BL057-26 Provision of Speed Humps on an Annual Contract

Gwinnett County Board of Commissioners issued Invitation to Bid BL057-26 for the provision, installation, marking, and repair of asphaltic speed humps on an annual contract basis for the Department of Transportation. The procurement seeks qualified contractors with documented experience in speed hump installation to perform work throughout Gwinnett County on an as-needed basis. The bid schedule includes approximately 200 speed hump installations annually, 25 linear feet of additional width installations, 10 changeable message signs per seven days, 50 pavement marking installations, 25 speed hump repairs per ramp, and 10 speed hump removals, with quantities subject to increase or decrease based on County needs. All materials must be sourced from Georgia Department of Transportation-certified suppliers and meet GDOT specifications, and all work must be completed within 30 business days of written notice, with liquidated damages of $250 per calendar day assessed for delays. Contractors must provide comprehensive general liability, automobile liability, workers' compensation, and umbrella/excess liability insurance with minimum A.M. Best ratings of A-7, submit a Code of Ethics affidavit and E-Verify compliance certification, and provide references from three similar projects completed within the last five years. Sealed bids are due by 2:50 p.m. on March 20, 2026, at Gwinnett County Financial Services-Purchasing Division, 75 Langley Drive, Lawrenceville, Georgia 30046, with virtual bid opening at 3:00 p.m. the same day. The contract term is one year from award with three one-year renewal options, pricing must remain firm for the initial term, and contractors may propose percentage increases or decreases for renewal periods.

The solicitation does not specify any set-aside designations or restrictions on respondent types, disadvantaged enterprise requirements, or incumbent vendor information. Award will be made to the lowest responsive and responsible bidder, and the County reserves the right to award to a single contractor or multiple contractors as deemed in its best interest. All work is guaranteed for one year after installation, and the County does not commit to full-time inspection during construction. Contractors are advised to visit work sites prior to bidding to familiarize themselves with site conditions. No bid bond is required, and specific budget or award values are not disclosed in the invitation materials.