Carbonless Paper

Unicor, SV0227-26
Carbonless Paper
Solicitation posted on SAM.gov: 7/15/2026
Deadline for quotes: 7/31/2026
SOLICITATION: Issued as Request for Quote (RFQ) for a Firm-Fixed-Price, Definite Delivery-Definite Quantity type contract.
Set Aside: This solicitation is an 100% set-aside for small business.
Requirement: Federal Prison Industries (FPI) is seeking to purchase:
500,000 SETS of PCL0051
8.5 x 11
2 part reverse.
NCR - Carbonless paper
White/Canary
Delivered FBO Destination to:
Unicor
2300 County Road 29
Sandstone, MN, 55072
Questions for this solicitation will be addressed in writing to: wesley.newell2@usdoj.gov.
AWARD METHODOLOGY: This acquisition will be procured in accordance with FAR Part 12 – Acquisition of Commercial Items and Part 13 – Simplified Acquisition Procedures. The Government intends to evaluate quotes and award a contract that is the best overall value to the government, in accordance with FAR 52.212-1(g). Evaluation factors are price, quality, and past performance, and lead time.
The Government reserves the right to require the quoter to submit additional information or samples as necessary to support a pre-award determination of responsibility.
PERIOD OF PERFORMANCE: UNICOR’s desired delivery is as soon as possible. Vendors are required to provide their best delivery time for evaluation. Delivery schedule will be established at time of award.
OFFERS: Signed and dated offers are submitted by email to: wesley.newell2@usdoj.gov
The date and time for receipt of quotes is:
Friday, July 31, 2026, at 2:00 p.m. EASTERN STANDARD TIME (EST).
Do not send offers via U.S. mail. OMB Clearance 1103-0018.
Offer must indicate Solicitation No. SV0227-26, time specified for receipt of offer, name, address, telephone number of offeror, technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation, terms of any expressed warranty, price and any discount terms. Offer must include acknowledgment of all amendments, if any.
THE FOLLOWING INFORMATION IS REQUIRED TO BE COMPLETED BY THE OFFEROR:
SAM UNIQUE ENTITY IDENTIFIER (UEI): _______________________________________
VENDOR POINT OF CONTACT: _____________________________________
VENDOR TELEPHONE & FAX NUMBER: _____________________________
VENDOR EMAIL ADDRESS: ________________________________________
VENDOR BUSINESS SIZE FOR NAICS CODE 485991: Small Business (Y or N): _____________
By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a quote, during performance and through final payment of any contract resulting from this solicitation.
The Contracting Officer is Wesley Newell at wesley.newell2@usdoj.gov.
PART I: INFORMATION
This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued. The solicitation number is SV227-26 and this solicitation is issued as a Request For Quote (RFQ). The North American Industry Classification System code is 322120, Paper (small business size 1,250).
This solicitation should result in a Purchase Order. It will not be an ongoing contract.
NOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:
In the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Contracting Officer at UNICOR in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.
INVOICES ARE TO BE EMAILED TO:
Accounts.payable@usdoj.gov