W912EQ22B0006 Amendment 0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

This amendment is to change the follow ing:

See Summary of changes.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 06-Apr-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912EQ22B0006

X 9B. DATED (SEE ITEM 11)

01-Apr-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

06-Apr-2022

CODE

DEPARTMENT OF THE ARMY

CORPS OF ENGINEERS, MEMPHIS DISTRICT

167 N. MAIN ST., B-202

MEMPHIS TN 38103-1894

7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

x

W912EQ22B0006

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

SUMMARY OF CHANGES

1. Change the Bid Opening date from 8 Apr 2022, to read 11 Apr 2022 at 1300.

2. There is no wastewater treatment plant. Connections to municipal sewer are shown on the plans.

3. Will a stone/aggregate base be required beneath each concrete pads? Yes 4" pad with a stone/aggregate base.

4. Bid Bonds are not required.

5. Rainbow bid schedule has been revised. See attached bid schedule

6. POC for Entergy: John Slay, 504-365-3625

7. ProjNet will not be used for this project, submit question to priscilla.g.sweeney@usace.army.mil

8. There doesn't seem to be a spec for embankment. Please clarify if fill is required or if the intent is to provide positive drainage by shaping materials on site. The intent is, to the degree possible, utilize on-site materials. As such, to minimize borrow / waste, elevations given may vary and are generally intended to show the overall site drainage pattern.

9. Will river sand be acceptable to fill areas that fail proof roll? Yes

10. Much of the site is Schriever Clay, which will likely require stabilization. Is stabilization by using a lime additive acceptable? Yes

11. Is geotextile fabric is needed under all aggregate locations. Geotextiles are required under all aggregate locations as shown.

12. Sheet 5 "gravel Typical Sections Detail, please clarify that the total thickness of Other areas is 6" and the total thickness of Streets area is 8". This is correct.

13. What is the required wind speed rating for the chain link fence? Not mentioned in fence spec. As required by local building codes.

14. SECTION 01200 implies that there is only one invoice submitted at the very end of the project versus every two weeks through RMS. What is the intention of the Government on the periodic payments to the WOSB for this project? Every two week through RMS.

15. The plans call for an 8’ privacy fence along the south and southeast perimeter. Spec 02600 para 2.7 only specifies 6’ high fence with privacy slats. No spec for the 20’ swing gate along the south fence. Unit price schedule indicates both 6' and 8' fence is required, but quantities don't match drawings. Provide the 8’ tall fence in area delineated on the drawing. The 20’ swing gage should generally match the 8’ fence where it’s installed.

mailto:priscilla.g.sweeney@usace.army.mil

16. There are multiple references to the UFAS pads (handicap accessible) but how many and their locations are not shown on the drawings. UFAS units are the 55’ wide sites rather than 40’, and are shown with longer MHU’s than non-UFAS sites. UFAS Sites are as follows: 3, 10, 16, 22, 28, 31, 32, 38, 44, 50, 56, 59, 61, 68, 74, 80, 86, and 88 through 99.

17. No specification or detail provided for fence around metered pole. 6’ fence as specified elsewhere unless otherwise required by AHJ

18. What size is the medium voltage aerial cable? Size by contractor in accordance with National Electric Code (NFPA 70) and AHJ to provide functional electrical distribution system.

19. What size is the secondary cable? Size by contractor in accordance with National Electric Code (NFPA 70) and AHJ to provide functional electrical distribution system

20. Section K indicates bidders MAY be requested to submit past performance projects, and later in paragraph 3 of Section K addresses submission of 2 but not more than 3 past projects involving Tier 4 diesel engine installation or removal. Are we required to submit past performance projects with our bid, and if so, how and where should they be documented? No, you do not required too submit past performance information unless requested.

21. On page 6 of the solicitation there are two volumes for submission, but there is no indication of what goes in each volume. Page 4 lists items to be included in the bid package, which does not reflect 2 volumes?

What information needs to be submitted with the bid and in what format? You are to submit the documents Are being requested on page four (4).

22. Payment and Performance Bond will be required.

SECTION 00 72 00 - GENERAL CONDITIONS

The following have been modified:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $9,067.39 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)