36C24118R0127-00004001.pdf

Item Number

Description Lump Sum Amount

0001 GENERAL CONSTRUCTION: Work includes the necessary supervision, labor, equipment, material, transportation, testing and infrastructure required to complete work for Building 1 Fire Door Repairs, Providence Veterans Affairs Medical Center, Providence, Rhode Island in accordance with the Contract Documents, including Technical Specifications and Drawings. Work includes, but is not limited to, general construction, selective demolition, alterations, ceilings, partition renovation, doors, finishes, miscellaneous specialties, electrical, and certain other items. Replace and Repair fire doors on 7 Floors between Building 1 and E-Wing.

INCLUDE A DETAILED PRICE BREAKDOWN ATTACHED TO THIS PROPOSAL.

SIGNATURE: COMPANY NAME

Name and title of person authorized to sign Offer Date

650-16-011 Prov Fire Door Seed Project

EXHIBIT F-1 SEED PROJECT

NOTICE OF PROPOSED PROJECT, PROPOSAL FORM

Date:

PROJECT TITLE AND NO.: Project 650-16-011, Fire Door Repair, Providence, RI

PROJECT DESCRIPTION: The Contractor shall provide all labor, materials, equipment, transportation, disposal and supervision necessary to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

CAT I $2,000 - $1,000,000

MAGNITUDE OF PROJECT: Between $100,000 and $250,000

PERFORMANCE PERIOD: 365 Calendar Days

SITE VISIT: A site visit for this project will be held on 5/24/18 at 11:00am.

PERFORMANCE & PAYMENT BONDS: In accordance with FAR 28.102-1 and Contract Clause 52.228-15, Contractors are reminded that any amount awarded over $35,000 shall require Payment Bonds, and awards exceeding $150,000 shall require both Payment and Performance Bonds. All bonds are due no later than 10 days after award.

WAGE DETERMINATION: Currently, General Decision Number: RI180001 Modification No 5 dated 05/11/2018 is applicable to this task order. However, the current prevailing Wage Determination will be incorporated at time of award.

PROJECT SAFETY: In accordance with FAR 52.236-13, Accident Prevention, construction contractors shall immediately notify the Contracting Officer’s Representative (COR) and shall prepare a Report of Accident (VA Form 2162 or equivalent) in quadruplicate and forward the original and two copies to the Contracting Officer or COR for forwarding to Safety Officer.

PROPOSAL DUE DATE: All offers are due with proposal for MATOC basic contract. Failure to provide a price will make offer noncompliant, eliminated from the competition and offeror ineligible for a basic contract award. Basis for award is in the RFP.

EXHIBIT F – 1A - CALCULATION OF SELF-PERFORMED WORK

PROJECT: Project 650-16-011, Fire Door Repairs, Providence, RI VISN 1

Use a format similar to the following to identify and calculate cost of the work to be self-performed. Refer to the definitions pertaining to “Self-performance of work”, “On the Site” and “Total amount of work to be performed under the contract”. (Includes mobilization and utilization of owned or rented plant and equipment to be operated by the prime contractor’s own employees; only those materials which will be both purchased and installed by the prime’s own forces; labor associated with those aforementioned materials or equipment; only those supplies to directly support work performed by the contractor’s own employees; and the contractor’s own job overhead costs.) NOTE: The intention of this set-aside is to have actual work performed by the Contractor’s own forces or the forces of other SDVOSB contractors and not just “contract management”. This contract is not intended for construction contract management firms.

Clearly describe the work to be self-performed:

Show Calculation of Self-Performed work:

B.1 Total Offer Price: $___

B.2 If applying for consideration as a General Contractor (multi-discipline projects) subtract Specialty Trades (Unless being self performed) $ ______

B.3 Subtract G&A, home office overhead, prime contractor’s markups for profit, bond, state use tax, etc. ($)

B.4 Remainder is “Total amount of work to be performed under the Contract” = $

B.5 “Work to be self-performed”: = $ Amount shown on this line should match the amount shown for “Show Calculation of Self-Performed work”?

(Includes mobilization and utilization of owned or rented plant and equipment to be operated by the prime contractor’s own employees; only those materials which will be both purchased and installed by the prime’s own forces; labor associated with those aforementioned materials or equipment; only those supplies to directly support work performed by the contractor’s own employees;

and the contractor’s own job overhead costs.)

B.6 15 % Self-performed Work = Line B.5 / B.4 X 100% = %

650-16-011 Prov Fire Door Seed Project

EXHIBIT F-1 SEED PROJECT

NOTICE OF PROPOSED PROJECT, PROPOSAL FORM

Date:

PROJECT TITLE AND NO.: Project 650-16-011, Fire Door Repair, Providence, RI

PROJECT DESCRIPTION: The Contractor shall provide all labor, materials, equipment, transportation, disposal and supervision necessary to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

CAT I $2,000 - $1,000,000

MAGNITUDE OF PROJECT: Between $100,000 and $250,000

PERFORMANCE PERIOD: 365 Calendar Days

SITE VISIT: A site visit for this project will be held on 5/24/18 at 11:00am.

PERFORMANCE & PAYMENT BONDS: In accordance with FAR 28.102-1 and Contract Clause 52.228-15, Contractors are reminded that any amount awarded over $35,000 shall require Payment Bonds, and awards exceeding $150,000 shall require both Payment and Performance Bonds. All bonds are due no later than 10 days after award.

WAGE DETERMINATION: Currently, General Decision Number: RI180001 Modification No 5 dated 05/11/2018 is applicable to this task order. However, the current prevailing Wage Determination will be incorporated at time of award.

PROJECT SAFETY: In accordance with FAR 52.236-13, Accident Prevention, construction contractors shall immediately notify the Contracting Officer’s Representative (COR) and shall prepare a Report of Accident (VA Form 2162 or equivalent) in quadruplicate and forward the original and two copies to the Contracting Officer or COR for forwarding to Safety Officer.

PROPOSAL DUE DATE: All offers are due with proposal for MATOC basic contract. Failure to provide a price will make offer noncompliant, eliminated from the competition and offeror ineligible for a basic contract award. Basis for award is in the RFP.

June 07, 2017

CONTRACTOR SCOPE OF WORK

VA MEDICAL CENTER PROVIDENCE, RI

Fire Door Repairs Project 650-16-011

The Department of Veterans Affairs (VA) proposes to repair and/or replace non-compliant fire door assemblies within Building No. 1 of the Providence VA Medical Center (VAMC) campus located at 830 Chalkstone Ave., Providence, RI 02908.

It is the intent of the Department of Veterans Affairs, Facilities Management Section (FMS) to obtain construction services to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

Work includes the necessary supervision, labor, equipment, material, transportation, testing and infrastructure required to complete work for Building 1 Fire Door Repairs, Providence Veterans Affairs Medical Center, Providence, Rhode Island in accordance with the Contract Documents, including Technical Specifications and Drawings. Work includes, but is not limited to, general construction, selective demolition, alterations, ceilings, partition renovation, doors, finishes, miscellaneous specialties, electrical, and certain other items.

The contract duration is six months. Infectious Control will be required. Some night work will be required since the doors open to the main elevator lobby of the building and several elevators will have to be temporarily placed out commission during some construction periods.

650-16-011 Prov Fire Door Seed Project

EXHIBIT F-1 SEED PROJECT

NOTICE OF PROPOSED PROJECT, PROPOSAL FORM

Date:

PROJECT TITLE AND NO.: Project 650-16-011, Fire Door Repair, Providence, RI

PROJECT DESCRIPTION: The Contractor shall provide all labor, materials, equipment, transportation, disposal and supervision necessary to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

CAT I $2,000 - $1,000,000

MAGNITUDE OF PROJECT: Between $100,000 and $250,000

PERFORMANCE PERIOD: 365 Calendar Days

SITE VISIT: A site visit for this project will be held on 5/24/18 at 11:00am.

PERFORMANCE & PAYMENT BONDS: In accordance with FAR 28.102-1 and Contract Clause 52.228-15, Contractors are reminded that any amount awarded over $35,000 shall require Payment Bonds, and awards exceeding $150,000 shall require both Payment and Performance Bonds. All bonds are due no later than 10 days after award.

WAGE DETERMINATION: Currently, General Decision Number: RI180001 Modification No 5 dated 05/11/2018 is applicable to this task order. However, the current prevailing Wage Determination will be incorporated at time of award.

PROJECT SAFETY: In accordance with FAR 52.236-13, Accident Prevention, construction contractors shall immediately notify the Contracting Officer’s Representative (COR) and shall prepare a Report of Accident (VA Form 2162 or equivalent) in quadruplicate and forward the original and two copies to the Contracting Officer or COR for forwarding to Safety Officer.

PROPOSAL DUE DATE: All offers are due with proposal for MATOC basic contract. Failure to provide a price will make offer noncompliant, eliminated from the competition and offeror ineligible for a basic contract award. Basis for award is in the RFP.

WAGE RATES

General Decision Number: RI180001 05/11/2018 RI1 Superseded General Decision Number: RI20170001 State: Rhode Island Construction Types: Building, Heavy (Heavy and Marine) and Highway Counties: Rhode Island Statewide.

BUILDING CONSTRUCTION PROJECTS (does not include residential construction consisting of single family homes and apartments up to and including 4 stories) HEAVY, HIGHWAY AND MARINE CONSTRUCTION PROJECTS Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.35 for calendar year 2018 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.35 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2018. The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis- Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/05/2018 1 01/12/2018 2 01/19/2018 3 03/02/2018 4 03/16/2018 5 05/11/2018

ASBE0006-006 06/01/2015

Rates Fringes

HAZARDOUS MATERIAL HANDLER

(Includes preparation, wetting, stripping, removal scrapping, vacuuming, bagging & disposing of all insulation materials, whether they contain asbestos or not, from mechanical systems)..............$ 31.63 18.30

ASBE0006-008 09/01/2017

Rates Fringes Asbestos Worker/Insulator Includes application of all insulating materials, protective coverings, coatings & finishes to all types of mechanical systems.$ 41.48 27.35

BOIL0029-001 01/01/2017

Rates Fringes

BOILERMAKER......................$ 42.42 24.92

BRRI0003-001 12/01/2017

Rates Fringes Bricklayer, Stonemason, Pointer, Caulker & Cleaner.......$ 37.38 26.59

BRRI0003-002 03/01/2018

Rates Fringes Marble Setter, Terrazzo

Worker & Tile Setter.............$ 37.16 27.66

BRRI0003-003 03/01/2018

Rates Fringes Marble, Tile & Terrazzo Finisher.........................$ 31.32 26.30

CARP0094-001 06/05/2017

Rates Fringes CARPENTER (Includes Soft Floor Layer).....................$ 35.28 27.15 Diver Tender.....................$ 36.28 27.15

DIVER............................$ 47.08 27.15

Piledriver.......................$ 35.28 27.15

WELDER...........................$ 36.28 27.15

FOOTNOTES:

When not diving or tending the diver, the diver and diver tender shall receive the piledriver rate. Diver tenders shall receive $1.00 per hour above the pile driver rate when tending the diver.

Work on free-standing stacks, concrete silos & public utility electrical power houses, which are over 35 ft. in height when constructed: $.50 per hour additional.

Work on exterior concrete shear wall gang forms, 45 ft. or more above ground elevation or on setback: $.50 per hour additional.

The designated piledriver, known as the "monkey": $1.00 per hour additional.

CARP1121-002 10/01/2017

Rates Fringes

MILLWRIGHT.......................$ 36.85 27.50

ELEC0099-002 06/01/2017

Rates Fringes

ELECTRICIAN......................$ 38.08 57.24%

Teledata System Installer........$ 28.56 13.1%+13.76

FOOTNOTES:

Work of a hazardous nature, or where the work height is 30 ft. or more from the floor, except when working OSHA-approved lifts: 20% per hour additional.

Work in tunnels below ground level in combined sewer outfall: 20% per hour additional.

ELEV0039-001 01/01/2018

Rates Fringes

ELEVATOR MECHANIC................$ 49.96 32.645+A+B

FOOTNOTES:

A. PAID HOLIDAYS: New Years Day; Memorial Day; Independence Day; Labor Day; Veterans' Day; Thanksgiving Day; the Friday after Thanksgiving Day; and Christmas Day.

B. Employer contributes 8% basic hourly rate for 5 years or more of service of 6% basic hourly rate for 6 months to 5 years of service as vacation pay credit.

ENGI0057-001 12/03/2017

Rates Fringes Operating Engineer: (power plants, sewer treatment plants, pumping stations, tunnels, caissons, piers, docks, bridges, wind turbines, subterranean & other marine and heavy construction work)

GROUP 1.....................$ 37.90 25.10+a GROUP 2.....................$ 33.52 25.10+a GROUP 3.....................$ 30.67 25.10+a GROUP 4.....................$ 36.95 25.10+a GROUP 5.....................$ 27.75 25.10+a GROUP 6.....................$ 21.75 25.10+a GROUP 7.....................$ 33.60 25.10+a GROUP 8.....................$ 37.52 25.10+a

a. BOOM LENGTHS, INCLUDING JIBS:

150 feet and over + $ 2.00 180 feet and over + $ 3.00 210 feet and over + $ 4.00 240 feet and over + $ 5.00 270 feet and over + $ 7.00 300 feet and over + $ 8.00 350 feet and over + $ 9.00 400 feet and over + $10.00

a. PAID HOLIDAYS: New Year's Day, President's Day, Memorial Day, July Fourth, Victory Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day, Christmas Day. a: Any employee who works 3 days in the week in which a holiday falls shall be paid for the holiday.

a. FOOTNOTES:

Hazmat work: $2.00 per hour additional.

Tunnel/Shaft work: $5.00 per hour additional.

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Digging machine, Ross Carrier, crane, lighter, locomotive, derrick, hoist, elevator, bidwell-type machine, shot & water blasting machine, paver, spreader, graders, front end loader (3 yds. and over), vibratory hammer & vacuum truck, roadheaders, forklifts, economobile type equipment, tunnel boring machines, concrete pump and on site concrete plants.

GROUP 2: Oilers on cranes.

GROUP 3: Oiler on crawler backhoe.

GROUP 4: Bulldozer, bobcats, skid steer loader, tractor, scraper, combination loader backhoe, roller, front end loader (less than 3 yds.), street and mobile-powered sweeper (3-yd. capacity), 8-ft. sweeper minimum 65 HP).

GROUP 5: Well-point installation crew.

GROUP 6: Utility Engineers and Signal Persons GROUP 7: Heater, concrete mixer, stone crusher, welding machine, generator and light plant, gas and electric driven pump and air compressor.

GROUP 8: Boat & tug operator.

ENGI0057-002 11/06/2017

Rates Fringes Power Equipment Operator (highway construction projects; water and sewerline projects which are incidental to highway construction projects; and bridge projects that do not span water) GROUP 1....................$ 33.05 25.10+a GROUP 2....................$ 27.75 25.10+a GROUP 3....................$ 21.75 25.10+a GROUP 4....................$ 28.33 25.10+a GROUP 5....................$ 32.03 25.10+a GROUP 6....................$ 31.65 25.10+a GROUP 7....................$ 27.30 25.10+a GROUP 8....................$ 28.68 25.10+a GROUP 9....................$ 30.63 25.10+a

a. FOOTNOTE: a. Any employee who works three days in the week in which a holiday falls shall be paid for the holiday.

a. PAID HOLIDAYS: New Year's Day, President's Day, Memorial Day, July Fourth, Victory Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day & Christmas Day.

POWER EQUIPMENT OPERATOR CLASSIFICATIONS

GROUP 1: Digging machine, crane, piledriver, lighter, locomotive, derrick, hoist, boom truck, John Henry's, directional drilling machine, cold planer, reclaimer, paver, spreader, grader, front end loader (3 yds. And over), vacuum truck, test boring machine operator, veemere saw, water blaster, hydro-demolition robot, forklift, economobile, Ross Carrier, concrete pump operator and boats GROUP 2: Well point installation crew GROUP 3: Utlity engineers and signal persons GROUP 4: Oiler on cranes GROUP 5: Combination loader backhoe, front end loader (less than 3 yds.), forklift, bulldozers & scrapers and boats GROUP 6: Roller,skid steer loaders, street sweeper GROUP 7: Gas and electric drive heater, concrete mixer, light plant, welding machine, pump & compressor GROUP 8: Stone crusher GROUP 9: Mechanic & welder

ENGI0057-003 12/03/2017

BUILDING CONSTRUCTION

Rates Fringes Power Equipment Operator GROUP 1....................$ 37.17 25.10+a GROUP 2....................$ 36.95 25.10+a GROUP 3....................$ 32.95 25.10+a GROUP 4....................$ 30.10 25.10+a GROUP 5....................$ 36.25 25.10+a GROUP 6....................$ 35.82 25.10+a GROUP 7....................$ 33.14 25.10+a a.BOOM LENTHS, INCLUDING JIBS:

150 ft. and over: + $ 2.00 180 ft. and over: + $ 3.00 210 ft. and over: + $ 4.00 240 ft. and over: + $ 5.00 270 ft. and over: + $ 7.00 300 ft. and over: + $ 8.00 350 ft. and over: + $ 9.00 400 ft. and over: + $10.00

a. PAID HOLIDAYS: New Year's Day, President's Day, Memorial Day, July Fourth, Victory Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day & Christmas Day. a: Any employee who works 3 days in the week in which a holiday falls shall be paid for the holiday.

a. FOOTNOTE: Hazmat work: $2.00 per hour additional.

Tunnel/Shaft work: $5.00 per hour additional.

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Digging machine, Ross carrier, crane, boomtrucks, lighter, locomotive, derrick, hoist, elevator, bidwell-type machine, shot & water blasting machine, paver, spreader, front end loader (3 yds. and over), vibratory hammer and vacuum truck GROUP 2: Telehandler equipment, forklift, concrete pump & on-site concrete plant GROUP 3: Fireman & oiler GROUP 4: Oiler on crawler backhoe GROUP 5: Bulldozer,skid steer loaders,bobcats, tractor, grader, scraper,combination loader backhoe, roller, front end loader (less than 3 yds.), street and mobile powered sweeper (3 yds. capacity), 8-ft. sweeper (minimum 65 hp) GROUP 6: Well point installation crew GROUP 7: Heater, concrete mixer, stone crusher, welding machine, generator for light plant, gas and electric driven pump & air compressor

IRON0037-001 09/16/2017

IRONWORKER.......................$ 34.89 26.87

LABO0271-001 06/05/2016

BUILDING CONSTRUCTION

Rates Fringes

LABORER

GROUP 1.....................$ 29.20 23.80

GROUP 2.....................$ 29.45 23.80

GROUP 3.....................$ 29.95 23.80

GROUP 4.....................$ 30.20 23.80

GROUP 5.....................$ 31.20 23.80

LABORERS CLASSIFICATIONS

GROUP 1: Laborer, Carpenter Tender, Mason Tender, Cement Finisher Tender, Scaffold Erector, Wrecking Laborer, Asbestos Removal [Non-Mechanical Systems] GROUP 2: Asphalt Raker, Adzemen, Pipe Trench Bracer, Demolition Burner, Chain Saw Operator, Fence & Guard Rail Erector, Setter of Metal Forms for Roadways, Mortar Mixer, Pipelayer, Riprap & Dry Stonewall Builder, Highway Stone Spreader, Pneumatic Tool Operator, Wagon Drill Operator, Tree Trimmer, Barco-Type Jumping Tamper, Mechanical Grinder Operator GROUP 3: Pre-Cast Floor & Roof Plank Erectors GROUP 4: Air Track Operator, Hydraulic & Similar Self-Powered Drill, Block Paver, Rammer, Curb Setter, Powderman & Blaster GROUP 5: Toxic Waste Remover

LABO0271-002 06/05/2016

HEAVY AND HIGHWAY CONSTRUCTION

Rates Fringes

LABORER

COMPRESSED AIR

Group 1....................$ 46.63 21.80 Group 2....................$ 36.15 21.80 Group 3....................$ 48.63 21.80

FREE AIR

Group 1....................$ 38.70 21.80 Group 2....................$ 36.15 21.80 Group 3....................$ 40.70 21.80

LABORER

Group 1....................$ 29.20 21.80 Group 2....................$ 29.45 21.80 Group 3....................$ 30.20 21.80 Group 4....................$ 22.70 21.80 Group 5....................$ 31.20 21.80

OPEN AIR CAISSON,

UNDERPINNING WORK AND

BORING CREW

Bottom Man.................$ 35.20 21.80 Top Man & Laborer..........$ 34.25 21.80

TEST BORING

Driller....................$ 35.65 21.80 Laborer....................$ 34.25 21.80

LABORER CLASSIFICATIONS

GROUP 1: Laborer; Carpenter tender; Cement finisher tender; Wrecking laborer; Asbestos removers [non-mechanical systems]; Plant laborer; Driller in quarries GROUP 2: Adzeperson; Asphalt raker; Barcotype jumping tamper; Chain saw operators; Concrete and power buggy operator; Concrete saw operator; Demolition burner; Fence and guard rail erector; Highway stone spreader; Laser beam operator; Mechanical grinder operator; Mason tender; Mortar mixer; Pneumatic tool operator; Riprap and dry stonewall builder; Scaffold erector; Setter of metal forms for roadways; Wagon drill operator; Wood chipper operator; Pipelayer;

Pipe trench bracer GROUP 3: Air track drill operator; Hydraulic and similar powered drills; Brick paver; Block paver; Rammer and curb setter; Powderperson and blaster GROUP 4: Flagger & signaler GROUP 5: Toxic waste remover

LABORER - COMPRESSED AIR CLASSIFICATIONS

GROUP 1: Mucking machine operator, tunnel laborer, brake person, track person, miner, grout person, lock tender, gauge tender, miner: motor person & all others in compressed air GROUP 2: Change house attendant, powder watchperson, top person on iron GROUP 3: Hazardous waste work within the "HOT" zone

LABORER - FREE AIR CLASSIFICATIONS

GROUP 1: Grout person - pumps, brake person, track person, form mover & stripper (wood & steel), shaft laborer, laborer topside, outside motorperson, miner, conveyor operator, miner welder, heading motorperson, erecting operator, mucking machine operator, nozzle person, rodperson, safety miner, shaft & tunnel, steel & rodperson, mole nipper, concrete worker, form erector (wood, steel and all accessories), cement finisher (this type of work only), top signal person, bottom person (when heading is 50' from shaft), burner, shield operator and TBM operator GROUP 2: Change house attendant, powder watchperson GROUP 3: Hazardous waste work within the "HOT" zone

PAIN0011-005 06/01/2017

Rates Fringes

PAINTER

Brush and Roller............$ 32.72 20.45 Epoxy, Tanks, Towers, Swing Stage & Structural Steel.......................$ 34.72 20.45 Spray, Sand & Water Blasting....................$ 35.72 20.45 Taper.......................$ 33.47 20.45 Wall Coverer................$ 33.22 20.45

PAIN0011-006 06/01/2017

Rates Fringes

GLAZIER..........................$ 36.28 20.45

FOOTNOTES:

SWING STAGE: $1.00 per hour additional.

PAID HOLIDAYS: Labor Day & Christmas Day.

PAIN0011-011 06/01/2017

Rates Fringes Painter (Bridge Work)...........$ 48.55 20.45

PAIN0035-008 06/01/2011

Rates Fringes Sign Painter.....................$ 24.79 13.72

PLAS0040-001 01/01/2018

BUILDING CONSTRUCTION

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 34.75 27.30

FOOTNOTE: Cement Mason: Work on free swinging scaffolds under 3 planks width and which is 20 or more feet above ground and any offset structure: $.30 per hour additional.

PLAS0040-002 01/01/2018

HEAVY AND HIGHWAY CONSTRUCTION

CEMENT MASON/CONCRETE FINISHER...$ 30.70 22.00

PLAS0040-003 01/01/2018

Rates Fringes

PLASTERER........................$ 34.75 27.30

PLUM0051-002 09/01/2017

Rates Fringes Plumbers and Pipefitters.........$ 40.69 28.80

ROOF0033-004 12/01/2017

Rates Fringes

ROOFER...........................$ 35.50 24.37

SFRI0669-001 04/01/2017

Rates Fringes

SPRINKLER FITTER.................$ 43.92 21.49

SHEE0017-002 03/01/2018

Rates Fringes Sheet Metal Worker...............$ 35.17 34.59

* TEAM0251-001 05/01/2018

HEAVY AND HIGHWAY CONSTRUCTION

Rates Fringes

TRUCK DRIVER

GROUP 1....................$ 27.21 25.7525+A+B+C

GROUP 2....................$ 27.36 25.7525+A+B+C

GROUP 3....................$ 27.41 25.7525+A+B+C

GROUP 4....................$ 27.46 25.7525+A+B+C

GROUP 5....................$ 27.56 25.7525+A+B+C

GROUP 6....................$ 27.96 25.7525+A+B+C

GROUP 7....................$ 28.16 25.7525+A+B+C

GROUP 8....................$ 27.66 25.7525+A+B+C

GROUP 9....................$ 27.91 25.7525+A+B+C

GROUP 10....................$ 27.71 25.7525+A+B+C

FOOTNOTES:

A. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Christmas Day, plus Presidents' Day, Columbus Day, Veteran's Day & V-J Day, providing the employee has worked at least one day in the calendar week in which the holiday falls.

B. Employee who has been on the payroll for 1 year or more but less than 5 years and has worked 150 Days during the last year of employment shall receive 1 week's paid vacation; 5 to 10 years - 2 weeks' paid vacation; 10 or more years - 3 week's paid vacation.

C. Employees on the seniority list shall be paid a one hundred dollar ($100.00) bonus for every four hundred (400) hours worked, up to a maximum of five hundred dollars ($500.00) All drivers working on a defined hazard material job site shall be paid a premium of $2.00 per hour over applicable rate.

TRUCK DRIVER CLASSIFICATIONS

GROUP 1: Pick-up trucks, station wagons, & panel trucks GROUP 2: Two-axle on low beds GROUP 3: Two-axle dump truck GROUP 4: Three-axle dump truck GROUP 5: Four- and five-axle equipment GROUP 6: Low-bed or boom trailer.

GROUP 7: Trailers when used on a double hook up (pulling 2 trailers) GROUP 8: Special earth-moving equipment, under 35 tons

GROUP 9: Special earth-moving equipment, 35 tons or over GROUP 10: Tractor trailer WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications;

however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014.

UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210 2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210 The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210 4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

TECHNICAL SPECIFICATIONS FOR

FIRE DOOR REPAIRS

VA MEDICAL CENTER

VA PROJECT NUMBER 650-16-011

Project Location:

Veterans Administration Medical Center

830 Chalkstone Avenue

PROVIDENCE, RHODE ISLAND 02908

Submission Type: Issued for Construction

Submission Date: January 13, 2017

Submitted by:

Mabbett & Associates, Inc.

5 Alfred Circle – Bedford – MA – 01730

(781) 275-6050

Prepared by:

Architect – Engineers

SMRT, Inc.

One Dundee Park, Suite 4 – Andover – MA – 01810

(978) 474-1721

For:

Department of Veterans Affairs

Network Contracting Activity 1

623 Atwells Avenue

Providence, RI 02909

(401) 273-7100

650-16-011 Prov Fire Door Seed Project

EXHIBIT F-1 SEED PROJECT

NOTICE OF PROPOSED PROJECT, PROPOSAL FORM

Date:

PROJECT TITLE AND NO.: Project 650-16-011, Fire Door Repair, Providence, RI

PROJECT DESCRIPTION: The Contractor shall provide all labor, materials, equipment, transportation, disposal and supervision necessary to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

CAT I $2,000 - $1,000,000

MAGNITUDE OF PROJECT: Between $100,000 and $250,000

PERFORMANCE PERIOD: 365 Calendar Days

SITE VISIT: A site visit for this project will be held on 5/24/18 at 11:00am.

PERFORMANCE & PAYMENT BONDS: In accordance with FAR 28.102-1 and Contract Clause 52.228-15, Contractors are reminded that any amount awarded over $35,000 shall require Payment Bonds, and awards exceeding $150,000 shall require both Payment and Performance Bonds. All bonds are due no later than 10 days after award.

WAGE DETERMINATION: Currently, General Decision Number: RI180001 Modification No 5 dated 05/11/2018 is applicable to this task order. However, the current prevailing Wage Determination will be incorporated at time of award.

PROJECT SAFETY: In accordance with FAR 52.236-13, Accident Prevention, construction contractors shall immediately notify the Contracting Officer’s Representative (COR) and shall prepare a Report of Accident (VA Form 2162 or equivalent) in quadruplicate and forward the original and two copies to the Contracting Officer or COR for forwarding to Safety Officer.

PROPOSAL DUE DATE: All offers are due with proposal for MATOC basic contract. Failure to provide a price will make offer noncompliant, eliminated from the competition and offeror ineligible for a basic contract award. Basis for award is in the RFP.

NOTICE OF PROPOSED PROJECT, PROPOSAL FORM

Date:

PROJECT TITLE AND NO.: Project 650-16-011, Fire Door Repair, Providence, RI

PROJECT DESCRIPTION: The Contractor shall provide all labor, materials, equipment, transportation, disposal and supervision necessary to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

CAT I $2,000 - $1,000,000

MAGNITUDE OF PROJECT: Between $100,000 and $250,000

PERFORMANCE PERIOD: 365 Calendar Days

SITE VISIT: A site visit for this project will be held on 5/24/18 at 11:00am.

PERFORMANCE & PAYMENT BONDS: In accordance with FAR 28.102-1 and Contract Clause 52.228-15, Contractors are reminded that any amount awarded over $35,000 shall require Payment Bonds, and awards exceeding $150,000 shall require both Payment and Performance Bonds. All bonds are due no later than 10 days after award.

WAGE DETERMINATION: Currently, General Decision Number: RI180001 Modification No 5 dated 05/11/2018 is applicable to this task order. However, the current prevailing Wage Determination will be incorporated at time of award.

PROJECT SAFETY: In accordance with FAR 52.236-13, Accident Prevention, construction contractors shall immediately notify the Contracting Officer’s Representative (COR) and shall prepare a Report of Accident (VA Form 2162 or equivalent) in quadruplicate and forward the original and two copies to the Contracting Officer or COR for forwarding to Safety Officer.

PROPOSAL DUE DATE: All offers are due with proposal for MATOC basic contract. Failure to provide a price will make offer noncompliant, eliminated from the competition and offeror ineligible for a basic contract award. Basis for award is in the RFP.

VAMC Providence Replace Fire Doors 11-01-16

Providence, Rhode Island January 13, 2017

VA Project No. 650-16-011 Issued for Construction

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 10 Table of Contents 11-16

00 01 15 List of Drawing Sheets 07-15

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 10-12

01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 04-13

01 33 23 Shop Drawings, Product Data, and Samples 07-15

01 35 13 Special Project Procedures

01 35 33 Infection Control Procedures

01 42 19 Reference Standards 05-16

01 45 02 Quality Control Systems (QCS)

01 58 16 Temporary Interior Signage 07-15

01 62 35 Recycled/Recovered Materials

01 74 19 Construction and Demolition Waste Management

01 81 11 Sustainable Design Requirements 12-16

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 02-15

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 84 00 Firestopping 02-16

07 92 00 Joint Sealants 10-15

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 08-16

08 14 00 Interior Wood Doors 02-16

08 71 00 Door Hardware 01-16

08 71 13 Automatic Door Operators 02-16

08 80 00 Glazing 10-15

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 02-15

09 22 16 Non-Structural Metal Framing 05-16

09 29 00 Gypsum Board 11-14

09 65 13 Resilient Base and Accessories 02-16

09 65 19 Resilient Tile Flooring 12-15

09 91 00 Painting 01-16

NOTICE OF PROPOSED PROJECT, PROPOSAL FORM

Date:

PROJECT TITLE AND NO.: Project 650-16-011, Fire Door Repair, Providence, RI

PROJECT DESCRIPTION: The Contractor shall provide all labor, materials, equipment, transportation, disposal and supervision necessary to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

CAT I $2,000 - $1,000,000

MAGNITUDE OF PROJECT: Between $100,000 and $250,000

PERFORMANCE PERIOD: 365 Calendar Days

SITE VISIT: A site visit for this project will be held on 5/24/18 at 11:00am.

PERFORMANCE & PAYMENT BONDS: In accordance with FAR 28.102-1 and Contract Clause 52.228-15, Contractors are reminded that any amount awarded over $35,000 shall require Payment Bonds, and awards exceeding $150,000 shall require both Payment and Performance Bonds. All bonds are due no later than 10 days after award.

WAGE DETERMINATION: Currently, General Decision Number: RI180001 Modification No 5 dated 05/11/2018 is applicable to this task order. However, the current prevailing Wage Determination will be incorporated at time of award.

PROJECT SAFETY: In accordance with FAR 52.236-13, Accident Prevention, construction contractors shall immediately notify the Contracting Officer’s Representative (COR) and shall prepare a Report of Accident (VA Form 2162 or equivalent) in quadruplicate and forward the original and two copies to the Contracting Officer or COR for forwarding to Safety Officer.

PROPOSAL DUE DATE: All offers are due with proposal for MATOC basic contract. Failure to provide a price will make offer noncompliant, eliminated from the competition and offeror ineligible for a basic contract award. Basis for award is in the RFP.

VAMC Providence Replace Fire Doors 11-01-16

00 01 10-2

NOTICE OF PROPOSED PROJECT, PROPOSAL FORM

Date:

PROJECT TITLE AND NO.: Project 650-16-011, Fire Door Repair, Providence, RI

PROJECT DESCRIPTION: The Contractor shall provide all labor, materials, equipment, transportation, disposal and supervision necessary to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

CAT I $2,000 - $1,000,000

MAGNITUDE OF PROJECT: Between $100,000 and $250,000

PERFORMANCE PERIOD: 365 Calendar Days

SITE VISIT: A site visit for this project will be held on 5/24/18 at 11:00am.

PERFORMANCE & PAYMENT BONDS: In accordance with FAR 28.102-1 and Contract Clause 52.228-15, Contractors are reminded that any amount awarded over $35,000 shall require Payment Bonds, and awards exceeding $150,000 shall require both Payment and Performance Bonds. All bonds are due no later than 10 days after award.

WAGE DETERMINATION: Currently, General Decision Number: RI180001 Modification No 5 dated 05/11/2018 is applicable to this task order. However, the current prevailing Wage Determination will be incorporated at time of award.

PROJECT SAFETY: In accordance with FAR 52.236-13, Accident Prevention, construction contractors shall immediately notify the Contracting Officer’s Representative (COR) and shall prepare a Report of Accident (VA Form 2162 or equivalent) in quadruplicate and forward the original and two copies to the Contracting Officer or COR for forwarding to Safety Officer.

PROPOSAL DUE DATE: All offers are due with proposal for MATOC basic contract. Failure to provide a price will make offer noncompliant, eliminated from the competition and offeror ineligible for a basic contract award. Basis for award is in the RFP.

VAMC Providence Replace Fire Doors 07-01-15

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

Drawing No. Title

GI001 Cover Sheet, Drawing List, and Symbols

AD101 E Wing Partial Architectural Demolition Floor Plans

AE101 E Wing Partial Architectural Floor Plans

AE601 Door Schedule and Details

- - - END - - -

NOTICE OF PROPOSED PROJECT, PROPOSAL FORM

Date:

PROJECT TITLE AND NO.: Project 650-16-011, Fire Door Repair, Providence, RI

PROJECT DESCRIPTION: The Contractor shall provide all labor, materials, equipment, transportation, disposal and supervision necessary to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

CAT I $2,000 - $1,000,000

MAGNITUDE OF PROJECT: Between $100,000 and $250,000

PERFORMANCE PERIOD: 365 Calendar Days

SITE VISIT: A site visit for this project will be held on 5/24/18 at 11:00am.

PERFORMANCE & PAYMENT BONDS: In accordance with FAR 28.102-1 and Contract Clause 52.228-15, Contractors are reminded that any amount awarded over $35,000 shall require Payment Bonds, and awards exceeding $150,000 shall require both Payment and Performance Bonds. All bonds are due no later than 10 days after award.

WAGE DETERMINATION: Currently, General Decision Number: RI180001 Modification No 5 dated 05/11/2018 is applicable to this task order. However, the current prevailing Wage Determination will be incorporated at time of award.

PROJECT SAFETY: In accordance with FAR 52.236-13, Accident Prevention, construction contractors shall immediately notify the Contracting Officer’s Representative (COR) and shall prepare a Report of Accident (VA Form 2162 or equivalent) in quadruplicate and forward the original and two copies to the Contracting Officer or COR for forwarding to Safety Officer.

PROPOSAL DUE DATE: All offers are due with proposal for MATOC basic contract. Failure to provide a price will make offer noncompliant, eliminated from the competition and offeror ineligible for a basic contract award. Basis for award is in the RFP.

VAMC Providence Replace Fire Doors 07-01-15

00 01 15 - 2

NOTICE OF PROPOSED PROJECT, PROPOSAL FORM

Date:

PROJECT TITLE AND NO.: Project 650-16-011, Fire Door Repair, Providence, RI

PROJECT DESCRIPTION: The Contractor shall provide all labor, materials, equipment, transportation, disposal and supervision necessary to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

CAT I $2,000 - $1,000,000

MAGNITUDE OF PROJECT: Between $100,000 and $250,000

PERFORMANCE PERIOD: 365 Calendar Days

SITE VISIT: A site visit for this project will be held on 5/24/18 at 11:00am.

PERFORMANCE & PAYMENT BONDS: In accordance with FAR 28.102-1 and Contract Clause 52.228-15, Contractors are reminded that any amount awarded over $35,000 shall require Payment Bonds, and awards exceeding $150,000 shall require both Payment and Performance Bonds. All bonds are due no later than 10 days after award.

WAGE DETERMINATION: Currently, General Decision Number: RI180001 Modification No 5 dated 05/11/2018 is applicable to this task order. However, the current prevailing Wage Determination will be incorporated at time of award.

PROJECT SAFETY: In accordance with FAR 52.236-13, Accident Prevention, construction contractors shall immediately notify the Contracting Officer’s Representative (COR) and shall prepare a Report of Accident (VA Form 2162 or equivalent) in quadruplicate and forward the original and two copies to the Contracting Officer or COR for forwarding to Safety Officer.

PROPOSAL DUE DATE: All offers are due with proposal for MATOC basic contract. Failure to provide a price will make offer noncompliant, eliminated from the competition and offeror ineligible for a basic contract award. Basis for award is in the RFP.

VAMC Providence Replace Fire Doors 11-01-15

01 00 00 -1

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 GENERAL INTENTION

A. All employees of general contractor and subcontractors shall comply with

VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

B. Prior to commencing work, general contractor shall provide proof that a

OSHA certified “competent person” (CP) (29 CFR 1926.20(b)(2) will maintain a presence at the work site whenever the general or subcontractors are present.

C. Training:

1. All employees of general contractor or subcontractors shall have the

10-hour OSHA certified Construction Safety course and or other relevant competency training, as determined by the VA CP with input from the Construction Safety Committee of VAMC Providence.

2. Submit training records of all such employees for approval before the start of work.

1.2 STATEMENT OF BID ITEMS

A. Replace and repair fire doors on 7 Floors between Building 1 and E-Wing.

1.3 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. AFTER AWARD OF CONTRACT, A single CD-ROM of the contract documents in pdf format will be furnished.

B. Additional sets of drawings may be made by the Contractor, at

Contractor's expense, from the CD-ROM furnished by the Contracting

Officer.

1.4 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

650-16-011 Prov Fire Door Seed Project

EXHIBIT F-1 SEED PROJECT

NOTICE OF PROPOSED PROJECT, PROPOSAL FORM

Date:

PROJECT TITLE AND NO.: Project 650-16-011, Fire Door Repair, Providence, RI

PROJECT DESCRIPTION: The Contractor shall provide all labor, materials, equipment, transportation, disposal and supervision necessary to repair or replace double doors and fire door assemblies on seven floors of E-Wing and to inspect and certify the doors as fully operational fire doors meeting NFPA specifications.

CAT I $2,000 - $1,000,000

MAGNITUDE OF PROJECT: Between $100,000 and $250,000

PERFORMANCE PERIOD: 365 Calendar Days

SITE VISIT: A site visit for this project will be held on 5/24/18 at 11:00am.

PERFORMANCE & PAYMENT BONDS: In accordance with FAR 28.102-1 and Contract Clause 52.228-15, Contractors are reminded that any amount awarded over $35,000 shall require Payment Bonds, and awards exceeding $150,000 shall require both Payment and Performance Bonds. All bonds are due no later than 10 days after award.

WAGE DETERMINATION: Currently, General Decision Number: RI180001 Modification No 5 dated 05/11/2018 is applicable to this task order. However, the current prevailing Wage Determination will be incorporated at time of award.

PROJECT SAFETY: In accordance with FAR 52.236-13, Accident Prevention, construction contractors shall immediately notify the Contracting Officer’s Representative (COR) and shall prepare a Report of Accident (VA Form 2162 or equivalent) in quadruplicate and forward the original and two copies to the Contracting Officer or COR for forwarding to Safety Officer.

PROPOSAL DUE DATE: All offers are due with proposal for MATOC basic contract. Failure to provide a price will make offer noncompliant, eliminated from the competition and offeror ineligible for a basic contract award. Basis for award is in the RFP.

01 00 00 -2

1. General Contractor’s employees shall not enter the project site without appropriate badge.