Attch_10_Price_Schedule_Site_13580_14Apr2016.pdf

ISRAEL

TASK Description Column A Column B Column C Job Base Bid Construction

All work as required for the construction of the Base Bid Task as described in the solicitation documents.

Period of Performance and Liquated Damages are identified for each Task

0001 CONSTRUCTION OF OPERATIONAL FACILITY $________ $________ $________ $________

Construction including all required utilities and infrastructure as described in the solicitation documents for the following: ten (10) aircraft hangars (Hangars #1-5 and #7- 11), two (2) aircraft support buildings: one staff and one technical building (Support Buildings 300 and 400), three (3) equipment sheds (Equipment Sheds 610, 631, and 632), and a maintenance station (Maintenance Station 800). Upgrades and new construction of existing roadways and parking lots are also included.

Period of Performance: All work shall be completed within 548 calendar days after the Notice to Proceed (NTP).

Liquidated Damages: If the Contractor fails to complete the base bid work within the base bid period of performance, the Contractor shall pay Liquidated Damages to the Government in the amount of $7,349 for each calendar day of delay until the work is completed or accepted.

TOTAL PRICE BASE BID $________ $________ $________ $________

Optional Construction

0002 OPTION 1 - CONSTRUCTION OF WESTERN RUNWAY $________ $________ $________ $________

Construction to extend the existing western runway and construction of a new western taxiway (apron) connecting from western runway to the facilities as described in the solicitation documents.

Period of Performance: Option 1 work shall be completed within 90 calendar days after the award date of the option.

Reference is made to the clauses in this solicitation implementing the U.S. Government International Balance of Payments Program (IBOP) and to U.S. Government policies concerning Off-Shore Procurement (OSP), including Federal Acquisition Regulation (FAR), part 25 and Department of Defense FAR Supplement (DFARS), Part 225. Offerors are advised that a waiver of OSP requirements will not be available for this procurement. Accordingly, at least 51% of the dollar value of this contract, exclusive of the cost of bulk materials, or other items that the FAR or DFARS exclude from Buy American considerations, must be of U.S. origin. Please note that this is different from the rules governing projects under the Wye River Program.

In addition, notwithstanding the status of Israel as a designated country under IBOP, no Israeli content will be allowed on this contract except bulk materials (such as sand, gravel, or other soil material, plant materials, stone, cement or cement products, concrete masonry units or fired brick and other materials as listed in the OSP worksheet), materials described in the "Direction on Israeli Content - Other Bulk Items" and other items specifically authorized for purchase in Israel either in the contract specifications or by express written authorization of the Contracting Officer (not ACO or COR). Labor to deliver and install bulk or other exempted materials is likewise allowed to be Israeli content. If it is determined that the Contractor under this solicitation has used unauthorized Israeli content, payments to the Contractor may be reduced by the value of the unauthorized Israeli content or at the Government's option, the Contractor may be required to remove the unauthorized content and replace it with authorized content.

Contractors participating in this solicitation must be U.S. firms or joint ventures of U.S. firms. Offers from non- U.S. firms will be rejected. Israeli subcontractors and Israeli labor may be used for work associated with exempted materials.

PRICE SCHEDULE

PROJECT 13580

The Offeror shall provide pricing for all base and option bid tasks. Provide completion of all construction of awarded items from Notice to Proceed (NTP) as described in the FAR Clause 52.211-10 "COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK" according to the following schedule. The total Period of Performance of the Base Bid Tasks and Option Tasks if awarded, are identified in the Price Schedule below. The contractor shall have the project fully functional and available for normal, regular use no later than the end date of the period of performance. See FAR Clause 52.211-12 for liquidated damages. Liquidated damages apply to the completion date specified in the contract or BID Schedule including interim completion dates for individual facilities. The Government reserves the right to exercise any and all options no later than 120 calendar days from the date of award.

7-Apr-16

In addition, Offerors shall complete the OSP Worksheet for this project.

The above OSP provisions are incorporated into the contract resulting from this solicitation.

Offerors shall provide their price in the following categories:

Column A: FAR/DFAR exempted materials (Reference FAR 25.104) Column B: Residual non-exempt IBOP foreign content

Job: Total price for bid item.

Column C: US content

Solicitation W912GB-16-R-0030 Site 13580 - Israel (Attachment 10)

Liquidated Damages: If the Contractor fails to complete the Option 1 work within 90 calendar days of the option award date, the Contractor shall pay Liquidated Damages to the Government in the amount of $6,482 for each calendar day of delay until the work is completed or accepted.

0003 OPTION 2 - CONSTRUCTION OF EASTERN TAXIWAY $________ $________ $________ $________

Construction of a new eastern taxiway (apron) connecting from western runway to existing eastern runwayas described in the solicitation documents.

Period of Performance: Option 2 work shall be completed within 90 calendar days after NTP for the option. NTP for Option 2 will not be issued until the Option 1 work has been completed and accepted by the government.

Liquidated Damages: If the Contractor fails to complete the Option 2 work within 90 calendar days of the option award date, the Contractor shall pay Liquidated Damages to the Government in the amount of $6,482 for each calendar day of delay until the work is completed or accepted.

0004 OPTION 3 - CONSTRUCTION OF FUEL STATION 700 $________ $________ $________ $________

Construction of a new fuel station including all required utilities and infrastructure as described in the solicitation documents.

Period of Performance: The Option 3 work shall be completed within the base period of performance.

Liquidated Damages: If the Contractor fails to complete the Option 3 work within the base bid construction period of performance, the Contractor shall pay Liquidated Damages to the Government in the amount of $7,349 for each calendar day of delay until the work is completed or accepted.

0005 OPTION 4 - CONSTRUCTION OF STORAGE BUILDING 500 $________ $________ $________ $________

Construction of a new storage building including all required utilities and infrastructure as described in the solicitation documents.

Period of Performance: The Option 4 work shall be completed within the base period of performance.

Liquidated Damages: If the Contractor fails to complete the Option 4 work within the base bid construction period of performance, the Contractor shall pay Liquidated Damages to the Government in the amount of $7,349 for each calendar day of delay until the work is completed or accepted.

0006 OPTION 5 - CONSTRUCTION OF ADDITIONAL HANGARS $________ $________ $________ $________

Construction of two additional hangars (Hangars #6 and #12) including all required utilities and infrastructure as described in the solicitation documents.

Period of Performance: The Option 5 work shall be completed within the base period of performance.

Liquidated Damages: If the Contractor fails to complete the Option 5 work within the base bid construction period of performance, the Contractor shall pay Liquidated Damages to the Government in the amount of $7,349 for each calendar day of delay until the work is completed or accepted.

0007 OPTION 6 - INSTALLATION OF HANGAR GATES $________ $________ $________ $________

Installation of twelve (12) aircraft hangar gates including all required utilities and infrastructure as described in the solicitation documents.

Period of Performance: The Option 6 work shall be completed within the base period of performance.

Liquidated Damages: If the Contractor fails to complete the Option 6 work within the base bid construction period of performance, the Contractor shall pay Liquidated Damages to the Government in the amount of $7,349 for each calendar day of delay until the work is completed or accepted.

TOTAL PRICE OPTIONS BID $________ $________ $________ $________

TOTAL PRICE BASE AND OPTIONS BID $________ $________ $________ $________

NOTE: Base and Option Liquidated Damages will not be assessed twice. Total Government Liquidated Damages will not exceed $7,349 per calendar day.

Solicitation W912GB-16-R-0030

Columns A, B and C are intended for Government use only. These items are not for bidding purposes or Task’s and are only evaluated for compliance with OSP requirements.

The cost of Defense Base Act (DBA) Insurance premiums are____ / are not____ included in our proposal. Mark as appropriate.

End of Bid Schedule

Solicitation W912GB-16-R-0030