Construction: Taylorsville High School Addition
Open State & local contract opportunity Posted
- Solicitation number
- DB27-011-RFP
- State
- Utah
- Responses due
Opportunity facts
- Jurisdiction
Opportunity details come from utah.bonfirehub.com. Updated .
About this opportunity
Granite School District is requesting proposals for a general contractor to build a new office wing, new classroom wing, new athletics wing, remodel existing classroom and office spaces, and make miscellaneous site improvements at Taylorsville High School, with proposals due November 19, 2026, and a mandatory pre-bid meeting and site tour on October 27, 2026 at 1:00 PM Mountain Time. Only respondents prequalified under DB27-009-RFSQ may respond, a restrictive eligibility gate.
The scope includes selective demolition, site improvements, fire protection and alarm system modifications, mechanical and electrical systems, communication and audio/visual systems, and installation of new Culinary Arts lab equipment. Construction is anticipated to commence in mid-December 2026 with Substantial Completion not later than July 9, 2029. The project manual requires a full-time Site Superintendent on-site whenever work is performed; both the Site Superintendent and Project Manager must pass background checks. Contractors must disclose all subcontractors with contract values of $50,000 or greater and provide a detailed construction schedule in Gantt chart format identifying work sequences, summer break activities, long lead items, and milestone dates, with scheduling to prioritize completion of the office wing and work during non-school periods to minimize disruption.
Evaluation is scored on a 100-point basis: Project Cost (80 points maximum, with the lowest cost response receiving 80 points and each successively higher response receiving three points less), Project Team (2 points), and Proposed Construction Schedule (18 points maximum). A Bid Bond is required for responses of $50,000 or greater. Award recommendation will be presented at the November 24, 2026 board meeting, with final award issued after board approval. Questions are due November 9, 2026 at 2:00 PM Mountain Time. Asbestos-containing materials have been identified throughout the facility and in relocatable units; GSD will abate identified asbestos prior to contractor work commencement.
Opportunity text
Issuing and Conducting Procurement Unit: Granite School District (GSD) The purpose of this Request for Proposals (RFP) is to enter into a contract to provide General Contractor for the construction of a new office wing, new classroom wing, new athletics wing, remodeling of existing classroom and office spaces, and miscellaneous site improvements at Taylorsville High School according to the attached Project Manual for Taylorsville High School Addition. It is anticipated that this RFP will result in a single contract award to the responsive and responsible vendor with the highest score justified by the procurement code. Please review Instructions to Respondents to know how scoring will occur for this Request for Proposal. Only Respondents that were prequalified in DB27-009-RFSQ may respond to this solicitation. Pre-Bid Meeting: Attendance is required - See Project Manual document for details. It is anticipated this expenditure will require GSD Board approval. Award recommendation will be presented at the 11/24/2026 board meeting. Final award will be issued after board approval is given.
Files
Show all 12
On GovTribe
Work this opportunity
- Track it in your pipeline
- Similar opportunities
- Ask GovTribe AI about this opportunity