33330222RF0010030 RFP.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGESPAGE OF

7. ISSUED BY CODE

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

SMITHSONIAN INSTITUTION

P.O. BOX 37012

MRC 1200

Washington DC 20013-7012

OCON

Christine Grant 202-633-7290

1630102 x

33330222RF0010030

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

This Solicitation is for the Construction of Pod 6 located at the Smithsonian

Institution's Museum Support Center, 4210 Silver Hill Road, Suitland, Maryland

20746. The successful Contractor shall furnish all supervision, labor, materials and equipment needed to perform construction services to complete the work as described in the Drawings and Specifications for SF Project No. 1630102 dated

January 21, 2022 and Ayers/Saint/Gross Addendum #01 dated April 6, 2022. All work shall be done in accordance with applicable codes and regulations.

The Pod 6 addition at the MSC is a joint effort between the Smithsonian Institution and the National Gallery of Art (NGA) who share similar requirements for collections storage.

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 688 calendar days and complete it within ________________ ________________ calendar days after receiving

Description/Specifications

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

8. ADDRESS OFFER TO

Smithsonian Institution

Office of Contracting

600 Maryland Ave. SW, Ste. 500E

Washington, DC 20024

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

OCON

P.O. BOX 37012

MRC 1200

Washington DC 20013-7012

OCON

Thomas Dempsey

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED OFPAGE

33330222RF0010030

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

PRE-BID TOUR OF THE SITE

The tour will be conducted on June 15, 2022.

Offerors can contact Christine Grant at grantca@si.edu to schedule. A maximum of ten people are allowed and mask are required to be worn at all times while on site. All offerors are required to follow the Coronavirus (COVID-19) Prevention and Control Plan Guidelines (see attachment).

QUESTIONS/CLARIFICATIONSIt is desired that all questions/clarifications be sent in, sequentially numbered for example first questions 1,2,3, second set of questions 4,5,6 etc. in word format to grantca@si.edu. It is requested that all questions be sent in June 22, 2022 no later than

2PM EST.

Proposals are to be submitted to DropBox.com using link (see below)and Express mailed in pdf format on a flash drive each file labeled separately. If any pricing information is on the Technical proposal you will be disqualified.

Flash Drives should be delivered via FedEx, UPS or courier to:

Smithsonian Institution

Office of Contracting

600 Maryland Ave. SW, Ste. 500E

Washington, DC 20024

THE PROPOSAL DUE DATE IS July 6, 2022

AT 2:00PM EST

Offerors shall submit with their proposal a Small Business and Small Disadvantaged Business

Subcontracting Plan which will be evaluated for compliance with FAR 19.7, statutory requirements of Public Laws 95-507, 99-661, 100-656, and Executive Order 13360.

grantca Highlight grantca Highlight grantca Highlight grantca Highlight grantca Highlight grantca Highlight grantca Highlight grantca Highlight grantca Highlight

A - Contract Form (SF 1442 Pg 1-3)

B - Supplies or Services/Prices

C - Description/Specifications

D - Packaging and Marking

E - Inspection and Acceptance

F - Deliveries or Performance

G - Contract Administration Data

H - Special Contract Requirements

I - Contract Clauses

J - List of Documents, Exhibits and Other Attachments

K - Representations, Certifications, and Other Statements of Bidders

L - Instructions,Conditions, and Notices to Bidders

M - Evaluation Factors for Award

Table of Contents

B - Services/Prices

B.1. The Smithsonian Institution intends to award a firm fixed-price multi-year construction contract to the successful Contractor/Offeror.

B.2. The successful Contractor shall furnish all supervision, labor, materials and equipment needed for the Construction of Pod 6 located at the Smithsonian Institution's Museum Support Center, 4210 Silver Hill Road, Suitland, Maryland 20746, as set forth in the attached documents in Section J.

These drawings and specification are collectively referred to herein as the “Construction Documents.” All work shall be performed in strict accordance with the plans and specification as shown or as may be changed by modification issued by the Contracting Officer. No deviations are permitted unless a change notice is issued and approved by an authorized official at the Smithsonian Institution.

B.3. Pricing – The successful contractor/offeror shall identify all costs associated with the Construct Pod 6 project, as set forth in the Construction Documents. Offerors are required to provide the Base Cost Proposal Submission as per the Bid Form and Multi-year FY Funding Increments Form (See Attachments J1).

B.3.1. Base Cost Proposal Submission - Provide a comprehensive cost and Bid Schedule for the Construct Pod 6 project. The format for the Base Cost Proposal Submission shall be the Construction Specifications Institute (CSI) divisions of work. Break down the Base Cost Proposal Submission into the CSI divisions listed (See Attachments J1).

B.3.2. Multi-year FY Funding Increments – The Smithsonian has identified $10,000,000 to fund performance of the awarded contract for the first fiscal year. The Smithsonian Institution’s obligation under this contract beyond that amount is contingent upon the availability of appropriated funds from which payment under this contract can be made. No legal liability on the part of the Smithsonian Institution for any payment may arise for performance under this contract beyond $10,000,000 unless and until funds are made available to the Contracting Officer for payment for performance under the contract and the Contractor receives notice of availability of funds, which must be confirmed in writing to the Contractor by the Contracting Officer. The Contractor shall not be obligated to continue performance beyond the funds allocated under this contract. Offerors are reminded that they must include in their proposal a termination cost in the event that subsequent year funds are not appropriated. Smithsonian Institution will not be liable for any costs in excess of the termination cost (cancellation charge).

Because FY22, FY23 and FY24 funding will be used on this construction project the cost proposal is required to reflect the division of costs on the following timetable:

1) Expected start of project Aug. 15, 2022 to October 30, 2022;

2) Nov. 1, 2022 to Oct 30, 2023;

3) Nov 1, 2023 to project completion

The total of FY 22, FY23 and FY24 increments should equal the Base Cost Proposal Total.

333302-22RF-0010030 MSC Construct Pod 6 5 of 66

C - Description/Specifications

The successful offeror shall provide all materials, equipment, labor and supervision necessary to complete the following work for the Construction of Pod 6 located at the Smithsonian Institution's Museum Support Center, 4210 Silver Hill Road, Suitland, Maryland 20746, as set forth in the following documents.

The Work includes, but is not limited to, all work specified in the drawings and specifications beginning with Division 1 and ending with Division 33 (with some sections omitted).

The objective of the Construct Pod 6 project is to construct a complete and usable collections storage facility. Work under this project includes but is not limited to:

• Selective demolition

• Excavation and site work

• Driving steel H piles and installation of pad and grade beam foundations

• Erection of a three-level steel superstructure

• Installation of a poured concrete flooring system

Work will require coordination with the Museum Support Center (MSC) in order to provide access to visitors and staff throughout construction. The Center will remain operational during the course of the project and continue to receive staff and visitors.

Construction Schedule: Total period of performance allowed for construction is 688 calendar days from the Notice to Proceed.

Construction Budget: Estimated cost range is between $85M and $95M, including all packages and options.

The following briefly summarizes the program requirements for this effort.

The Smithsonian’s Suitland Collections Center (SCC) is composed of three separate districts:

• The Paul F. Garber Preservation, Restoration and Storage Facility (Garber),

• The Museum Support Center (MSC) and

• The National Museum of the American Indian (NMAI) Cultural Resource Center (CRC).

Both the Smithsonian and the National Gallery need additional storage to promote collections care. This effort includes the construction of Pod 6 on site at the MSC for the purpose of addressing that need. Pod 6 is in design and the site has been approved by National Capital Planning Commission (NCPC) as part of NCPC’s approval of the SCC Master Plan. Pod 6 leverages past investment in infrastructure, such as site utilities and a loading dock to limit project costs. SI and NGA are equally proximate to MSC, which is approximately 7 miles from the National Mall.

With SI's established legacy of construction, maintenance and operation of over 1.2 million square feet of off-mall collections storage, SI has the expertise and ability to partner with NGA to solve an inter-agency collections storage need.

333302-22RF-0010030 MSC Construct Pod 6 6 of 66

333302-22RF-0010030 MSC Construct Pod 6 7 of 66

At SCC, the existing NCPC-approved Master Plan includes the Pod 6 addition at the western end of MSC. After multiple reviews a three-story option was selected for further development.

In developing the logistics of inter-agency space sharing, the following guidelines have been established:

• SI and NGA will maintain separate collections storage spaces with independent security.

• SI will be the Authority Having Jurisdiction (AHJ) and the first responder.

• Mechanical systems will be separated at the Air Handler Units (AHU)s. SI AHUs will be headered together for redundancy. NGA will be served by a fully redundant AHU. In shared schemes, N+1 redundancy (there is a power backup in place should any single system component fail) of heating and cooling plant water will be provided through SI equipment.

Please see Attachments for additional information.

D - Packaging and Marking

Not Applicable

E - Inspection and Acceptance

52.246-S0038 Smithsonian Institution Inspection and Acceptance (Jun 2000)

Inspection and acceptance may be made on a daily basis on work performed at the job site, by the Contracting Officers Technical Representative. All work shall be coordinated through the COTR for acceptance of work, payrolls and invoice(s).

52.246-S0039 Final Inspection and Tests (Jun 2000)

The requirements of the Inspection of Construction clause prescribed in FAR 52.246-12, are supplemented to provide that the Contractor shall give the Contracting Officer at least 10 calendar days advance written notice of the date the work will be fully completed and ready for final inspection and tests. Final inspection and tests will be started within 10 calendar days from the date specified in the aforesaid notice unless the Contracting Officer determines that the work is not ready for final inspection and so informs the Contractor.

52.246-S0057 Inspection

(a) Upon proper notice and during normal working hours, the Smithsonian Institution reserves the right to perform any inspections and tests as deemed necessary to assure that the Contractor is performing in accordance with the terms and specifications as set forth herein.

(b) Inspection may be at the Contractor's place of business or at any location where work is being performed in conjunction with this contract.

(c) Inspection by the Smithsonian Institution shall not relieve the Contractor of responsibility for any or all quality control aspects during the life of the contract. This shall include quality control for items covered by this contract that may be subcontracted.

52.246-S0058 Acceptance

(a) The supplies and services rendered under this contract will be accepted and approved by the Contracting Officer or a designated representative thereto. Such approval, when given, will indicate acceptability to the Smithsonian Institution of performance in accordance with the terms and conditions of this contract, and will be subject to applicable warranties. The Smithsonian Institution reserves the right to reject works not conforming to prescribed contract requirements.

(b) Neither the Smithsonian Institution's review, approval, or acceptance of services and/or supplies, nor payment for any of the services or supplies required under this contract, shall be construed to operate as a waiver of any claim or action arising out of the performance of this contract. Furthermore, the Contractor shall be and remain liable to the Smithsonian Institution in accordance with applicable law for all damages to the Smithsonian Institution caused by the Contractor's negligent performance of any of the supplies or services furnished under this contract.

(c) Acceptance by the Smithsonian Institution does not relieve the Contractor of responsibility for correction of errors or omissions that may arise after such acceptance if the errors and omissions arise out of any negligence or fault in Contractor performance.

F - Deliveries or Performance

52.211-S0025 Commencement, Prosecution, and Completion of Work (Jun 2000)

(a) Definitions.

(1) The Contract Time is the period of time allotted in the Contract Documents for Final Completion of the Work as defined in this Construction Contract Clause, including authorized extensions thereto. The Contractor shall complete Work within the Contract Time as stated in the SF 1442, or as modified.

(2) The date of commencement of the Work is the date established in the Notice To Proceed issued by the Contracting Officer (C.O.). Submission by the Contractor of its Performance and Payment Bonds, Preliminary Schedule and all Certificates of Insurance and their approval by SI are conditions precedent to the issuance of the Notice to Proceed. The Contractor shall not commence the Work or store materials or equipment on site until written Notice to Proceed is issued or until the Contractor otherwise receives the written consent of the C.O.

(3) The date of Substantial Completion of the Work or designated portion thereof is the date certified by the COTR when the Work or a designated portion thereof is sufficiently complete, in accordance with the Contract Documents, so SI and NGA can fully occupy the Work or designated portion thereof for the use for which it is intended, with all of the Project's parts and systems operable as required by the Contract Documents. Only punch list work and any final cleaning beyond that needed for the SI’s and NGA's full use may remain for Final Completion.

(4) The date of Final Completion of the Work is the date certified by the COTR when the Work is totally complete, to include punch list work and final clean up, in accordance with the Contract Documents and SI and NGA may fully occupy and fully utilize the Work for the use for which it is intended.

(5) If a date or time of completion is included in the Contract, it shall be the Date of Final Completion as defined in this Construction Contract Clause, including authorized extensions thereto, unless otherwise provided.

(6) The term Day as used in the Contract Documents shall mean calendar day unless otherwise specifically designated. All dates shall mean midnight of the indicated day unless otherwise stipulated.

333302-22RF-0010030 MSC Construct Pod 6 8 of 66

(b) Progress and Completion.

(1) All time limits stated in the Contract Documents are of the essence of the Contract.

(2) The Contractor shall prosecute the Work diligently to Final Completion.

(c) Delays and Extensions of Time.

(1) The time during which the Contractor is delayed in the performance of the Work, by the acts or omissions of SI, the Architect, or their employees or agents, acts of God, unusually severe and abnormal climatic conditions, fires, floods, epidemics, quarantine restrictions, strikes, riots, civil commotion or freight embargoes, or other conditions beyond the Contractor's control and which the Contractor could not reasonably have foreseen and provided against, shall be added to the Contract Time; provided, however, that no claim by the Contractor for an extension of time for delays will be considered unless made in compliance with the requirements of this Article and other provisions of the Contract Documents.

(2) Neither SI nor the Architect shall be obligated or liable to the Contractor for, and the Contractor hereby expressly waives any claims against SI and the Architect on account of, any indirect or direct damages, costs or expenses of any nature which the Contractor, Subcontractors, Suppliers or any other person may incur as a result of any delays, interference, changes in sequence or the like, which are reasonable, foreseeable, contemplated, or avoidable by the Contractor, arising from or out of any act or omission of SI or the Architect, or their agents, employees, consultants, separate contractors or any governmental representative, it being understood and agreed that the Contractor's sole and exclusive remedy in any such events shall be an extension of the Contract Time, but only as determined in accordance with the provisions of the Contract Documents.

(3) The Contract Time shall be adjusted only for Change Orders pursuant to the Construction Contract Clause entitled "Changes," excusable delays pursuant to Construction Contract Clause entitled "Delays and Extensions of Time," and Construction Contract Clause entitled "Smithsonian Institution's Right to Stop or to Suspend the Work." In the event the Contractor requests an extension of the Contract Time, the Contractor shall furnish such justification and supporting evidence as the C.O may deem necessary for a determination of whether the Contractor is entitled to an extension of time under the provisions of the Contract. The burden of proof to substantiate a claim for an extension of the Contract Time shall rest with the Contractor, including evidence that the cause was beyond his control. The C.O. shall base his findings of fact and decision on such justification and supporting evidence and shall advise the Contractor in writing thereof. If the C.O. finds that the Contractor is entitled to any extension of the Contract Time, the C.O.'s determination of the total number of days' extension shall be based upon the currently approved Progress Schedule and on all data relevant to the extension. Such data will be incorporated into the Progress Schedule in the form of a revision thereto, accomplished in a timely manner. The Contractor acknowledges and agrees that actual delays (due to said changes, suspensions of work or excusable delays) in activities which, according to the Progress Schedule, do not affect the Contract Time, do not have any effect upon the Contract Time and therefore will not be the basis for a change therein. The Contractor acknowledges and agrees that time extensions will be granted only to the extent that excusable delays exceed the available float in the Contractor's Progress Schedule.

(4) Subject to other provisions of the Contract, the Contractor may be entitled to an extension of the Contract Time (but no increase in the Contract Price) for delays arising from unforeseeable

333302-22RF-0010030 MSC Construct Pod 6 9 of 66 causes beyond the control and without the fault or negligence of the Contractor, his Subcontractors or Suppliers as follows:

(i) Labor disputes and strikes (including strikes affecting transportation), that do, in fact, directly and critically affect the progress of the Work; however, an extension of Contract time on account of an individual labor strike shall not exceed the number of days of said strike;

(ii) Acts of God, tornado, fire, hurricane, blizzard, earthquake, typhoon, or flood that damage completed work or stored materials.

(iii) Abnormal inclement weather; however, the Contract Time will not be extended due to normal inclement weather. The time for performance of this Contract, as stated in the Contract Documents, includes an allowance for calendar days, which may not be available for construction out-of-doors; for purposes of the Contract, the Contractor agrees that said number of calendar days per month are to be considered as normal inclement weather. Unless the Contractor can substantiate to the satisfaction of the S.I. that there was greater than normal inclement weather considering the full term of the Contract Time using a ten-year average of accumulated record mean values from climatological data compiled by the U.S. Department of Commerce, National Oceanic and Atmospheric Administration, for the locale of the Project, and that such alleged greater than normal inclement weather actually delayed the Work or portions thereof which had an effect upon the Contract Time, the Contractor shall not be entitled to an extension of time. If the total accumulated number of calendar days lost due to inclement weather, from the start of Work until Final Completion, exceeds the total accumulated number to be expected for the same period from the aforesaid climatological data, time for completion will be extended by the number of calendar days needed to include the excess number of calendar days lost.

(iv) Acts of the public enemy, acts of the state, Federal or local government in its sovereign capacity, and acts of a separate contractor in the performance of its contract with the S.I. relating to the Project.

(5) The Contractor shall not be entitled to and hereby expressly waives any extension of time resulting from any conditions or cause unless said claim for extensions of time is made in writing to the C.O. within seven (7) days of the first instance of delay. Circumstances and activities leading to such claim shall be indicated or referenced in a daily field inspection report for the day(s) affected; otherwise, all such claims are waived by the Contractor. In every such written claim, the Contractor shall provide the following information:

(i) Nature of the delay;

(ii) Date (or anticipated date) of commencement of delay;

(iii) Activities on the Progress Schedule affected by the delay, and/or new activities created by the delay and their relationship with existing activities;

(iv) Identification of person(s) or organizations(s) or event(s) responsible for the delay;

(v) Anticipated extent of the delay;

(vi) Recommended action to avoid or minimize the delay.

(d) Responsibility for Completion.

333302-22RF-0010030 MSC Construct Pod 6 10 of 66

(1) The Contractor shall furnish such manpower, materials, facilities and equipment and shall work such hours, including night shifts, overtime operations and Sundays and holidays, as may be necessary to insure the progress and completion of the Work in accordance with the approved and currently updated Progress Schedule. If Work actually in place falls behind the currently updated and approved Progress Schedule and it becomes apparent from the current Progress Schedule that the Work will not be completed within the Contract Time, the Contractor agrees that he will, as necessary, take some or all of the following actions at no additional cost to the S.I., as required to eliminate substantially the backlog of the Work:

(i) Increase manpower in quantities and crafts as necessary;

(ii) Increase the number of work hours per shift, shifts per working day, working days per week, the amount of equipment, or any combination of the foregoing; and/or

(iii) Re-schedule activities to achieve maximum practical concurrence.

(2) The COTR may require the Contractor to submit a Recovery Schedule in accordance with the Supplementary Construction Contract Clause, demonstrating his program and proposed plan to make up the lag in scheduled progress and to ensure completion of the Work within the Contract Time. If the COTR finds the proposed plan not acceptable, he may require the Contractor to submit a new plan. If the actions taken by the Contractor or the second plan proposed are not satisfactory, the COTR may require the contractor to take any of the actions set forth in this Construction Contract Clause without additional costs to the S.I., to make up the lag in scheduled progress.

(3) Failure of the Contractor to comply substantially with the requirements of this Construction Contract Clause may be considered grounds for a determination by the S.I., pursuant to the Construction Contract Clause entitled "Default," that the Contractor is failing to prosecute the Work with the sufficient diligence to ensure its completion with the Contract Time.

52.228-S0081 Period of Performance-Bonds & Insurance-Construction

Contractor must submit approved Certificate of Insurance and Performance/Payment Bonds within ten (10) days of contract award.

52.236-S0036 Smithsonian Institution's Right to Stop or to Suspend the Work (Jun 2000)

(a) If the Contractor fails to correct defective Work as required by the Construction Contract Clause entitled "Correction of Work," or fails to carry out the Work or supply labor and materials in accordance with the Contract Documents, the C.O. by a written order may order the Contractor to stop the Work, or any portion thereof, without monetary compensation to the Contractor until the cause for such order has been eliminated.

(b) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the Work for such period of time as he may determine to be appropriate for the convenience of the S.I.

(c) If the performance of all or any part of the Work is, for an unreasonable period of time, suspended, delayed, or interrupted by the S.I. or its authorized representatives in the administration of this Contract, or by failure of any one of them to act within the time specified in this Contract (or if no time is specified, within a reasonable time), an adjustment shall be made for an increase in the actual time required for performance of the Work by the Contractor, due solely to such unreasonable suspension, delay, or interruption and the Contract modified in

333302-22RF-0010030 MSC Construct Pod 6 11 of 66 writing accordingly. However, no claim for an extension of time shall be made under this Construction Contract Clause for any suspension, delay, or interruption pursuant to this Construction Contract Clause, or for which claim is provided or excluded under any other provision of this Contract. No claim under this Construction Contract Clause shall be allowed for any claim for an extension of time required for performance, unless within twenty (20) days after the act or failure to act involved, the Contractor submits to the COTR a written statement setting forth, as then practicable, the extent of such claimed time extension, and unless the claim for an extension of time is asserted in writing as soon as practicable after the termination of such suspension, delay, or interruption. No claim shall be made for direct or indirect costs incurred by Contractor as a result of the events described in this Construction Contract Clause, a time extension being the Contractor's sole remedy.

(d) A claim under this clause shall not be allowed (1) for any costs incurred more than twenty

(20) days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order), and (2) unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(e) In the event of a suspension of work or delay or interruption of work, the Contractor will protect carefully, and will cause his subcontractors to protect carefully, his and their materials and work against damage or injury from the weather, will and maintain completed and uncompleted portions of the work as required by the Contract Documents. If, in the opinion of the COTR, any work or material shall have been damaged or injured by reason of failure on the part of the Contractor or any of his subcontractors to so protect same, such work and materials shall be removed and replaced at the expense of the Contractor.

(f) No claim by the Contractor for an equitable adjustment under the Construction Contract Clause entitled "Equitable Adjustments" shall be allowed if asserted after Final Payment under this Contract.

52.246-S0041 Additional Warranties and Guarantees (Jun 2000)

(a) The Contractor guarantees and warrants to the S.I. all work as follows:

(1) That all materials and equipment furnished under this Contract will be new and the best of its respective kind unless otherwise specified;

(2) That all Work will be first-class quality and free of omissions and faulty, poor quality, imperfect or defective material or workmanship;

(3) That where no standard is specified for such workmanship or materials, they shall be the best of their respective kinds;

(4) That the Work shall be entirely watertight and leakproof in accordance with all applicable industry customs and practices, and shall be free of shrinkage and settlement, (normal shrinkage inherent in the specified materials is acceptable);

(5) That the Work, including but not limited to, mechanical and electrical machines, devices and equipment shall be fit and fully usable for its intended and specified purpose and shall operate satisfactorily with ordinary care;

333302-22RF-0010030 MSC Construct Pod 6 12 of 66

(6) That consistent with requirements of the Contract Documents the Work shall be installed and oriented in such a manner as to facilitate unrestricted access for the operation and maintenance of fixed equipment;

(7) That the Work will be free of abnormal or unusual deterioration which occurs because of poor quality materials, workmanship or unsuitable storage.

(b) That all work not conforming to guarantees and warranties specified in the Contract Documents, including substitutions not properly approved and authorized, may be considered defective. If required by the COTR, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. This warranty is not limited by the provisions of the Construction Contract Clauses entitled "Uncovering of Work" and "Correction of Work."

(c) The warranties set forth in this Construction Contract Clause entitled "Additional Warranties and Guarantees" and elsewhere in the Contract Documents shall survive Final Completion of the Work under the Construction Contract Clause entitled "Payments and Completion."

(d) If, within one year after the Date of Final Completion of the Work or designated portion thereof, or within one year after acceptance by the S.I. of designated equipment, or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective, not in accordance with the Contract Documents, or not in accordance with the guarantees and warranties specified in the Contract Documents, the Contractor shall correct it within five (5) working days, or such other period as mutually agreed, after receipt of a written notice from the COTR to do so.

(e) Any materials or other portions of the Work installed, furnished or stored on site which are not of the character or quality required by the specifications, or are otherwise not acceptable to the COTR, shall be immediately removed and replaced by the Contractor to the satisfaction of the COTR, when notified to do so by the COTR.

(f) If the Contractor fails to correct defective or nonconforming Work as required by the Construction Contract Clause entitled "Correction of Work," or if the Contractor fails to remove defective or nonconforming Work from the site as required by the Construction Contract Clause entitled "Uncovering of Work," the S.I. may elect to either correct such work in accordance with the Construction Contract Clause entitled "Smithsonian Institution's Right to Carry Out The Work" or remove and store materials and equipment at the expense of the Contractor.

(g) The Contractor shall bear the cost of making good all work of the S.I., separate contractors or others, destroyed or damaged by such correction or removal required under this Construction Contract Clause or the Construction Contract Clauses entitled "Uncovering of Work" and "Correction of Work" or elsewhere in the Contract Documents.

SI-0080 Period of Performance-NTP

The contract shall become effective upon execution of the contract and upon the Smithsonian Institution Contracting Officer's Notice to Proceed.

SI-0082 Period of Performance-Options

Optional Services: Smithsonian Institution reserves the sole right to exercise option(s).

333302-22RF-0010030 MSC Construct Pod 6 13 of 66

G - Contract Administration Data

52.202-S0059 Contract Management

Notwithstanding the Contractor's responsibility for total management during the performance of this contract, the administration of the contract will require maximum coordination between the Smithsonian and the Contractor. The following individuals will be the Smithsonian points of contact during the performance of the contract.

52.202-S0060 Contracting Officer

All contract administration will be effected by the Contracting Officer. Communications pertaining to contractual administrative matters will be addressed to the Contracting Officer. No changes in or deviation from the scope of work shall be effected without a written modification to the contract executed by the Contracting Officer authorizing such changes.

52.202-S0061 Contracting Officer's Technical Representative (COTR) (Apr 1988)

(a) The Contracting Officer's Technical Representative (COTR) or her authorized representative shall act for and on behalf of the Contracting Officer in the administration of any resultant contract with respect to:

1. Resolution of issues that may arise between the Contractor and the Smithsonian Institution in connection with such matters as acceptability of workmanship and other technical requirements;

2. Evaluation on an overall basis of the acceptability of workmanship and Contractor's compliance with technical requirements; and

3. The approval and acceptance of work performed under this contract.

(a) This delegation does not authorize the modification of any of the contract's provisions, terms or conditions. All authorities not herein delegated are reserved to the Contracting Officer.

(b) The Contractor shall make available such records, reports and facilities as may be required to carry out this assignment.

(c)Contractor’s performance will be evaluated using the respective contractor performance evaluation report entry system located on the website http://www.cpars.gov/. Prior to commencement of work the contractor is required to provide the government with the name, phone number and e-mail address of the “Contractor’s Representative” that will be responsible for receipt and review of draft performance evaluations prepared by the government in the appropriate system. It is the contractor’s responsibility to keep this contact information current.

52.202-S0062 Authorities

The Contractor is advised that only the Contracting Officer can change or modify the terms of this contract or take any other action which obligates the Smithsonian and any such action must be set forth in a formal modification to the Contract. The authority of the COTR is strictly limited to the specific duties set forth in her letter of appointment, a copy of which will be furnished the Contractor. Contractors who rely on direction from persons other than the Contracting Officer (or a COTR acting within the strict limits of his/her responsibilities as set forth in his/her letter of appointment) do so at their own risk and expense, as such actions do not bind the Smithsonian contractually. All questions concerning the authority of a Smithsonian employee to direct the Contractor contractually should be referred to the Contracting Officer.

333302-22RF-0010030 MSC Construct Pod 6 14 of 66

52.213-S0094 Application for Payment

The Contractor shall submit Application for Payment in triplicate copies and in accordance with the Construction Contract Clauses. All Applications for Payment shall identify the Contract Number and Project Title and shall be submitted to the COTR at the address specified by the Work Order.

Note: The Prompt Payment Act (31 U.S.C. Section 3901) is not applicable to the Smithsonian Institution. The Smithsonian Institution shall take all reasonable measures to ensure that payment for invoice(s) properly documented and submitted shall be paid within thirty (30) days from receipt of an approved proper invoice.

52.215-S0002 Authorized Negotiators (Apr 1984)

The offeror or quoter represents that the following persons are authorized to negotiate on its behalf with the Government in connection with this request for proposals or quotations: [list names, titles, and telephone numbers of the authorized negotiators].

52.215-S0063 Key Personnel

(a) The Contractor shall include the key personnel to be assigned under this contract those persons listed below:

NAME LABOR CATEGORY

Offerors shall also provide this information in their technical proposal.

(b) The persons named above are considered key personnel. The Contractor shall give at least 14 calendar days advance notice if any of these persons are to be removed or diverted from this contract, and shall supply written justification as part of this notice, and shall name the proposed substitute or replacement; but the Contractor will not remove or divert such persons unless authorized by written consent of the Contracting Officer.

333302-22RF-0010030 MSC Construct Pod 6 15 of 66

333302-22RF-0010030 MSC Construct Pod 6 16 of 66

(c) General Approval. All Contractor personnel assigned to this contract are subject to Smithsonian review in accordance with the defined labor categories herein. Contractor personnel found unacceptable by the Smithsonian at any time shall be removed from performing under this contract within 14 calendar days after notification. Such notification shall be delivered in writing by the Contracting Officer to the Contractor.

SI-0064 Incorporation of Contractor's Proposal

It is understood and agreed that the Contractor shall, in meeting the requirements of the contract, perform the work in accordance with his/her proposal to the Smithsonian Institution for services;

however, to the extent that any provisions of the articles set forth herein are in conflict or inconsistent with any provisions of said proposal, the provisions of the articles of this contract shall be controlling and shall supersede the provisions of said proposal.

H - Special Contract Requirements

52.202-S0010R Use of Smithsonian Name

It is recognized and acknowledged that Contractor shall have no right to use the name "Smithsonian" or "Smithsonian Institution", or the name of any Smithsonian Museum or part thereof, including the Facilities, in connection with any of its own advertising, marketing or promotion. The provisions of this clause shall survive the termination of this Agreement.

The Prime Contractor shall be responsible for compliance by any subcontractor or supplier or lower tier subcontractor or lower tier supplier with this clause. After award of the contract and upon request of the Contracting Officer, the Prime Contractor shall deliver a written statement acknowledging that this clause has been included in contracts with all subcontractors and suppliers.

The Contractor shall not use the name of the National Gallery of Art (Gallery or NGA), its seal, logos or designs, its Web sites, images of the NGA's exterior or the interior, including images of artwork owned by or on the premises of the NGA, or any element of the foregoing, for any reason, in any media. However, the Contractor may use the NGA's name on its client list. The NGA may at any time, in its sole discretion, without cause, revoke any permission granted under this clause. The provisions of this clause shall survive the termination of this Agreement.

52.203-S0004 Advertising of Award Smithsonian Institution

The Contractor shall not refer to the Smithsonian or to any of its museums, organizations, or facilities in any manner or through any medium, whether written, oral or visual, for any purpose whatsoever, including advertising, marketing, and promotion.

52.215-S0009 Information, Services and Rights of the Smithsonian (Apr 1988)

(a) The S.I., through the C.O. and COTR, will provide administration of the contract as hereinafter described.

(b) The S.I. or its authorized representatives shall at all times have access to the Work whenever it is in preparation or progress. The Contractor shall provide safe facilities for such access.

(c) The S.I. or its authorized representatives shall not be responsible for or have control or charge of the construction means, methods, techniques, sequences, or procedures, or for safety precautions and program in connection with the Work, and will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents.

(d) The COTR shall have authority to reject Work when in his/her opinion, the Work does not conform to the Contract Documents.

(e) Whenever in the COTR's reasonable opinion it is considered necessary or advisable for the implementation of the intent of the Contract Documents, the COTR will have authority to require special inspection or testing of the Work in accordance with the provisions of the Contract Documents whether or not such Work be then fabricated, installed or completed.

(f) The COTR shall have the authority and discretion to call, schedule, and conduct job meetings to be attended by the Contractor, representatives of his Subcontractors, and the Architect to discuss such matters as procedures, progress, problems, payments and scheduling.

(g) The COTR will establish procedures to be followed for processing all Shop Drawings, catalogs, and other project reports and other documentation, test reports, and maintenance manuals.

(h) The COTR will review all requests for changes and shall implement the processing of Change Orders, including applications for extension of the Contract Time.

(1) The COTR will review and process all Progress Payments including the Final Payment.

(2) The Smithsonian Institution or its authorized representatives shall not be responsible or liable to the Contractor for the acts, errors or omissions of the Contractor, any separate Subcontractor, any separate contractor or any contractor's or subcontractor's agents or employees, or any other persons performing any of the Work.

(k) Unless otherwise provided in the Contract Documents, the Contractor will be furnished, free of charge, ten copies of full size Drawings and Specifications reasonably necessary for the execution of the Work.

(l) The foregoing rights are in addition to other rights of the S.I. enumerated herein and those provided by law.

52.223-S0070 Dissemination of Information

There shall be no dissemination or publication of information, except between the Contractor and any subcontractors, developed under this contract or any task orders awarded under the terms of this contract or contained in reports to be furnished pursuant to this contract without the prior written approval of the Contracting Officer.

52.236-S0030 Availability and Use of Utility Services (Jun 2000)

(a) The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract. These services shall be furnished without charge to the Contractor. The Contractor shall carefully conserve any utilities furnished without charge.

(b) The Contractor, at its expense and in a workmanlike manner satisfactory to the Contracting Officer, shall install and maintain all necessary temporary connections and distribution lines.

Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, and associated paraphernalia.

333302-22RF-0010030 MSC Construct Pod 6 17 of 66

52.236-S0031 Use of Site (Jun 2000)

The Contractor shall confine operations at the site to areas permitted by law, ordinances, permits, easements, right-of-way agreements and the Contract Documents. The Contractor shall not unreasonably encumber the site, in the opinion of the COTR, with any materials, equipment or trailers, nor shall the Contractor block the entrances or otherwise prevent reasonable access to the site, other working and parking areas, completed portions of the Work and/or other properties, storage areas, loading dock and other areas of the work site or areas that are adjacent to the work site. If the Contractor fails or refuses to move said materials, equipment or trailers within 24 hours of notification by the COTR to so do, the COTR shall have the right, without further notice, to remove, at the Contractor's expense, any material, equipment and/or trailers which the COTR deems are in violation of this Construction Contract Clause entitled "Use of Site."

52.242-S0020 Historic & Archeological Rights (Jun 2000)

(a) If during the excavation of the site items of historic and archeological significance are found, the contractor shall stop work and notify the COTR immediately. Subsequent excavation work shall proceed as directed by the COTR.

(b) All items considered by the Smithsonian Institution to have historic or archaeological significance are the property of the Smithsonian Institution.

SI-0091 Internet Protocol Version 6 (IPv6) Compliance (Jan 2006)

In the event that Contractor will be developing, acquiring, and/or producing products and/or systems pursuant to this Contract that will be connected to a network or that will interface with the World Wide Web, the following provisions…