DAY & V-J

DAY, PROVIDING THE EMPLOYEE HAS WORKED AT LEAST ONE

DAY IN THE CALENDAR WEEK IN WHICH THE HOLIDAY

FALLS. B. EMPLOYEE WHO HAS BEEN ON THE PAYROLL

FOR 1 YEAR OR MORE BUT LESS THAN 5 YEARS AND HAS

WORKED 150 DAYS DURING THE LAST YEAR OF EMPLOYMENT

SHALL RECEIVE 1 WEEK'S PAID VACATION; 5 TO 10 YEARS

- 2 WEEKS' PAID VACATION; 10 OR MORE YEARS - 3

WEEK'S PAID VACATION. C. EMPLOYEES ON THE

SENIORITY LIST SHALL BE PAID A ONE HUNDRED DOLLAR

($100.00) BONUS FOR EVERY FOUR HUNDRED (400) HOURS

WORKED, UP TO A MAXIMUM OF FIVE HUNDRED DOLLARS

($500.00) ALL DRIVERS WORKING ON A DEFINED HAZARD

MATERIAL JOB SITE SHALL BE PAID A PREMIUM OF $2.00

PER HOUR OVER APPLICABLE RATE. .....$ 32.56 34.51

8 SPECIAL EARTH-MOVING EQUIPMENT, UNDER 35 TONS

FOOTNOTES: A. PAID HOLIDAYS: NEW

YEAR'S DAY, MEMORIAL DAY, INDEPENDENCE DAY, LABOR

DAY, THANKSGIVING DAY AND CHRISTMAS DAY, PLUS

PRESIDENTS' DAY, COLUMBUS DAY, VETERAN'S DAY & V-J

DAY, PROVIDING THE EMPLOYEE HAS WORKED AT LEAST ONE

DAY IN THE CALENDAR WEEK IN WHICH THE HOLIDAY

FALLS. B. EMPLOYEE WHO HAS BEEN ON THE PAYROLL

FOR 1 YEAR OR MORE BUT LESS THAN 5 YEARS AND HAS

WORKED 150 DAYS DURING THE LAST YEAR OF EMPLOYMENT

SHALL RECEIVE 1 WEEK'S PAID VACATION; 5 TO 10 YEARS

- 2 WEEKS' PAID VACATION; 10 OR MORE YEARS - 3

WEEK'S PAID VACATION. C. EMPLOYEES ON THE

SENIORITY LIST SHALL BE PAID A ONE HUNDRED DOLLAR

($100.00) BONUS FOR EVERY FOUR HUNDRED (400) HOURS

WORKED, UP TO A MAXIMUM OF FIVE HUNDRED DOLLARS

($500.00) ALL DRIVERS WORKING ON A…