ATTACHMENT 1 - Specifications Vol 1 of 2.pdf

PROJECT SPECIFICATIONS

Department of Veterans Affairs VA Northern California Healthcare System

Design Modular Medical Specialty Clinic VA Project No. 612-122

100% Construction Documents September 10, 2021

Volume 1 of 2

Prepared by:

Apogee Consulting Group, PA

1151 Kildaire Farm Road Cary, NC 27511

VA Northern California Healthcare System

DESIGN MEDICAL SPECIALTY CLINIC

Project: 612-122

1000 Centre Avenue, Suite 120

Fort Collins CO, 80526 acg-pa.com

Date: DECEMBER 17, 2021 - ADDENDUM

DocuSign Envelope ID: 54B78FE4-2298-4CCA-BE1D-F9D477D050BF

Design Medical Specialty Clinic

Date: September 10, 2021

Gregory M. Gordon, PE SE Structural Engineer

09/30/22

09/10/21

Walter David Van Scoter, AIA

Senior Project Architect

Rajesh Kaul, PE

Sr. Mechanical & FP Engineer

DocuSign Envelope ID: 2390CF73-1058-4E11-83D6-D11B065FEEAE

Joshua A. VandenEnde, PE

Electrical Department Manager

James V. Ezekiel, RCDD

Electrical Designer

DocuSign Envelope ID: 2390CF73-1058-4E11-83D6-D11B065FEEAE

VA Northern California Healthcare System September 10, 2021 Design Medical Specialty Clinic 100% Construction Documents Mather, CA Project No. 612-122

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 15 List of Drawing Sheets 07-15

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 12-18 01 00 01 SMUD Commitment Drawing 01 00 02 SMUD Commitment Letter 01 00 03 SMUD Electric Service Requirements – Distribution

Underground Structure

01 00 04 SMUD Electric Service Requirements – Commercial Industrial

01 32 16.15 Project Schedules 03-18 01 33 23 Shop Drawings, Product Data, and Samples 05-17 01 35 26 Safety Requirements 02-17 01 42 19 Reference Standards 05-16 01 45 00 Quality Control 03-19 01 45 29 Testing Lab 08-17 01 45 35 Special Instructions 03-19 01 45 36 Special Instructions Worksheet 01 57 19 Temporary Environmental Controls 01-11 01 58 16 Temporary Interior Signage 07-15 01 74 19 Construction Waste Management 09-13 01 91 00 General Commissioning Requirements 10-15

DIVISION 02 – EXISTING CONDITIONS

02 21 13 Site Surveys 08-16

DIVISION 03 – CONCRETE

03 30 00 Cast-in-Place Concrete 12-15

DIVISION 04 – MASONRY

04 05 13 Masonry Mortaring 10-17 04 20 00 Unit Masonry 08-17

DIVISION 05 – METALS

05 12 00 Structural Steel Framing 11-18 05 31 00 Steel Decking 02-16 05 40 00 Cold-Formed Metal Framing 05-16 05 50 00 Metal Fabrications 08-18

00 01 10-2

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 06 00 Translucent resin panel system 06 10 00 Rough Carpentry 10-17 06 16 63 Cementitious Sheathing 02-16

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 11 13 Bituminous Dampproofing 02-16 07 21 13 Thermal Insulation 10-17 07 22 00 Roof and Deck Insulation 02-16 07 24 00 Exterior Insulation and Finish Systems 02-16 07 27 27 Fluid-Applied Membrane Air Barrier, Vapor Retarding 02-16 07 54 23 Thermoplastic Polyolefin (TPO) Roofing 08-16 07 60 00 Flashing and Sheet Metal 07-14 07 71 00 Roof Specialties 10-15 07 72 00 Roof Accessories 10-15 07 84 00 Firestopping 02-16 07 92 00 Joint Sealants 10-17

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 08-16 08 14 00 Interior Wood Doors 02-16 08 31 13 Access Doors and Frames 02-16 08 41 13 Aluminum-Framed Entrances and Storefronts 08-16 08 51 13 Aluminum Windows 02-16 08 71 00 Door Hardware 01-16 08 71 13 Automatic Door Operators 02-16 08 80 00 Glazing 10-15 08 90 00 Louvers and Vents 05-15

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 02-15 09 06 00 Schedule for Finishes 04-15 09 22 16 Non-Structural Metal Framing 06-18 09 29 00 Gypsum Board 06-18 09 30 13 Ceramic/Porcelain Tiling 09-15 09 51 00 Acoustical Ceilings 12-18 09 65 13 Resilient Base and Accessories 02-16 09 65 16 Resilient Sheet Flooring 05-18 09 65 19 Resilient Tile Flooring 05-18 09 68 00 Carpeting 10-15 09 91 00 Painting 01-16

DIVISION 10 – SPECIALTIES

10 14 19 Fabricated Stainless Steel Dimensional Graphics N/A 10 21 23 Cubicle Curtain Tracks 05-15 10 26 00 Wall and Door Protection 10-15

00 01 10-3

10 28 00 Toilet, Bath, and Laundry Accessories 02-16 10 44 13 Fire Extinguisher Cabinets 08-18

DIVISION 12 – FURNISHINGS

12 32 00 Manufactured Wood Casework 09-15 12 36 00 Countertops 12-18 12 51 16.19 Plastic Laminate Casework

DIVISION 13 - SPECIAL CONSTRUCTION

13 05 41 Seismic Restraint Requirements for Non-Structural

Components 01-14

DIVISION 21 - FIRE SUPPRESSION

21 08 00 Commissioning of Fire Suppression System 11-16 21 13 13 Wet-Pipe Sprinkler Systems 06-15

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 07-16 22 05 19 Meters and Gages for Plumbing Piping 09-15 22 05 23 General-Duty Valves for Plumbing Piping 09-15 22 07 11 Plumbing Insulation 09-15 22 08 00 Commissioning of Plumbing Systems 11-16 22 11 00 Facility Water Distribution 09-15 22 13 00 Facility Sanitary and Vent Piping 09-15 22 14 00 Facility Storm Drainage 09-15 22 33 00 Electric Domestic Water Heaters 09-15 22 40 00 Plumbing Fixtures 09-15

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 08-17 23 05 41 Noise and Vibration Control for HVAC Piping and

Equipment 02-15

23 05 93 Testing, Adjusting, and Balancing for HVAC 02-15 23 07 11 HVAC and Boiler Plant Insulation 02-15 23 08 00 Commissioning of HVAC Systems 11-16 23 09 23 Direct-Digital Control System for HVAC 09-11 23 23 00 Refrigerant Piping 02-15 23 31 00 HVAC Ducts and Casings 03-13 23 34 00 HVAC Fans 02-15 23 36 00 Air Terminal Units 02-15 23 37 00 Air Outlets and Inlets 02-15 23 40 00 HVAC Air Cleaning Devices 02-12 23 81 00 Decentralized Unitary HVAC Equipment 02-11 23 82 00 Convection Heating and Cooling Units 04-11 23 82 16 Air Coils 04-11

00 01 10-4

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16 26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17 26 05 26 Grounding and Bonding for Electrical Systems 01-17 26 05 33 Raceway and Boxes for Electrical Systems 01-18 26 05 41 Underground Electrical Construction 01-17 26 05 73 Overcurrent Protective Device Coordination Study 01-18 26 08 00 Commissioning of Electrical Systems 11-16 26 09 23 Lighting Controls 01-18 26 24 16 Panelboards 01-18 26 27 26 Wiring Devices 01-18 26 29 11 Motor Controllers 01-18 26 29 21 Enclosed Switches and Circuit Breakers 01-17 26 32 13 Engine Generators 01-18 26 36 23 Automatic Transfer Switches 01-17 26 41 00 Facility Lightning Protection 01-17 26 43 13 Surge Protective Devices 01-17 26 51 00 Interior Lighting 01-18 26 56 00 Exterior Lighting 01-18

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 06-15 27 05 26 Grounding and Bonding for Communications Systems 06-15 27 05 33 Raceways and Boxes for Communications Systems 10-18 27 08 00 Commissioning of Communications Systems 11-16 27 10 00 Control, Communication and Signal Wiring 06-15 27 11 00 Communications Equipment Room Fittings 06-15 27 15 00 Communications Structured Cabling 01-16

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 04-18 28 05 13 Conductors and Cables for Electronic Safety and

Security 10-18

28 05 26 Grounding and Bonding for Electronic Safety and Security

09-11

28 05 28.33 Conduits and Backboxes for Electronic Safety and Security

09-11

28 08 00 Commissioning of Electronic Safety and Security Systems 11-16 28 23 00 Video Surveillance 09-11 28 31 00 Fire Detection and Alarm 10-11

VA Northern California Healthcare System December 17, 2021

Design Medical Specialty Clinic 100% CD – Addendum 1

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWINGS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title

GENERAL

G-001 COVER

G-100 GENERAL INFORMATION

LS100 LIFE SAFETY PLAN AND CODE ANALYSIS

LS100A LIFE SAFETY PLAN - DEDUCT ALTERNATE #4

CIVIL

EC-1 EXISTING CONDITIONS MAP

DM-1 DEMOLITION AND EROSION CONTROL PLAN

SP-1 SITE PLAN

GP-1 GRADING PLAN

CD-1 CIVIL DETAILS

OU-1 OVERALL UTILITY PLAN

DP-1 SITE PLAN DEDUCT ITEM 3*

LANDSCAPE

L-101 PLANTING PLAN

STRUCTURAL

S-001 ABBREVIATIONS, SYMBOL LEGEND, AND GENERAL STRUCTURAL NOTES

S-002 SPECIAL INSPECTIONS

S-101 FOUNDATION PLAN

S-102 ROOF FRAMING PLAN

S-501 DETAILS

S-502 DETAILS

S-503 DETAILS

S-504 DETAILS

ARCHITECTURAL

A-001 ARCHITECTURAL SYMBOLS, ABBREVIATIONS AND NOTES

A-101 FIRST FLOOR ARCHITCTURAL PLAN

00 01 15 - 2

A-101A FIRST FLOOR ARCHITECTURAL PLAN - DEDUCT ALTERNATE #4

A-102 FIRST FLOOR DIMENSION PLAN

A-102A FIRST FLOOR DIMENSION PLAN - DEDUCT ALTERNATE #4

A-103 ROOF PLAN AND DEDUCT ALTERNATE #1

A-110 FIRST FLOOR REFLECTED CEILING PLAN AND DETAILS

A-110A FIRST FLOOR REFLECTED CEILING PLAN - DEDUCT ALTERNATE #4

A-201 EXTERIOR ELEVATIONS AND DEDUCT ALTERNATE #2

A-301 BUILDING SECTIONS

A-302 WALL SECTIONS

A-303 WALL SECTIONS

A-304 PLAN DETAILS

A-601 DOOR SCHEDULE, ELEVATIONS, DETAILS AND DEDUCT ALTERNATE #2 & 4

INTERIORS

I-001 PRODUCT SCHEDULES, SYMBOLS AND ABBREVIATIONS

I-101 FIRST FLOOR FINISH PLAN

I-120 FIRST FLOOR FLOOR PATTERN PLAN

I-201 CASEWORK ELEVATIONS

I-202 CASEWORK DETAILS

I-401 INTERIOR WALL PROTECTION ELEVATIONS

I-402 INTERIOR WALL PROTECTION ELEVATIONS AND DETAILS

I-403 INTERIOR EQUIPMENT ELEVATIONS

I-411 FIRST FLOOR OVERALL EQUIPMENT PLAN

I-421 FIRST FLOOR ENLARGED EQUIPMENT PLAN A

I-422 FIRST FLOOR ENLARGED EQUIPMENT PLAN B

I-423 ENLARGED EQUIPMENT PLANS

I-424 ENLARGED EQUIPMENT PLANS

I-431 ENLARGED TOILET PLANS

I-432 ENLARGED TOILET PLANS

I-601 EQUIPMENT JSN LEGEND AND EQUIPMENT SCHEDULE

I-602 EQUIPMENT SCHEDULE

I-603 EQUIPMENT SCHEDULE

FIRE SUPPRESSION

FX001 FIRE SUPPRESSION GENERAL INFORMATION

FX101 FIRST FLOOR FIRE SUPPRESSION PLAN

FX101A FIRST FLOOR FIRE SUPPRESSION PLAN - DEDUCT ALTERNATE

00 01 15 - 3

FX102 FIRST FLOOR FIRE SUPPRESSION REFLECTED CEILING PLAN

FX102A FIRST FLOOR FIRE SUPPRESSION REFLECTED CEILING PLAN - DEDUCT

ALTERNATE

PLUMBING

P-001 PLUMBING GENERAL INFORMATION

PP101 FIRST FLOOR PLUMBING PLAN AND SCHEDULES

PP101A FIRST FLOOR DOMESTIC WATER PLAN - DEDUCT ALTERNATE

PP102 ROOF PLUMBING PLAN

PW100 UNDERSLAB DRAIN, WASTE, AND VENT PLAN

PW100A UNDERSLAB DRAIN, WASTE, AND VENT PLAN - DEDUCT ALTERNATE

PW101 FIRST FLOOR DRAIN, WASTE, AND VENT PLAN

PW101A FIRST FLOOR DRAIN, WASTE, AND VENT PLAN - DEDUCT ALTERNATE

P-501 PLUMBING DETAILS

P-901 DRAIN, WASTE, VENT, AND STORM RISER DIAGRAMS

P-901A DRAIN, WASTE, AND VENT RISER DIAGRAM - DEDUCT ALTERNATE

P-902 DOMESTIC WATER RISER DIAGRAM

P-902A DOMESTIC WATER RISER DIAGRAM - DEDUCT ALTERNATE

MECHANICAL

M-001 MECHANICAL GENERAL INFORMATION

M-101 FIRST FLOOR MECHANICAL PLAN AND SCHEDULES

M-101A FIRST FLOOR MECHANICAL PLAN - DEDUCT ALTERNATE

M-102 ROOF MECHANICAL PLAN AND SECTIONS

M-501 MECHANICAL DETAILS

M-502 MECHANICAL CONTROLS

ELECTRICAL

E-001 ELECTRICAL GENERAL NOTES, SYMBOL LEGENDS, AND ABBREVIATIONS

ES101 ELECTRICAL SITE PLAN

EP101 FIRST FLOOR POWER PLAN

EP101A FIRST FLOOR POWER PLAN - DEDUCT ALTERNATE #4

EP102 ROOF POWER PLAN

EM101 FIRST FLOOR MECHANICAL POWER PLAN

EM101A FIRST FLOOR MECHANICAL POWER PLAN - DEDUCT ALTERNATE #4

EL101 FIRST FLOOR LIGHTING PLAN

EL101A FIRST FLOOR LIGHTING PLAN - DEDUCT ALTERNATE #4

00 01 15 - 4

E-501 ELECTRICAL DETAILS

E-502 ELECTRICAL DETAILS

E-601 ELECTRICAL DIAGRAMS

E-602 PANEL SCHEDULES

E-603 ELECTRICAL SCHEDULES

TECHNOLOGY

TK001 TECHNOLOGY GENERAL NOTES, SYMBOL LEGEND, AND ABBREVIATIONS

TS101 TECHNOLOGY SITE PLAN

TK101 FIRST FLOOR TECHNOLOGY PLAN

TK101A FIRST FLOOR TECHNOLOGY PLAN - DEDUCT ALTERNATE #4

TK501 TECHNOLOGY DETAILS

TK502 TECHNOLOGY DETAILS

TK601 PARTIAL TECHNOLOGY RISER

FIRE ALARM

FA001 FIRE ALARM GENERAL NOTES, SYMBOL LEGEND, AND ABBREVIATIONS

FA101 FIRST FLOOR FIRE ALARM PLAN

FA101A FIRST FLOOR FIRE ALARM - DEDUCT ALTERNATE #4

FA102 ROOF FIRE ALARM AND TECHNOLOGY PLAN

FA501 FIRE ALARM DETAILS

- - - E N D - - -

Mather, CA Project No. 612-122

01 00 00 - 1

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 GENERAL INTENTION

1.2 STATEMENT OF BID ITEM(S)

1.3 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.4 CONSTRUCTION PROJECT SCHEDULE

1.5 CONSTRUCTION SAFETY REQUIREMENTS

1.6 CONSTRUCTION SECURITY REQUIREMENTS

1.7 CONSTRUCTION QUALITY CONTROL PLAN

1.8 CONSTRUCTION SCHEDULE OF VALUES

1.9 NAME BRAND ITEMS

1.10 OPERATIONS AND STORAGE AREAS

1.11 ALTERATIONS

1.12 DISPOSAL AND RETENTION

1.13 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, AND UTILITIES

1.14 RESTORATION

1.15 PHYSICAL DATA

1.16 PROFESSIONAL SURVEYING SERVICES

1.17 LAYOUT OF WORK

1.18 AS-BUILT DRAWINGS

1.19 USE OF ROADWAYS

1.20 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

1.21 TEMPORARY TOILETS

1.22 AVAILABILITY AND USE OF UTILITY SERVICES

1.23 NEW TELEPHONE EQUIPMENT

1.24 TESTS

1.25 INSTRUCTIONS

1.26 GOVERNMENT-FURNISHED PROPERTY

1.27 RELOCATED EQUIPMENT AND/OR ITEMS

1.28 CONSTRUCTION SIGN

1.29 SAFETY SIGN

1.30 REQUIRED USE OF SUBMITTAL EXCHANGE

1.31 PHOTOGRAPHIC DOCUMENTATION

1.32 FINAL ELEVATION DIGITAL IMAGES

1.33 WARRANTY PERIOD OF SERVICES

01 00 00 - 2

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 GENERAL INTENTION

A. Contractor shall furnish all labor, materials, equipment, supervision and necessary engineering to perform the work as required by the project specifications and drawings. This shall include, but not limited to, completely preparing site for building operations, all demolition activities and/or removal of existing structures required to perform the work, foundations, superstructure, mechanical, electrical, plumbing, special systems, landscaping and other site improvements.

B. Visits to the site by Bidders may be made only by appointment with the

Contracting Officer.

C. Offices of Apogee Consulting Group, as Architect-Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

D. Before placement and installation of work subject to tests by testing laboratory retained by the Contractor, the Contractor shall notify the COR in sufficient time to allow COR witnessing of testing laboratory personnel proper taking and testing of specimens and field inspection. Such prior notice shall be not less than three work days unless otherwise designated by the COR.

E. All employees of general Contractor and Subcontractors shall comply with

VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

F. The Key Personnel assigned by the contractor for the performance of work on this contract shall be acceptable to VA in terms of personal and professional conduct and technical knowledge. Should the assignment to this contract of any person by the contractor be deemed to conflict with the interests of VA, or in the event performance is deemed to be unsatisfactory at any time during the life of the contract, the

Contracting Officer may notify the contractor and request the person be removed from the assignment. The reason for removal will be documented and a request to receive key personnel replacement within three (3) business days of the notification will be made. Replacement of key

01 00 00 - 3 personnel qualifications shall be equal to or greater than those of the key personnel being replaced. Employment and staffing difficulties will not be justification for failure to meet established schedules. The contractor is required to submit a resume with qualifications for the proposed replacement which shall be approved by the COR and CO prior to the replacement starting work.

1.2 STATEMENT OF BID ITEM(S)

A. BID ITEM 1 (BASE BID):

ITEM I, GENERAL CONSTRUCTION: Work includes general construction, alterations, roads, walks, grading, drainage, and construction and certain other items.

ITEM II, Civil Work: Work includes all labor, material, equipment and supervision to perform the required civil construction work on this project including the installation of sidewalks, asphalt, site utilities, and other components related to civil engineering elements. SEE CIVIL

DRAWINGS.

ITEM III, Landscape Work: Work includes all labor, material, equipment and supervision to perform the required landscape construction work on this project including the installation of all top-soil, stone, plantings, and other components related to civil engineering elements. SEE LANDSCAPE

DRAWINGS.

ITEM IV, Structural Work: Work includes all labor, material, equipment and supervision to perform the required structural construction work on this project including the installation of foundations, slabs, structural steel framing, and other components related to structural engineering elements. SEE STRUCTURAL DRAWINGS.

ITEM V, Architectural Work: Work includes all labor, material, equipment and supervision to perform the required architectural construction work on this project including the installation of interior and exterior materials and finishes; exterior wall assemblies, finishes, and materials; roof assemblies, finishes, and materials; casework and/or systems furniture;

doors and windows and associated frames, glazing, and hardware; interior partition assemblies; ceiling systems; rated assemblies; and other components related to architectural finishes and systems. SEE

ARCTHITECTURAL AND INTERIOR DESIGN DRAWINGS.

ITEM VI, Fire Protection Work: Work includes all labor, material, equipment and supervision to perform the required fire protection

01 00 00 - 4 construction work on this project including the installation of fire suppression, fire alarm systems, and any other components related to fire suppression or fire alarm systems. SEE FIRE PROTECTION DRAWINGS.

ITEM VII, Plumbing Work: Work includes all labor, material, equipment and supervision to perform the required plumbing construction work on this project including the installation of plumbing fixtures, domestic hot and cold water supply piping, waste water piping, vent piping, roof drainage piping, and any other components related to plumbing systems. SEE

PLUMBING DRAWINGS.

ITEM VIII, Mechanical Work: Work includes all labor, material, equipment and supervision to perform the required mechanical construction work on this project including the installation of mechanical systems, ductwork, supply/return grilles, and other components related to mechanical systems.

SEE MECHANICAL DRAWINGS.

ITEM IX, Electrical Work: Work includes all labor, material, equipment and supervision to perform the required electrical construction work on this project including the installation of power, lighting, fixtures, panels, conduit, and other components related to electrical systems. SEE

ELECTRICAL DRAWINGS.

ITEM X, Technology Work: Work includes all labor, material, equipment and supervision to perform the required telecom/data construction work on this project including the installation of cabling, cable trays, racks, conduit, panels, security, and other components related to technology systems. SEE TECHNOLOGY DRAWINGS.

B. BID ITEM 2 (DEDUCT 1): INCLUDES ALL WORK IN BID ITEM 1 WITH THE FOLLOWING

EXCEPTIONS:

(A) DELETE ALL WORK AND MATERIAL FOR SUPPORT STEEL FOR ROOF SCREENS

(FROM TOP FLANGE OF ROOF STEEL UP). DELETE ALL WORK AND MATERIAL FOR

INSTALLATION OF ROOF SCREEN. DELETE ALL ROOFING WORK ASSOCIATED WITH

FLASING IN VERTICAL SCREEN SUPPORTS. SEE STRUCTURAL AND ARCHITECTURAL

DRAWINGS.

(B) REMOVE ALL WORK AND MATERIAL TO INSTALL BASIS OF DESIGN: HERMAN

MILLER COMBO CASEWORK/SINKS AT ALL LOCATIONS AND REPLACE WITH HAND SINK

AND SOLID SURFACE SPLASH PROTECTION. SEE PLUMBING AND INTERIOR

DRAWINGS.

01 00 00 - 5

(C) DELETE ALL WORK AND MATERIAL TO INSTALL GENERATOR – INCLUDING

WIRING, SWITCHGEAR, AND CONCRETE GENERATOR PAD. SEE CIVIL AND

ELECTRICAL DRAWINGS.

C. BID ITEM 3 (DEDUCT 2): INCLUDES ALL WORK IN BID ITEM 2 WITH THE FOLLOWING

EXCEPTIONS:

(A) INSTALL MANUAL SWING DOORS IN LIEU OF AUTOMATIC SLIDING DOORS AT

VESTIBULE 100 (2 PARIS). SEE ARCHITECTURAL DRAWINGS.

D. BID ITEM 4 (DEDUCT 3): INCLUDES ALL WORK IN BID ITEM 3 WITH THE FOLLOWING

EXCEPTIONS:

(A) DELETE ALL WORK AND MATERIAL FOR ALL ASPHALT PAVING, ADA STALLS,

PROVIDE GRAVEL EMERGENCY ACCESS ONLY. SEE CIVIL DRAWINGS.

E. BID ITEM 5 (DEDUCT 4): INCLUDES ALL WORK IN BID ITEM 4 WITH THE FOLLOWING

EXCEPTIONS:

(A) DELETE ALL WORK AND MATERIAL IN DESIGNATED AREA AND REPLACE WITH

UNOCCUPIED SPACE. DELETED WORK AFFECTS ALL DISCIPLINES. SEE

DISCIPLINE DRAWINGS FOR SPECIFIC DEDUCT WORK.

1.3 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractors expense.

1.4 CONSTRUCTION PROJECT SCHEDULE

A. Contractor shall submit a prepared work schedule for approval and arrange with the COTR the sequence of work. Phasing of work may be required for completion of this project and shall be planned thoroughly by the

Contractor. Project will require night and weekend work to accomplish specific tasks (i.e. any work that will be disruptive to current daily operations will need to be scheduled during nights and weekends). Work areas shall remain protected, per the project Specifications, from employee and patient access throughout the contract period. 100% of ALL project submittals shall be approved prior to the construction start date.

B. General Contractor schedule shall account for time required to obtain approval on all submittals prior to ‘breaking ground’ for construction work. Submitted project schedule shall show expected submittal period.

General Contractor shall note that it will generally take 14 days for AE review, followed by an additional 5 to 14 days for Department of Veterans

Affairs to review and approve submittals, depending on the content.

C. Refer to section 01 32 16, PROJECT SCHEDULES, for project scheduling requirements.

01 00 00 - 6

1.5 CONSTRUCTION SAFETY REQUIREMENTS

A. The General Contractor shall develop a plan for both the area of work and the interaction of the work with the facility per OSHA, AIA, and VA guidelines. The Infection Prevention Measures, as set forth in the VA

Infection Control Risk Assessment, shall be included in the Safety Plan.

The Interim Life Safety Measures (ILSM), as set forth in the project ILSM, shall also be implemented in the Safety Plan. The General Contractor shall submit a copy of their Daily Safety Inspection form. The Safety Plan shall be a submittal and approved by the designated VA COR prior to the start of construction. Contractor shall note that the required training of all personnel shall be specific for ‘Construction Safety’, (29 CFR 1926), NOT

‘General Industry’ safety training, (29 CFR 1910). Contractor shall reference project Specifications for in depth safety and documentation requirements such as hazard analyses and respective hazard mitigation techniques to be required for specific work activities. Some general safety precautions are listed below:

1. Work shall be conducted in a manner to afford maximum protection to

Contractors, VA employees, patients, public guests, existing building infrastructure, and to prevent unreasonable delay or interference with normal hospital operations.

2. Provide fire extinguishers that are readily available at all times.

Provide additional fire detection equipment as required to meet VA guidelines and the project ILSM.

3. It will be the obligation of the Contractor to maintain clean work site. Material and tools shall be kept within designated areas and trash will be removed daily.

4. It will be the responsibility of the Contractor to seek and obtain any required permits for construction, which includes but not limited to

NESHAPS Permit, Dust Permit, etc. Reference project Specifications for details.

B. Refer to section 01 35 26, SAFETY REQUIREMENTS, for safety and infection control requirements.

1.6 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

01 00 00 - 7

2. The General Contractor is responsible for assuring that all sub-

Contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractors employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give one week’s notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General Contractors employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the Contracting Officer.

C. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the Contracting officers representative COR for the purpose of security inspections of every area of project including tool boxes and parked machines and take any emergency action.

2. The General Contractor shall turn over all permanent lock cylinders to the VA locksmith for permanent installation.

D. Document Control:

1. Before starting any work, the General Contractor/ Subcontractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of “sensitive information”.

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and drawings may be marked “Law Enforcement Sensitive” or “Sensitive Unclassified”. Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the

Contracting Officer upon request.

01 00 00 - 8

4. These security documents shall not be removed or transmitted from the project site without the written approval of Contracting Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an Engineering Document

Management Software (EDMS).

a. Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the

EDMS system.

b. “Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

E. Records Management Requirements: The following standard items relate to records generated in executing the contract and should be included in a typical Electronic Information Systems (EIS) procurement contract:

1. Citations to pertinent laws, codes and regulations such as 44 U.S.C chapters 21, 29, 31 and 33; Freedom of Information Act (5 U.S.C. 552);

Privacy Act (5 U.S.C. 552a); 36 CFR Part 1222 and Part 1228.

2. Contractor shall treat all deliverables under the contract as the property of the U.S. Government for which the Government Agency shall have unlimited rights to use, dispose of, or disclose such data contained therein as it determines to be in the public interest.

3. Contractor shall not create or maintain any records that are not specifically tied to or authorized by the contract using Government IT equipment and/or Government records.

4. Contractor shall not retain, use, sell, or disseminate copies of any deliverable that contains information covered by the Privacy Act of

1974 or that which is generally protected by the Freedom of Information

Act.

5. Contractor shall not create or maintain any records containing any

Government Agency records that are not specifically tied to or authorized by the contract.

6. The Government Agency owns the rights to all data/records produced as part of this contract.

01 00 00 - 9

7. The Government Agency owns the rights to all electronic information

(electronic data, electronic information systems, electronic databases, etc.) and all supporting documentation created as part of this contract. Contractor must deliver sufficient technical documentation with all data deliverables to permit the agency to use the data.

8. Contractor agrees to comply with Federal and Agency records management policies, including those policies associated with the safeguarding of records covered by the Privacy Act of 1974. These policies include the preservation of all records created or received regardless of format

[paper, electronic, etc.] or mode of transmission [e-mail, fax, etc.] or state of completion [draft, final, etc.].

9. No disposition of documents will be allowed without the prior written consent of the Contracting Officer. The Agency and its Contractors are responsible for preventing the alienation or unauthorized destruction of records, including all forms of mutilation. Willful and unlawful destruction, damage or alienation of Federal records is subject to the fines and penalties imposed by 18 U.S.C. 2701. Records may not be removed from the legal custody of the Agency or destroyed without regard to the provisions of the agency records schedules.

10.Contractor is required to obtain the Contracting Officer's approval prior to engaging in any contractual relationship (Subcontractor) in support of this contract requiring the disclosure of information, documentary material and/or records generated under, or relating to, this contract. The Contractor (and any Subcontractor) is required to abide by Government and Agency guidance for protecting sensitive and proprietary information.

F. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. The Contractor shall only park within its construction designated area of work. Offsite parking is allowed. Permission to park onsite can be approved on a case by case basis if and only if there are reasons that benefit the govt or the project.

01 00 00 - 10

1.7 CONSTRUCTION QUALITY CONTROL PLAN

A. The General Contractor shall develop a plan for which all construction crews under this project shall follow. The General Contractor shall specifically identify appropriate standard forms for Quality Control inspections that will become part of the construction documents. This includes the punch lists format that the Contractor will be using internally for their work inspections. Quality Control Plan shall be a submittal and approved by the COR prior to the start of construction.

B. The General Contractor is responsible for the Quality Control of their work. The Department of Veterans Affairs is responsible for the Quality

Assurance of the General Contractors process. Once the General Contractor is ready for project turnover to the VA, the results of the Contractor

Quality Control plan will be presented to the COR. Once reviewed, the

General Contractors superintendent will present the Contractors pre-final acceptance walk through (punch list) to the COR. Only at this point will the General Contractor and the Department of Veterans Affairs conduct the final acceptance inspection. Once satisfactory, project will be turned over to the Department of Veterans Affairs.

C. Prior to the project final acceptance, General Contractor shall submit to the COR completed ‘New Equipment Entry Form(s)’ for every piece of equipment installed during project that will require future maintenance or as directed by the project COTR. General Contractor shall make all subcontractors, vendors and/or material suppliers aware of this requirement. The ‘New Equipment Entry Form(s)’ is attached or will be provided by the COR.

D. Refer to section 01 45 00, QUALITY CONTROL, for QAQC requirements.

1.8 CONSTRUCTION SCHEDULE OF VALUES

A. The General Contractors Schedule of Values shall be broken down by a) work related tasks as derived from the project schedule, then by b) division, as detailed in the VA Master Specification. Schedule of Values shall be broken down further at the request of the COR. The total price will be shown separately (to include cost break down by divisions as detailed above). Schedule of Values shall be a submittal and approved by the COR prior to the start of construction.

B. General Contractors Schedule of Values shall mirror the project schedule for work related tasks. Coordinate with COR as necessary.

01 00 00 - 11

1.9 NAME BRAND ITEMS

A. Contractor shall reference solicitation for Contracting Officers approved list of NAME BRAND ITEMS (FAR 52.236-5).

1.10 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the

Contracting Officer. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractors performance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the Contracting

Officer and shall be built with labor and materials furnished by the

Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the Contractor and shall be removed by the Contractor at its expense upon completion of the work. With the written consent of the Contracting Officer, the buildings and utilities may be abandoned and need not be removed.

C. The Contractor shall, under regulations prescribed by the Contracting

Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting

Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the

Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

D. Working space and space available for storing materials shall be as shown on the drawings or determined by the COR.

F. Workmen are subject to rules of the Medical Center applicable to their conduct.

G. Execute work in such a manner as to interfere as little as possible with work being done by others. Keep roads clear of construction materials, debris, standing construction equipment and vehicles at all times.

H. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit

01 00 00 - 12 vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractors personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of Veterans Affairs in quantities sufficient for not more than two work days. Provide unobstructed access to Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractors materials and equipment will be permitted subject to fire and safety requirements.

I. Utilities Services: Where necessary to cut existing pipes, electrical wires, conduits, cables, etc., of utility services, or of fire protection systems or communications systems (except telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR. All such actions shall be coordinated with the COR or Utility Company involved:

1. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Contractor.

J. Phasing: The Medical Center must maintain its operation 24 hours a day, 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur. It is the Contractors responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. To insure such executions, Contractor shall furnish the COR with an accurate schedule of dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR three (3) weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such dates to insure

01 00 00 - 13 accomplishment of this work in successive phases mutually agreeable to COR and Contractor, as follows:

1. General Contractors base bid shall include the necessary compensation for nights and/or weekend work to accomplish specific tasks in order to limit disturbances, impacts, and/or interruptions to the Medical Center.

K. Construction Fence: Before construction operations begin, Contractor shall provide a chain link construction fence, 2.1m (seven feet) minimum height, around the construction area indicated on the drawings. Provide gates as required for access with necessary hardware, including hasps and padlocks.

Fasten fence fabric to terminal posts with tension bands and to line posts and top and bottom rails with tie wires spaced at maximum 375mm (15 inches). Bottom of fences shall extend to 25mm (one inch) above grade.

Remove the fence when directed by COR.

L. When a building and/or construction site is turned over to Contractor, Contractor shall accept entire responsibility including upkeep and maintenance therefore:

1. Contractor shall maintain a minimum temperature of 4 degrees C (40 degrees F) at all times, except as otherwise specified.

2. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make arrangements for pre-inspection of site with Fire Department or Company (Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from

Contractors employee or watchman.

M. Utilities Services: Maintain existing utility services for Medical Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services. Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR. Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized

01 00 00 - 14 circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval.

2. Contractor shall submit a request to interrupt any such services to

COR, in writing, 21 days in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical Center. Interruption time approved by Medical Center may occur at other than Contractors normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 21 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

N. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

O. To minimize interference of construction activities with flow of Medical

Center traffic, comply with the following:

1. Keep roads, walk ways and entrances to grounds, parking and occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

2. Whenever an excavation for new utility lines crosses existing roads, at least one lane must remain open to traffic at all times. Contractor must have COR approval prior to modifying traffic flow and/or start of excavation activities.

3. Method and scheduling of required cutting, altering and removal of existing roads, walk ways and entrances must be approved by the COR.

01 00 00 - 15

P. Coordinate the work for this contract with other construction operations as directed by COR. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF ROADWAYS.

1.11 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by both, to the

Contracting Officer. This report shall list by rooms and spaces:

1. Existing conditions and types of resilient flooring, doors, windows, walls and other surfaces not required to be altered throughout affected areas of building.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, shades, etc., required by drawings to be either reused or relocated, or both.

3. Shall note any discrepancies between drawings and existing conditions at site.

4. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur and which have been agreed upon by Contractor and COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of the COR, to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by the Contractor with new items in accordance with the project specifications. Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE CONDITIONS".

C. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls and other surfaces as compared with conditions of same as noted in first condition survey report:

1. Re-survey report shall also list any damage caused by Contractor to such flooring and other surfaces, despite protection measures; and, will form basis for determining extent of repair work required of

Contractor to restore damage caused by Contractors workmen in executing work of this contract.

01 00 00 - 16

D. Protection: Provide the following protective measures:

1. Wherever existing roof surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

1.12 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are identified by attached tags or noted on drawings as items to be stored.

Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the

Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractors operation.

1.13 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, AND UTILITIES

A. The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so, and shall avoid

01 00 00 - 17 damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workmen, the Contractor shall trim those limbs or branches with a clean cut and paint the cut with a tree-pruning compound as directed by the Contracting Officer.

B. The Contractor shall protect from damage all existing improvements and utilities at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the

Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the Contractor fails or refuses to repair the damage promptly, the Contracting Officer may have the necessary work performed and charge the cost to the Contractor.

C. Refer to Section 01 57 19, TEMPORARY ENVIRONMENTAL CONTROLS, for additional requirements on protecting vegetation, soils and the environment. Refer to Articles, "Alterations", "Restoration", and

"Operations and Storage Areas" for additional instructions concerning repair of damage to structures and site improvements.

D. Refer to FAR clause, "Permits and Responsibilities," which is included in

General Conditions. A National Pollutant Discharge Elimination System

(NPDES) permit is required for this project. The Contractor is considered an "operator" under the permit and has extensive responsibility for compliance with permit requirements. VA will make the permit application available at the (appropriate medical center) office. The apparent low bidder, Contractor and affected Subcontractors shall furnish all information and certifications that are required to comply with the permit process and permit requirements. Many of the permit requirements will be satisfied by completing construction as shown and specified. Some requirements involve the Contractors method of operations and operations planning and the Contractor is responsible for employing best management practices. The affected activities often include, but are not limited to the following:

- Designating areas for equipment maintenance and repair;

- Providing waste receptacles at convenient locations and provide regular collection of wastes;

01 00 00 - 18

- Locating equipment wash down areas on site, and provide appropriate control of wash-waters;

- Providing protected storage areas for chemicals, paints, solvents, fertilizers, and other potentially toxic materials; and

- Providing adequately maintained sanitary facilities.

1.14 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the COR.

Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed.