50150622_Glendale_Fire_Station_Specs_2024.pdf

CONSTRUCTION AND TECHNICAL

SPECIFICATIONS

FOR

GLENDALE FIRE STATION

PREPARED FOR:

WALTON COUNTY

PREPARED BY:

February 2024

PROJECT #: 50150622

CONTRACT DOCUMENTS FOR GLENDALE FIRE STATION

WALTON COUNTY, FLORIDA PROJECT # 50150622 Table of Contents: Page 1 of 4

TABLE OF CONTENTS FOR GLENDALE FIRE STATION

BIDDING AND CONTRACT DOCUMENTS PAGES

Document No. 1 Section 00015 Project Overview 1

Document No. 2 Section 00030 Bid Form 1-3

Document No. 3 Section 00100 Change Order 1-2

Document No. 4 Section 00110 General Conditions 1-15

GENERAL REQUIREMENTS PAGES

Document No. 1 Section 01030 Alternates 1

Document No. 2 Section 01090 Definitions and Standards 1-4

Document No. 3 Section 01155 Schedules, Reports, Payments 1-2

Document No. 4 Section 01205 Procedures and Controls 1-4

Document No. 5 Section 01340 Submittals 1-2

Document No. 6 Section 01605 Products and Substitutions 1-4

Document No. 7 Section 01705 Project Closeout 1-4

SITEWORK PAGES

Document No. 1 Section 02110 Site Clearing 1-3

Document No. 2 Section 02200 Earthwork 1-8

Document No. 3 Section 02210 Grassing 1-4

Document No. 4 Section 02211 Sodding 1-3

Document No. 5 Section 02800 Irrigation 1-5

Document No. 6 Section 02830 Chain Link Fencing and Gates 1-5

WALTON COUNTY, FLORIDA PROJECT # 50150622 Table of Contents: Page 2 of 4

ASPHALT PAGES

Document No. 1 Section 02500 Paving Quality Control System 1

Document No. 2 Section 02505 Paving Construction Details 1 and Materials

Document No. 3 Section 02510 General Construction Requirements 1-11 for Asphalt Testing

Document No. 4 Section 02516 Limerock Base Course 1-3

Document No. 5 Section 02518 Painting Traffic Stripes 1-4

Document No. 6 Section 02519 Sand-Clay Base 1-3

Document No. 7 Section 02520 Asphalt Testing 1-2

CONCRETE PAGES

Document No. 1 Section 03310 Concrete Work 1-15

Document No. 2 Section 03390 Curing, Sealing, and Hardening 1-3 Concrete Floors

BUILDING PAGES

Document No. 1 Section 05120 Structural Steel 1-11

Document No. 2 Section 05400 Cold-Formed Metal Framing 1-9

Document No. 3 Section 05500 Metal Fabrication 1-9

Document No. 4 Section 06100 Rough Carpentry 1-7

Document No. 5 Section 06402 Interior Architectural Woodwork 1-9

Document No. 6 Section 07210 Building Insulation 1-5

Document No. 7 Section 07620 Sheet Metal Flashing and Trim 1-6

Document No. 8 Section 07901 Joint Sealants 1-11

Document No. 9 Section 07910 Joint Firestopping 1-9

WALTON COUNTY, FLORIDA PROJECT # 50150622 Table of Contents: Page 3 of 4

Document No. 10 Section 07920 Penetration Firestopping 1-7

Document No. 11 Section 07930 Water Repellents 1-8

Document No. 12 Section 08110 Steel Doors and Frames 1-6

Document No. 13 Section 08210 Wood Doors 1-4

Document No. 14 Section 08360 Sectional Overhead Doors 1-5

Document No. 15 Section 08400 Glass, Glazing and Aluminum Windows 1-8

Document No. 16 Section 08710 Door Hardware 1-13

Document No. 17 Section 09255 Gypsum Board Assemblies 1-15

Document No. 18 Section 09310 Ceramic Tile 1-10

Document No. 19 Section 09670 Fluid Applied Resinous Floorings 1-5

Document No. 20 Section 09900 Painting 1-12

Document No. 21 Section 09910 Light Commercial / Residential Painting 1-7

Document No. 22 Section 10810 Toiletry Accessories 1-2

Document No. 23 Section 12300 Fire Extinguishers, Cabinets and 1-4 Accessories

Document No. 24 Section 12366 Solid Surface Countertops 1-6

Document No. 25 Section 12370 Wood Cabinets 1-6

Document No. 26 Section 12375 Wood Veneer Cabinets 1-9

PEMB PAGES

Document No.1 Section 13000 Metal Building Systems 1-15

MECHANICAL PAGES

Document No. 1 Section 15010 Basic Mechanical Requirements 1-3

Document No. 2 Section 15051 Mechanical Related Work 1-2

Document No. 3 Section 15060 Pipe and Pipe Fittings 1-6

WALTON COUNTY, FLORIDA PROJECT # 50150622 Table of Contents: Page 4 of 4

Document No. 4 Section 15065 Gravity Sanitary Sewage Systems 1-4

Document No. 5 Section 15100 Valves and Gates 1-9

Document No. 6 Section 15120 Piping Specialties 1-3

STORMWATER CONVEYANCE PAGES

Document No. 1 Section 334200 Stormwater Conveyance 1-9

APPENDICIES

APPENDIX A General Vicinity Map and Location Maps

APPENDIX B Geotechnical Report

APPENDIX C Roof Panel Installation Guide

APPENDIX D 10-2 Self Certification for Stormawater

APPENDIX E Septic Permit

APPENDIX F Water Storage Tank Pad Detail

CONTRACT DOCUMENTS FOR GLENDALE FIRE STATION Section 00015

WALTON COUNTY, FLORIDA - PROJECT#50150622 Project Overview: Page 1 of 1

TECHNICAL SPECIFICATIONS FOR GLENDALE FIRE STATION

SECTION 00015-PROJECT OVERVIEW

The project includes the construction of a new 8,120-sf pre-fabricated / engineered steel and wood construction fire station for Walton County Fire Rescue. Project scope includes mechanical, electrical, plumbing, building construction, and site work. The project site is located northeast of the intersection of

SR-83 and County Highway 2, located in Glendale, Walton County, Florida. The property is approximately 7.58 acres and is identified by parcel # 27-5N-19-21000-001-0040 based on Walton

County Property Appraiser data. The existing site is currently undeveloped. Water and sewer are currently not available to the site. Please refer to the bidding and contract specifications for more information.

CONTRACT DOCUMENTS FOR GLENDALE FIRE STATION Section 00100 WALTON COUNTY, FLORIDA - PROJECT #50150622 Change Order: Page 1 of 2

CHANGE ORDER

Order No.

Date:

Agreement Date:

Name of Project:

Owner:

Contractor:

The following changes are hereby made to the Contract Documents:

Justification:

CONTRACT DOCUMENTS FOR GLENDALE FIRE STATION Section 00100 WALTON COUNTY, FLORIDA - PROJECT #50150622 Change Order: Page 2 of 2

ORIGINAL Contract Price:

PREVIOUS CHANGES to Contract Price:

Current Contract Price adjusted by PREVIOUS Change Order:

The Contract Price due to this Change Order will be (INCREASED) (DECREASED)

By:

The NEW Contract Price including THIS Change Order will be:

Change CONTRACT TIME:

The CONTRACT TIME will be (INCREASED) (DECREASED) by:

calendar days.

The DATE FOR COMPLETION of all work will be (Date)

Approvals Required:

Owner:

Contractor:

Engineer:

CONTRACT DOCUMENTS FOR GLENDALE FIRE STATION Section 00110 WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 1 of 15

TECHNICAL SPECIFICATIONS FOR GLENDALE FIRE STATION

SECTION 00110-GENERAL CONDITIONS

1. Definitions

2. Additional Instructions and Detail Drawings

3. Schedules, Reports, and Records

4. Drawings and Specifications

5. Shop Drawings

6. Materials, Services, and Facilities

7. Inspection and Testing

8. Substitutions

9. Patents

10. Surveys, Permits, Regulations

11. Protection of Work, Property, Persons

12. Supervision by Contractor

13. Changes in the Work

14. Changes in Contract Price

15. Time for Completion and Liquidated Damages

16. Correction of Work

17. Subsurface Conditions

18. Suspension of Work, Termination, and Delay

19. Assignments

20. Indemnification

21. Separate Contracts

22. Subcontracting

23. Engineer's Authority

24. Land and Rights-of-Way

25. Guarantee

26. Arbitration (Not Applicable)

27. Taxes

1. DEFINITIONS

1.1 Wherever used in the Contract Documents, the following terms shall have the meanings indicated and shall be applicable to both the singular and plural thereof:

1.2 ADDENDA - Written or graphic instruments issued prior to the execution of the Agreement which modify or interpret the CONTRACT DOCUMENTS, DRAWINGS and SPECIFICATIONS, by additions, deletions, clarifications, or corrections.

1.3 BID - The offer or proposal of the BIDDER submitted on the prescribed form setting forth the prices for the WORK to be performed.

1.4 BIDDER - Any person, firm, or corporation submitting a BID for the WORK.

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 2 of 15

1.5 BONDS - Bid, Performance, and Payment Bonds and other instruments of surety, furnished by the CONTRACTOR and the CONTRACTOR'S surety in accordance with the CONTRACT

DOCUMENTS.

1.6 CHANGE ORDER - A written order to the CONTRACTOR authorizing an addition, deletion, or revision in the WORK within the general scope of the CONTRACT DOCUMENTS, or authorizing an adjustment in the CONTRACT PRICE or CONTRACT TIME.

1.7 CONTRACT DOCUMENTS - The contract, including Advertisement for BIDS, Information for BIDDERS, BID, BID BOND, Agreement, Payment BOND, Performance BOND, NOTICE OF AWARD, NOTICE TO PROCEED, CHANGE ORDER, DRAWINGS, SPECIFICATIONS, and

ADDENDA.

1.8 CONTRACT PRICE - The total monies payable to the CONTRACTOR under the terms and conditions of the CONTRACT DOCUMENTS.

1.9 CONTRACT TIME - The number of calendar days stated in the CONTRACT DOCUMENTS for the completion of the WORK.

1.10 CONTRACTOR - The person, firm or corporation with whom the OWNERS has executed the Agreement.

1.11 DRAWINGS - The parts of the CONTRACT DOCUMENTS which show the characteristics and scope of the WORK to be performed and which have been prepared or approved by the

ENGINEER.

1.12 ENGINEER - The person, firm, or corporation named as such in the CONTRACT

DOCUMENTS.

1.13 FIELD ORDER - A written order effecting a change in the WORK not involving an adjustment in the CONTRACT PRICE or an extension of the CONTRACT TIME, issued by the ENGINEER to the CONTRACTOR during construction.

1.14 NOTICE OF AWARD - The written notice of the acceptance of the BID from the OWNERS to the successful BIDDER.

1.15 NOTICE TO PROCEED - Written communication issued by the OWNERS to the CONTRACTOR authorizing him/her to proceed with the WORK and establishing the date for commencement of the WORK.

1.16 OWNERS - A public or quasi-public body or authority, corporation, association, partnership, or an individual for whom the WORK is to be performed.

1.17 PROJECT - The undertaking to be performed as provided in the CONTRACT

DOCUMENTS.

1.18 RESIDENT PROJECT REPRESENTATIVE - The authorized representative of the OWNERS who is assigned to the PROJECT site or any part thereof.

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 3 of 15

1.19 SHOP DRAWINGS - All drawings, diagrams, illustrations, brochures, schedules and other data which are prepared by the CONTRACTOR, a SUBCONTRACTOR, manufacturer, SUPPLIER or distributor, which illustrate how specific portions of the WORK shall be fabricated or installed.

1.20 SPECIFICATIONS - A part of the CONTRACT DOCUMENTS consisting of written descriptions of a technical nature of materials, equipment, construction systems, standards and workmanship.

1.21 SUBCONTRACTOR - An individual, firm, or corporation having a direct contract with CONTRACTOR or with any other SUBCONTRACTOR for the performance of a part of the WORK at the site.

1.22 SUBSTANTIAL COMPLETION - That date certified by the ENGINEER when the construction of the PROJECT or a specified part thereof is sufficiently completed, in accordance with the CONTRACT DOCUMENTS, so that the PROJECT or specified part can be utilized for the purposes for which it is intended.

1.23 SUPPLEMENTAL GENERAL CONDITIONS - Modifications to General Conditions required by a State agency for participation in the PROJECT and approved by the agency in writing prior to inclusion in the CONTRACT DOCUMENTS, or such requirements that may be imposed by applicable state laws or by the OWNERS' governing regulations.

1.24 SUPPLIER - Any person or organization who supplies materials or equipment for the WORK, including that fabricated to a special design, but who does not perform labor at the site.

1.25 WORK - All labor necessary to produce the construction required by the CONTRACT DOCUMENTS, and all materials and equipment incorporated or to be incorporated in the PROJECT.

1.26 WRITTEN NOTICE - Any notice to any party of the Agreement relative to any part of this Agreement in writing and considered delivered and the service thereof completed, when posted by certified or registered mail to the said party at their last given address, or delivered in person to said party or their authorized representative on the WORK.

2. ADDITIONAL INSTRUCTION AND DETAIL DRAWINGS

2.1 The CONTRACTOR may be furnished additional instructions and detail drawings, by the ENGINEER, as necessary to carry out the WORK required by the CONTRACT DOCUMENTS.

2.2 The additional drawings and instructions thus supplied will become a part of the CONTRACT DOCUMENTS. The CONTRACTOR shall carry out the WORK in accordance with the additional detail drawings and instructions.

3. SCHEDULES, REPORTS AND RECORDS

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 4 of 15

3.1 The CONTRACTOR shall submit to the OWNERS such schedule of quantities and costs, progress schedules, payrolls, reports, estimates, records and other data where applicable as are required by the CONTRACT DOCUMENTS for the WORK to be performed.

3.2 Prior to the first partial estimate the CONTRACTOR shall submit construction progress schedules showing the order in which the CONTRACTOR proposes to carry on the WORK, including dates at which the various parts of the WORK will be started, estimated date of completion of each part and, as applicable:

3.2.1 The dates at which special detail drawings will be required; and

3.2.2 Respective dates for submission of SHOP DRAWINGS, the beginning of manufacture, the testing and the installation of materials, supplies and equipment.

3.3 The CONTRACTOR shall also submit a schedule of payments that the CONTRACTOR anticipates will be earned during the course of the WORK.

4. DRAWINGS AND SPECIFICATIONS

4.1 The intent of the DRAWINGS and SPECIFICATIONS is that the CONTRACTOR shall furnish all labor, materials, tools, equipment, and transportation necessary for the proper execution of the WORK in accordance with the CONTRACT DOCUMENTS and all incidental work necessary to complete the PROJECT in an acceptable manner, ready for use, occupancy or operation by the

OWNERS.

4.2 In case of conflict between the DRAWINGS and SPECIFICATIONS, the DRAWINGS shall govern. Figure dimensions on DRAWINGS shall govern over general DRAWINGS.

4.3 Any discrepancies found between the DRAWINGS and SPECIFICATIONS and site conditions or any inconsistencies or ambiguities in the DRAWINGS or SPECIFICATIONS shall be immediately reported to the ENGINEER, in writing, who shall promptly correct such inconsistencies or ambiguities in writing. WORK done by the CONTRACTOR after discovery of such discrepancies, inconsistencies or ambiguities shall be done at the CONTRACTOR'S risk.

5. SHOP DRAWINGS

5.1 The CONTRACTOR shall provide SHOP DRAWINGS as may be necessary for the prosecution of the WORK as required by the CONTRACT DOCUMENTS. The ENGINEER shall promptly review all SHOP DRAWINGS. The ENGINEER'S approval of any SHOP DRAWING shall not release the CONTRACTOR from responsibility for deviations from the CONTRACT DOCUMENTS. The approval of any SHOP DRAWING which substantially deviates from the requirement of the CONTRACT DOCUMENTS shall be evidenced by a CHANGE ORDER.

5.2 When submitted for the ENGINEER'S review, SHOP DRAWINGS shall bare the CONTRACTOR'S certification that he has reviewed, checked and approved the SHOP DRAWINGS and that they are in conformance with the requirements of the CONTRACT DOCUMENTS.

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 5 of 15

5.3 Portions of the WORK requiring a SHOP DRAWING or sample submission shall not begin until the SHOP DRAWING or submission has been approved by the ENGINEER. A copy of each approved SHOP DRAWING and each approved sample shall be kept in good order by the CONTRACTOR at the site and shall be available to the ENGINEER.

6. MATERIALS, SERVICES AND FACILITIES

6.1 It is understood that, except as otherwise specifically stated in the CONTRACT DOCUMENTS, the CONTRACTOR shall provide and pay for all materials, labor, tools, equipment, water, light, power, transportation, supervision, temporary construction of any nature, and all other services and facilities of any nature whatsoever necessary to execute, complete, and deliver the WORK within the specified time.

6.2 Materials and equipment shall be so stored as to insure the preservation of their quality and fitness for the WORK. Stored materials and equipment to be incorporated in the WORK shall be located so as to facilitate prompt inspection.

6.3 Manufactured articles, materials, and equipment shall be applied, installed, connected, erected, used, cleaned and conditioned as directed by the manufacturer.

6.4 Materials, supplies, or equipment shall be in accordance with samples submitted by the CONTRACTOR and approved by the ENGINEER.

6.5 Materials, supplies, or equipment to be incorporated into the WORK shall not be purchased by the CONTRACTOR or the SUBCONTRACTOR subject to chattel mortgage or under a conditional sale contract or other agreement by which in interest is retained by the seller.

7. INSPECTION AND TESTING

7.1 All materials and equipment used in the construction of the PROJECT shall be subject to adequate inspection and testing in accordance with generally accepted standards, as required and defined in the CONTRACT DOCUMENTS.

7.2 The OWNERS shall provide all inspection and testing services not required by the

CONTRACT DOCUMENTS.

7.3 The CONTRACTOR shall provide at the CONTRACTOR'S expense all testing and inspection services required by the CONTRACT DOCUMENTS.

7.4 If the CONTRACT DOCUMENTS, laws, ordinances, rules, regulations or orders of any public authority having jurisdiction require any WORK to specifically be inspected, tested, or approved by someone other than the CONTRACTOR, the CONTRACTOR will give the ENGINEER timely notice of readiness. The CONTRACTOR will then furnish the ENGINEER the required certificates of inspection, testing or approval.

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 6 of 15

7.5 Inspections, tests, or approvals by the ENGINEER or others shall not relieve the CONTRACTOR from the obligations to perform the WORK in accordance with the requirements of the CONTRACT DOCUMENTS.

7.6 The ENGINEER and the ENGINEER'S representatives will at all times have access to the WORK. In addition, authorized representatives and agents of any participating Federal or State agency shall be permitted to inspect all work, materials, payrolls, records or personnel, invoices of materials, and other relevant data and records. The CONTRACTOR will provide proper facilities for such access and observation of the WORK and also for any inspection or testing thereof.

7.7 If any WORK is covered contrary to the written instruction of the ENGINEER, it must, if requested by the ENGINEER, be uncovered for the ENGINEER'S observation and replaced at the CONTRACTOR'S expense.

7.8 If the ENGINEER considers it necessary or advisable that covered WORK be inspected or tested by others, the CONTRACTOR, at the ENGINEER's request, will uncover, expose or otherwise make available for observation, inspection or testing as the ENGINEER may require, that portion of the WORK in question, furnishing all necessary labor, materials, tools, and equipment. If it is found that such WORK is defective, the CONTRACTOR will bear all the expenses of such uncovering, exposure, observation, inspection and testing, and of satisfactory reconstruction. If, however, such WORK is not found to be defective, the CONTRACTOR will be allowed an increase in the CONTRACT PRICE or an extension of the CONTRACT TIME, or both, directly attributable to such uncovering, exposure, observation, inspection, testing and reconstruction, and an appropriate CHANGE ORDER shall be issued.

8. SUBSTITUTIONS

8.1 Whenever a material, article, or piece of equipment is identified on the DRAWINGS or SPECIFICATIONS by reference to brand name or catalogue numbers, it shall be understood that this is the only acceptable product. In cases where two or more products are identified, then the CONTRACTOR may select from the products identified. Whenever a product is identified on the DRAWINGS or SPECIFICATIONS by reference to a brand name with "or approved equal" appended, then the CONTRACTOR may recommend the substitution of a material, article, or piece of equipment of equal substance and function for those referred to in the CONTRACT DOCUMENTS, and if, in the opinion of the ENGINEER, such material, article, or piece of equipment is of equal substance and function to that specified, the ENGINEER will allow its substitution and use by the CONTRACTOR. The CONTRACTOR will be required to identify selected items by brand name at the time of bidding. No substitutions will be allowed for these items, after the bids are opened.

9. PATENTS

9.1 The CONTRACTOR shall pay all applicable royalties and license fees, and shall defend all suits or claims for infringement of any patent rights and save the OWNERS harmless from loss in account thereof, except that the OWNERS shall be responsible for any such loss when a particular process, design, or product of a particular manufacturer or manufacturers is specified. However, if the CONTRACTOR has reason to believe that the design, process or products specified is an

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 7 of 15 infringement of a patent, the CONTRACTOR shall be responsible for such loss unless the CONTRACTOR promptly gives such information to the ENGINEER.

10. SURVEYS, PERMITS, REGULATIONS

10.1 The OWNERS shall furnish all boundary surveys and establish all base lines for locating the principal component parts of the WORK together with a suitable number of bench marks adjacent to the WORK as shown in the CONTRACT DOCUMENTS. From the information provided by the OWNERS, unless otherwise specified in the CONTRACT DOCUMENTS, the CONTRACTOR shall develop and make all detail surveys needed for construction such as slope stakes, batter boards, stakes for pipe locations and other working points, lines, elevations, and cut sheets.

10.2 The CONTRACTOR shall carefully preserve bench marks, reference points and stakes and, in case of willful or careless destruction, shall be charged with the resulting expense and shall be responsible for any mistake that may be caused by their unnecessary loss or disturbance.

10.3 Permits and licenses of a temporary nature necessary for the prosecution of the WORK shall be secured and paid for by the CONTRACTOR unless otherwise stated in the SUPPLEMENTAL GENERAL CONDITIONS. (These shall include City and/or County building permits, burn permits, debris disposal permits, etc.) Permits, licenses and easements for permanent structures or permanent changes in existing facilities shall be secured and paid for by the OWNERS, unless otherwise specified. The CONTRACTOR shall give all notices and comply with all laws, ordinances, rules and regulations bearing on the conduct of the WORK as drawn and specified. If the CONTRACTOR observes that the CONTRACT DOCUMENTS are at variance therewith, the CONTRACTOR shall promptly notify the ENGINEER in writing, and any necessary changes shall be adjusted as provided in Section 13, CHANGES IN THE WORK.

11. PROTECTION OF WORK, PROPERTY, AND PERSONS

11.1 The CONTRACTOR will be responsible for initiating, maintaining, and supervising all safety precautions and programs in connection with the WORK. The CONTRACTOR will take all necessary precautions for the safety of, and will provide the necessary protection to prevent damage, injury or loss to all employees on the WORK and other persons who may be affected thereby, all the WORK and all materials or equipment to be incorporated therein, whether in storage on or off the site, and other property at the site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction.

11.2 The CONTRACTOR will comply with all applicable law, ordinances, rules, regulations, and orders of any public body having jurisdiction. The CONTRACTOR will erect and maintain, as required by the conditions and progress of the WORK, all necessary safeguards for safety and protection. The CONTRACTOR will notify OWNERS of adjacent utilities when prosecution of the WORK may affect them. The CONTRACTOR will remedy all damage, injury or loss to any property caused, directly or indirectly, in whole or part, by the CONTRACTOR, any SUBCONTRACTOR or anyone directly or indirectly employed by any of them or anyone of whose acts any of them may be liable, except damage or loss attributable to the fault of the CONTRACT DOCUMENTS or the acts

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 8 of 15 or omissions of the OWNERS, of the ENGINEER or anyone employed by either of them or anyone for whose acts either of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of the CONTRACTOR.

11.3 In emergencies affecting the safety of persons or the WORK or property at the site or adjacent thereto, the CONTRACTOR, without special instructions or authorization from the ENGINEER or OWNERS, shall act to prevent threatened damage, injury or loss. The CONTRACTOR will give the ENGINEER prompt WRITTEN NOTICE of any significant changes in the WORK or deviations from the CONTRACT DOCUMENTS caused thereby, and a CHANGE ORDER shall thereupon be issued covering the changes and deviations involved.

12. SUPERVISION BY CONTRACTOR

12.1 The CONTRACTOR will supervise and direct the WORK. He will be solely responsible for the means, methods, techniques, sequences and procedures of construction. The CONTRACTOR will employ and maintain on the WORK a qualified supervisor or superintendent who shall have been designated in writing by the CONTRACTOR as the CONTRACTOR'S representative at the site. The supervisor shall have full authority to act on behalf of the CONTRACTOR and all communications given to the supervisor shall be as binding as if given to the CONTRACTOR. The supervisor shall be present on the site at all times as required to perform adequate supervision and coordination of the

WORK.

13. CHANGES IN THE WORK

13.1 The OWNERS may at any time, as the need arises, order changes within the scope of the WORK without invalidating the Agreement. If such changes increase or decrease the amount due under the CONTRACT DOCUMENTS, or in the time required for performance of the WORK, an equitable adjustment shall be authorized by CHANGE ORDER.

13.2 The ENGINEER, also, may at any time, by issuing a FIELD ORDER, make changes in the details of the WORK. The CONTRACTOR shall proceed with the performance of any changes in the WORK so ordered by the ENGINEER unless the CONTRACTOR believes that such FIELD ORDER entitles the CONTRACTOR to a change in CONTRACT PRICE or TIME, or both, in which event the CONTRACTOR shall give the ENGINEER WRITTEN NOTICE thereof within seven (7) days after the receipt of the ordered change. Thereafter the CONTRACTOR shall document the basis for the change in CONTRACT PRICE or TIME within thirty (30) days. The CONTRACTOR shall not execute such changes pending the receipt of an executed CHANGE ORDER or further instruction from the OWNERS.

14. CHANGES IN CONTRACT PRICE

14.1 The CONTRACT PRICE may be changed only by a CHANGE ORDER. The value of any WORK covered by a CHANGE ORDER or of any claim for increase or decrease in the CONTRACT PRICE shall be determined by one or more of the following methods in the order of precedence listed below:

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 9 of 15

a. Unit prices contained in the bid schedule.

b. An agreed lump sum.

15. TIME FOR COMPLETION AND LIQUIDATED DAMAGES

15.1 The date of beginning and the time for completion of the WORK are essential conditions of the CONTRACT DOCUMENTS and the WORK embraced shall be commenced on a date specified in the NOTICE TO PROCEED.

15.2 The CONTRACTOR will proceed with the WORK at such rate of progress to insure full completion within the CONTRACT TIME. It is expressly understood and agreed, by and between the CONTRACTOR and the OWNERS, that the CONTRACT TIME for the completion of the WORK described herein is a reasonable time, taking into consideration the average climatic and economic conditions and other factors prevailing in the locality of the WORK.

15.3 If the CONTRACTOR shall fail to complete the WORK within the CONTRACT TIME, or extension of time granted by the OWNERS, then the CONTRACTOR will pay to the OWNERS the amount for liquidated damages as specified in the Bid for each calendar day that the CONTRACTOR shall be in default after the time stipulated in the CONTRACT DOCUMENTS.

15.4 The CONTRACTOR shall not be charged with liquidated damages or any excess cost when the delay in completion of the WORK is due to the following and the CONTRACTOR has promptly given WRITTEN NOTICE of such delay to the OWNERS or ENGINEER.

15.4.1 To any preference, priority or allocation order duly issued by the OWNERS.

15.4.2 To unforeseeable causes beyond the control and without the fault or negligence of the

CONTRACTOR, including but not restricted to, acts of God, or of the public enemy, acts of the OWNERS, acts of another CONTRACTOR in the performance of a contract with the OWNERS, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and abnormal and unforeseeable weather; and

15.4.3 To any delays of SUBCONTRACTORS occasioned by any of the causes specified in paragraphs 15.4.1 and 15.4.2 of this article.

16. CORRECTION OF WORK

16.1 The CONTRACTOR shall promptly remove from the premises all WORK rejected by the ENGINEER for failure to comply with the CONTRACT DOCUMENTS, whether incorporated in the construction or not, and the CONTRACTOR shall promptly replace and re-execute the WORK in accordance with the CONTRACT DOCUMENTS and without expense to the OWNERS and shall bear the expense of making good all WORK of other CONTRACTORS destroyed or damaged by such removal or replacement.

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 10 of 15

16.2 All removal and replacement WORK shall be done at the CONTRACTOR'S expense. If the CONTRACTOR does not take action to remove such rejected WORK within ten (10) days after receipt of WRITTEN NOTICE, the OWNERS may remove such WORK and store the materials at the expense of the CONTRACTOR.

17. SUBSURFACE CONDITIONS

17.1 The CONTRACTOR shall promptly, and before such conditions are disturbed, except in the event of an emergency, notify the OWNERS by WRITTEN NOTICE of:

17.1.1 Subsurface or latent physical conditions at the site differing materially from those indicated in the CONTRACT DOCUMENTS; or

17.1.2 Unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent in WORK of the character provided for in the CONTRACT DOCUMENTS.

17.2 The OWNERS shall promptly investigate the conditions, and if it is found that such conditions do so materially differ and cause an increase or decrease in the cost of, or in the time required for, performance of the WORK, an equitable adjustment shall be made and the CONTRACT DOCUMENTS shall be modified by a CHANGE ORDER. Any claim of the CONTRACTOR for adjustment hereunder shall not be allowed unless the required WRITTEN NOTICE has been given;

provided that the OWNERS may, if the OWNERS determines the facts so justify, consider and adjust any such claims asserted before the date of final payment.

18. SUSPENSION OF WORK, TERMINATION, AND DELAY

18.1 The OWNERS may suspend the WORK or any portion thereof for a period of not more than ninety days or such further time as agreed upon by the CONTRACTOR, by WRITTEN NOTICE to the CONTRACTOR and the ENGINEER which shall fix the date on which WORK shall be resumed.

The CONTRACTOR will resume that WORK on the date so fixed. The CONTRACTOR will be allowed an increase in the CONTRACT PRICE or an extension of the CONTRACT TIME, or both, directly attributable to any suspension.

18.2 If the CONTRACTOR is adjudged as bankrupt or insolvent, or makes a general assignment for the benefit of its creditors, or if a trustee or receiver is appointed for the CONTRACTOR or for any of its property, or if CONTRACTOR files a petition to take advantage of any debtor's act, or to reorganize under the bankruptcy or applicable laws, or repeatedly fails to supply sufficient skilled workmen or suitable materials or equipment, or repeatedly fails to make prompt payments to SUBCONTRACTORS or for labor, materials or equipment, or disregards laws, ordinances, rules, regulations or orders of any public body having jurisdiction of the WORK or disregards the authority of the ENGINEER, or otherwise violates any provision of the CONTRACT DOCUMENTS, then the OWNERS may, without prejudice to any other right or remedy and after giving the CONTRACTOR and its surety a minimum of ten (10) days from delivery of a WRITTEN NOTICE, terminate the services of the CONTRACTOR and take possession of the PROJECT and of all materials, equipment, tools, construction equipment and machinery thereon owned by the CONTRACTOR, and finish the

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 11 of 15

WORK by whatever method the OWNERS may deem expedient. In such case the CONTRACTOR shall not be entitled to receive any further payment until the WORK is finished. If the unpaid balance of the CONTRACT PRICE exceeds the direct and indirect costs of completing the project, including compensation for additional professional services, such excess SHALL BE PAID TO THE CONTRACTOR. If such costs exceed such unpaid balance, the CONTRACTOR will pay the difference to the OWNERS. Such costs incurred by the OWNERS will be determined by the ENGINEER and incorporated in a CHANGE ORDER.

18.3 Where the CONTRACTOR'S services have been so terminated by the OWNERS, said termination shall not affect any right of the OWNERS against the CONTRACTOR then existing or which may thereafter accrue. Any retention or payment of monies by the OWNERS due the CONTRACTOR will not release the CONTRACTOR from compliance with the CONTRACT

DOCUMENTS.

18.4 After ten (10) days from delivery of a WRITTEN NOTICE to the CONTRACTOR and the ENGINEER, the OWNERS may, without cause and without prejudice to any other right or remedy, elect to abandon the PROJECT and terminate the CONTRACT. In such case the CONTRACTOR shall be paid for all WORK executed and any expense sustained plus reasonable profit.

18.5 If, through no act or fault of the CONTRACTOR, the WORK is suspended for a period of more than ninety (90) days by the OWNERS or under an order of court or other public authority, or the ENGINEER fails to act on any request for payment within thirty (30) days after it is submitted, or the OWNERS fails to pay the CONTRACTOR substantially the sum approved by the ENGINEER or awarded by arbitrators within thirty (30) days of its approval and presentation, then the CONTRACTOR may after ten (10) days from delivery of a WRITTEN NOTICE to the OWNERS and the ENGINEER terminate the CONTRACT and recover from the OWNERS payment for all WORK executed and all expenses sustained. In addition and in lieu of terminating the CONTRACT, if the ENGINEER has failed to act on a request for payment or if the OWNERS has failed to make any payment as aforesaid, the CONTRACTOR may upon ten (10) days written notice to the OWNERS and the ENGINEER stop the WORK until paid all amounts then due, in which event and upon resumption of the WORK CHANGE ORDERS shall be issued for adjusting the CONTRACT PRICE or extending the CONTRACT TIME or both to compensate for the costs and delays attributable to the stoppage of the WORK.

18.6 If the performance of all or any portion of the WORK is suspended, delayed, or interrupted as a result of a failure of the OWNERS or ENGINEER to act within the time specified in the CONTRACT DOCUMENTS, or if no time is specified, within a reasonable time, an adjustment in the CONTRACT PRICE or an extension of the CONTRACT TIME, or both, shall be made by CHANGE ORDER to compensate the CONTRACTOR for the costs and delays necessarily caused by the failure of the OWNERS or ENGINEER.

19. ASSIGNMENTS

19.1 Neither the CONTRACTOR nor the OWNERS shall sell, transfer, assign, or otherwise dispose of the Contract or any portion thereof, or of any right, title or interest therein, or any obligations thereunder, without written consent of the other party.

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 12 of 15

20. INDEMNIFICATION

20.1 The CONTRACTOR will indemnify and hold harmless the OWNERS and the ENGINEER and their agents and employees from and against all claims, damages, losses and expenses including attorney's fees arising out of or resulting from the performance of the WORK, provided that any such claims, damage, loss or expense is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property including the loss of use resulting therefrom; and is caused in whole or in part by any negligent or willful act or omission of the CONTRACTOR, and SUBCONTRACTOR, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable.

20.2 In any and all claims against the OWNERS or the ENGINEER, or any of their agents or employees, by any employee of the CONTRACTOR, any SUBCONTRACTOR, anyone directly or indirectly employed by any of them, or anyone for whose acts any of them may be liable, the indemnification obligation shall not be limited in any way by any limitation on the amount or type of damages, compensation or benefits payable by or for the CONTRACTOR or any SUBCONTRACTOR under workmen's compensation acts, disability benefit acts or other employee benefits acts.

20.3 The obligation of the CONTRACTOR under this paragraph shall not extend to the liability of the ENGINEER, its agents or employees arising out of the preparation or approval of maps, DRAWINGS, opinions, reports, surveys, CHANGE ORDERS, designs or SPECIFICATIONS.

21. SEPARATE CONTRACTS

21.1 The OWNERS reserves the right to let other contracts in connection with this PROJECT.

The CONTRACTOR shall afford other CONTRACTORS reasonable opportunity for the introduction and storage of their materials and the execution of their WORK, and shall properly connect and coordinate the WORK with theirs. If the proper execution or results of any part of the CONTRACTOR'S WORK depends upon the WORK of any other CONTRACTOR, the CONTRACTOR shall inspect and promptly report to the ENGINEER any defects in such WORK that render it unsuitable for such proper execution and results.

21.2 The OWNERS may perform additional WORK related to the PROJECT or the OWNERS may let other contracts containing provisions similar to these. The CONTRACTOR will afford the other CONTRACTORS who are parties to such Contracts (or the OWNERS, if the OWNERS is performing the additional WORK) reasonable opportunity for the introduction and storage of materials and equipment and the execution of WORK, and shall properly connect and coordinate the WORK with theirs.

21.3 If the performance of additional WORK by the CONTRACTORS or the OWNERS is not noted in the CONTRACT DOCUMENTS prior to the execution of the CONTRACT, written notice thereof shall be given to the CONTRACTOR prior to starting any such additional WORK. If the CONTRACTOR believes that the performance of such additional WORK by the OWNERS or others involves it in additional expense or entitles it to an extension of the CONTRACT TIME, the CONTRACTOR may make a claim thereof as provided in Sections 14 and 15.

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 13 of 15

22. SUBCONTRACTING

22.1 The CONTRACTOR may utilize the services of specialty SUBCONTRACTS on those parts of the WORK which, under normal contracting practices, are performed by specialty

SUBCONTRACTORS.

22.2 The CONTRACTOR shall not award WORK to SUBCONTRACTOR(S), in excess of fifty (50%) percent of the CONTRACT PRICE, without prior written approval of the OWNERS.

22.3 The CONTRACTOR shall be fully responsible to the OWNERS for the acts and omissions of its SUBCONTRACTORS, and of persons either directly or indirectly employed by them, as the CONTRACTOR is for the acts and omissions of persons directly employed by it.

22.4 The CONTRACTOR shall cause appropriate provisions to be inserted in all subcontracts relative to the WORK to bind SUBCONTRACTORS to the CONTRACTOR by the terms of the CONTRACT DOCUMENTS insofar as applicable to the WORK of SUBCONTRACTORS and give the CONTRACTOR the same power as regards terminating any subcontract that the OWNERS may exercise over the CONTRACTOR under any provision of the CONTRACT DOCUMENTS.

22.5 Nothing contained in this CONTRACT shall create any contractual relation between any SUBCONTRACTOR and the OWNERS.

23. ENGINEER'S AUTHORITY

23.1 The ENGINEER shall act as the OWNERS' representative during the construction period, shall decide questions which may arise as to quality and acceptability of materials furnished and WORK performed, and shall interpret the intent of the CONTRACT DOCUMENTS in a fair and unbiased manner. The ENGINEER will make visits to the site and determine of the WORK is proceeding in accordance with the CONTRACT DOCUMENTS.

23.2 The CONTRACTOR will be held strictly to the intent of the CONTRACT DOCUMENTS in regard to the quality of materials, workmanship, and execution of the WORK. Inspections may be at the factory or fabrication plant of the source of material supply.

23.3 The ENGINEER will not be responsible for the construction means, controls, techniques, sequences, procedures, or construction safety.

23.4 The ENGINEER shall promptly make decisions relative to interpretation of the CONTRACT

DOCUMENTS.

24. LAND AND RIGHTS-OF-WAY

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 14 of 15

24.1 Prior to issuance of NOTICE TO PROCEED, the OWNERS shall obtain all land and rights-of-way necessary for carrying out and for the completion of the WORK to be performed pursuant to the CONTRACT DOCUMENTS, unless otherwise mutually agreed.

24.2 The OWNERS shall provide to the CONTRACTOR information which delineates and describes the lands owned and rights-of-way acquired.

24.3 The CONTRACTOR shall provide at its own expense and without liability to the OWNERS any additional land and access thereto that the CONTRACTOR may desire for temporary construction facilities, or storage of materials.

25. GUARANTEE

25.1 The CONTRACTOR shall guarantee all materials and equipment furnished and WORK performed for a period of one year from the date of SUBSTANTIAL COMPLETION. The CONTRACTOR warrants and guarantees for a period of one (1) year from the date of SUBSTANTIAL COMPLETION of the system that the completed system if free from all defects due to faulty materials or workmanship and the CONTRACTOR shall promptly make such corrections as may be necessary by reason of such defects including the repairs of the damage of other parts of the system resulting from such defects. The OWNERS will give notice of observed defects with reasonable promptness. In the event that the CONTRACTOR should fail to make such repairs, adjustments, or other WORK that may be made necessary by such defects, the OWNERS may do so and charge the CONTRACTOR the cost thereby incurred. The Performance BOND shall remain in full force and effect through the guarantee period.

26. ARBITRATION

26.1 All claims, disputes, and other matters in question arising out of, or relating to, the CONTRACT DOCUMENTS or the breach thereof, except for claims which have been waived by making an acceptance of final payment as provided by Section 20, shall be decided by arbitration in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association.

This agreement to arbitrate shall be specifically enforceable under the prevailing arbitration law. The award rendered by the arbitrators shall be final, and judgment may be entered upon it in any court having jurisdiction thereof.

26.2 Notice of the demand for arbitration shall be filed in writing with the OWNERS party to the CONTRACT DOCUMENTS and with the American Arbitration Association and a copy shall be filed with the ENGINEER. Demand for arbitration shall in no event be made on any claim, dispute, or other matter in question which would be barred by the applicable statute of limitations.

26.3 The CONTRACTOR will carry on the WORK and maintain the progress schedule during any arbitration proceedings, unless otherwise mutually agreed in writing.

27. TAXES

WALTON COUNTY, FLORIDA - PROJECT #50150622 General Conditions: Page 15 of 15

27.1 The CONTRACTOR will pay all sales, consumer, use, and other similar taxes required by the laws of the place where the WORK is performed.

CONTRACT DOCUMENTS FOR GLENDALE FIRE STATION Section 01030 WALTON COUNTY, FLORIDA - PROJECT #50150622 Alternates: Page 1 of 1

TECHNICAL SPECIFICATIONS FOR GLENDALE FIRE STATION

SECTION 01030-ALTERNATES

PART 1 - GENERAL

Related Documents:

Drawings and general provisions of Contract, including General and Supplementary Conditions, apply to work of this section.

Description of Requirements:

Definition: An alternate is an amount proposed by Bidders and stated on the Bid Form that will be added to, deducted from, or substituted for an item in the Base Bid amount if the Owner decided to accept a corresponding change in either scope of work or in products, materials, equipment, systems or installation methods described in Contract Documents.

“Include as part of each alternate, miscellaneous devices, appurtenances and similar items incidental to or required for a complete installation whether or not mentioned as part of the alternate.”

Coordination: Coordinate related work and modify or adjust adjacent work as required to ensure that work affected by each accepted alternate is complete and fully integrated into the project.

CONTRACT DOCUMENTS FOR GLENDALE FIRE STATION Section 01090 WALTON COUNTY, FLORIDA - PROJECT #50150622 DEFINITIONS AND STANDARDS-Page 1 of 4

TECHNICAL SPECIFICATIONS FOR GLENDALE FIRE STATION

SECTION 01090-DEFINITIONS AND STANDARDS

PART 1 - GENERAL

RELATED DOCUMENTS:

Drawings and general provisions of Contract, including General and Special Conditions, apply to work of this section.

DEFINITIONS:

GENERAL EXPLANATION: A substantial amount of specification language constitutes definitions for terms found in other contract documents, including drawings which must be recognized as diagrammatic in nature and not completely descriptive of requirements indicated thereon. Certain terms used in contract documents are defined generally in this article. Definitions and explanations of this section are not necessarily either complete or exclusive, but are general for the work extent not stated more explicitly in another provision of contract documents.

INDICATED: The term "Indicated" is a cross-reference to graphics, notes or schedules on drawings, to other paragraphs or schedules in the specifications, and to similar means of recording requirements in contract documents. Where terms such as "shown", "noted", "scheduled" and "specified" are used in lieu of "indicated", it is for purpose of helping reader locate cross-reference, and no limitation of location is intended except as specifically noted.

DIRECTED, REQUESTED, ETC.: Where not otherwise explained, terms such as "directed", "requested", "authorized", "selected", "approved", "required", "accepted", and "permitted" mean "directed by Engineer", "requested by Engineer", etc. However, no such implied meaning will be interpreted to extend Engineer's responsibility into Contractor's area of construction supervision.

APPROVE: Where used in conjunction with Engineer's response to submittals, requests, applications, inquiries, reports and claims by Contractor, the meaning of term "approved" will be held to limitations of Engineer's responsibilities and duties as specified in General and Special Conditions. In no case will "approval" by Engineer be interpreted as a release of Contractor from responsibilities to fulfill requirements of contract documents.

PROJECT SITE: The space available to Contractor for performance of the work, either exclusively or in conjunction with others performing other work as part of the project. The extent of project site is shown on drawings, and may or may not be identical with description of land upon which project is to be built.

FURNISH: Except as otherwise defined in greater detail, the term "furnish" is used to mean supply and deliver to project site, ready for unloading, unpacking, assembly, installation, etc., as applicable in each instance.

INSTALL: Except as otherwise defined in greater detail, term "install" is used to describe operations at project site including unloading, unpacking, assembly, erection, placing, anchoring, applying, working to dimension, finishing, curing, protecting, cleaning and similar operations, as applicable in each instance.

WALTON COUNTY, FLORIDA - PROJECT #50150622 DEFINITIONS AND STANDARDS-Page 2 of 4

PROVIDE: Except as otherwise defined in greater detail, term "provide" means furnish and install, complete and ready for intended use, as applicable in each instance.

INSTALLER: The entity (person or firm) engaged by Contractor or its subcontractor or sub-contractor for performance of a particular unit of work at project site, including installation, erection, application and similar required operations. It is a general requirement that such entities (Installers) be expert in operations they are engaged to perform.

TESTING LABORATORY: An independent entity engaged to perform specific inspections of tests of work, either at project site or elsewhere; and to report and (if required) interpret results of those inspections or tests.

SPECIFICATION EXPLANATIONS:

SPECIFICATION CONTENT: Because of methods by which this project specification has been produced, certain general characteristics of content, and conventions in use of language are explained as follows:

SPECIFYING METHODS: The techniques or methods of specifying to record requirements varies throughout text, and may include "prescriptive", "open generic-descriptive", "compliance with standards", "performance", "proprietary", or a combination of these.