S02 - Att2 Insert A BID SCHEDULE.pdf
PDF 115 KB Posted
- Solicitation number
- 36C25224B0013
About this file
This document is a Bid Schedule for Solicitation 36C25224B0013 for the SCI Recreation Area Outdoor Construction project at the Edward Hines Jr. VA Hospital in Hines, IL.
The scope of work includes all labor, equipment, supplies, and materials necessary to construct a multi-sport recreational court between Buildings 221 and 1. The Base Bid requires the work to be completed within 240 calendar days, with a Lump Sum price requested. An Alternate Bid 1 is also included to provide separate pricing for removing work associated with a new structural canopy over an accessibility ramp, to be completed within 226 calendar days.
The solicitation states that award will be made to the responsible bidder submitting the lowest responsive bid, either on the Base Bid or Alternate Bid 1 if the Base Bid exceeds available funding. Bidders must submit a cost-loaded, approved Critical Path Method (CPM) construction schedule prior to starting work. The contracting agency is the Department of Veterans Affairs, Veterans Health Administration, Veterans Integrated Service Network 12.
View the file
Other files
Show all 35
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
BID SCHEDULE
SOLICITATION: 36C25224B0013
PROJECT: SCI Recreation Area Outdoor Construction
STATEMENT OF BID ITEM(S)
The Scope of Work for this project includes all labor, management, equipment, supplies and materials necessary for constructing a multi-sport recreational court between Building 221 and Building 1. All measurements/dimensions are approximate, and the Contractor shall verify all measurements/dimensions.
Work location is on the campus of the Edward Hines Jr. VA Hospital at 5000 S. Fifth Avenue, Hines, IL 60141.
BASE BID:
All work shall be completed within 240 calendar days after receipt of the Notice to Proceed.
All-Inclusive Base Bid LUMP SUM: $ ___________________________
ALTERNATE BID 1:
Contractor shall provide separate pricing for the following alternate:
Remove all work associated with new structural canopy to be installed over the existing accessibility ramp leading into B221.
All work shall be completed within 226 calendar days after receipt of the Notice to Proceed.
All-Inclusive Alternate Bid 1 LUMP SUM: $ ___________________________
NOTICE TO BIDDERS: Award will be made to the responsible bidder who submitted the lowest responsive bid. A single award will be made on Base Bid, but in the event the offer exceeds the funds available, a single award will be made on Alternate Bid Item 1 based on available funding.
Offerors should quote a price on each item listed. Only one award will be made as a result of this solicitation.
For Bid Deducts, bidders should ensure that the all-inclusive price after the deductions are subtracted has been entered. Do not enter the amount of the deduction.
NOTICE TO BIDDERS: Work shall not commence until all required submittals are approved by the Contracting Officer or the Contracting Officer’s Representative (COR). An approved cost-loaded, Critical Path Method (CPM) construction schedule is required prior to commencement of construction. See specifications for details. CPM schedule shall be approved by the Contracting Officer or the Contracting Officer’s Representative. See specifications for details.
BID SCHEDULE
File details come from the government source that posted it. Updated .