W912P821B0042 Amendment 0001.pdf

TBD ED 20-004

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The subject Solicitation for Flood Control, Amite River and Tributaries Comite River Basin, Comite River Diversion Project, Channel Segment 2A, East Baton Rouge, Louisiana is hereby amended.

The solicitation closing date and time remain the same.

Please see Continuation Page, Block 14.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 13

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 26-Jul-2021

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912P821B0042

X 9B. DATED (SEE ITEM 11)

02-Jul-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

26-Jul-2021

CODE

USACE, CONTRACTING DIVISION

ATTN: CEMVN-CT, ROOM 172

7400 LEAKE AVE.

NEW ORLEANS LA 70118-3651

W912P8 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912P821B0042

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by reference:

52.243-4 Changes JUN 2007 52.249-10 Default (Fixed-Price Construction) APR 1984

The following have been added by full text:

AMENDMEND 001

The following changes have been made to the solicitation:

1. Blk 10 - Change Contractor question cut off from 20 JUL to 06 AUG 2021.

2. Deleted bid schedule in its entirety and added the revised bid schedule.

3. Deleted Wage Determination LA20210002 Rev 3. In its entirety and added Wage Determination LA20210002 Rev 4.

4 Delete Sheet Identification Nos. G-04, C-03 and C-09 through C-13 and added revised drawings of the same Sheet Identification Nos.

5. Contractor Questions Q1. How are bids to be submitted? Will the Government provide a DoD SAFE upload link? Or can bids be emailed?

A1. The bids will be submitted via DoD SAFE. Further instructions will be included in a forthcoming Amendment.

Q2. The bid opening date in the solicitation states 08.11.2021. The bid opening date on the advertisement page www.betasam.gov states 08.30.2021. Which one is correct?

A2. The bid opening date is 30 August 2021. The date in Block 13A has been updated.

Q3. Are contractors able to access the project site to evaluate existing conditions? If so, please provide access points. Will there be an official site visit scheduled for all bidders?

A03. The POC for site visits are as follows: Mr. Jules Boudreaux at jules.d.boudreaux@usace.army.mil or 504-862-2783 or Mr. Stephen Hinkamp at Stephen.b.hinkamp@usace.army.mil or 504-862-2268.

Q4. I was told previously that there would be an organized site visit. What date, time and location will this take place?

A4. The POC for site visits are as follows: Mr. Jules Boudreaux at jules.d.boudreaux@usace.army.mil or 504-862-2783 or Mr. Stephen Hinkamp at Stephen.b.hinkamp@usace.army.mil or 504-862-2268.

Q5. Since the Site Visit has not been announced nor occurred, please consider an extension to the deadline for RFI’s ( Q and A’s) for at least a few days after the Site Visit so that once potential bidders view the site, we will be allowed ample time to assimilate relevant questions subsequent to the Site Visit.

A5. The POC for site visits are as follows: Mr. Jules Boudreaux at jules.d.boudreaux@usace.army.mil or 504-862-2783 or Mr. Stephen Hinkamp at Stephen.b.hinkamp@usace.army.mil or 504-862-2268.

Q6. In Beta Sam, when you go to search for this project, it comes up and states the Bid Date is to be August 30, 2021. However, the Solicitation states the bid Date to be August 11, 2021. Which date is correct please?

A6. The bid opening date is 30 August 2021. The date in Block 13A has been updated.

Q7. On pages 12 and 13 of the solicitation Bid Items # 0023, 0024, and 0025 are listed in Units of “Ton Miles”. However, on the Bidding Schedule on page 17 of the Solicitation, those same items are listed as “Tons”, not Ton Miles. As those are 2 distinctively different units of measure, which is correct?

A7. The contract writing software does not provide Tons as a unit of measure. The bid schedule is correct.

Q8. In some USACE Projects, “Projent” is used as an avenue for Q and A’s. Are all Inquiries, Q and A’s, etc.to be directed to Ms. Pitre via email?

A8. Projnet will not be utilized for questions and answers. Please send all questions to Ms. Pitre at dorothy.j.pitre@usace.army.mil.

SECTION 00010 - SOLICITATION CONTRACT FORM

The required response date/time has changed from 11-Aug-2021 10:00 AM to 30-Aug-2021 10:00 AM.

The required performance has changed from Flood Control, Amite River and Tributaries, LA Comite River Basin, Comite River Diversional Project, Comite River DIversion Channel Reach 2A.DESCRIPTION AND MAGNITUDE OF WORK: The work consists of excavation of a segment of the Comite River Diversion channel, stockpiling of excavated earthen materials, placement of bedding material and channel riprap, clearing and grubbing, utility relocation, construction of access road, drainage, culverts, construction unwatering, and traffic control and coordination. The estimated time of completion is 578 calendar days after receipt of Notice to Proceed.The estimated magnitude is between $35,000,000.00 and $40,000,000.00.This procurement is a 100% Small Business Set-Aside.This will be a virtual bid opening. Bid opening call-in instructions will be provided via Amendment.The cut off date for Contractor questions is 20 July 2021 at 11:00 AM CST. to Flood Control, Amite River and Tributaries, LA Comite River Basin, Comite River Diversional Project, Comite River DIversion Channel Reach 2A.DESCRIPTION AND MAGNITUDE OF WORK: The work consists of excavation of a segment of the Comite River Diversion channel, stockpiling of excavated earthen materials, placement of bedding material and channel riprap, clearing and grubbing, utility relocation, construction of access road, drainage, culverts, construction unwatering, and traffic control and coordination. The estimated time of completion is 578 calendar days after receipt of Notice to Proceed.The estimated magnitude is between $35,000,000.00 and $40,000,000.00.This procurement is a 100% Small Business Set-Aside.This will be a virtual bid opening. Bid opening call-in instructions will be provided via Amendment.The cut off date for Contractor questions is 06 August 2021 at 11:00 AM CST..

The following have been modified:

BID SCHEDULE

SECTION 00010 – BIDDING SCHEDULE

Flood Control, Amite River and Tributaries, Louisiana, Comite River Basin, Comite River Diversion Project, Comite River Diversion Channel Reach 2A, East Baton Rouge Parish, Louisiana

Item Description Estimated Quantity

Unit Unit Price Estimated Amount

0001 Mobilization and Demobilization 1 JOB

0002 Safety Fence 1 JOB

Video and Photographic Documentation

1 JOB

0004 Traffic Control 1 JOB

0005 Silt Fences 7,665 LF

0006 Straw Bales 475 LF

0007 Truck Wash-Down Rack 1 JOB

0008* Channel Excavation 1,418,000 CY

0009 Drainage Ditch Excavation 30,675 CY

0010* Compacted Fill 186,525 CY

0011 Separator Geotextile 252,825 SY

Drainage Ditch Separator Geotextile

153 SY

0013 Clearing Areas 1 JOB

0014 Clearing and Grubbing Areas 1 JOB

0015 Construction Unwatering 1 JOB

0016 Grouted Riprap 9,300 CY

0017 Access Roads/Staging Areas 1 JOB

Turf Establishment and Maintenance

108 AC

0019 48” Reinforced Concrete Pipes 504 LF

0020 48" Concrete Headwall 2 EA

0021 48-Inch Corrugated Metal Pipes 1 JOB

0022 48" Aluminum Flap Gate 4 EA

0023* Bedding 63,000 TON

0024* Channel Riprap R-90 123,000 TON

0025 Drainage Ditch Riprap R-90 70 TON

*Indicates changes from the previous Bidding Schedule.

Award will be made as a whole to one bidder.

NOTE 1: The unit “Job” as used in this Bidding Schedule is synonymous with the term “Lump Sum” used elsewhere within these plans and specifications.

NOTE 2: Bidders shall furnish unit prices for all items listed on schedule of bid items, which require unit prices. If the bidder fails to insert a unit price in the appropriate blank for required items but does furnish an extended total or an estimated amount for such items, the Government will deem his unit price to be the quotient obtained by dividing the extended estimated amount for that line item by the quantity. IF THE BIDDER OMITS

BOTH THE UNIT PRICE AND THE EXTENDED ESTIMATED AMOUNT FOR ANY

REQUIRED ITEM, HIS BID WILL BE DECLARED NON-RESPONSIVE.

NOTE 3: THE NOTICE TO PROCEED (NTP): The successful bidder is advised that performance and payment bonds shall be submitted in accordance with the time frame in block 12B of SF 1442 after Notice of Award. The NTP will be issued immediately after verification of acceptable performance and payment bonds. Within 7 days after issuance of the NTP, the Contractor shall initiate a meeting to discuss the submittal process with the Area or Resident Engineer or his authorized representative. Physical work cannot start until the Accident Prevention Program, Contractor Quality Control Plan, and other submittals which may be required, have been submitted and approved and all preliminary meetings called for under the contract, have been conducted.

NOTE 4: Any bid may be rejected if the Contracting Officer determines in writing that it is unreasonable as to price. Unreasonableness of price includes not only total price of bid, but the price for individual line items as well. Any bid may be rejected if the prices for any line items or subline items are materially unbalanced (See FAR 14.404-2).

NOTE 5: RAPID VENDOR PAYMENT: Web based instructions for the submission of invoices;

http://www.mvn.usace.army.mil/BusinessWithUs/Contracting/RapidVendorPayment.aspx

SECTION 00700 - CONTRACT CLAUSES

The following have been added by full text:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 578 calendar days after the date of receipt by him of the notice to proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $3,665.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 20% percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by surveys.

(b) Weather conditions. Data on weather conditions may be obtained from the National Weather Service.

(c) Transportation facilities. The Contractor can access the site from the south and north via public Highway 964.

The Contractor shall coordinate with the Highway 964 Contractor for maintaining roadways and traffic control. No impacts to construction will be allowed for any coordination required between the different Contractors working in the area.

(d) The Contractor is responsible for keeping streets free of mud, tracking, spillage and/or other surface pollution from his equipment and operations. Contractor shall take whatever means required (i.e., street cleaners, manual labor, water trucks with sprayers) as often as needed to maintain clean streets near the work site. All debris resulting from street cleaning operations shall be hauled off-site and disposed of properly.

(e) Estimates of quantities involved in certain items of work for which bids are being solicited on a lump sum or job basis have been made for the use of the Government. Copies of these quantity estimates may be viewed or obtained by contacting the U.S. Army Engineer District, New Orleans, Corps of Engineers, Attention: Contracting Officer, CEMVN-CT, 7400 Leake Ave, New Orleans, Louisiana 70118-3651. It is expressly understood that the accuracy of these estimates is in no way warranted and that the furnishing of this information to a bidder will not relieve him of his responsibility to estimate the quantities involved.

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor's right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

52.236-16 QUANTITY SURVEYS (APR 1984)

(a) Quantity surveys shall be conducted, and the data derived from these surveys shall be used in computing the quantities of work performed and the actual construction completed and in place.

(b) The Government shall conduct the original and final surveys and make the computations based on them. The Contractor shall conduct the surveys for any periods for which progress payments are requested and shall make the computations based on these surveys. All surveys conducted by the Contractor shall be conducted under the direction of a representative of the Contracting Officer, unless the Contracting Officer waives this requirement in a specific instance.

(c) Promptly upon completing a survey, the Contractor shall furnish the originals of all field notes and all other records relating to the survey or to the layout of the work to the Contracting Officer, who shall use them as necessary to determine the amount of progress payments. The Contractor shall retain copies of all such material furnished to the Contracting Officer.

52.236-17 LAYOUT OF WORK (APR 1984)

The Contractor shall lay out its work from Government established base lines and bench marks indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at its own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting Officer. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through its negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor.

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

Title File Drawing No.

Flood Control, Amite River H-16-48249 G-01 thru G-04 and Tributaries, Louisiana C-01 thru C-16 Comite River Basin, Comite B-01 thru B- 04 Project River Diversion Project, RD-01 thru RD-05 Comite River Diversion Channel Reach 2A, East Baton Rouge Parish, Louisiana

252.236-7004 PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (DEC 1991)

(a) The Government will pay all costs for the mobilization and demobilization of all of the Contractor's plant and equipment at the contract lump sum price for this item.

(1) 60% percent of the lump sum price upon completion of the contractor's mobilization at the work site.

(2) The remaining 40% percent upon completion of demobilization.

(b) The Contracting Officer may require the Contractor to furnish cost data to justify this portion of the bid if the Contracting Officer believes that the percentages in paragraphs (a) (1) and (2) of this clause do not bear a reasonable relation to the cost of the work in this contract.

(1) Failure to justify such price to the satisfaction of the Contracting Officer will result in payment, as determined by the Contracting Officer, of --

(i) Actual mobilization costs at completion of mobilization;

(ii) Actual demobilization costs at completion of demobilization; and

(iii) The remainder of this item in the final payment under this contract.

(2) The Contracting Officer's determination of the actual costs in paragraph (b)(1) of this clause is not subject to appeal.

The following have been modified:

WAGE DETERMINATION

"General Decision Number: LA20210002 07/23/2021

Superseded General Decision Number: LA20200002

State: Louisiana

Construction Type: Heavy

Counties: Acadia, Ascension, Bossier, Caddo, Calcasieu, East Baton Rouge, Lafayette, Lafourche, Livingston, Ouachita, Rapides, St Landry, St Martin, Terrebonne, Webster and West Baton Rouge Counties in Louisiana.

HEAVY CONSTRUCTION PROJECTS (includes flood control, water &sewer lines, and water wells; excludes elevated storage tanks,industrial construction-chemical processing, power plants, and refineries) Note: Under Executive Order (EO) 13658, an hourly minimum wageof $10.95 for calendar year 2021 applies to all contractssubject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.95 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2021. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, thecontractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate). The EO minimum wage ratewill be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/01/2021 1 01/08/2021 2 02/05/2021 3 03/12/2021 4 07/23/2021

CARP1098-004 07/01/2014

ASCENSION, EAST BATON ROUGE, LIVINGSTON AND WEST BATON ROUGE

PARISHES

Rates Fringes

CARPENTER

(formbuilding/formsetting).......$ 26.16 8.39

CARP1098-014 07/01/2014

CALCASIEU PARISH

Rates Fringes

CARPENTER

(formbuilding/formsetting).......$ 26.16 6.80

CARP1098-015 07/01/2014

ACADIA, LAFAYETTE, ST. LANDRY AND ST. MARTIN PARISHES

Rates Fringes

CARPENTER

(formbuilding/formsetting).......$ 26.16 5.60

CARP1098-016 07/01/2014

BOSSIER, CADDO, OUACHITA, RAPIDES AND WEBSTER PARISHES

Rates Fringes

CARPENTER

(formbuilding/formsetting).......$ 20.80 6.80

* CARP1846-008 07/01/2021

LAFOURCHE and TERREBONNE PARISHES Rates Fringes

CARPENTER

(formbuilding/formsetting).......$ 28.29 9.97

ELEC0130-009 11/30/2020

LAFOURCHE AND TERREBONNE PARISHES

Rates Fringes

ELECTRICIAN......................$ 31.65 13.13

ELEC0194-007 09/07/2020

BOSSIER, CADDO, and WEBSTER PARISHES Rates Fringes

ELECTRICIAN

Lineman and Heavy Equipment Operator..........$ 28.95 12.82

ELEC0446-007 03/01/2021

OUACHITA PARISH

Rates Fringes

ELECTRICIAN......................$ 25.40 1%+12.71

ELEC0576-006 09/01/2020

RAPIDES PARISH

Rates Fringes

ELECTRICIAN......................$ 25.30 4.25%+8.40

ELEC0861-006 01/01/2021

ACADIA, CALCASIEU, LAFAYETTE, AND ST. MARTIN PARISHES

Rates Fringes

ELECTRICIAN......................$ 28.58 4.34%+12.70

ELEC0995-006 01/01/2021

ASCENSION, EAST BATON ROUGE, LIVINGSTON, ST. LANDRY, AND WEST

BATON ROUGE PARISHES

Rates Fringes

ELECTRICIAN......................$ 27.03 11.49

SULA2004-006 04/29/2004

Rates Fringes CARPENTER (all other work).......$ 12.81 0.00 Cement Mason/Concrete Finisher...$ 13.77 0.00 Laborers Common......................$ 8.20 0.00 Pipelayer...................$ 9.45 0.00 Power Equipment Operators Backhoe/Excavator...........$ 13.01 0.00 Bulldozer...................$ 13.83 0.00 Crane.......................$ 16.62 3.28 Dragline....................$ 15.16 0.00 Front End Loader............$ 11.50 0.00 Motor Grader/Blade..........$ 11.75 0.00 Oiler.......................$ 8.59 2.50 Trackhoe....................$ 12.64 0.00 Water Well Driller..........$ 11.91 2.44 Winch.......................$ 11.38 0.00 Truck Driver, Dump...............$ 10.25 0.00 WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on whichthese classifications and rates are based. The next number, 007in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completiondate for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for theclassifications was union data. EXAMPLE: UAVG-OH- 001008/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 inthe example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January ofeach year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION"

The following have been deleted:

CONTRACT CLAUSES

(End of Summary of Changes)