amd9.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

CONSTRUCTION OF DISSOLVED OXYGEN INJECTION SYSTEMS AS PART OF THE SAVANNAH HARBOR EXPANSION PROJECT

Per revisions addressed in this amendment, ( see SF 30 continuation page) please revise and resubmit Factor 3 – Summary Schedule of your proposal and pricing. Please utilize most recent conformed solicitation section 00010 to submit revised pricing. Please submit your complete response by 2:00 local time, May 27, 2015. Submissions shall be submitted electronically via ARMDEC SAFE. Instructions for how to submit in ARMDEC SAFE can be found in the solicitation.

Title the file in the follow ing format:

W912HN-13-R-0018_COMPANY NAME_ AMENDMENTRESPONSE

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 08-May-2015

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912HN-13-R-0018

X 9B. DATED (SEE ITEM 11)

01-Oct-2014

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

08-May-2015

CODE

U.S. ARMY ENGINEER DISTRICT, SAVANNAH

100 WEST OGLETHORPE AVE

SAVANNAH GA 31401-3640

W912HN 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912HN-13-R-0018

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

CHANGES

A. CONTRACT CHANGES: The following information has been revised:

Section 00100 paragraph 6.2.1,

6.2.1 Proposed Contract Duration: The maximum allowed duration is 820 calendar days from issuance of Notice to Proceed (NTP). However, the maximum allowed construction duration for the Lower DO System at Hutchinson Island is 450 days after issuance of NTP. The maximum allowed construction duration for the Upper DO System at the McIntosh DO Plant is 820 days after issuance of NTP. The Government may take into account how well the summary schedule supports the duration, as well as use other information, such as but not limited to, independent judgment concerning logic, constraints and typical construction durations. An offer which proposes contract duration longer than the maximum allowed duration will not be accepted by the Government.

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 820 calendar days from issuance of Notice to Proceed (NTP).* The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $10,699.81 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

B. TECHNICAL SPECIFICATION CHANGES: None

C. CONTRACT DRAWINGS: None