B08_Attachment_7_140P8422R0005_Changes_to_Provisions_and_Clauses_0002.pdf

SOLICITATION NO. 140P8422R0005

REPLACE FAILED SEPTIC TANK & DRAINFIELD SYSTEMS

PINNACLES NATIONAL PARK

AMENDMENT 0002

CHANGES TO SOLICITATION PROVISIONS AND CLAUSES

This document details changes to the provisions and clauses for any impacted sections of the solicitation.

Edits to existing clauses are noted in red text for clarity.

SECTION F

The following clause is changed:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than September 30, 2023. The time stated for completion shall include final cleanup of the premises.

(End of clause)

SECTION I

The following clause is deleted:

52.219-27 NOTICE OF SERVICE-DISABLED VETERAN-OWNED SMALL BUSINESS SET-ASIDE (SEP

2021)

The following clause is added:

52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (NOV 2021)

SECTION J

The list of attachments has been updated as follows:

B08_Attachment_3_140P8422R0005_Wage_Determination.pdf is replaced with:

B08_Attachment_3A_140P8422R0005_Wage_Determination_29July2022.pdf

B08_Solit_PSP_Vol_I_PastPerf.docx (found within B08_Attachment_4_Proposal_Submission_Package.pdf) is replaced with:

140P8422R0005, Changes to Solicitation Provisions and Clauses

B08_Solit_PSP_Vol_I_PastPerf_02Aug2022.docx (this replacement Past Performance Questionnaire form is provided with Amendment 0002 and simply updates the due date for proposals at the bottom of the form.)

SECTION L

The following provision is changed:

52.236-27 SITE VISIT (CONSTRUCTION) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for—

Tuesday, August 16, 2022, at 11:00 a.m. Pacific Daylight Time

(c) Participants will meet at— The parking lot in front of Pinnacles Visitor Center

5000 CA-146, Paicines, CA 95043

(d) RSVP Required

To participate in the site visit, send an email to the Contracting Officer at alanna_gardner@nps.gov with the following information:

Email title: “140P8422R0005, Request for Site Visit Participation”.

The email shall contain: The Name of the Participant, Company Name, Trade (ex. General

Contractor, Roofer, etc.) and phone number and email address of all participants.

You may also RSVP via telephone by calling the Contracting Officer at 415-858-9668 and providing the information listed above.

(e) COVID-19 Public Health Information

Any attendees of the site visit shall adhere to applicable social distancing guidelines as recommended by Centers for Disease Control and Prevention (CDC) at cdc.gov and conform to all current local government health orders and Park regulations. When required, participants shall provide their own personal protective equipment including facial coverings.

California State guidance can be found here: https://covid19.ca.gov/

San Benito County guidance can be found here: https://hhsa.cosb.us/public-health/covid-19/

(End of provision)

The following section is changed:

E. VOLUME I, TECHNICAL PROPOSAL – FORMAT, ORGANIZATION, CONTENTS

140P8422R0005, Changes to Solicitation Provisions and Clauses

SUBFACTOR 3B–SCHEDULE: Submit your proposed construction schedule for THIS SPECIFIC PROJECT showing completion within the required period of performance contained in this solicitation with accompanying schedule narrative. Submit your schedule in MS Project Gantt Chart or similar format; for evaluation purposes only assume a Notice to Proceed date of November 1, 2022 (for materials procurement and coordination with PG&E) and onsite construction work Notice to Proceed date of May 1, 2023; and include specific activities required for this project and a clear critical path with major milestones and applicable predecessor activities. In your accompanying narrative, explain schedule logic, critical path activities, and key considerations and constraints. There is no preprinted form for this submittal.

The following section is changed as noted below:

E. VOLUME I, TECHNICAL PROPOSAL – FORMAT, ORGANIZATION, CONTENTS,

SAM REGISTRATION AND SECTION K, REPRESENTATIONS, CERTIFICATIONS AND

PROVISIONS:

The following text is deleted:

SERVICE-DISABLED VETERAN-OWNED SMALL BUSINESS STATUS. For this acquisition, proposals are solicited only from Service-Disabled Veteran-Owned small business concerns. The small business size standard that applies to this acquisition is stated in Section K.1 (FAR 52.204-8, Annual Representations and Certifications), along with the North American Industry Classification System (NAICS) code on which it is based. The offeror’s Reps & Certs within their SAM profile will be used to verify whether or not the offeror is a small business concern under the NAICS code that applies to this acquisition and will be used to verify the offeror’s self-certification of its socio-economic status as a Service-Disabled Veteran-Owned small business concern.

The following text is added:

SMALL BUSINESS STATUS. For this acquisition, proposals are solicited only from small business concerns. The small business size standard that applies to this acquisition is stated in Section K.1 (FAR 52.204-8, Annual Representations and Certifications), along with the North American Industry Classification System (NAICS) code on which it is based. The offeror’s Reps & Certs within their SAM profile will be used to verify whether or not the offeror is a small business concern under the NAICS code that applies to this acquisition.

--END OF DOCUMENT--