Attachment 03-Specs-EHRM Upgrades Heinz Campus - 06-27-25.pdf

EHRM INFRASTRUCTURE

UPGRADES

Final Bid Documents

Project Manual

VAPHS H. J. Heinz Campus 1010 Delafield Road, Pittsburgh, Pennsylvania

June 27, 2025

Project No. 646A-22-700

VA Pittsburgh Healthcare System (VAPHS)

H. J. Heinz III Campus | EHRM Infrastructure Upgrades

Project Number 646A-22-700 | Issue Date: 06-27-25

CONSULTANTS DIRECTORY 000103 - 1

SECTION 000103

CONSULTANTS DIRECTORY

PART 1 - GENERAL

1.01 PROJECT LISTING

A. Architect / Physical Security

Awen Solutions Group

4196 Merchant Plaza Woodbridge, Virginia 22192

B. Mechanical /Electrical / Plumbing / Fire Protection Engineer

IMEG Corp

15 Sunnen drive, Suite 104

St. Louis, Missouri 63143

C. Civil Engineer

Langan Engineering and Environmental Science

2400 Ansys Drive, Suite 403

Canonsburg, Pennsylanvia 15317

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

---END---

TABLE OF CONTENTS 000110 - 1

DOCUMENT 000110

TABLE OF CONTENTS

SECTION NO DIVISION AND SECTION TITLES DATE

DIVISION 00 - SPECIAL SECTIONS

00 01 03 Consultants Directory

00 01 10 Table of Contents

00 01 15 List of Drawing Sheets 05-20

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 11-21

01 01 10 VA Medical Center Requirements

01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 01-24

01 33 23 Shop Drawings, Product Data, and Samples 11-23

01 35 26 Safety Requirements 05-24

01 42 19 Reference Standards 11-20

01 45 00 Quality Control 02-21

01 45 29 Testing Laboratory Services 11-18

01 45 35 Special Inspections 06-21

01 57 19 Temporary Environmental Controls 01-21

01 58 16 Temporary Interior Signage 07-15

01 74 19 Construction Waste Management 04-22

01 91 00 General Commissioning Requirements 04-22

DIVISION 02 – EXISTING CONDITIONS

02 20 60 Protection of Existing Utilities

02 41 19 Selective Demolition

02 82 11 Traditional Asbestos Abatement 01-21

02 82 13.19 Asbestos Floor Tile and Mastic Abatement 01-21

02 83 33.13 Lead-Based Paint Removal and Disposal 01-21

DIVISION 03 – CONCRETE

Not Applicable

DIVISION 04 – MASONRY

04 05 13 Masonry Mortaring 10-17

04 05 16 Masonry Grouting 01-21

04 20 00 Unit Masonry 08-17

DIVISION 05 – METALS

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 10 00 Rough Carpentry 10-17

TABLE OF CONTENTS 000110 - 2

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 81 00 Applied Fireproofing 07-23

07 84 00 Firestopping 01-21

07 92 00 Joint Sealants 04-22

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 01-21

08 31 13 Access Doors and Frames 04-22

08 71 00 Door Hardware 03-24

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 01-21

09 06 00 Schedule for Finishes 01-21

09 22 16 Non-Structural Metal Framing 06-18

09 29 00 Gypsum Board 04-20

09 65 13 Resilient Base and Accessories 01-21

09 65 19 Resilient Tile Flooring 05-18

09 91 00 Painting 01-21

DIVISION 10 – SPECIALTIES

10 44 13 Fire Extinguisher Cabinets 08-18

DIVISION 11 – EQUIPMENT

DIVISION 12 – FURNISHINGS

DIVISION 13 - SPECIAL CONSTRUCTION

13 05 41 Seismic Restraint Requirements for Non-Structural Components 01-21

DIVISION 14– CONVEYING EQUIPMENT

DIVISION 20 – MECHANICAL SUPPORT

DIVISION 21 - FIRE SUPPRESSION

21 08 00 Commissioning of Fire Suppression Systems 11-16

21 13 13 Wet-Pipe Sprinkler Systems 06-15

TABLE OF CONTENTS 000110 - 3

DIVISION 22 – PLUMBING

DIVISION 23 – HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 03-23

23 05 12 General Motor Requirements for HVAC and Steam Generation Equipment 03-23

23 05 93 Testing, Adjusting, and Balancing for HVAC 03-23

23 07 11 HVAC and Boiler Plant Insulation 02-20

23 08 00 Commissioning of HVAC Systems 03-23

23 09 23 Direct-Digital Control System for HVAC 03-23

23 21 13 Hydronic Piping 03-23

23 23 00 Refrigerant Piping 03-24

23 31 00 HVAC Ducts and Casings 03-23

23 37 00 Air Outlets and Inlets 03-23

23 81 00 Decentralized Unitary HVAC Equipment 03-24

23 81 23 Computer-Room Air-Conditioners 03-24

DIVISION 25 – INTEGRATED AUTOMATION

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 11-22

26 05 19 Low-Voltage Electrical Power Conductors and Cables 11-22

26 05 26 Grounding and Bonding for Electrical Systems 11-22

26 05 33 Raceway and Boxes for Electrical Systems 11-22

26 05 73 Overcurrent Protective Device Coordination Study 11-22

26 08 00 Commissioning of Electrical Systems 11-22

26 09 23 Lighting Controls 11-22

26 24 16 Panelboards 11-22

26 27 26 Wiring Devices 11-22

26 29 21 Enclosed Switches and Circuit Breakers 11-22

26 33 53 Static Uninterruptible Power Supply 11-22

26 41 00 Facility Lightning Protection 11-22

26 43 13 Surge Protective Devices 11-22

26 51 00 Interior Lighting 03-24

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 09-19

27 05 26 Grounding and Bonding for Communications Systems 06-15

27 05 33 Conduits and Backboxes for Communications Systems 10-18

27 05 36 Cable Trays for Communications Systems

27 05 53 Identification for Communications Systems

27 08 00 Commissioning of Communications Systems 11-16

27 10 00 Structured Cabling

27 11 16 Communications Cabinets, Racks, Frames, and Enclosures

27 11 19 Communications Termination Blocks and Patch Panels

TABLE OF CONTENTS 000110 - 4

27 11 26 Communications Rack Mounted Power Protection and Power Strips

27 13 13 Communications Copper Backbone Cabling

27 13 13.13 Communications Copper Cabling Splicing and Terminations

27 13 23 Communications Optical Fiber Backbone Cabling

27 13 23.13 Communications Optical Fiber Splicing and Terminations

27 15 13 Communications Copper Horizontal Cabling

27 16 19 Communications Patch Cords, Station Cords, and Cross Connection Wire

27 78 00 Closeout Submittals for Communications

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 04-18

28 05 13 Conductors and Cables for Electronic Safety and Security 10-18

28 05 28.33 Conduits and Backboxes for Electronic Safety and Security 09-11

28 08 00 Commissioning of Electronic Safety and Security Systems 11-16

28 13 00 Physical Access Control System 10-11

28 23 00 Video Surveillance 09-11

28 31 00 Fire Detection and Alarm 10-11

DIVISION 31 – EARTHWORK

31 20 00 Earthwork 08-23

31 23 16 Excavation and Back Fill for Trenching

31 25 00 Erosion and Sediment Control

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 12 16 Asphalt Paving 09-15

32 13 13 Concrete Paving

DIVISION 33 – UTILITIES

33 90 00 Other Utilities

DIVISION 34 – TRANSPORTATION

DIVISION 35 – WATERWAYS AND MARINE CONSTRUCTION

DIVISION 40 – PROCESS INTERCONNECTIONS

TABLE OF CONTENTS 000110 - 5

DIVISION 41 – MATERIAL PROCESSING AND HANDLING EQUIPMENT

DIVISION 42 – PROCESS HEATING, COOLING, AND DRYING EQUIPMENT

DIVISION 43 – PROCESS GAS AND LIQUID HANDLING, PURIFICATION AND

STORAGE EQUIPMENT

DIVISION 44 – POLLUTION CONTROL EQUIPMENT

DIVISION 45 – INDUSTRY-SPECIFIC MANUFACTURING EQUIPMENT

DIVISION 46 – WATER AND WASTEWATER EQUIPMENT

DIVISION 48 – Electrical Power Generation

---END---

LIST OF DRAWING SHEETS 000115 - 1

SECTION 000115

LIST OF DRAWING SHEETS

The Drawings listed below accompanying this specification form a part of the contract.

00-GENERAL

00-GI000 COVER SHEET

00-GI001 SHEET INDEX

00-GI002 SHEET INDEX

00-GI003 GENERAL NOTES AND CODE REQUIREMENTS

00-GI004 GENERAL NOTES

00-GI005 TIL ABBREVIATION LIST (PG-18-4)

00-GI010 PROJECT INFORMATION

00-GI011 INFECTION CONTROL RISK ASSESSMENT - CLASS IV

00-GI012 TYPICAL ADA REQUIREMENTS - INTERIOR CLEARANCES

00-GI020 FACILITY MEDICAL REQUIREMENTS

00-GI021 FACILITY MEDICAL REQUIREMENTS

00-GI022 FACILITY MEDICAL REQUIREMENTS

00-GI025 REPORTS

00-GI101 CAMPUS SITE PLAN

05-CIVIL

00-CS002 GENERAL NOTES

00-CE100 OVERALL UTILITY, EROSION AND SEDIMENT CONTROL PLAN

00-CE101 UTILITY, EROSION AND SEDIMENT CONTROL PLAN 1

00-CE102 UTILITY, EROSION AND SEDIMENT CONTROL PLAN 2

00-CE103 UTILITY, EROSION AND SEDIMENT CONTROL PLAN 3

00-CE104 UTILITY, EROSION AND SEDIMENT CONTROL PLAN 4

00-CE105 UTILITY, EROSION AND SEDIMENT CONTROL PLAN 5

00-CE106 UTILITY, EROSION AND SEDIMENT CONTROL PLAN 6

00-CE107 UTILITY, EROSION AND SEDIMENT CONTROL PLAN 7

00-CE108 UTILITY, EROSION AND SEDIMENT CONTROL PLAN 8

00-CE109 UTILITY, EROSION AND SEDIMENT CONTROL PLAN 9

00-CS100 OVERALL SITE PLAN

00-CS101 SITE PLAN 1

00-CS102 SITE PLAN 2

00-CS103 SITE PLAN 3

00-CS104 SITE PLAN 4

LIST OF DRAWING SHEETS 000115 - 2

00-CS105 SITE PLAN 5

00-CS106 SITE PLAN 6

00-CS107 SITE PLAN 7

00-CS108 SITE PLAN 8

00-CS109 SITE PLAN 9

00-CE501 SOIL EROSION & SEDIMENT CONTROL NOTES

00-CE502 SOIL EROSION & SEDIMENT CONTROL DETAILS

00-CS501 SITE DETAILS

00-CS502 SITE DETAILS

08-ARCHITECTURE

00-AE520 INTERIOR ASSEMBLIES

00-AE522 ROOF DETAILS

00-AE523 DOOR DETAILS

00-AE524 INTERIOR FRAMING DETAILS

00-AE525 INTERIOR FRAMING DETAILS

00-AE526 PARTITION AND MISCELLANEOUS DETAILS

00-AE527 CEILING DETAILS

14-MECHANICAL

00-MG000 MECHANICAL COVERSHEET

00-MG500 MECHANICAL DETAILS

00-MG600 MECHANICAL SCHEDULES

00-MG700 CONTROL DIAGRAMS

00-MG701 VRF TREE DIAGRAMS

15-ELECTRICAL

00-EG000 ELECTRICAL COVERSHEET

00-EG400 ELECTRICAL DETAILS

00-EG401 ELECTRICAL DETAILS

00-EP400 ELECTRICAL SCHEDULES

16-TELECOMMUNICATION

00-TG000 TECHNOLOGY COVERSHEET

00-TG500 TECHNOLOGY DETAILS

00-TG501 TECHNOLOGY DETAILS

00-TG600 TECHNOLOGY DIAGRAMS

00-TG601 TECHNOLOGY DIAGRAMS

00-TG602 TECHNOLOGY DIAGRAMS

00-TG603 TECHNOLOGY DIAGRAMS

00-TG700 TECHNOLOGY SCHEDULES

LIST OF DRAWING SHEETS 000115 - 3

00-TS101 TECHNOLOGY SITE PLAN

16.4.0-PHYSICAL SECURITY

00-TY001 SECURITY NOTES, SYMBOLS, AND ABBREVIATIONS

01-GENERAL

32-GI001 COVER SHEET

32-GI110 EGRESS & SEQUENCE DIAGRAMS

08-ARCHITECTURE

32-AE120 BASEMENT FLOOR PLAN

32-AE121 FIRST & SECOND FLOOR PLANS

32-AE401 ENLARGED PLANS - BASEMENT - TR BA110A

32-AE402 ENLARGED DEMO PLAN - DATA CENTER

32-AE403 ENLARGED FLOOR PLAN - DATA CENTER

32-AE404 ENLARGED PLANS - FIRST FLOOR - TR 1A116

32-AE405 ENLARGED PLANS - SECOND FLOOR - TR 2A112.2

32-AE601 SCHEDULES AND DIAGRAMS

32-H406 ENLARGED HAZMAT PLAN - BASEMENT - TR BA110A

14-MECHANICAL

32-MD100 BASEMENT DEMOLITION PLAN - MECHANICAL

32-MD101 FIRST FLOOR DEMOLITION PLAN - MECHANICAL

32-MD102 SECOND FLOOR DEMOLITION PLAN - MECHANICAL

32-MN100 BASEMENT PLAN - MECHANICAL

32-MN101 FIRST FLOOR PLAN - MECHANICAL

32-MN102 SECOND FLOOR PLAN - MECHANICAL

32-MN400 ENLARGED PLANS - BASEMENT - DC BA120

32-MN401 ENLARGED PLANS - BASEMENT - DC BA120

32-MN402 ENLARGED PLANS - TR

15-ELECTRICAL

32-ED100 BASEMENT DEMOLITION PLAN - ELECTRICAL

32-ED101 FIRST FLOOR DEMOLITION PLAN - ELECTRICAL

32-ED102 SECOND FLOOR DEMOLITION PLAN - ELECTRICAL

32-EN100 BASEMENT PLAN - ELECTRICAL

32-EN101 FIRST FLOOR PLAN - ELECTRICAL

32-EN102 SECOND FLOOR PLAN - ELECTRICAL

32-EN300 ELECTRICAL DETAILS

32-EN301 ELECTRICAL RISER DIAGRAM

32-EN302 ELECTRICAL SCHEDULES

LIST OF DRAWING SHEETS 000115 - 4

32-EN402 ENLARGED PLAN - BASEMENT - TR BA110A

32-EN403 ENLARGED PLAN - FIRST FLOOR - TR 1A116

32-EN404 ENLARGED PLAN - SECOND FLOOR - TR 2A112

16-TELECOMMUNICATION

32-TD100 BASEMENT DEMOLITION PLAN - TECHNOLOGY

32-TD101 FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY

32-TD102 SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY

32-TN100 BASEMENT PLAN - TECHNOLOGY

32-TN101 FIRST FLOOR PLAN - TECHNOLOGY

32-TN102 SECOND FLOOR PLAN - TECHNOLOGY

32-TN400 EXISTING ENLARGED PLANS - BASEMENT - DC BA120

32-TN401 NEW ENLARGED PLANS - BASEMENT - DC BA120

32-TN402 ENLARGED PLANS - BASEMENT - DC BA120

32-TN403 ENLARGED PLANS - BASEMENT - TR BA110A

32-TN404 ENLARGED PLANS - LEVEL 1 - TR 1A116

32-TN405 ENLARGED PLANS - LEVEL 2 - TR 2A112

16.4-PHYSICAL SECURITY

32-TY101 BASEMENT FLOOR SECURITY PLANS

32-TY102 FIRST FLOOR SECURITY PLAN

32-TY103 SECOND FLOOR SECURITY PLAN

32-TY401 DATA CENTER ENLARGED SECURITY PLAN

49-GI001 COVER SHEET

49-GI110 EGRESS & SEQUENCE DIAGRAMS

08-ARCHITECTURE

49-AE101 OVERALL FIRST FLOOR PLAN

49-AE401 ENLARGED PLANS - FIRST FLOOR - TR 1A108A

49-AE601 SCHEDULES AND DIAGRAMS

49-H402 ENLARGED HAZMAT FLOOR PLAN - TR 1A108A

14-MECHANICAL

49-MD101 OVERALL FIRST FLOOR DEMOLITION PLAN - MECHANICAL

49-MN101 OVERALL FIRST FLOOR PLAN - MECHANICAL

49-MN102 ENLARGED PLANS - LEVEL 1 -TR 1A108A

15-ELECTRICAL

49-ED101 OVERALL FIRST FLOOR DEMOLITION PLAN - ELECTRICAL

49-EN101 OVERALL FIRST FLOOR PLAN - ELECTRICAL

LIST OF DRAWING SHEETS 000115 - 5

49-EN400 ENLARGED PLAN - FIRST FLOOR - TR 1A108A

16-TELECOMMUNICATION

49-TD101 OVERALL FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY

49-TD101A FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

49-TD101B FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

49-TN101 OVERALL FIRST FLOOR PLAN - TECHNOLOGY

49-TN101A FIRST FLOOR PLAN - TECHNOLOGY - AREA A

49-TN101B FIRST FLOOR PLAN - TECHNOLOGY - AREA B

49-TN400 ENLARGED PLANS - LEVEL 1 -TR 1A108A

16.4-PHYSICAL SECURITY

49-TY101 FIRST FLOOR SECURITY PLAN

50-GI001 COVER SHEET

50-GI110 EGRESS & SEQUENCE DIAGRAMS

08-ARCHITECTURE

50-AE100 OVERALL GROUND FLOOR PLAN

50-AE101 OVERALL FIRST FLOOR PLAN

50-AE120A GROUND FLOOR PLAN - AREA A

50-AE120B GROUND FLOOR PLAN - AREA B

50-AE120C GROUND FLOOR PLAN - AREA C

50-AE120D GROUND FLOOR PLAN - AREA D

50-AE120E GROUND FLOOR PLAN - AREA E

50-AE121A FIRST FLOOR PLAN - AREA A

50-AE121B FIRST FLOOR PLAN - AREA B

50-AE121C FIRST FLOOR PLAN - AREA C

50-AE121D FIRST FLOOR PLAN - AREA D

50-AE121E FIRST FLOOR PLAN - AREA E

50-AE401 ENLARGED PLANS - GROUND FLOOR - TR GA131

50-AE402 ENLARGED PLANS - FIRST FLOOR - TR 1A129A

50-AE601 SCHEDULES AND DIAGRAMS

14-MECHANICAL

50-MD100 OVERALL GROUND FLOOR DEMOLITION PLAN - MECHANICAL

50-MD101 OVERALL FIRST FLOOR DEMOLITION PLAN - MECHANICAL

50-MN100 OVERALL GROUND FLOOR PLAN - MECHANICAL

50-MN101 OVERALL FIRST FLOOR PLAN - MECHANICAL

50-MN400 ENLARGED PLANS - TR

LIST OF DRAWING SHEETS 000115 - 6

15-ELECTRICAL

50-ED100 OVERALL GROUND FLOOR DEMOLITION PLAN - ELECTRICAL

50-ED101 OVERALL FIRST FLOOR DEMOLITION PLAN - ELECTRICAL

50-EN100 OVERALL GROUND FLOOR PLAN - ELECTRICAL

50-EN101 OVERALL FIRST FLOOR PLAN - ELECTRICAL

50-EN400 ENLARGED PLAN - GROUND - TR GA131

50-EN401 ENLARGED PLAN - FIRST FLOOR - TR 1A129

16-TELECOMMUNICATION

50-TD100 OVERALL GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY

50-TD100A GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

50-TD100B GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

50-TD100C GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA C

50-TD100D GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA D

50-TD100E GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA E

50-TD101 OVERALL FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY

50-TD101A FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

50-TD101B FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

50-TD101C FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA C

50-TD101D FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA D

50-TD101E FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA E

50-TN100 OVERALL GROUND FLOOR PLAN - TECHNOLOGY

50-TN100A GROUND FLOOR PLAN - TECHNOLOGY - AREA A

50-TN100B GROUND FLOOR PLAN - TECHNOLOGY - AREA B

50-TN100C GROUND FLOOR PLAN - TECHNOLOGY - AREA C

50-TN100D GROUND FLOOR PLAN - TECHNOLOGY - AREA D

50-TN100E GROUND FLOOR PLAN - TECHNOLOGY - AREA E

50-TN101 OVERALL FIRST FLOOR PLAN - TECHNOLOGY

50-TN101A FIRST FLOOR PLAN - TECHNOLOGY - AREA A

50-TN101B FIRST FLOOR PLAN - TECHNOLOGY - AREA B

50-TN101C FIRST FLOOR PLAN - TECHNOLOGY - AREA C

50-TN101D FIRST FLOOR PLAN - TECHNOLOGY - AREA D

50-TN101E FIRST FLOOR PLAN - TECHNOLOGY - AREA E

50-TN400 ENLARGED PLANS - GROUND - TR GA130A

50-TN401 ENLARGED PLANS - LEVEL 1 - TR 1A129A

16.4- SECURITY

50-TY120A GROUND FLOOR SECURITY PLAN

50-TY121A FIRST FLOOR SECURITY PLAN

LIST OF DRAWING SHEETS 000115 - 7

51-GI001 COVER SHEET

51-GI110 EGRESS DIAGRAMS

51-GI115 SEQUENCE DIAGRAMS

08-ARCHITECTURE

51-AE100 GROUND FLOOR OVERALL PLAN

51-AE101 FIRST FLOOR OVERALL PLAN

51-AE102 SECOND FLOOR OVERALL PLAN

51-AE103 THIRD FLOOR OVERALL PLAN

51-AE120 GROUND FLOOR PLAN - AREA A

51-AE121 GROUND FLOOR PLAN - AREA B

51-AE122 FIRST FLOOR PLAN - AREA A

51-AE123 FIRST FLOOR PLAN - AREA B

51-AE124 SECOND FLOOR PLAN - AREA A

51-AE125 SECOND FLOOR PLAN - AREA B

51-AE126 THIRD FLOOR PLAN - AREA A

51-AE127 THIRD FLOOR PLAN - AREA B

51-AE401 ENLARGED PLANS - GROUND FLOOR - TR GA102A

51-AE402 ENLARGED PLANS - GROUND FLOOR - TR GA114

51-AE403 ENLARGED PLANS - GROUND FLOOR - TR GB136

51-AE404 ENLARGED PLANS - FIRST FLOOR - TR 1A106

51-AE405 ENLARGED PLANS - FIRST FLOOR - TR 1A121

51-AE406 ENLARGED PLANS - FIRST FLOOR - TR 1B151

51-AE407 ENLARGED PLANS - SECOND FLOOR - TR 2A130

51-AE408 ENLARGED PLANS - SECOND FLOOR - TR 2B169

51-AE409 ENLARGED PLANS - THIRD FLOOR - TR 3A130

51-AE410 ENLARGED PLANS - THIRD FLOOR - TR 3B171

51-AE601 SCHEDULES AND DIAGRAMS

14-MECHANICAL

51-MD100 GROUND FLOOR DEMOLITION PLAN - MECHANICAL

51-MD101 FIRST FLOOR DEMOLITION PLAN - MECHANICAL

51-MD102 SECOND FLOOR DEMOLITION PLAN - MECHANICAL

51-MD103 THIRD FLOOR DEMOLITION PLAN - MECHANICAL

51-MN100 GROUND FLOOR PLAN - MECHANICAL

51-MN101 FIRST FLOOR PLAN - MECHANICAL

51-MN102 SECOND FLOOR PLAN - MECHANICAL

LIST OF DRAWING SHEETS 000115 - 8

51-MN103 THIRD FLOOR PLAN - MECHANICAL

51-MN400 ENLARGED PLANS - TR - BASEMENT

51-MN401 ENLARGED PLANS - TR - FIRST FLOOR

51-MN402 ENLARGED PLANS - TR - SECOND FLOOR

51-MN403 ENLARGED PLANS - TR - THIRD FLOOR

15-ELECTRICAL

51-ED100 GROUND FLOOR DEMOLITION PLAN - ELECTRICAL

51-ED101 FIRST FLOOR DEMOLITION PLAN - ELECTRICAL

51-ED102 SECOND FLOOR DEMOLITION PLAN - ELECTRICAL

51-ED103 THIRD FLOOR DEMOLITION PLAN - ELECTRICAL

51-EN100 GROUND FLOOR PLAN - ELECTRICAL

51-EN101 FIRST FLOOR PLAN - ELECTRICAL

51-EN102 SECOND FLOOR PLAN - ELECTRICAL

51-EN103 THIRD FLOOR PLAN - ELECTRICAL

51-EN400 ENLARGED PLAN - GROUND FLOOR - TR GA114

51-EN401 ENLARGED PLAN - GROUND FLOOR - TR GB136

51-EN402 ENLARGED PLAN - GROUND FLOOR - TR GA102A

51-EN403 ENLARGED PLAN - FIRST FLOOR - TR 1A121

51-EN404 ENLARGED PLAN - FIRST FLOOR - TR 1B151

51-EN405 ENLARGED PLAN - FIRST FLOOR - TR 1A106

51-EN406 ENLARGED PLAN - SECOND FLOOR - TR 2A130

51-EN407 ENLARGED PLAN - SECOND FLOOR - TR 2B169

51-EN408 ENLARGED PLAN - THIRD FLOOR - TR 3A130

51-EN409 ENLARGED PLAN - THIRD FLOOR - TR 3B171

16-TELECOMMUNICATION

51-TD100 OVERALL GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY

51-TD100A GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

51-TD100B GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

51-TD101 OVERALL FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY

51-TD101A FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

51-TD101B FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

51-TD102 OVERALL SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY

51-TD102A SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

51-TD102B SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

51-TD103 OVERALL THIRD FLOOR DEMOLITION PLAN - TECHNOLOGY

51-TD103A THIRD FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

51-TD103B THIRD FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

LIST OF DRAWING SHEETS 000115 - 9

51-TD104 OVERALL ATTIC DEMOLITION PLAN - TECHNOLOGY

51-TD104A ATTIC DEMOLITION PLAN - TECHNOLOGY - AREA A

51-TD104B ATTIC DEMOLITION PLAN - TECHNOLOGY - AREA B

51-TN100 OVERALL GROUND FLOOR PLAN - TECHNOLOGY

51-TN100A GROUND FLOOR PLAN - TECHNOLOGY - AREA A

51-TN100B GROUND FLOOR PLAN - TECHNOLOGY - AREA B

51-TN101 OVERALL FIRST FLOOR PLAN - TECHNOLOGY

51-TN101A FIRST FLOOR PLAN - TECHNOLOGY - AREA A

51-TN101B FIRST FLOOR PLAN - TECHNOLOGY - AREA B

51-TN102 OVERALL SECOND FLOOR PLAN - TECHNOLOGY

51-TN102A SECOND FLOOR PLAN - TECHNOLOGY - AREA A

51-TN102B SECOND FLOOR PLAN - TECHNOLOGY - AREA B

51-TN103 OVERALL THIRD FLOOR PLAN - TECHNOLOGY

51-TN103A THIRD FLOOR PLAN - TECHNOLOGY - AREA A

51-TN103B THIRD FLOOR PLAN - TECHNOLOGY - AREA B

51-TN104 OVERALL ATTIC PLAN - TECHNOLOGY

51-TN104A ATTIC PLAN - TECHNOLOGY - AREA A

51-TN104B ATTIC PLAN - TECHNOLOGY - AREA B

51-TN400 ENLARGED PLANS - GROUND - TR GA114

51-TN401 ENLARGED PLANS - GROUND - TR GB136

51-TN402 ENLARGED PLANS - GROUND - TR GA102A

51-TN403 ENLARGED PLANS - LEVEL 1 - TR 1A121

51-TN404 ENLARGED PLANS - LEVEL 1 - TR 1B151

51-TN405 ENLARGED PLANS- LEVEL 1 - TR 1A106

51-TN406 ENLARGED PLANS - LEVEL 2 - TR 2A130

51-TN407 ENLARGED PLANS - LEVEL 2 - TR 2B169

51-TN408 ENLARGED PLANS - LEVEL 3 - TR 3A130

51-TN409 ENLARGED PLANS - LEVEL 3 - TR 3B171

16.4- PHYSICAL SECURITY

51-TY120 GROUND FLOOR SECURITY PLAN

51-TY121 FIRST FLOOR SECURITY PLANS

51-TY122 SECOND FLOOR SECURITY PLAN

51-TY123 THIRD FLOOR SECURITY PLAN

LIST OF DRAWING SHEETS 000115 - 10

52-GI001 COVER SHEET

52-GI110 EGRESS & SEQUENCE DIAGRAMS

08-ARCHITECTURE

52-AE120 OVERALL BASEMENT & FIRST FLOOR PLANS

52-AE401 ENLARGED PLANS - BASEMENT - TE BA107

52-AE601 SCHEDULES AND DIAGRAMS

52-H120 BASEMENT HAZMAT PLAN

15-ELECTRICAL

52-ED100 BASEMENT DEMOLITION PLAN - ELECTRICAL

52-EN100 BASEMENT PLAN - ELECTRICAL

16-TELECOMMUNICATION

52-TD100 BASEMENT DEMOLITION PLAN - TECHNOLOGY

52-TD101 GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY

52-TN100 BASEMENT PLAN - TECHNOLOGY

52-TN101 GROUND FLOOR PLAN - TECHNOLOGY

52-TN400 ENLARGED PLANS - BASEMENT - TE BA107

52-TY120 OVERALL BASEMENT & FIRST FLOOR PLANS

53-GI001 COVER SHEET

53-GI110 EGRESS & SEQUENCE DIAGRAMS

08-ARCHITECTURE

53-AE121 FIRST & MEZZANINE FLOOR PLAN

53-AE401 ENLARGED PLANS - FIRST FLOOR - TE 1A104

53-AE601 SCHEDULES AND DIAGRAMS

15-ELECTRICAL

53-ED100 FIRST FLOOR DEMOLITION PLAN - ELECTRICAL

53-EN100 FIRST FLOOR PLAN - ELECTRICAL

16-TELECOMMUNICATION

53-TD100 FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY

53-TD101 MEZZANINE DEMOLITION PLAN - TECHNOLOGY

53-TN100 FIRST FLOOR PLAN - TECHNOLOGY

53-TN101 MEZZANINE PLAN - TECHNOLOGY

53-TN400 ENLARGED PLANS - LEVEL 1 - TE1A104

LIST OF DRAWING SHEETS 000115 - 11

53-TY121 FIRST FLOOR SECURITY PLANS

69-GI001 COVER SHEET

69-GI110 EGRESS DIAGRAMS

69-GI115 SEQUENCE DIAGRAMS

08-ARCHITECTURE

69-AE120A FIRST FLOOR PLAN - AREA A

69-AE120B FIRST FLOOR PLAN - AREA B

69-AE121A SECOND FLOOR PLAN - AREA A

69-AE121B SECOND FLOOR PLAN - AREA B

69-AE401 ENLARGED PLANS - FIRST FLOOR - TR 1A131

69-AE402 ENLARGED PLANS - SECOND FLOOR - TR 2A104

69-AE601 SCHEDULES AND DIAGRAMS

14-MECHANICAL

69-MD100 FIRST FLOOR DEMOLITION PLAN - MECHANICAL

69-MD101 SECOND FLOOR DEMOLITION PLAN - MECHANICAL

69-MN100 FIRST FLOOR PLAN - MECHANICAL

69-MN101 SECOND FLOOR PLAN - MECHANICAL

69-MN400 ENLARGED PLANS - TR

15-ELECTRICAL

69-ED100 FIRST FLOOR DEMOLITION PLAN - ELECTRICAL

69-ED101 SECOND FLOOR DEMOLITION PLAN - ELECTRICAL

69-EN100 FIRST FLOOR PLAN - ELECTRICAL

69-EN101 SECOND FLOOR PLAN - ELECTRICAL

69-EN400 ENLARGED PLAN - FIRST FLOOR - TR 1A131

69-EN401 ENLARGED PLAN - SECOND FLOOR - TR 2A104

16-TELECOMMUNICATION

69-TD100 OVERALL FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY

69-TD100A FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

69-TD100B FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

69-TD101 OVERALL SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY

69-TD101A SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

69-TD101B SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

69-TN100 OVERALL FIRST FLOOR PLAN - TECHNOLOGY

69-TN100A FIRST FLOOR PLAN - TECHNOLOGY - AREA A

69-TN100B FIRST FLOOR PLAN - TECHNOLOGY - AREA B

LIST OF DRAWING SHEETS 000115 - 12

69-TN101 OVERALL SECOND FLOOR PLAN - TECHNOLOGY

69-TN101A SECOND FLOOR PLAN - TECHNOLOGY - AREA A

69-TN101B SECOND FLOOR PLAN - TECHNOLOGY - AREA B

69-TN400 ENLARGED PLANS - LEVEL 1 - TR 1A131

69-TN401 ENLARGED PLANS - LEVEL 2 - TR 2A104

16.4- PHYSICAL SECURITY

69-TY120 FIRST & SECOND FLOOR SECURITY PLANS

70-GI001 COVER SHEET

70-GI110 EGRESS DIAGRAMS

70-GI115 SEQUENCE DIAGRAMS

08-ARCHITECTURE

70-AE120 BASEMENT FLOOR PLAN

70-AE121A FIRST FLOOR PLAN - AREA A

70-AE121B FIRST FLOOR PLAN - AREA B

70-AE122A SECOND FLOOR PLAN - AREA A

70-AE122B SECOND FLOOR PLAN - AREA B

70-AE401 ENLARGED PLANS - BASEMENT - TR BA003

70-AE402 ENLARGED PLANS - FIRST FLOOR - TR 1A140A

70-AE403 ENLARGED PLANS - FIRST FLOOR - TR 1A166

70-AE404 ENLARGED PLANS - SECOND FLOOR - TR 2A239A

70-AE405 ENLARGED PLANS - SECOND FLOOR - TR 2A260

70-AE601 SCHEDULES AND DIAGRAMS

14-MECHANICAL

70-MD100 BASEMENT DEMOLITION PLAN - MECHANICAL

70-MD101 FIRST FLOOR DEMOLITION PLAN - MECHANICAL

70-MD102 SECOND FLOOR DEMOLITION PLAN - MECHANICAL

70-MN100 BASEMENT PLAN - MECHANICAL

70-MN101 FIRST FLOOR PLAN - MECHANICAL

70-MN102 SECOND FLOOR PLAN - MECHANICAL

70-MN400 ENLARGED PLANS - TR

70-MN401 ENLARGED PLANS - TR

15-ELECTRICAL

70-ED100 GROUND FLOOR DEMOLITION PLAN - ELECTRICAL

70-ED101 FIRST FLOOR DEMOLITION PLAN - ELECTRICAL

70-ED102 SECOND FLOOR DEMOLITION PLAN - ELECTRICAL

LIST OF DRAWING SHEETS 000115 - 13

70-EN100 GROUND FLOOR PLAN - ELECTRICAL

70-EN101 FIRST FLOOR PLAN - ELECTRICAL

70-EN102 SECOND FLOOR PLAN - ELECTRICAL

70-EN300 ELECTRICAL SCHEDULES

70-EN400 ENLARGED PLAN - BASEMENT - TR BA003

70-EN401 ENLARGED PLAN - FIRST FLOOR - TR 1A140A

70-EN402 ENLARGED PLAN - FIRST FLOOR - TR 1A166

70-EN403 ENLARGED PLAN - SECOND FLOOR - TR 2A260

70-EN404 ENLARGED PLAN SECOND FLOOR - TR 2A239A

16-TELECOMMUNICATION

70-TD100 OVERALL BASEMENT FLOOR DEMOLITION PLAN - TECHNOLOGY

70-TD100A BASEMENT FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

70-TD101 OVERALL FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY

70-TD101A FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

70-TD101B FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

70-TD102 OVERALL SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY

70-TD102A SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

70-TD102B SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

70-TN100 OVERALL BASEMENT FLOOR PLAN - TECHNOLOGY

70-TN100A BASEMENT FLOOR PLAN - TECHNOLOGY - AREA A

70-TN100B BASEMENT FLOOR PLAN - TECHNOLOGY - AREA B

70-TN101 OVERALL FIRST FLOOR PLAN - TECHNOLOGY

70-TN101A FIRST FLOOR PLAN - TECHNOLOGY - AREA A

70-TN101B FIRST FLOOR PLAN - TECHNOLOGY - AREA B

70-TN102 OVERALL SECOND FLOOR PLAN - TECHNOLOGY

70-TN102A SECOND FLOOR PLAN - TECHNOLOGY - AREA A

70-TN102B SECOND FLOOR PLAN - TECHNOLOGY - AREA B

70-TN400 ENLARGED PLANS - BASEMENT - TR BA003

70-TN401 ENLARGED PLANS - LEVEL 1 - TR 1A140A

70-TN402 ENLARGED PLANS - LEVEL 1 - TR 1A166

70-TN403 ENLARGED PLANS - LEVEL 2 - TR 2A260

70-TN404 ENLARGED PLANS - LEVEL 2 - TR 2A239A

16.4-PHYSICAL SECURITY

70-TY120 BASEMENT FLOOR SECURITY PLAN

70-TY121 FIRST FLOOR SECURITY PLAN

70-TY122 SECOND FLOOR SECURITY PLAN

LIST OF DRAWING SHEETS 000115 - 14

71-GI001 COVER SHEET

71-GI110 EGRESS DIAGRAMS

71-GI115 SEQUENCE DIAGRAMS

08-ARCHITECTURE

71-AE100 OVERALL GROUND FLOOR PLAN

71-AE101 OVERALL FIRST FLOOR PLAN

71-AE102 OVERALL SECOND FLOOR PLAN

71-AE120A GROUND FLOOR PLAN - AREA A

71-AE120B GROUND FLOOR FLOOR - AREA B

71-AE121A FIRST FLOOR PLAN - AREA A

71-AE121B FIRST FLOOR PLAN - AREA B

71-AE121C FIRST FLOOR PLAN - AREA C

71-AE122A SECOND FLOOR PLAN - AREA A

71-AE122B SECOND FLOOR PLAN - AREA B

71-AE122C SECOND FLOOR PLAN - AREA C

71-AE401 ENLARGED PLANS - GROUND FLOOR - TR GA119

71-AE402 ENLARGED PLANS - FIRST FLOOR - TR 1A168

71-AE403 ENLARGED PLANS - FIRST FLOOR - TR 1C122

71-AE404 ENLARGED PLANS - SECOND FLOOR - TR 2A127

71-AE405 ENLARGED PLANS - SECOND FLOOR - TR 2C108

71-AE601 SCHEDULES AND DIAGRAMS

14-MECHANICAL

71-MD100 OVERALL GROUND FLOOR DEMOLITION PLAN - MECHANICAL

71-MD101 OVERALL FIRST FLOOR DEMOLITION PLAN - MECHANICAL

71-MD102 OVERALL SECOND FLOOR DEMOLITION PLAN - MECHANICAL

71-MD103 OVERALL ROOF DEMOLITION PLAN - MECHANICAL

71-MN100 OVERALL GROUND FLOOR PLAN - MECHANICAL

71-MN101 OVERALL FIRST FLOOR PLAN - MECHANICAL

71-MN102 OVERALL SECOND FLOOR PLAN - MECHANICAL

71-MN103 OVERALL ROOF PLAN - MECHANICAL

71-MN400 ENLARGED PLANS - TR - GROUND FLOOR

71-MN401 ENLARGED PLANS - TR - LEVEL 1

71-MN402 ENLARGED PLANS - TR - LEVEL 2

15-ELECTRICAL

71-ED100 OVERALL GROUND FLOOR DEMOLITION PLAN - ELECTRICAL

71-ED101 OVERALL FIRST FLOOR DEMOLITION PLAN - ELECTRICAL

LIST OF DRAWING SHEETS 000115 - 15

71-ED102 OVERALL SECOND FLOOR DEMOLITION PLAN - ELECTRICAL

71-EN100 OVERALL GROUND FLOOR PLAN - ELECTRICAL

71-EN101 OVERALL FIRST FLOOR PLAN - ELECTRICAL

71-EN102 OVERALL SECOND FLOOR PLAN - ELECTRICAL

71-EN300 ELECTRICAL SCHEDULES

71-EN400 ENLARGED PLAN - GROUND - TE GA119

71-EN401 ENLARGED PLAN - FIRST FLOOR - TR 1A168

71-EN402 ENLARGED PLAN - FIRST FLOOR - TR 1C122

71-EN403 ENLARGED PLAN - SECOND FLOOR - TR 2C108

71-EN404 ENLARGED PLAN - SECOND FLOOR - TR 2A127

16-TELECOMMUNICATION

71-TD100 OVERALL GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY

71-TD100A GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

71-TD100B GROUND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

71-TD101 OVERALL FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY

71-TD101A FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

71-TD101B FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

71-TD101C FIRST FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA C

71-TD102 OVERALL SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY

71-TD102A SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA A

71-TD102B SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA B

71-TD102C SECOND FLOOR DEMOLITION PLAN - TECHNOLOGY - AREA C

71-TN100 OVERALL GROUND FLOOR PLAN - TECHNOLOGY

71-TN100A GROUND FLOOR PLAN - TECHNOLOGY - AREA A

71-TN100B GROUND FLOOR PLAN - TECHNOLOGY - AREA B

71-TN101 OVERALL FIRST FLOOR PLAN - TECHNOLOGY

71-TN101A FIRST FLOOR PLAN - TECHNOLOGY - AREA A

71-TN101B FIRST FLOOR PLAN - TECHNOLOGY - AREA B

71-TN101C FIRST FLOOR PLAN - TECHNOLOGY - AREA C

71-TN102 OVERALL SECOND FLOOR PLAN - TECHNOLOGY

71-TN102A SECOND FLOOR PLAN - TECHNOLOGY - AREA A

71-TN102B SECOND FLOOR PLAN - TECHNOLOGY - AREA B

71-TN102C SECOND FLOOR PLAN - TECHNOLOGY - AREA C

71-TN400 ENLARGED PLANS - GROUND - TE GA119

71-TN401 ENLARGED PLANS - LEVEL 1 - TR 1A168

71-TN402 ENLARGED PLANS - LEVEL 1 - TR 1C122

71-TN403 ENLARGED PLANS - LEVEL 2 - TR 2C108

LIST OF DRAWING SHEETS 000115 - 16

71-TN404 ENLARGED PLANS - LEVEL 2 - TR 2A127

16.4- PHYSICAL SECURITY

71-TY120 GROUND FLOOR SECURITY PLANS

71-TY121 FIRST FLOOR SECURITY PLANS

71-TY122 SECOND FLOOR SECURITY PLAN

- - - E N D - - -

GENERAL REQUIREMENTS 010000 - 1

SECTION 010000

GENERAL REQUIREMENTS

PART 1 - GENERAL

1.01 SAFETY REQUIREMENTS

A. Refer to section 013526, SAFETY REQUIREMENTS for safety and infection control requirements.

1.02 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing items, and furnish labor and materials and perform work for the EHRM upgrades to the VA Pittsburgh Healthcare System (VAPHS) H. J. Heinz III Campus as required by drawings and specifications.

B. Visits to the site by Bidders may be made in accordance with what is listed in the solicitation and at the discretion of the Contracting Officer.

C. Offices of AWEN SOLUTIONS GROUP LLC, as ArchitectEngineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

D. Before placement and installation of work subject to tests by testing laboratory retained by Department of Veterans Affairs, the Contractor shall notify the COR in sufficient time to enable testing laboratory personnel to be present at the site in time for proper taking and testing of specimens and field inspection. Such prior notice shall be not less than three workdays unless otherwise designated by the COR.

E. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

F. Normal working hours for this contract will be from 7:00AM to 4:30PM (local time) Monday through Friday except for weekends and established Federal Holidays.

G. Performing on-site work outside normal working hours will require approval from the Contracting Officer and the COR. Requests shall be submitted via email at least 72 hours prior to the requested date and at no additional cost to the Government. Approvals are subject to the availability of on-site staff.

1.03 STATEMENT OF BID ITEM(S)

A. ITEM I, GENERAL CONSTRUCTION: BASE BID: Work includes but not limited to general construction, infrastructure upgrades, reconfiguration, expansion, and renovation of existing space (demo, new construction, finishes, cable). TInfrastructure upgrades include electrical, bonding, UPS, building management system interfaces, HVAC, communication, physical security upgrades, and fiber infrastructure backbone campus wide. Within each and in between the buildings, which will include modification that may impact roads, walks, grading, drainage, and other

GENERAL REQUIREMENTS 010000 - 2

existing utilities. Data Center WAN updates and hazardous material abatement. Project Buildings are 32, 49, 50, 51, 52, 53, 69, 70, 71, and any associated work in other buildings and site as indicated. The work includes phasing and ICRA requirements for area closures and utility shutdowns that shall be required to accommodate the proposed construction work.

1.04 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense.

1.05 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give one week’s notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section. This notice is also separate from any additional security and badging requirements provided for elsewhere in this contract.

3. No photography of VA premises is allowed without written permission of the Contracting Officer. Patients and staff are not to be photographed at any time.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the Contracting Officer.

5. For any request for working outside the “regular hours” as defined in the contract, the General Contractor shall give the Contracting Officer/Contracting Officer’s Representative a minimum of 5 business day notice so that security can be arranged, and notifications can be made. This notice is separate from any notices required for utility shutdowns described later in this section.

C. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the Contracting officers representative (COR) for the purpose of security inspections of every area of project including tool boxes and parked machines and take any emergency action.

2. The General Contractor shall turn over all permanent lock cylinders to the VA locksmith for permanent installation. See Section 087100, DOOR HARDWARE and coordinate.

D. Document Control:

GENERAL REQUIREMENTS 010000 - 3

1. Before starting any work, the General Contractor/Sub Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of “sensitive information”.

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and drawings may be marked “Law Enforcement Sensitive” or “Sensitive Unclassified”.

Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the Contracting Officer upon request.

4. These security documents shall not be removed or transmitted from the project site without the written approval of Contracting Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an Engineering Document Management Software (EDMS).

a. Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the EDMS system.

b. “Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

E. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. No parking is permitted on site during this project. No permits for parking onsite shall be issued during this project. Any employee of the General Contractor or any subcontractor found parking onsite may be issued a citation and fine by the VA Police at any time. Any employee of the General Contractor or any subcontractor found parking onsite shall be asked to remove their vehicle from the site immediately and that employee shall be permanently prohibited from working on this project for the duration of this contract.

1.06 OPERATIONS AND STORAGE AREAS (FAR 52.236-10)

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the Contracting Officer and shall be built with labor and materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the Contractor and

GENERAL REQUIREMENTS 010000 - 4

shall be removed by the Contractor at its expense upon completion of the work. With the written consent of the Contracting Officer, the buildings and utilities may be abandoned and need not be removed.

C. The Contractor shall, under regulations prescribed by the Contracting Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

D. Working space and space available for storing materials shall be as determined by the COR. All space(s) provided by the COR are not to be considered permanent. The COR may request that the contractor relocate, enlarge, shrink, and/or eliminate any or all spaces provided during the project. All reconfiguration of space shall be done at no additional cost to the government.

E. Workers are subject to rules of Medical Center applicable to their conduct.

F. Execute work in such a manner as to interfere as little as possible with work being done by others. Keep roads clear of construction materials, debris, standing construction equipment and vehicles at all times.

G. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR.

1. Do not store materials and equipment in other than assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of Veterans Affairs in quantities sufficient for not more than two work days. Provide unobstructed access to Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

H. Utilities Services: Maintain existing utility services for Medical Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR and Projects Supervisor.

Electrical work shall be accomplished with all affected circuits or

GENERAL REQUIREMENTS 010000 - 5

equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval. Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, 27 05 11 REQUIREMENTS FOR COMMUNICATIONS INSTALLATIONS and 28 05 00, COMMON WORK RESULTS FOR ELECTRONIC SAFETY AND SECURITY for additional requirements.

2. Contractor shall submit a request to interrupt any such services to COR, in writing, 14 days in advance of proposed interruption.

Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor shall be advised (in writing) of approval of request, or of which other date and/or time such interruption shall cause least inconvenience to operations of Medical Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours. Performance of a utility outage at other than the Contractor’s requested date and time to minimize impact on medical center operations shall not be a basis for additional contract time, cost, or contract delay and shall be done at no additional cost to the government.

4. Major interruptions of any system must be requested, in writing, at minimum 21 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service shall be interrupted on approval of COR. Such approval shall be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

I. Phasing:

1. The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur. It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety and infection control measures (outlined by ICRA standard) to be used during the work, and a schedule defining the duration of the work with milestone subtasks.

2. To ensure such executions, Contractor shall furnish the COR with a schedule of approximate phasing dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. Since unpredictable variables may affect the construction sequence scheduling, a protocol for making changes due to unforeseen problems should be plainly stated. The contractor shall update the Construction Sequencing Plan as changes occur during the course of work. In addition, Contractor shall notify the COR three weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof.

Arrange such dates to ensure accomplishment of this work in successive phases mutually agreeable to COR and Contractor.

GENERAL REQUIREMENTS 010000 - 6

3. Contractor shall take all measures and provide all material necessary for protecting existing equipment and property in affected areas of construction against dust and debris, so that equipment and affected areas to be used in the Medical Centers operations will not be hindered. Contractor shall permit access to Department of Veterans Affairs personnel and patients through other construction areas which serve as routes of access to such affected areas and equipment. These routes whether access or egress shall be isolated from the construction area by temporary partitions and have walking surfaces, lighting etc. to facilitate patient and staff access. Coordinate alteration work in areas occupied by Department of Veterans Affairs so that Medical Center operations will continue during the construction period.

J. Construction Fence: Before construction operations begin, Contractor shall provide a chain link construction fence, 2.1m (seven feet) minimum height, around the construction area indicated on the drawings. Provide gates as required for access with necessary hardware, including hasps and padlocks. Fasten fence fabric to terminal posts with tension bands and to line posts and top and bottom rails with tie wires spaced at maximum 375mm (15 inches). Bottom of fences shall extend to 25mm (one inch) above grade. Remove the fence when directed by COR.

K. When a building and/or construction site is turned over to Contractor, Contractor shall accept entire responsibility including upkeep and maintenance therefore:

1. Contractor shall maintain a minimum temperature of 4 degrees C (40 degrees F) at all times, except as otherwise specified.

2. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make arrangements for pre-inspection of site with Fire Department or Company (Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from Contractor's employee or worker.

L. Utilities Services: Maintain existing utility services for Medical Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR and Projects Supervisor.

Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval. Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, 27 05 11 REQUIREMENTS FOR COMMUNICATIONS INSTALLATIONS and 28 05 00, COMMON WORK RESULTS FOR ELECTRONIC SAFETY AND SECURITY for additional requirements.

2. Contractor shall submit a request to interrupt any such services to COR, in writing, 14 days in advance of proposed interruption.

GENERAL REQUIREMENTS 010000 - 7

Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours. Performance of a utility outage at other than the Contractor’s requested date and time to minimize impact on medical center operations shall not be a basis for additional contract time, cost, or contract delay and shall be done at no additional cost to the government.

4. Major interruptions of any system must be requested, in writing, at least 21 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

M. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, shall be removed back to their source. Those which are indicated to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

N. To minimize interference of construction activities with flow of Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.