W912ES22B0009_SPECS.pdf

SOLICITATION NO. W912ES22B0009

UPPER MISSISSIPPI RIVER

LOCKS 3 & 4

MITER GATE SUPPLY

MINNESOTA & WISCONSIN

FABRICATION

DOCUMENTS

FOR

June 2024

US Army Corps of Engineers Saint Paul, MN

CODE

(Hour)

PAGE(S)

until local t ime

X

A X B

C D

EX

X G F

179 - 197

198 - 208 X H 209

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA FAR (48 CFR) 53.214(c)

1 209

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

W912ES 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and 1 copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

8 - 11

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT

PACKAGING AND MARKING

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

12 - 14

15 - 20 X K REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 21 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 22 - 26 X M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIO NS AND INSTRUCTIO NS

PART III - LIST O F DO CUMENTS, EXHIBITS AND O THER ATTACHMENTS

27 - 177

PART II - CO NTRACT CLAUSES

CONTRACTING DIVISION

USACE - ST PAUL

332 MINNESOTA STREET

SUITE E1500

SAINT PAUL MN 55101

651-290-5414

FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.5. DATE ISSUED4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

W912ES22B0009 06/18/2024 W81G6741514242

(See Bid Submission Instructions - Section L) 2:00 PM 23 July 2024

W912ES22B0009

TABLE OF CONTENTS

TABLE OF CONTENTS

SECTION B - SUPPLIES OR SERVICES AND PRICES

BID SCHEDULE

SECTION E - INSPECTION AND ACCEPTANCE

52.246-2 INSPECTION OF SUPPLIES--FIXED-PRICE (AUG 1996)

52.246-16 RESPONSIBILITY FOR SUPPLIES (APR 1984)

SECTION F - DELIVERIES OR PERFORMANCE

52.211-8 TIME OF DELIVERY. (JUN 1997) -- ALTERNATE I (APR 1984)

52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

52.246-15 CERTIFICATE OF CONFORMANCE (APR 1984)

52.247-34 F.O.B. DESTINATION (NOV 1991)

252.246-7005 NOTICE OF WARRANTY TRACKING OF SERIALIZED ITEMS (MAR 2016)

252.246-7006 WARRANTY TRACKING OF SERIALIZED ITEMS (MAR 2016)

SECTION G - CONTRACT ADMINISTRATION DATA

252.204-7006 BILLING INSTRUCTIONS—COST VOUCHERS (MAY 2023)

SECTION H - SPECIAL CONTRACT REQUIREMENTS

ALL OR NONE QUALIFICATIONS

PARTNERING

BIDDER'S QUALIFICATIONS

WORK PERFORMED BY THE CONTRACTOR

REQUIREMENT FOR BID GUARANTEE

BASIS FOR SETTLEMENT OF PROPOSALS

APPARENT CLERICAL MISTAKES

EPA DESIGNATED (CPG)

SAFER CHOICE

BIO-BASED

ANTI-TERRORISM / OPERATIONS SECURITY (AT/OPSEC)

GENERAL SECURITY REQUIREMENTS AND GUIDANCE:

FOR CONTRACTORS WHO DO NOT REQUIRE CAC, BUT REQUIRE ACCESS TO A DOD FACILITY OR INSTALLATION. .. 24 WILL BE ESCORTED IN AREAS WHERE THEY MAY BE EXPOSED TO CLASSIFIED AND/OR SENSITIVE MATERIALS

AND/OR SENSITIVE OR RESTRICTED AREAS

SUSPICIOUS ACTIVITY REPORTING TRAINING (E.G. IWATCH, CORPSWATCH, OR SEE SOMETHING, SAY SOMETHING)

PRE-SCREEN CANDIDATES USING E-VERIFY PROGRAM

VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

SAFETY AND HEALTH REQUIREMENTS MANUAL INTERIM CHANGES, EM 385-1-1

FLOATING PLANT EQUIPMENT

OBSTRUCTION OF CHANNEL

SIGNAL LIGHTS

RADIO

LABORATORY AND TESTING FACILITIES

SECTION I - CONTRACT CLAUSES

52.202-1 DEFINITIONS (JUN 2020)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (JUN 2020)

52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY (MAY

2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (JUN 2020)

52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (NOV 2021)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS (NOV 2023)

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS OR STATEMENTS

(JAN 2017)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS (JUN 2020)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (AUG 2020)

52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS (NOV 2021) 52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES DEVELOPED OR

PROVIDED BY KASPERSKY LAB COVERED ENTITIES (DEC 2023)

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE

SERVICES OR EQUIPMENT (NOV 2021)

52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUN 2023)

52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH CONTRACTORS

DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (NOV 2021)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018).. 51 52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS. (NOV 2015)

52.210-1 MARKET RESEARCH (NOV 2021)

52.211-5 MATERIAL REQUIREMENTS (AUG 2000)

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

52.214-26 AUDIT AND RECORDS--SEALED BIDDING (JUN 2020)

52.214-27 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA—MODIFICATIONS—SEALED

BIDDING (DEVIATION 2022-O0001) (OCT 2021)

52.214-28 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA—MODIFICATIONS—SEALED BIDDING

(DEVIATION 2022-O0001) (OCT 2021)

52.214-29 ORDER OF PRECEDENCE--SEALED BIDDING (JAN 1986)

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (NOV 2020)

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (FEB 2024)

52.219-14 LIMITATIONS ON SUBCONTRACTING (DEVIATION 2021-O0008) (FEB 2023)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (SEP 2023)

52.222-3 CONVICT LABOR (JUN 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS - OVERTIME COMPENSATION (MAY 2018) 52.222-19 CHILD LABOR—COOPERATION WITH AUTHORITIES AND REMEDIES (DEVIATION 2020-O0019) (NOV

2023)

52.222-20 CONTRACTS FOR MATERIALS, SUPPLIES, ARTICLES, AND EQUIPMENT (JUN 2020)

52.222-21 PROHIBITION OF SEGREGATED FACILITIES (APR 2015)

52.222-26 EQUAL OPPORTUNITY (SEPT 2016)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUN 2020)

52.222-37 EMPLOYMENT REPORTS ON VETERANS (JUN 2020)

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS ACT (DEC 2010)

52.222-50 COMBATING TRAFFICKING IN PERSONS (NOV 2021)

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (NOV 2021)

52.223-11 OZONE-DEPLETING SUBSTANCES AND HIGH GLOBAL WARMING POTENTIAL

HYDROFLUOROCARBONS (MAY 2024)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (FEB 2021)

52.226-7 DRUG-FREE WORKPLACE (MAY 2024)

52.226-8 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING (MAY 2024)

52.227-1 AUTHORIZATION AND CONSENT (JUN 2020)

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JUN 2020)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-11 INDIVIDUAL SURETY—PLEDGE OF ASSETS (FEB 2021) (DEVIATION 2020-O0016)

52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (DEC 2022)

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.228-16 PERFORMANCE AND PAYMENT BONDS-OTHER THAN CONSTRUCTION (APR 2020) (DEVIATION 2020- O0016)

52.228-17 INDIVIDUAL SURETY--PLEDGE OF ASSETS (BID GUARANTEE) (FEB 2021)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013)

52.232-1 PAYMENTS (APR 1984)

52.232-8 DISCOUNTS FOR PROMPT PAYMENT (FEB 2002)

52.232-11 EXTRAS (APR 1984)

52.232-9 LIMITATION ON WITHHOLDING OF PAYMENTS (APR 1984)

52.232-16 PROGRESS PAYMENTS (NOV 2021)

52.232-17 INTEREST (MAY 2014)

52.232-23 ASSIGNMENT OF CLAIMS (MAY 2-14) - ALTERNATE I (APR 1984)

52.232-25 PROMPT PAYMENT (JAN 2017)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER—SYSTEM FOR AWARD MANAGEMENT (OCT 2018) .. 105

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (MAR 2023)

52.233-1 DISPUTES. (MAY 2014)

52.233-3 PROTEST AFTER AWARD (AUG. 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.242-2 PRODUCTION PROGRESS REPORTS (APR 1991)

52.242-13 BANKRUPTCY (JUL 1995)

52.243-1 CHANGES--FIXED-PRICE (AUG 1987)

52.244-6 SUBCONTRACTS FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (FEB 2024)

52.246-18 WARRANTY OF SUPPLIES OF A COMPLEX NATURE (MAY 2001) - ALTERNATE IV (APR 1984)

52.246-24 LIMITATION OF LIABILITY--HIGH-VALUE ITEMS (FEB 1997)

52.247-68 REPORT OF SHIPMENT (REPSHIP) (FEB 2006)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (APR 2012)

52.249-8 DEFAULT (FIXED-PRICE SUPPLY AND SERVICE) (APR 1984)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (NOV 2020)

52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

252.201-7000 CONTRACTING OFFICER'S REPRESENTATIVE (DEC 1991)

252.203-7000 REQUIREMENTS RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (SEP 2011) 252.203-7001 PROHIBITION ON PERSONS CONVICTED OF FRAUD OR OTHER DEFENSE-CONTRACT-RELATED

FELONIES (JAN 2023)

252.203-7002 REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (DEC 2022)

252.203-7003 AGENCY OFFICE OF THE INSPECTOR GENERAL (AUG 2019)

252.203-7004 DISPLAY OF HOTLINE POSTERS (JAN 2023)

252.204-7003 CONTROL OF GOVERNMENT PERSONNEL WORK PRODUCT (APR 1992)

252.204-7012 SAFEGUARDING COVERED DEFENSE INFORMATION AND CYBER INCIDENT REPORTING (MAY 2024) 252.204-7015 NOTICE OF AUTHORIZED DISCLOSURE OF INFORMATION FOR LITIGATION SUPPORT (JAN 2023) . 128 252.204-7018 PROHIBITION ON THE ACQUISITION OF COVERED DEFENSE TELECOMMUNICATIONS EQUIPMENT

OR SERVICES (JAN 2023)

252.204-7020 NIST SP 800-171 DOD ASSESSMENT REQUIREMENTS (NOV 2023)

252.205-7000 PROVISION OF INFORMATION TO COOPERATIVE AGREEMENT HOLDERS (JUN 2023) 252.209-7004 SUBCONTRACTING WITH FIRMS THAT ARE OWNED OR CONTROLLED BY THE GOVERNMENT OF A

COUNTRY THAT IS A STATE SPONSOR OF TERRORISM (MAY 2019)

252.211-7003 ITEM UNIQUE IDENTIFICATION AND VALUATION (MAR 2016)

252.211-7008 USE OF GOVERNMENT-ASSIGNED SERIAL NUMBERS (SEP 2010)

252.216-7001 ECONOMIC PRICE ADJUSTMENT--NONSTANDARD STEEL ITEMS (JAN 2023)

252.223-7006 PROHIBITION ON STORAGE, TREATMENT, AND DISPOSAL OF TOXIC OR HAZARDOUS MATERIALS--

BASIC (SEP 2014)

252.223-7008 PROHIBITION OF HEXAVALENT CHROMIUM (JAN 2023)

252.225-7001 BUY AMERICAN AND BALANCE OF PAYMENTS PROGRAM--BASIC (FEB 2024)

252.225-7002 QUALIFYING COUNTRY SOURCES AS SUBCONTRACTORS (MAR 2022)

252.225-7008 RESTRICTION ON ACQUISITION OF SPECIALTY METALS (MAR 2013)

252.225-7012 PREFERENCE FOR CERTAIN DOMESTIC COMMODITIES (APR 2022)

252.225-7030 RESTRICTION ON ACQUISITION OF CARBON, ALLOY, AND ARMOR STEEL

PLATE (DEC 2006)

252.225-7048 EXPORT-CONTROLLED ITEMS (JUNE 2013)

252.225-7056 PROHIBITION REGARDING BUSINESS OPERATIONS WITH THE MADURO REGIME (JAN 2023) 252.225-7058 POSTAWARD DISCLOSURE OF EMPLOYMENT OF INDIVIDUALS WHO WORK IN THE PEOPLE'S

REPUBLIC OF CHINA (JAN 2023)

252.225-7060 PROHIBITION ON CERTAIN PROCUREMENTS FROM THE XINJIANG UYGHUR AUTONOMOUS REGION

(JUN 2023)

252.226-7001 UTILIZATION OF INDIAN ORGANIZATIONS, INDIAN-OWNED ECONOMIC ENTERPRISES, AND NATIVE

HAWAIIAN SMALL BUSINESS CONCERNS (JAN 2023)

252.227-7013 RIGHTS IN TECHNICAL DATA--OTHER THAN COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

(MAR 2023)

252.227-7016 RIGHTS IN BID OR PROPOSAL INFORMATION (JAN 2023)

252.227-7030 TECHNICAL DATA--WITHHOLDING OF PAYMENT (MAR 2000)

252.227-7037 VALIDATION OF RESTRICTIVE MARKINGS ON TECHNICAL DATA (JAN 2023)

252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS (DEC 2018)

252.232-7004 DOD PROGRESS PAYMENT RATES (OCT 2014)

252.232-7010 LEVIES ON CONTRACT PAYMENTS (DEC 2006)

252.232-7017 ACCELERATING PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS--PROHIBITION ON FEES AND

CONSIDERATION (APR 2020)

252.243-7001 PRICING OF CONTRACT MODIFICATIONS (DEC 1991)

252.243-7002 REQUESTS FOR EQUITABLE ADJUSTMENT (DEC 2022)

252.244-7000 SUBCONTRACTS FOR COMMERCIAL PRODUCTS OR COMMERCIAL SERVICES (NOV 2023)

252.247-7023 TRANSPORTATION OF SUPPLIES BY SEA (JAN 2023)

5152.211-9001 VARIATIONS IN ESTIMATED QUANTITIES — SUBLINE ITEMS (DEC 2019)

SECTION J – LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION K - REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2023)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014) 52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES

OR EQUIPMENT (NOV 2021)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

52.209-12 CERTIFICATION REGARDING TAX MATTERS (OCT 2020)

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS--CERTIFICATION (NOV 2021) 252.203-7005 REPRESENTATION RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (SEP 2022)

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (NOV 2023)

252.204-7008 COMPLIANCE WITH SAFEGUARDING COVERED DEFENSE INFORMATION CONTROLS (OCT 2016) . 189 252.204-7017 PROHIBITION ON THE ACQUISITION OF COVERED DEFENSE TELECOMMUNICATIONS EQUIPMENT

OR SERVICES--REPRESENTATION (MAY 2021)

252.204-7019 NOTICE OF NIST SP 800-171 DOD ASSESSMENT REQUIREMENTS (NOV 2023)

252.216-7007 ECONOMIC PRICE ADJUSTMENT--BASIC STEEL, ALUMINUM, BRASS, BRONZE, OR COPPER MILL

PRODUCTS--REPRESENTATION (MAR 2012)

252.225-7050 DISCLOSURE OF OWNERSHIP OR CONTROL BY THE GOVERNMENT OF A COUNTRY THAT IS A STATE

SPONSOR OF TERRORISM (DEC 2022)

252.225-7055 REPRESENTATION REGARDING BUSINESS OPERATIONS WITH THE MADURO REGIME (MAY 2022) 252.225-7057 PREAWARD DISCLOSURE OF EMPLOYMENT OF INDIVIDUALS WHO WORK IN THE PEOPLE'S

REPUBLIC OF CHINA (AUG 2022)

252.225-7059 PROHIBITION ON CERTAIN PROCUREMENTS FROM THE XINJIANG UYGHUR AUTONOMOUS REGION

- REPRESENTATION (JUN 2023)

252.227-7017 IDENTIFICATION AND ASSERTION OF USE, RELEASE, OR DISCLOSURE RESTRICTIONS. (JAN 2023)

SECTION L - INSTRUCTIONS, CONDITIONS AND NOTICES TO BIDDERS

BID SUBMITTAL INSTRUCTIONS

52.204-7 SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (AUG 2020)

52.204-22 ALTERNATIVE LINE ITEM PROPOSAL (JAN 2017)

52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS (DEC 2016)

52.214-4 FALSE STATEMENTS IN BIDS (APR 1984)

52.214-5 SUBMISSION OF BIDS (DEC 2016)

52.214-6 EXPLANATION TO PROSPECTIVE BIDDERS (APR 1984)

52.214-7 LATE SUBMISSIONS, MODIFICATIONS, AND WITHDRAWALS OF BIDS (NOV 1999)

52.214-10 CONTRACT AWARD--SEALED BIDDING (JUL 1990)

52.214-12 PREPARATION OF BIDS (APR 1984)

52.214-34 SUBMISSION OF OFFERS IN THE ENGLISH LANGUAGE (APR 1991)

52.214-35 SUBMISSION OF OFFERS IN U.S. CURRENCY (APR 1991)

52.216-1 TYPE OF CONTRACT (APR 1984)

52.214-16 MINIMUM BID ACCEPTANCE PERIOD (APR 1984)

52.222-24 PREAWARD ON-SITE EQUAL OPPORTUNITY COMPLIANCE EVALUATION (FEB 1999)

52.228-1 BID GUARANTEE (SEP 1996)

52.233-2 SERVICE OF PROTEST (SEP 2006)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

252.217-7026 IDENTIFICATION OF SOURCES OF SUPPLY. (NOV 1995)

5152.211-9000 EVALUATION OF SUBLINE ITEMS (DEC 2019)

SECTION M - EVALUATION FACTORS FOR AWARD

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

SECTION B - SUPPLIES OR SERVICES AND PRICES

BID SCHEDULE

Item Description Quantity Unit of

Measure Unit Price Amount

Base Items

Bonds (Performance and Payment) 1 JOB $ $

Lock 4 Upstream Miter Gate Assembly (20' High) 1 JOB $ $

Lock 4 Downstream Miter Gate Assembly (23' High) 1 JOB $ $

Delivery of Lock 4 Miter Gate Assemblies 1 JOB $ $

Barge Demurrage for Lock 4 Miter Gate Assemblies $

0005AA First 30 Days 30 DAY $ $

0005AB Each Additional Day 120 DAY $ $

Lock 4 Disposal of Existing Upstream Miter Gate Assembly (20' High) 1 JOB $ $

Lock 4 Disposal of Existing Downstream Miter Gate Assembly (23' High) 1 JOB $ $

Anchorage Assembly for Lock 3 Miter Gates 8 EACH $ $

Anchorage Assembly for Lock 4 Miter Gates 16 EACH $ $

TOTAL BASE: $ -

Option Items

Option 1

Bonds (Performance and Payment) 1 JOB $ $

Lock 3 Upstream Miter Gate Assembly (25' High) 1 JOB $ $

Lock 3 Downstream Miter Gate Assembly (30' High) 1 JOB $ $

Delivery of Lock 3 Miter Gate Assemblies 1 JOB $ $

Barge Demurrage for Lock 3 Miter Gate Assemblies $

1005AA First 30 Days 30 DAY $ $

1005AB Each Additional Day 120 DAY $ $

Lock 3 Disposal of Existing Upstream Miter Gate Assembly (25' High) 1 JOB $ $

Lock 3 Disposal of Existing Downstream Miter Gate Assembly (30' High) 1 JOB $ $

TOTAL OPTION 1: $ -

Option 2

Bonds (Performance and Payment) 1 JOB $ $

Strut Arm Assembly for Lock 3 Miter Gates 4 EACH $ $

TOTAL OPTION 2: $ -

Option 3

Bonds (Performance and Payment) 1 JOB $ $

Strut Arm Assembly for Lock 4 Miter Gates 4 EACH $ $

TOTAL OPTION 3: $ -

Option 4

Bonds (Performance and Payment) 1 JOB $ $

Long Term Storage for Lock 3 Miter Gates 180 DAY $ $

TOTAL OPTION 4: $ -

Option 5

Bonds (Performance and Payment) 1 JOB $ $

Long Term Storage for Lock 4 Miter Gates 180 DAY $ $

TOTAL OPTION 5: $ -

Option 6

Bonds (Performance and Payment) 1 JOB $ $

6002 Spare Strut Arm Assembly 4 EACH $ $

TOTAL OPTION 6: $ -

Option 7

Bonds (Performance and Payment) 1 JOB $ $

7002 Spare Strut Arm Assembly 4 EACH $ $

TOTAL OPTION 7: $ -

Option 8

Bonds (Performance and Payment) 1 JOB $ $

8002 Spare Strut Arm Assembly 4 EACH $ $

TOTAL OPTION 8: $ -

Option 9

Bonds (Performance and Payment) 1 JOB $ $

9002 Spare Strut Arm Assembly 4 EACH $ $

TOTAL OPTION 9: $ -

Option 10

Bonds (Performance and Payment) 1 JOB $ $

9004 Spare Strut Arm Assembly 4 EACH $ $

TOTAL OPTION 10:

Option 11

Bonds (Performance and Payment) 1 JOB $ $

9006 Spare Strut Arm Assembly 4 EACH $ $

TOTAL OPTION 11: $ -

Option 12

Bonds (Performance and Payment) 1 JOB $ $

Spare Spanner Wrench for Strut Arm Assembly 2 EACH $ $

TOTAL OPTION 12: $ -

TOTAL

BASE

PLUS ALL

OPTIONS:

SECTION E - INSPECTION AND ACCEPTANCE

52.246-2 INSPECTION OF SUPPLIES--FIXED-PRICE (AUG 1996)

(a) Definition. "Supplies," as used in this clause, includes but is not limited to raw materials, components, intermediate assemblies, end products, and lots of supplies.

(b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering supplies under this contract and shall tender to the Government for acceptance only supplies that have been inspected in accordance with the inspection system and have been found by the Contractor to be in conformity with contract requirements. As part of the system, the Contractor shall prepare records evidencing all inspections made under the system and the outcome. These records shall be kept complete and made available to the Government during contract performance and for as long afterwards as the contract requires. The Government may perform reviews and evaluations as reasonably necessary to ascertain compliance with this paragraph. These reviews and evaluations shall be conducted in a manner that will not unduly delay the contract work. The right of review, whether exercised or not, does not relieve the Contractor of the obligations under the contract.

(c) The Government has the right to inspect and test all supplies called for by the contract, to the extent practicable, at all places and times, including the period of manufacture, and in any event before acceptance. The Government shall perform inspections and tests in a manner that will not unduly delay the work. The Government assumes no contractual obligation to perform any inspection and test for the benefit of the Contractor unless specifically set forth elsewhere in this contract.

(d) If the Government performs inspection or test on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties. Except as otherwise provided in the contract, the Government shall bear the expense of Government inspections or tests made at other than the Contractor's or subcontractor's premises; provided, that in case of rejection, the Government shall not be liable for any reduction in the value of inspection or test samples.

(e)(1) When supplies are not ready at the time specified by the Contractor for inspection or test, the Contracting Officer may charge to the Contractor the additional cost of inspection or test.

(2) The Contracting Officer may also charge the Contractor for any additional cost of inspection or test when prior rejection makes reinspection or retest necessary.

(f) The Government has the right either to reject or to require correction of nonconforming supplies. Supplies are nonconforming when they are defective in material or workmanship or are otherwise not in conformity with contract requirements. The Government may reject nonconforming supplies with or without disposition instructions.

(g) The Contractor shall remove supplies rejected or required to be corrected. However, the Contracting Officer may require or permit correction in place, promptly after notice, by and at the expense of the Contractor. The Contractor shall not tender for acceptance corrected or rejected supplies without disclosing the former rejection or requirement for correction, and, when required, shall disclose the corrective action taken.

(h) If the Contractor fails to promptly remove, replace, or correct rejected supplies that are required to be removed or to be replaced or corrected, the Government may either (1) by contract or otherwise, remove, replace, or correct the supplies and charge the cost to the Contractor or (2) terminate the contract for default. Unless the Contractor corrects or replaces the supplies within the delivery schedule, the Contracting Officer may require their delivery and make an equitable price reduction. Failure to agree to a price reduction shall be a dispute.

(i)(1) If this contract provides for the performance of Government quality assurance at source, and if requested by the Government, the Contractor shall furnish advance notification of the time (i) when Contractor inspection or tests will be performed in accordance with the terms and conditions of the contract and (ii) when the supplies will be ready for Government inspection.

(2) The Government's request shall specify the period and method of the advance notification and the Government representative to whom it shall be furnished. Requests shall not require more than 2 workdays of advance notification if the Government representative is in residence in the Contractor's plant, nor more than 7 workdays in other instances.

(j) The Government shall accept or reject supplies as promptly as practicable after delivery, unless otherwise provided in the contract. Government failure to inspect and accept or reject the supplies shall not relieve the Contractor from responsibility, nor impose liability on the Government, for nonconforming supplies.

(k) Inspections and tests by the Government do not relieve the Contractor of responsibility for defects or other failures to meet contract requirements discovered before acceptance. Acceptance shall be conclusive, except for latent defects, fraud, gross mistakes amounting to fraud, or as otherwise provided in the contract.

(l) If acceptance is not conclusive for any of the reasons in paragraph (k) hereof, the Government, in addition to any other rights and remedies provided by law, or under other provisions of this contract, shall have the right to require the Contractor (1) at no increase in contract price, to correct or replace the defective or nonconforming supplies at the original point of delivery or at the Contractor's plant at the Contracting Officer's election, and in accordance with a reasonable delivery schedule as may be agreed upon between the Contractor and the Contracting Officer;

provided, that the Contracting Officer may require a reduction in contract price if the Contractor fails to meet such delivery schedule, or (2) within a reasonable time after receipt by the Contractor of notice of defects or nonconformance, to repay such portion of the contract as is equitable under the circumstances if the Contracting Officer elects not to require correction or replacement. When supplies are returned to the Contractor, the Contractor shall bear the transportation cost from the original point of delivery to the Contractor's plant and return to the original point when that point is not the Contractor's plant. If the Contractor fails to perform or act as required in (1) or (2) above and does not cure such failure within a period of 10 days (or such longer period as the Contracting Officer may authorize in writing) after receipt of notice from the Contracting Officer specifying such failure, the Government shall have the right by contract or otherwise to replace or correct such supplies and charge to the Contractor the cost occasioned the Government thereby.

(End of clause)

52.246-16 RESPONSIBILITY FOR SUPPLIES (APR 1984)

(a) Title to supplies furnished under this contract shall pass to the Government upon formal acceptance, regardless of when or where the Government takes physical possession, unless the contract specifically provides for earlier passage of title.

(b) Unless the contract specifically provides otherwise, risk of loss of or damage to supplies shall remain with the Contractor until, and shall pass to the Government upon--

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Acceptance by the Government or delivery of the supplies to the Government at the destination specified in the contract, whichever is later, if transportation is f.o.b. destination.

(c) Paragraph (b) of this section shall not apply to supplies that so fail to conform to contract requirements as to give a right of rejection. The risk of loss of or damage to such nonconforming supplies remains with the Contractor until cure or acceptance. After cure or acceptance, paragraph (b) of this section shall apply.

(d) Under paragraph (b) of this section, the Contractor shall not be liable for loss of or damage to supplies caused by the negligence of officers, agents, or employees of the Government acting within the scope of their employment.

SECTION F - DELIVERIES OR PERFORMANCE

52.211-8 TIME OF DELIVERY. (JUN 1997) -- ALTERNATE I (APR 1984)

(a) The Government requires delivery to be made according to the following schedule:

REQUIRED DELIVERY SCHEDULE

ITEM NO. QUANTITY UNIT OF

ISSUE

REQUIRED DELIVERY DATE(S)

0001 1 JOB 10 DAYS ADC (After date of Contract)

0002 1 JOB 06/01/2028

0003 1 JOB 06/01/2028

0004 1 JOB 07/01/2028

0005AA 30 DAY TBD

0005AB 120 DAY TBD

0006 1 JOB 09/01/2028

0007 1 JOB 09/01/2028

0008 8 EACH 10/01/2028

0009 16 EACH 07/01/2028

1001 1 JOB 10 days after award of option

1002 1 JOB 06/01/2029

1003 1 JOB 06/01/2029

1004 1 JOB 07/01/2029

1005AA 30 DAY TBD

1005AB 120 DAY TBD

1006 1 JOB 09/01/2029

1007 1 JOB 09/01/2029

2001 1 JOB 10 days after award of option 2002 4 EACH 6 months after exercising option

3001 1 JOB 10 days after award of option 3002 4 EACH 6 months after exercising option

4001 1 JOB 10 days after award of option

4002 180 DAY TBD*

5001 1 JOB 10 days after award of option

5002 180 DAY TBD*

6001 1 JOB 10 days after award of option 6002 4 EACH 6 months after exercising option

7001 1 JOB 10 days after award of option 7002 4 EACH 6 months after exercising option

8001 1 JOB 10 days after award of option 8002 4 EACH 6 months after exercising option

9001 1 JOB 10 days after award of option 9002 4 EACH 6 months after exercising option

9003 1 JOB 10 days after award of option 9004 4 EACH 6 months after exercising option

9005 1 JOB 10 days after award of option 9006 4 EACH 6 months after exercising option

9007 1 JOB 10 days after award of option 9008 2 EACH 6 months after exercising option

* If exercised, delivery date will be extended accordingly

The Government will evaluate equally, as regards time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above. Offers that propose delivery that will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an offeror offers an earlier delivery schedule than required above. If the offeror proposes no other delivery schedule, the required delivery schedule above will apply.

OFFEROR'S PROPOSED DELIVERY SCHEDULE

WITHIN DAYS AFTER

ITEM NO. QUANTITY DATE OF CONTRACT

(b) The delivery dates or specific periods above are based on the assumption that the Government will make award by 09/30/2024. Each delivery date in the delivery schedule above will be extended by the number of calendar days after the above date that the contract is in fact awarded. Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed or otherwise furnished to the successful offeror results in a binding contract. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails.

52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

(a) If the performance of all or any part of the work of this contract is delayed or interrupted (1) by an act of the Contracting Officer in the administration of this contract that is not expressly or impliedly authorized by this contract, or (2) by a failure of the Contracting Officer to act within the time specified in this contract, or within a reasonable time if not specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this contract caused by the delay or interruption and the contract shall be modified in writing accordingly. Adjustment shall also be made in the delivery or performance dates and any other contractual term or condition affected by the delay or interruption. However, no adjustment shall be made under this clause for any delay or interruption to the extent that performance would have been delayed or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an adjustment is provided or excluded under any other term or condition of this contract.

(b) A claim under this clause shall not be allowed (1) for any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved, and (2) unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the delay or interruption, but not later than the day of final payment under the contract.

52.246-15 CERTIFICATE OF CONFORMANCE (APR 1984)

(a) When authorized in writing by the cognizant Contract Administration Office (CAO), the Contractor shall ship with a Certificate of Conformance any supplies for which the contract would otherwise require inspection at source.

In no case shall the Government's right to inspect supplies under the inspection provisions of this contract be prejudiced. Shipments of such supplies will not be made under this contract until use of the Certificate of Conformance has been authorized in writing by the CAO, or inspection and acceptance have occurred.

(b) The Contractor's signed certificate shall be attached to or included on the top copy of the inspection or receiving report distributed to the payment office or attached to the CAO copy when contract administration (Block 10 of the DD Form 250) is performed by the Defense Contract Administration Services. In addition, a copy of the signed certificate shall also be attached to or entered on copies of the inspection or receiving report accompanying the shipment.

(c) The Government has the right to reject defective supplies or services within a reasonable time after delivery by written notification to the Contractor. The Contractor shall in such event promptly replace, correct, or repair the rejected supplies or services at the Contractor's expense.

(d) The certificate shall read as follows:

"I certify that on ______ [insert date], the ____ [insert Contractor's name] furnished the supplies or services called for by Contract No._____ via ____ [Carrier] on ________[identify the bill of lading or shipping document] in accordance with all applicable requirements. I further certify that the supplies or services are of the quality specified and conform in all respects with the contract requirements, including specifications, drawings, preservation, packaging, packing, marking requirements, and physical item identification (part number), and are in the quantity shown on this or on the attached acceptance document."

Date of Execution: _______________________________

Signature: ______________________________________

Title: __________________________________________

(End of clause)

52.247-34 F.O.B. DESTINATION (NOV 1991)

(a) The term "f.o.b. destination," as used in this clause, means--

(1) Free of expense to the Government, on board the carrier's conveyance, at a specified delivery point where the consignee's facility (plant, warehouse, store, lot, or other location to which shipment can be made) is located; and

(2) Supplies shall be delivered to the destination consignee's wharf (if destination is a port city and supplies are for export), warehouse unloading platform, or receiving dock, at the expense of the Contractor. The Government shall not be liable for any delivery, storage, demurrage, accessorial, or other charges involved before the actual delivery (or "constructive placement" as defined in carrier tariffs) of the supplies to the destination, unless such charges are caused by an act or order of the Government acting in its contractual capacity. If rail carrier is used, supplies shall be delivered to the specified unloading platform of the consignee. If motor carrier (including "piggyback") is used, supplies shall be delivered to truck tailgate at the unloading platform of the consignee, except when the supplies delivered meet the requirements of Item 568 of the National Motor Freight Classification for "heavy or bulky freight." When supplies meeting the requirements of the referenced Item 568 are delivered, unloading (including movement to the tailgate) shall be performed by the consignee, with assistance from the truck driver, if requested. If the contractor uses rail carrier or freight forwarded for less than carload shipments, the contractor shall ensure that the carrier will furnish tailgate delivery, when required, if transfer to truck is required to complete delivery to consignee.

(b) The Contractor shall--

(1)(i) Pack and mark the shipment to comply with contract specifications; or

(ii) In the absence of specifications, prepare the shipment in conformance with carrier requirements;

(2) Prepare and distribute commercial bills of lading;

(3) Deliver the shipment in good order and condition to the point of delivery specified in the contract;

(4) Be responsible for any loss of and/or damage to the goods occurring before receipt of the shipment by the consignee at the delivery point specified in the contract;

(5) Furnish a delivery schedule and designate the mode of delivering carrier; and

(6) Pay and bear all charges to the specified point of delivery.

252.246-7005 NOTICE OF WARRANTY TRACKING OF SERIALIZED ITEMS (MAR 2016)

(a) Definitions. Duration, enterprise, enterprise identifier, fixed expiration, item type, serialized item, starting event, unique item identifier, usage, warranty administrator, warranty guarantor, and warranty tracking are defined in the clause at 252.246-7006, Warranty Tracking of Serialized Items.

(b) Reporting of data for warranty tracking and administration.

(1) The Offeror shall provide the information required by the attachment entitled “Warranty Tracking Information” on each contract line item number, subline item number, or exhibit line item number for warranted items with its offer. Information required in the warranty attachment for each warranted item shall include such information as duration, fixed expiration, item type, starting event, usage, warranty administrator enterprise identifier, and warranty guarantor enterprise identifier.

(2) The successful offeror will be required to provide the following information no later than when the warranted items are presented for receipt and/or acceptance, in accordance with the clause at 252.246-7006--

(i) The unique item identifier for each warranted item required by the attachment entitled “Warranty Tracking Information;” and

(ii) All information required by the attachment entitled “Source of Repair Instructions” for each warranted item.

(3) For additional information on warranty attachments, see the “Warranty and Source of Repair” training and “Warranty and Source of Repair Tracking User Guide” accessible on the Product Data Reporting and Evaluation Program (PDREP) Web site at https://www.pdrep.csd.disa.mil/pdrep_files/other/wsr.htm.

(End of provision)

252.246-7006 WARRANTY TRACKING OF SERIALIZED ITEMS (MAR 2016)

(a) Definitions. As used in this clause--

Duration means the warranty period. This period may be a stated period of time, amount of usage, or the occurrence of a specified event, after formal acceptance of delivery, for the Government to assert a contractual right for the correction of defects.

Enterprise means the entity (e.g., a manufacturer or vendor) responsible for granting the warranty and/or assigning unique item identifiers to serialized warranty items.

Enterprise identifier means a code that is uniquely assigned to an enterprise by an issuing agency.

First use means the initial or first-time use of a product by the Government.

Fixed expiration means the date the warranty expires and the Contractor's obligation to provide for a remedy or corrective action ends.

Installation means the date a unit is inserted into a higher level assembly in order to make that assembly operational.

Issuing agency means an organization responsible for assigning a globally unique identifier to an enterprise, as indicated in the Register of Issuing Agency Codes for International Standards Organization/International Electrotechnical Commission 15459, located at http://www.aimglobal.org/?Reg_Authority15459.

Item type means a coded representation of the description of the item being warranted, consisting of the codes C--component procured separate from end item, S--subassembly procured separate from end item or subassembly, E--embedded in component, subassembly or end item parent, and P--parent end item.

Starting event means the event or action that initiates the warranty, such as first use or upon installation.

https://www.pdrep.csd.disa.mil/pdrep_files/other/wsr.htm http://www.aimglobal.org/?Reg_Authority15459

Serialized item means each item produced is assigned a serial number that is unique among all the collective tangible items produced by the enterprise, or each item of a particular part, lot, or batch number is assigned a unique serial number within that part, lot, or batch number assignment within the enterprise identifier. The enterprise is responsible for ensuring unique serialization within the enterprise identifier or within the part, lot, or batch numbers, and that serial numbers, once assigned, are never used again.

Unique item identifier means a set of data elements marked on an item that is globally unique and unambiguous.

Usage means the quantity and an associated unit of measure that specifies the amount of a characteristic subject to the contractor's obligation to provide for remedy or corrective action, such as a number of miles, hours, or cycles.

Warranty administrator means the organization specified by the guarantor for managing the warranty.

Warranty guarantor means the enterprise that provides the warranty under the terms and conditions of a contract.

Warranty repair source means the organization specified by a warranty guarantor for receiving and managing warranty items that are returned by a customer.

Warranty tracking means the ability to trace a warranted item from delivery through completion of the effectivity of the warranty.

(b) Reporting of data for warranty tracking and administration.

(1) The Contractor shall provide the information required by the attachment entitled “Warranty Tracking Information” on each contract line item number, subline item number, or exhibit line item number for warranted items no later than the time of award. Information required in the warranty attachment shall include such information as duration, fixed expiration, item type, starting event, usage, warranty administrator enterprise identifier, and warranty guarantor enterprise identifier.

(2) The Contractor shall provide the following information no later than when the warranted items are presented for receipt and/or acceptance--

(i) The unique item identifier for each warranted item required by the attachment entitled “Warranty Tracking Information;”' and

(ii) The warranty repair source information and instructions for each warranted item required by the attachment entitled “Source of Repair Instructions.”

(3) The Contractor shall submit the data for warranty tracking to the Contracting Officer with a copy to the requiring activity and the Contracting Officer Representative.

(4) For additional information on warranty attachments, see the “Warranty and Source of Repair” training and “Warranty and Source of Repair Tracking User Guide” accessible on the Product Data Reporting and Evaluation Program (PDREP) Web site at https://www.pdrep.csd.disa.mil/pdrep_files/other/wsr.htm.

(c) Reservation of rights. The terms of this clause shall not be construed to limit the Government's rights or remedies under any other contract clause.

https://www.pdrep.csd.disa.mil/pdrep_files/other/wsr.htm

SECTION G - CONTRACT ADMINISTRATION DATA

252.204-7006 BILLING INSTRUCTIONS—COST VOUCHERS (MAY 2023)

When submitting a request for payment using a cost voucher, the Contractor shall--

(a) Identify the contract line item(s) on the payment request that reasonably reflect contract work performance; and

(b) Separately identify a payment amount for each contract line item included in the payment request.

SECTION H - SPECIAL CONTRACT REQUIREMENTS

ALL OR NONE QUALIFICATIONS

A vendor must provide a price on all items in this solicitation to be eligible for award. The Government will award on an “All or None” basis. Evaluation of bids/offers will be based upon only the total price included on the pricing schedule for all items. If options are included in the pricing schedule the evaluation will be conducted in accordance with the applicable option clause in the solicitation.

PARTNERING

The Government proposes to form a partnering relationship with the contractor. This partnering relationship will strive to facilitate communication and draw on the strengths of each organization in an effort to achieve a quality project, within budget, and on schedule. Participation will be totally voluntary. Partnering will not alter or supersede any provision of this contract nor will it provide either party with any additional contractual rights or obligations.

Participation in partnering will not affect award of this contract. Any cost associated with this partnering will be agreed to by both parties and will be shared equally, with no change in contract price.

BIDDER'S QUALIFICATIONS

Before a bid is considered for award, the bidder may be requested by the Government to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial resources, and plant available to be used in performing the work.

WORK PERFORMED BY THE CONTRACTOR

The successful bidder must furnish the Contracting Officer within 10 days after the award, the items of work which he will perform with their own forces, the percentage of the total work this represents, and the estimated cost thereof.

REQUIREMENT FOR BID GUARANTEE

Each bidder shall submit with its bid a Bid Bond (current version of Standard Form 24) with good and sufficient surety or sureties acceptable to the Government or other security as provided in the clause BID GUARANTEE in the form of twenty percent (20%) of the bid price or $3,000,000 whichever is lesser. The bid bond penalty may be expressed in terms of a percentage of the bid price or may be expressed in dollars and cents.

BASIS FOR SETTLEMENT OF PROPOSALS

“Actual costs will be used to determine equipment costs for a settlement proposal submitted on the total cost basis under FAR 49.206-2(b). In evaluating a terminations settlement proposal using the total cost basis, the following principles will be applied to determine allowable equipment costs:

1. Actual costs for each piece of equipment, or groups of similar serial or series equipment, need not be available in the contractor's accounting records to determine total actual equipment costs.

2. If equipment costs have been allocated to a contract using predetermined rates, those charges will be adjusted to actual costs.

3. Recorded job costs adjusted for unallowable expenses will be used to determine equipment operating expenses.

4. Ownership costs (depreciation) will be determined using the contractor's depreciation schedule (subject to the provisions of FAR 31.205-11).

5. License, taxes, storage and insurance costs are normally recovered as an indirect expense and unless the contractor charges these costs directly to contracts, they will be recovered through the indirect expense rate.”

APPARENT CLERICAL MISTAKES

For the purpose of initial evaluation of bids, the following will be utilized in resolving arithmetic discrepancies found on the face of bidding schedule as submitted by the bidder:

1. Obviously misplaced decimal points will be corrected;

2. Discrepancy between unit price and extended price, the unit price will govern;

3. Apparent errors in extension of unit prices will be corrected;

4. Apparent errors in addition of lump sum and extended prices will be corrected.

For the purpose of bid evaluation, the Government will proceed on the assumption that the bidder intends its bid to be evaluated on the basis of the unit prices, the totals arrived at by resolution of arithmetic discrepancies as provided above and the bid will be so reflected on the abstract of bids.

EPA DESIGNATED (CPG)

Under the Comprehensive Procurement Guidelines (CPG) program, the Environmental Protection Agency (EPA) designates products that are or can be made with recovered materials and recommends practices for buying these products. Any designated product that is being offered or supplied under this contract shall meet the minimum recommended content levels as identified under the CPG program. Visit http://www.epa.gov/epawaste/conserve/tools/cpg/products for a complete list of designated products and the associated recommended content levels. Offerors must be able to demonstrate that each offered product meets minimum content levels upon request.

SAFER CHOICE

The contractor shall provide Safer Choice labeled products under this contract, as applicable. The contractor is encouraged to visit http://www2.epa.gov/saferchoice/products for updated lists of qualifying products.

BIO-BASED

The United States Department of Agriculture (USDA) designates certain biobased products for federal procurement and specifies minimum biobased content levels for those products. Any designated product that is being offered or supplied under this contract shall meet USDA BioPreferred’s minimum biobased content level. Visit the BioPreferred web site for the complete list of designated products and the associated minimum biobased content level requirements.

ANTI-TERRORISM / OPERATIONS SECURITY (AT/OPSEC)

GENERAL SECURITY REQUIREMENTS AND GUIDANCE:

The security requirements described below apply to all…