A5_Blank Bid Schedule.pdf

PDF 63 KB Posted

Attached to
Repair MAF and Base Fire Alarms - DSN/CSN, IDIQ
Solicitation number
FA4626-26-R-0012
Issued by

About this file

This document is a Base Bid Schedule for repair and replacement of fire alarm systems at multiple Military Air Facilities (MAF).

The schedule contains nine contract line items (CLINs 0001-0009) with the following structure: CLIN 0001 covers Government Delays compensated at a crew-hour rate for up to 70 crew-hours, with delays measured in 15-minute increments and verified by the Contracting Officer's Representative (COR). All contractor personnel working simultaneously at the MAF constitute one crew, with one hourly rate covering all personnel and equipment costs regardless of staffing levels or equipment types. CLIN 0002 addresses Bonding as a lump sum payment per Delivery Order on a reimbursable cost basis without profit and overhead markup. CLINs 0003 through 0009 are substantially identical lump sum line items for fire alarm system repairs at specific MAF locations (D-01, E-01, F-01, I-01, L-01, N-01, and O-01). Each repair CLIN includes comprehensive costs for labor, materials, and equipment covering design, construction, mobilization, cleaning, installation, commissioning, and testing. Work scope includes removing existing Simplex fire alarm systems, designing new systems by NICET Level 3 Fire Alarm Specialists, obtaining licensed fire protection engineer review and stamping, installing new Harrington systems, system programming, training, and manufacturer certification. The document provides blank fields for contractors to enter unit prices and extended prices, with a final line for the Estimated Total of all CLINs 0001-0009.

View the file

Other files

Show all 19

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file

Text version

BASE BID SCHEDULE – Repair Fire Alarm, MAF TO1

0001 Government Delays. Measurement and payment for this item shall be at the contract unit price per crew-hour for “Government Delays.” Crew delays shall be measured by the crew hour and verified by the COR. The delay time will be broken down into 15-minute fractions of an hour. Crew-Hour shall include equipment time as well as personnel time. All contractor personnel simultaneously working at the MAF will be considered one crew for this item with one hourly rate to include all personnel and equipment. The bid price will cover all costs regardless of the number of employees, types of equipment, or nature of the work.

Unit Unit Price Unit Quantity Extended Price

Crew-Hour 70

Total

0002 Bonding. Shall be paid for as a Lump Sum per Delivery Order at the amount per Government contract requirements. Profit and Overhead are not applied to this sub-CLIN and will be paid on a reimbursable cost basis.

Unit Unit Price Unit Quantity Extended Price

Lump Sum 1

Total

0003 MAF D-01 Repair Fire Alarm. Payment shall include all costs for labor, materials, and equipment associated with design, construction, mobilization, cleaning, installation, commission, and testing associated with work to remove existing Simplex fire alarm system and devices, design of new system by NICET Level 3 FAS, licensed fire protection engineer review and stamp, installation of new Harrington system, system programming, system training, and system certification by manufacturer authorized personnel. Payment will include all other incidental items necessary to complete the work.

Unit Unit Price Unit Quantity Extended Price

Lump Sum 1

Total

0004 MAF E-01 Repair Fire Alarm. Payment shall include all costs for labor, materials, and equipment associated with design, construction, mobilization, cleaning, installation, commission, and testing associated with work to remove existing Simplex fire alarm system and devices, design of new system by NICET Level 3 FAS, licensed fire protection engineer review and stamp, installation of new Harrington system, system programming, system training, and system certification by manufacturer authorized personnel. Payment will include all other incidental items necessary to complete the work.

Unit Unit Price Unit Quantity Extended Price

0005 MAF F-01 Repair Fire Alarm. Payment shall include all costs for labor, materials, and commission, and testing associated with work to remove existing Simplex fire alarm system and devices, design of new system by NICET Level 3 FAS, licensed fire protection engineer review and stamp, installation of new Harrington system, system programming, system training, and system certification by manufacturer authorized personnel. Payment will include all other incidental items necessary to complete the work.

Unit Unit Price Unit Quantity Extended

0006 MAF I-01 Repair Fire Alarm. Payment shall include all costs for labor, materials, and commission, and testing associated with work to remove existing Simplex fire alarm system and devices, design of new system by NICET Level 3 FAS, licensed fire protection engineer review and stamp, installation of new Harrington system, system programming, system training, and system certification by manufacturer authorized personnel. Payment will include all other incidental items necessary to complete the work.

Unit Unit Price Unit Quantity Extended

0007 MAF L-01 Repair Fire Alarm. Payment shall include all costs for labor, materials, and commission, and testing associated with work to remove existing Simplex fire alarm system and devices, design of new system by NICET Level 3 FAS, licensed fire protection engineer review and stamp, installation of new Harrington system, system programming, system training, and system certification by manufacturer authorized personnel. Payment will include all other incidental items necessary to complete the work.

Unit Unit Price Unit Quantity Extended

0008 MAF N-01 Repair Fire Alarm. Payment shall include all costs for labor, materials, and commission, and testing associated with work to remove existing Simplex fire alarm system and devices, design of new system by NICET Level 3 FAS, licensed fire protection engineer review and stamp, installation of new Harrington system, system programming, system training, and system certification by manufacturer authorized personnel. Payment will include all other incidental items necessary to complete the work.

Unit Unit Price Unit Quantity Extended

0009 MAF O-01 Repair Fire Alarm. Payment shall include all costs for labor, materials, and commission, and testing associated with work to remove existing Simplex fire alarm system and devices, design of new system by NICET Level 3 FAS, licensed fire protection engineer review and stamp, installation of new Harrington system, system programming, system training, and system certification by manufacturer authorized personnel. Payment will include all other incidental items necessary to complete the work.

Unit Unit Price Unit Quantity Extended

Estimated Total CLINS 0001 – 0009 $_________

File details come from the government source that posted it. Updated .