Solicitation Amendment - W912HZ26QA0100001.pdf
PDF 3 MB Posted
- Attached to
- Dredge Material Placement Model Supplies Federal contract opportunity
- Solicitation number
- W912HZ26QA010
About this file
This is a Solicitation Amendment (W912HZ26QA0100001) issued by the U.S. Army Engineer Research and Development Center (ERDC), Coastal Hydraulics Laboratory (CHL), clarifying requirements for Dredge Material Placement Model Supplies in response to vendor questions. The amendment revises line item descriptions and corresponding specifications for CLINs 0001, 0002, 0025, 0026, 0027, 0028, and 0029, and includes a track-changed version of the Description of Requirement and Solicitation Q&A document. The solicitation is a Request for Quote (RFQ) issued January 14, 2026, with an offer due date of January 30, 2026, at 2:00 PM local time. This acquisition is set-aside for 100 percent small business concerns under NAICS code 332510 (metal pipe and tube manufacturing), with a firm fixed price arrangement for all line items.
The solicitation includes 41 line items comprising stainless steel fittings and pipes, aggregate, rebar, concrete, concrete forms and accessories, anchor bolts, scaffold brackets, turnbuckles, waler clamps, pipe braces, form ties, form cages, geogrid, and PVC pipe. Quantities range from 2 to 2,850 units depending on the item, with delivery required within 30 calendar days from the lead time event (15 days for aggregate). All items are to be delivered to the U.S. Engineer Research and Development Center in Vicksburg, Mississippi, with the contractor bearing transportation costs (FOB Destination). The Government reserves the right to award without discussions to the lowest priced, technically acceptable offeror. In accordance with the nonmanufacturer rule, offerors must certify that a minimum of 50 percent of total items proposed are manufactured by small business concerns. Invoices must be submitted via email within 45 days after final delivery.
View the file
Other files for this federal contract opportunity
| File | Type | Posted |
|---|---|---|
| B08.03 Vendor Q&A for RFQ Amendment 1.23.26.docx | DOCX document | |
| Solicitation Amendment W912HZ26QA0100001 SF 30.pdf | ||
| Description of Requirement for Amendment 0001.pdf | ||
| W912HZ26QA010 Amendment 0001 Description of Requirement Revised for Amendment - Track Changes.docx | DOCX document | |
| Solicitation - W912HZ26QA010 Attachment Description of Requirement.pdf | ||
| A02.09 BNJ_Dredge Material Placement Model Supplies_Redacted.pdf | ||
| Solicitation W912HZ26QA010.pdf |
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
WOMEN-OWNED SMALL
BUSINESS (WOSB)
SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES
1. REQUISITION NUMBER PAGE 1 OF
2. CONTRACT NUMBER 3. AWARD/EFFECTIVE
DATE
4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE
DATE
7. FOR SOLICITATION
INFORMATION CALL:
a. NAME b. TELEPHONE NUMBER (No collect 8. OFFER DUE DATE/
LOCAL TIME
9. ISSUED BY
13b. RATING
14. METHOD OF SOLICITATION
CODE
15. DELIVER TO 16. ADMINISTERED BY CODE
18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/
OFFEROR
CODE
FACILITY
CODE
CODE
TELEPHONE NUMBER
17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN
OFFER
18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK
BELOW IS CHECKED
REQUEST
FOR QUOTE
(RFQ)
INVITATION
FOR BID
(IFB)
REQUEST
FOR
PROPOSAL
(RFP)
SEE ADDENDUM
19.
ITEM NUMBER
20.
SCHEDULE OF SUPPLIES/SERVICES
21.
QUANTITY
22.
UNIT
23.
UNIT PRICE
24.
AMOUNT
(Use Reverse and/or Attach Additional Sheets as Necessary)
25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)
28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN
COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH
AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND
ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS
SPECIFIED
29. AWARD OF CONTRACT: REFERENCE OFFER
DATED . . YOUR OFFER ON SOLICITATION
(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE
SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:
30a. SIGNATURE OF OFFEROR/CONTRACTOR
30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED
31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)
31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED
AUTHORIZED FOR LOCAL REPRODUCTION
PREVIOUS EDITION IS NOT USABLE
STANDARD FORM 1449 (REV. 11/2021)
Prescribed by GSA - FAR (48 CFR) 53.212
10. THIS ACQUISITION IS UNRESTRICTED OR
NORTH AMERICAN
INDUSTRY CLASSIFICATION
STANDARD (NAICS):
SIZE STANDARD:
13a. THIS CONTRACT IS A
RATED ORDER UNDER
THE DEFENSE PRIORITIES
AND ALLOCATIONS
SYSTEM - DPAS (15 CFR 700)
SET ASIDE: % FOR:
11. DELIVERY FOR FREE ON
BOARD (FOB) DESTINATION
UNLESS BLOCK IS MARKED
SEE SCHEDULE
12. DISCOUNT TERMS
ARE ARE NOT ATTACHED
ARE ARE NOT ATTACHED
27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3
AND 52.212-5 ARE ATTACHED. ADDENDA
27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA
8(A)
ECONOMICALLY
DISADVANTAGED
WOMEN-OWNED SMALL
BUSINESS (EDWOSB)
SERVICE-DISABLED
VETERAN-OWNED
SMALL BUSINESS
(SDVOSB)
HUBZONE SMALL
BUSINESS
SMALL BUSINESS
NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.
calls)
Solicitation/Contract Form Continuation
Dredge Material Placement Model SuppliesInstrument Name:
W912HZ26QA0100001
Continuation of Supplies or Services and Prices/Costs
Additional Information/Notes
Item Supplies/Service Quantity Unit Unit Price
Amount
0001 24" 90-degree fitting, stainless SCH 40; 304L welded. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
1 Each
0002 24" Stainless pipe SCH 40; 304L 20' welded. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
1 Each
Option Line Item
#610 Aggregate Tons. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
1,200 Actual Tons
Option Line Item
#5 Grade 60 rebar (20 LF). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
2,850 Each
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
Option Line Item
#7 Grade 60 rebar (20 LF). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
75 Each
Option Line Item
4500 PSI CONC (CY). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
650 Cubic Yard
Option Line Item
Sika Swellstop 1in x 3/4in 100' carton. Brand Name Only. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
12 Each
Option Line Item
Sika Swellstop Primer Adhesive 1 gal. Brand Name Only. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
10 Gallon
Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
Option Line Item
Concrete Form 24INX8FT S/P PANEL. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
200 Each
Option Line Item
Concrete Form 22INX8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
2 Each
Option Line Item
Concrete Form 20INX8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
2 Each
Option Line Item
Concrete Form 18INX8FT S/P FILLER. All costs, including shipping, to meet the specifications
8 Each
0012 in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
Option Line Item
Concrete Form 16INX8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
8 Each
Option Line Item
Concrete Form 14IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
8 Each
Option Line Item
Concrete Form 12IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
2 Each
Option 2 Each
Line Item
Concrete Form 10IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
Option Line Item
Concrete Form 8IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
2 Each
Option Line Item
Concrete Form 6IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
2 Each
Option Line Item
Concrete Form 4IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E
2 Each
Pricing Arrangement: Firm Fixed Price
Option Line Item
Concrete Form 2INX8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
4 Each
Option Line Item
Concrete Form 1INX8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
4 Each
Option Line Item
Concrete Form 6IN X 8FT INSIDE CORNER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
4 Each
Option Line Item
Concrete Form 8FT S/P OUTSIDE CORNER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
4 Each
Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
Option Line Item
Concrete Form 8FT S/P FILLER ANGLE. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
12 Each
Option Line Item
Concrete Anchor WEDGE BOLT 3-3 /4" x 1-3/8". All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
1,500 Each
Option Line Item
Concrete Anchor LONG BOLT 4-1 /4" x 1-3/8". All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
50 Each
Option Line Item
S/P RIGID SCAFFOLD BRKT.
Scaffold Bracket has a Safe Working Load of 400 lbs. (4:1 Safety Factor).
100 Each
0027 All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
Option Line Item
TURNBUCKLE STRAIGHT PLATE.
Concrete Turnbuckle Form Aligner - Adjustable Wall Brace. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
30 Each
Option Line Item
1 PC WALER CLAMP. One-Piece Waler Clamp - Concrete Form Brackets - Compatible with Symons Forms - 5 Gauge Steel. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
100 Each
Option Line Item
UP1 PIPE BRACE 7' TO 13'6. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E
20 Each
Pricing Arrangement: Firm Fixed Price
Option Line Item
12" X-FLAT TIE. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
1,500 Each
Option Line Item
8FT FORM CAGE - CRANE PICK.
All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
8 Each
Option Line Item
#610 aggregate (Tons). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
350 Actual Tons
Option Line Item
4500 PSI CONC. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
60 Cubic Yard
Option
Item
#5 Grade 60 rebar (20ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
250 Each
Option Line Item
#7 Grade 60 rebar (20ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
125 Each
Option Line Item
Tensar InterAxTM Foundation NXFTM Geogrid (square yards).
Brand Name Only. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
2,500 Square Yard
Option Line Item
18 PVC SDR26 HW SWR PIPE (G),
($/ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
1,000 Each
Item
18 N12 F2648 STIB SOLID 20'
DUAL WALL 18850020DW ($/ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
1,000 Each
Option Line Item
24 PVC SDR26 HW SWR PIPE (G)
($/ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
1,000 Each
Option Line Item
24 N12 F2648 STIB SOLID 20'
DUAL WALL 24850020DW ($/ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.
Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price
1,000 Each
Continuation of Description
Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0003 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0004 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0005 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0006 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0007 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0008 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0009 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0010 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0011 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0012 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0013 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0014 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0015 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0016 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0017 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0018 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0019 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0020 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0021
North American Industry Classification System (NAICS) : 332510
Option Line Item 0022 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0023 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0024 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0025 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0026 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0027 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0028 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0029 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0030 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0031 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0032
North American Industry Classification System (NAICS) : 332510
Option Line Item 0033 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0034 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0035 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0036 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0037 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0038 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0039 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0040 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Option Line Item 0041 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510
Continuation of Packaging and Marking
Continuation of Inspection and Acceptance
Overall Contract Inspection/Acceptance Locations
0001 Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
0002 Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Option Line Item
Inspection and Acceptance Location
Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD
VICKSBURG, MS 39180-6199
UNITED STATES
Continuation of Deliveries or Performance
AWARD TO SUCCESSFUL OFFEROR
Only a Warranted Contracting Officer, acting within his/her delegated limits, has the authority to issue modifications or otherwise change the terms and conditions of this Contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this Contract, you shall not proceed with the change and shall immediately notify the Contracting Officer.
POINTS OF CONTACT
VENDOR POC:
TBD
DELIVERY POC EMAIL: chl-acq-shippingnotification@usace.army.mil
INVOICING INSTRUCTIONS
(1) A proper invoice must be in accordance with FAR 32.905 (b)(1).
(2) Submit invoice via email to: CEERD-CHLInvoicing@usace.army.mil.
To avoid delay in payment, a copy must also be sent to the COR/TPOC.
(3) If more than one invoice is required, the contractor's final invoice shall be Submitted within 45 days after the final period of performance date specified in the contract. The invoice must be clearly marked "final" and submitted as outlined above.
*** END OF NARRATIVE 1 ***
0001 Delivery Schedule From date of lead time event to delivery 30 Calendar Days
W912HZ26QA0100001
mailto:chl-acq-shippingnotification@usace.army.mil mailto:CEERD-CHLInvoicing@usace.army.mil
Date of Award 1 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
0002 Delivery Schedule From date of lead time event to delivery 30 Calendar Days
Date of Award 1 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes
FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 15 Calendar Days
CLIN Only - Date of Option Exercised 1,200 Actual TonsQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 2,850 EachQuantity
Address and POC Ship To
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 75 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 650 Cubic YardQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 12 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 10 GallonQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 200 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 2 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 2 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 8 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 8 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Delivery Schedule
From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 8 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 2 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 2 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 2 EachQuantity
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 2 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 2 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 4 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 4 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Delivery Schedule
From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 4 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 4 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 12 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 1,500 EachQuantity
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 50 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 100 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 30 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 100 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Delivery Schedule
From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 20 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 1,500 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 8 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 350 Actual TonsQuantity
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 60 Cubic YardQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 250 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 125 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 2,500 Square YardQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Delivery Schedule
From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 1,000 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 1,000 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 1,000 EachQuantity
Address and POC Ship To DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Option Line Item
Delivery Schedule From date of lead time event to delivery 30 Calendar Days
CLIN Only - Date of Option Exercised 1,000 EachQuantity
DoDAAC: W912HZ CountryCode: USA
W2R2 USA ENGR R&D CTR
ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS
39180-6199 UNITED STATES
DELIVER_TO_EMP_ID_NO
Special Handling/Notes FoB Details
Party to Pay Transportation Cost: Contractor
Point Type: Destination
Continuation of Accounting and Appropriation Data
Contract Clauses
FAR Clauses Incorporated by Reference
Number Title Effective Date
Alternate Deviation
Variation Effective Date
52.203-3 Gratuities. 1984-04
52.204-13 System for Award Management Maintenance.
2018-10
52.204-18 Commercial and Government Entity Code Maintenance.
2020-08
52.212-4 Contract Terms and Conditions- Commercial Products and Commercial Services.
2023-11
52.219-33 Nonmanufacturer Rule. 2021-09
52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving.
2024-05
DFARS Clauses Incorporated by Reference
Number Title Effective Date
Alternate Deviation
Variation Effective Date
252.203-7000 Requirements Relating to Compensation of Former DoD Officials.
2011-09
252.203-7002 Requirement to Inform Employees of Whistleblower Rights.
2022-12
252.204…
This is the start of the file's text. The full file is on GovTribe.
File details come from the government source that posted it. Updated .