MAHG23-1034 Repair Well 9

The Department of the Air Force Air Education and Training Command seeks a firm fixed-price contract for repair of Well 9 at Keesler Air Force Base, Mississippi, including replacement of the well casing, drop pipe, pump, instrumentation, chlorination, and fluoride injection systems, with proposals due July 17, 2026 at 9:00 AM CDT and questions due July 2, 2026 at 11:00 AM CDT. This is a Total Small Business set-aside (NAICS 238990). A mandatory site visit is scheduled for June 23, 2026 at 1:00 PM CDT at Keesler AFB; valid government-issued photo identification is required for base access.

Place of performance is Keesler Air Force Base, Building 3967, Mississippi (Building 4705 for inspection and acceptance). Performance must commence within 10 calendar days of award and complete within 365 calendar days (target award date August 10, 2026). The contractor shall furnish all equipment, labor, materials, and supervision; provide Critical Path Method scheduling with Gantt chart submissions; and submit a Material Submittal Schedule with pre-approval requirements for major equipment including Cummins Onan diesel generator (150 KW), automatic transfer switch (225A), water-lubricated turbine pump, chlorination equipment, concrete mix, steel rebars, and fuel tank (1,000-gallon). The contractor must comply with Davis-Bacon prevailing wage rates (Harrison County, Mississippi; wage range $10.91 to $35.50 per hour base plus fringe benefits up to $17.77 per hour), OSHA, Storm Water Pollution Prevention Plan for ground disturbance exceeding 5,000 square feet, asbestos and lead-based paint abatement with Mississippi state certification, and AFI 32-1062 and UFC 3-540-01 standards. Contractor personnel require base passes and airfield driving training where applicable.

Performance and payment bonds are 100% of contract price; bid guarantee is 20 percent. Liquidated damages are $300.42 for the first day of delay and $276.42 per day thereafter. Proposals are submitted electronically in three parts: price proposal (firm-fixed single line item), technical proposal (construction approach, schedule, quality control plan, materials list, key personnel), and past performance information (no more than five recent relevant contracts). Evaluation criteria are Price, Technical Proposal (Acceptable/Unacceptable), and Past Performance (Acceptable/Unacceptable). The contracting officer is Tiffany Aultman (ty.le@us.af.mil); the primary point of contact is A1C Ty Le (81CONS.PKA.Flight@us.af.mil). FAR and DFARS clauses apply, including Buy American construction materials requirements and wage determination compliance.