B09_Amend03_Attach_ConstrClause_page_0003.pdf
PDF 113 KB Posted
- Attached to
- GRSM 158579/202623 - Look Rock Rehabilitation
- Solicitation number
- 140P2021R0007
About this file
This document provides details for a federal solicitation to rehabilitate the Look Rock Campground in the Great Smoky Mountains National Park. The solicitation number is 140P2021R0007 and seeks to repair and alter real property at the campground. Offerors must begin work within 10 days of receiving the notice to proceed and complete all work within 180 days, with liquidated damages of $1,482 per calendar day of delay. The solicitation is issued by the National Park Service on behalf of the Department of the Interior. It includes standard clauses on acceptance, liquidated damages, time extensions, and suspension of work.
View the file
Other files
Show all 27
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Solicitation 04/12/2021
Document No.
140P2021R0007
Document Title
GRSM 158579 / 202623 – Look Rock Campground Rehabilitation for Repair / Alteration of Real Property at Great Smoky Mountains National Park
(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.
(End of clause)
SECTION F – DELIVERIES OR PERFORMANCE
52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)
The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 180 Days after receipt of notice to proceed. The time stated for completion shall include final cleanup of the premises.
(End of clause)
52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)
(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,482.00 for each calendar day of delay until the work is completed or accepted.
(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.
(End of clause)
52.211-13 TIME EXTENSIONS (SEPT 2000)
Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.
(End of clause)
52.242-14 SUSPENSION OF WORK (APR 1984)
(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.
(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s
File details come from the government source that posted it. Updated .