Solicitation W912HZ26QA010.pdf

PDF 3 MB Posted

Attached to
Dredge Material Placement Model Supplies Federal contract opportunity
Solicitation number
W912HZ26QA010
Issued by
Department of the Army Corps of Engineers Engineer Research and Development Center

About this file

Written by GovTribe AI ·

This is a solicitation (Request for Quote) for Dredge Material Placement Model Supplies, issued by the U.S. Army Engineer Research and Development Center (ERDC), Coastal Hydraulics Laboratory. The solicitation (W912HZ26QA010) is set aside exclusively for small businesses and seeks various construction and engineering materials, including stainless steel pipe fittings, rebar, concrete, geogrid, PVC pipes, and associated construction supplies. The total quantity spans multiple line items, with quantities ranging from 2 to 2,850 units per item type.

Key solicitation details include an offer due date of 28 January 2026 at 2:00 PM, with a planned single purchase order award. The procurement uses a lowest-priced technically acceptable evaluation methodology, with offerors required to submit detailed technical descriptions and certify that a minimum of 50% of proposed items are manufactured by small business concerns. Delivery locations are specified as the ERDC Contracting Office in Vicksburg, Mississippi, with most items having a 30-calendar day delivery schedule. The solicitation uses firm fixed pricing and covers multiple option line items for various construction and engineering materials needed for a dredge material placement model project.

View the file

Other files for this federal contract opportunity

Other files attached to Dredge Material Placement Model Supplies, newest first.
File Type Posted
Solicitation Amendment - W912HZ26QA0100001.pdf PDF
Solicitation Amendment W912HZ26QA0100001 SF 30.pdf PDF
Description of Requirement for Amendment 0001.pdf PDF
W912HZ26QA010 Amendment 0001 Description of Requirement Revised for Amendment - Track Changes.docx DOCX document
B08.03 Vendor Q&A for RFQ Amendment 1.23.26.docx DOCX document
Solicitation - W912HZ26QA010 Attachment Description of Requirement.pdf PDF
A02.09 BNJ_Dredge Material Placement Model Supplies_Redacted.pdf PDF

On GovTribe

Work with this file on GovTribe

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file
Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

WOMEN-OWNED SMALL

BUSINESS (WOSB)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NUMBER 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect 8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NUMBER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

REQUEST

FOR QUOTE

(RFQ)

INVITATION

FOR BID

(IFB)

REQUEST

FOR

PROPOSAL

(RFP)

SEE ADDENDUM

19.

ITEM NUMBER

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH

AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND

ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS

SPECIFIED

29. AWARD OF CONTRACT: REFERENCE OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NORTH AMERICAN

INDUSTRY CLASSIFICATION

STANDARD (NAICS):

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

THE DEFENSE PRIORITIES

AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FREE ON

BOARD (FOB) DESTINATION

UNLESS BLOCK IS MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3

AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

8(A)

ECONOMICALLY

DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.

calls)

Solicitation/Contract Form Continuation

Dredge Material Placement Model SuppliesInstrument Name:

W912HZ26QA010

Continuation of Supplies or Services and Prices/Costs

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price

Amount

0001 24" 90-degree fitting, stainless SCH 40; 304L. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

1 Each

0002 24" Stainless pipe SCH 40; 304L 20'. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

#610 Aggregate Tons. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

1,200 Actual Tons

Option Line Item

#5 Grade 60 rebar (20 LF). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

2,850 Each

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

Option Line Item

#7 Grade 60 rebar (20 LF). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

75 Each

Option Line Item

4500 PSI CONC (CY). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

650 Cubic Yard

Option Line Item

Sika Swellstop 1in x 3/4in 100' carton. Brand Name Only. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

12 Each

Option Line Item

Sika Swellstop Primer Adhesive 1 gal. Brand Name Only. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

10 Gallon

Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

Option Line Item

Concrete Form 24INX8FT S/P PANEL. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

200 Each

Option Line Item

Concrete Form 22INX8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

2 Each

Option Line Item

Concrete Form 20INX8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

2 Each

Option Line Item

Concrete Form 18INX8FT S/P FILLER. All costs, including shipping, to meet the specifications

8 Each

0012 in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

Option Line Item

Concrete Form 16INX8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

8 Each

Option Line Item

Concrete Form 14IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

8 Each

Option Line Item

Concrete Form 12IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

2 Each

Option 2 Each

Line Item

Concrete Form 10IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

Option Line Item

Concrete Form 8IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

2 Each

Option Line Item

Concrete Form 6IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

2 Each

Option Line Item

Concrete Form 4IN X 8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E

2 Each

Pricing Arrangement: Firm Fixed Price

Option Line Item

Concrete Form 2INX8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

4 Each

Option Line Item

Concrete Form 1INX8FT S/P FILLER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

4 Each

Option Line Item

Concrete Form 6IN X 8FT INSIDE CORNER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

4 Each

Option Line Item

Concrete Form 8FT S/P OUTSIDE CORNER. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

4 Each

Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

Option Line Item

Concrete Form 8FT S/P FILLER ANGLE. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

12 Each

Option Line Item

Concrete Anchor WEDGE BOLT. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

1,500 Each

Option Line Item

Concrete Anchor LONG BOLT. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

50 Each

Option Line Item

S/P RIGID SCAFFOLD BRKT. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

100 Each

Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

Option Line Item

TURNBUCKLE STRAIGHT PLATE.

All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

30 Each

Option Line Item

1 PC WALER CLAMP. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

100 Each

Option Line Item

UP1 PIPE BRACE 7' TO 13'6. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

20 Each

Option Line Item

12" X-FLAT TIE. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement

1,500 Each

Claimant Program Code: C9E

Price

Option Line Item

8FT FORM CAGE - CRANE PICK.

All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

8 Each

Option Line Item

#610 aggregate (Tons). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

350 Actual Tons

Option Line Item

4500 PSI CONC. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

60 Cubic Yard

Option Line Item

#5 Grade 60 rebar (20ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E

250 Each

Price

Option Line Item

#7 Grade 60 rebar (20ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

125 Each

Option Line Item

Tensar InterAxTM Foundation NXFTM Geogrid (square yards).

Brand Name Only. All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

2,500 Square Yard

Option Line Item

18 PVC SDR26 HW SWR PIPE (G),

($/ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

1,000 Each

Option Line Item

18 N12 F2648 STIB SOLID 20'

DUAL WALL 18850020DW ($/ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

1,000 Each

Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

Option Line Item

24 PVC SDR26 HW SWR PIPE (G)

($/ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

1,000 Each

Option Line Item

24 N12 F2648 STIB SOLID 20'

DUAL WALL 24850020DW ($/ft). All costs, including shipping, to meet the specifications in the Description of Requirement attachment.

Part Number Description: Itemized in Description of Requirement Claimant Program Code: C9E Pricing Arrangement: Firm Fixed Price

1,000 Each

Continuation of Description

Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0003 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0004 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0005 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0006 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0007 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0008 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0009 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0010 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0011 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0012 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0013 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0014 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0015 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0016 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0017 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0018 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0019 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0020 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0021

North American Industry Classification System (NAICS) : 332510

Option Line Item 0022 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0023 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0024 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0025 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0026 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0027 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0028 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0029 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0030 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0031 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0032

North American Industry Classification System (NAICS) : 332510

Option Line Item 0033 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0034 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0035 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0036 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0037 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0038 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0039 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0040 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Option Line Item 0041 Product Service Code : 5340 North American Industry Classification System (NAICS) : 332510

Continuation of Packaging and Marking

Continuation of Inspection and Acceptance

Overall Contract Inspection/Acceptance Locations

0001 Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

0002 Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option

Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Instructions: Refer to the Description of Requirement for Inspection/Acceptance locations and criteria

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD

VICKSBURG, MS 39180-6199

UNITED STATES

Continuation of Deliveries or Performance

AWARD TO SUCCESSFUL OFFEROR

Only a Warranted Contracting Officer, acting within his/her delegated limits, has the authority to issue modifications or otherwise change the terms and conditions of this Contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this Contract, you shall not proceed with the change and shall immediately notify the Contracting Officer.

POINTS OF CONTACT

VENDOR POC:

TBD

DELIVERY POC EMAIL: chl-acq-shippingnotification@usace.army.mil

INVOICING INSTRUCTIONS

(1) A proper invoice must be in accordance with FAR 32.905 (b)(1).

(2) Submit invoice via email to: CEERD-CHLInvoicing@usace.army.mil.

To avoid delay in payment, a copy must also be sent to the COR/TPOC.

(3) If more than one invoice is required, the contractor's final invoice shall be Submitted within 45 days after the final period of performance date specified in the contract. The invoice must be clearly marked "final" and submitted as outlined above.

*** END OF NARRATIVE 1 ***

0001 Delivery Schedule From date of lead time event to delivery 30 Calendar Days

W912HZ26QA010

mailto:chl-acq-shippingnotification@usace.army.mil mailto:CEERD-CHLInvoicing@usace.army.mil

Date of Award 1 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0002 Delivery Schedule From date of lead time event to delivery 30 Calendar Days

Date of Award 1 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes

FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 15 Calendar Days

CLIN Only - Date of Option Exercised 1,200 Actual TonsQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 2,850 EachQuantity

Address and POC Ship To

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 75 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 650 Cubic YardQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 12 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 10 GallonQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 200 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 2 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 2 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 8 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 8 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Delivery Schedule

From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 8 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 2 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 2 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 2 EachQuantity

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 2 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 2 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 4 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 4 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Delivery Schedule

From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 4 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 4 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 12 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 1,500 EachQuantity

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 50 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 100 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 30 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 100 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Delivery Schedule

From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 20 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 1,500 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 8 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 350 Actual TonsQuantity

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 60 Cubic YardQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 250 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 125 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 2,500 Square YardQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Delivery Schedule

From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 1,000 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 1,000 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 1,000 EachQuantity

Address and POC Ship To DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Option Line Item

Delivery Schedule From date of lead time event to delivery 30 Calendar Days

CLIN Only - Date of Option Exercised 1,000 EachQuantity

DoDAAC: W912HZ CountryCode: USA

W2R2 USA ENGR R&D CTR

ERDC CONTRACTING OFC, 3909 HALLS FERRY ROAD VICKSBURG, MS

39180-6199 UNITED STATES

DELIVER_TO_EMP_ID_NO

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Continuation of Accounting and Appropriation Data

Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.203-3 Gratuities. 1984-04

52.204-13 System for Award Management Maintenance.

2018-10

52.204-18 Commercial and Government Entity Code Maintenance.

2020-08

52.212-4 Contract Terms and Conditions- Commercial Products and Commercial Services.

2023-11

52.219-33 Nonmanufacturer Rule. 2021-09

52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving.

2024-05

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials.

2011-09

252.203-7002 Requirement to Inform Employees of Whistleblower Rights.

2022-12

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

2023-01

252.223-7008 Prohibition of Hexavalent Chromium. 2023-01

252.225-7012 Preference for Certain Domestic Commodities.

2022-04

252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime.

2023-01

252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region.

2023-06

252.232-7003 Electronic Submission of Payment…

This is the start of the file's text. The full file is on GovTribe.

File details come from the government source that posted it. Updated .