2025 Roads Program
Open State & local contract opportunity Posted
- Solicitation number
- 26-07
- State
- New Jersey
- Responses due
Opportunity facts
- Jurisdiction
- Point of contact
-
- Sean Canning scanning@thecanninggroup.org (862) 228-3563
Opportunity details come from constructionbidsource.com. Updated .
About this opportunity
The Borough of Midland Park, Bergen County, New Jersey is requesting sealed bids for College Road Tennis Court Reconstruction, with bids due September 1, 2026 at 10:00 a.m. at the Municipal Building, 280 Godwin Avenue, Midland Park. This is a public works project subject to New Jersey prevailing wage requirements and the Public Works Contractor Registration Act.
The scope includes temporary removal and reinstallation of perimeter fence mesh and posts; milling of existing hot mix asphalt surface and intermediate courses to the gravel/dense-graded aggregate base while preserving the existing concrete perimeter curb; installation of new footings and net post sleeves; placement of DGA base course maintaining existing court slope with minimum 0.75% cross slope; placement of 2-inch HMA base course and 2-inch HMA surface course; flood testing and leveling to eliminate depressions; application of asphalt coating system with color and striping selected by the municipality; installation of new net posts and nets; and restoration of disturbed lawn areas with topsoil, seed, and mulch. Damaged fence materials must be replaced by the contractor at no additional cost.
Work must commence within 10 consecutive calendar days of award and be completed within 45 consecutive calendar days, with final completion no later than April 30, 2027. Liquidated damages range from $300 to $2,600 per calendar day for delays beyond the completion deadline. Bid security equals 10 percent of the total bid amount; the successful bidder must furnish Performance Bond and Labor and Material Bond each equal to 100 percent of contract amount, plus a one-year maintenance bond equal to 15 percent of contract amount. Plans and specifications are available from Borough Engineer Schwanewede Hals & Vince, 111 Littleton Road, Suite 200, Parsippany, New Jersey for a $125 non-refundable fee. Payment is made monthly upon Engineer approval with retainage of 10 percent for contracts of $100,000 or less, or 2 percent for contracts exceeding $100,000.
Opportunity text
4 versions
Update #4 · Latest ·
The Work of this Contract comprises the performance and completion of the entire Project within the time specified, including final cleaning up, the payment of all due obligations pertaining to the Project, and the replacing of defective work and materials, all in accordance with the Plans and Specifications. Unless otherwise specified, the Contractor shall furnish all materials, tools, plant, machinery, equipment, water, light, heat, fuel, power, labor, superintendence, transportation, temporary construction, and all other services and facilities of every nature whatsoever necessary to execute, complete and deliver to the Owner a functional and operating Project in accordance with the Contract Documents within the time specified, and the cost thereof shall be included in the prices bid for the various items scheduled in the Bid.
Update #3 ·
Atlantic City Municipal Utilities Authority (ACMUA), NJ is accepting bids for the Pacific Avenue Water Main Improvements Hartford Avenue To Arkansas Avenue And Indiana Avenue To North Carolina Avenue project.
Update #2 ·
Hauling and Recycling/Disposition of Leaves: The Contractor shall load and/or receive, transport, and lawfully deliver source-separated leaves collected by the Borough of Tenafly to an authorized leaf composting, recycling, or other facility legally authorized to receive such material. The receiving facility may be located within or outside the State of New Jersey, provided that the facility and transportation thereof comply with all applicable federal, New Jersey, receiving-state, county and local requirements, including N.J.S.A. 13:1E-99.21.
Update #1 ·
WORK TASKS 1. Temporary removal of all fence mesh and posts as needed for work access. The fence/mesh and posts shall be stored in a safe and secure location in order to prevent damage to the materials. 2. Mill existing HMA surface and intermediate courses (total of 4 average thickness) of existing tennis courts surface to existing gravel/DGA base. The existing concrete curb around the perimeter of the tennis courts is to remain. Care shall be taken to not damage the curb around the perimeter of the courts. 3. Install new footings and net post sleeves. 4. Place DGA base course as directed by the Engineer to grade subbase smooth. The existing slope of the courts is to be maintained. Courts to have minimum cross slope of 0.75%.. 5. Place 2 thick H.M.A. base course, and 2 thick H.M.A. surface course, including areas under perimeter fence mesh. 6. Flood courts to locate any depressions or puddles. Provide leveling coats to eliminate any depressions or puddles. 7. Apply complete asphalt coating system (color and color pattern selected by municipality) and line striping, after manufacturers required H.M.A. curing period. Include HMA areas under perimeter fence mesh. 8. Install existing fencing mesh and posts with all new hardware. Any damaged fence materials shall be replaced in kind by the Contractor at no additional expense to the Municipality. 9. Install new net posts and new nets. 10. Clean up the work area to the satisfaction of the Engineer and Municipality. All disturbed lawn areas are to be redressed with topsoil, seed, and mulch as directed by the Engineer.
Files
On GovTribe
Work this opportunity
- Track it in your pipeline
- Similar opportunities
- Ask GovTribe AI about this opportunity