Solicitation Amendment W912EF25BA0170001 released SF 30 Yakima Delta.pdf

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER.

If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Section 00 00 00 - Procurement and Contracting Requirements

The following changes have been made:

INFORMATION FROM TO

Response Due Date 17 Oct 2025 22 Oct 2025

Miscellaneous text in this section has been added to:

Summary of changes for Amend -0001

Bateman Island Causeway Removal

Solicitation Number W912EF25BA017

1. Update solicitation response date from 17 October 2025 to 22 October 2025

2. Provide updated Wage Decision Number WA20250121 09/19/2025

3. Add clause 52.237-27 Site Visit (Construction) with site visit information.

4. Add clause 52.204-8 Annual Representations and Certifications (MAR 2025) (DEVIATION O0003 and 2025 O0004)

5. Revised the following Specifications:

a. SECTION 01 11 01.00 28 SUPPLEMENTARY REQUIREMENTS

Revised paragraph 1.2 SUBMITTALS.

Added paragraph 1.14.2 CAD Requirements and Coordination Meeting

b. SECTION 01 33 00 SUBMITTAL PROCEDURES

Revised paragraph 1.4 CAD FILE REQUIREMENTS.

c. SECTION 01 71 23.01 28 CONTRACTOR SURVEYS AND REMOTE SENSING DATA

COLLECTION

Revised paragraph 3.1.2.03.1 Project Elements and Features

See revisions in Amendment 0001 and specifications for details.

W912EF25BA0170001

1.

2.

Section 00 21 00 - Instructions

Miscellaneous text in this section has been modified to:

Added Amendment 0001

52.236-27 Site Visit (Construction). (Alternate I) (Tailored) (Feb 1995)

Alternate I (Feb 1995). If an organized site visit will be conducted, substitute a paragraph substantially the same as the following for paragraph (b) of the basic provision:

(b) An organized site visit has been scheduled for-

Friday 3 October 2025 at 10:00 a.m.

(c) Participants will meet at-

Wye Park

1600 Columbia Park Trl, Richland, WA 99352

Note: Government Personnel will meet Site visit attendees at Wye Park (See address details above.

A Government hosted Kick off of site visit rules of engagement will take place.

Please provide your list of attendees, to LeAnne Walling (leanne.r.walling@usace.army.mil) and copy Chandra Crow (Chandra.d.crow@usace.army.mil) via email NLT Thursday 2 October 2025 by 3:00 P.M.

Bidder is asked to provide the following information for the Government's use in the determination of bidder responsibility, pursuant to FAR Part 9.

Current Balance Sheet and latest Profit and Loss Statement prepared from the most recent fiscal /calendar year and certified by an officer of the company The name of your banking institution, telephone number and the name of the individual to contact for a line-of-credit reference. (Please contact your bank reference to let him/her know our office will be calling for financial information.)

Bank Institution ________________________________

Telephone Number ______________________________

Contact ________________________________________

Email Address __________________________________

3. ________________________Tax Identification Number

4. List of present work to include agency or firm name, address, telephone number, and email address of primary point of contact responsible for inspection and acceptance of the work. (Attach list)

Percentage of work under this contract to be subcontracted. ________ %.

Will performance of the present work inhibit your ability to perform this contract? ___________

5. Bidder's email address: ____________________________________

Return completed form with all attachments to:

Email: leanne.r.walling@usace.army.mil.

BONDS: 100% PAYMENT AND PERFORMANCE BONDS ARE REQUIRED.

REQUIRED LIABILITY INSURANCE PURSUANT TO FAR 28: In accordance with the clause 52.228-5 Insurance - Work on a Government Installation, the Contractor shall procure and maintain during the entire period of performance under this contract the following minimum insurance: i) Coverage complying with state laws governing insurance requirements pertaining to Workmen's Compensation and Employers" Liability Insurance. ii) Bodily injury liability insurance with minimum limits of $500,000 per occurrence shall be required on the comprehensive form of policy. iii) Automobile bodily injury and property damage liability with minimum limits of $200,000 per person and $500,000 per occurrence for bodily injury liability; and $20,000 per occurrence for property damage liability shall be required. iv) The coverage required under Longshore and Harbor Workers Compensation Act, if applicable. v) The Insurance Certificate will name the Walla Walla District, U.S. Army Corps of Engineers, 201 N. Third Avenue, Walla Walla, Washington 99362 as the Certificate Holder.

The bidder is required to bid on ALL line items of the Bid Schedule. Bidders are required to complete and submit the Standard Form 1442 Back, Bid Schedule, and Section 00 45 00, Representations and Certifications.

Each emailed proposal package shall display the following information:

Solicitation No. W912EF25BA0017 Bid Due Date and Time: As shown in box 13, Page 1.

Bid Validity Date: As shown in box 13, Page 1.

Proposal must be emailed to:

Jani Long, Contracting Officer: jani.c.long@usace.army.mil LeAnne Walling, Contracting Specialist: leanne.r.walling@usace.army.mil Chandra Crow, Secondary Contracting Specialist: chandra.d.crow@usace.army.mil

The resulting award will be FOB Destination. Proposed price must include all shipping to destination and all Federal, State, and local taxes. Inspection and acceptance will be at destination.

AWARD will be made on the basis of lowest evaluated price for all line items of the bid schedule.

NOTE: Proposed prices must include all Federal, state, and local taxes in accordance with Contract Clause: 52.229-3 FEDERAL, STATE, AND LOCAL TAXES.

OFFERORS are required to complete and submit the Standard solicitation form, Bid Schedule, and Section 00 45 00, Representations and Certifications.

All work shall be in accordance with the specifications, drawings, and all other terms and conditions herein. This work is considered a construction project exceeding $2,000 therefore, the Construction Wage Rates (formerly Davis Bacon Act) applies. No laborer or mechanics employed directly upon the site of work shall receive less than the prevailing wage rates as determined by the Secretary of Labor and the wages specified in FAR Clause 52.222-6, Construction Wage Rate Requirements.

BID SUBMISSION:

SUBMIT BID IN ELECTRONIC COPY: The electronic copy must be submitted in a readable format as indicated below. The following additional restrictions apply to an electronic form of proposal submission:

PURSUANT TO FAR 14.201-5

Each email package shall display the following information:

Solicitation No. W912EF25BA0017 Bid Due Date and Time: As shown in box 13, Page 1.

Bid Validity Date: As shown in box 13, Page 1.

Email bid package to the following:

Jani Long, Contracting Officer: Jani.c.long@usace.army.mil LeAnne Walling, Contracting Specialist: leanne.r.walling@usace.army.mil Chandra Crow, Secondary Contracting Specialist: chandra.d.crow@usace.army.mil

Bids received after the date and time stated within Block 13 of the SF1442, or Block 14 of the most recently issued SF 30 as applicable, will be handled IAW FAR 52.214-7, Late Submissions, Modifications, and Withdrawals of Bids. To avoid rejection of a bid, the bidder must make every effort to ensure the bid is delivered by the date and time specified. When utilizing zip files, it is the responsibility of the bidder to ensure the zip file can be accessed by Government Personnel prior to the bid opening.

The following additional restrictions apply to an electronic bid is submission:

File Packaging. All the bid files shall be compressed (zipped) into one file entitled bid zip using WinZip version 6.2 or later, with windows supported files, i.e., doc, xls, ppt, etc., and provided via email. Zip disks are not permitted. Files shall be in read-only format, using PDF, xls, word or ppt files. All price breakdown information to aid in the Price evaluation shall be submitted in Microsoft Office Excel Read /Write format. Each file shall be labeled with the volume number (if applicable), date, and the bidder's name. **Please note - Self extracting exe files are not acceptable. ** Zip files are required; however, in some cases they do not allow access. It is highly encouraged you ensure the files can be accessed by the Contract Specialist prior to the solicitation submission deadline.

BID QUANTITIES Bids for less than specified quantities of each item in Section 00 10 00 of the Schedule will not be considered. Failure to submit a unit price for each item where required in the Schedule will be considered as a material deviation from the requirements of the solicitation, and the bid will be rejected. (FAR 14.201-5)

BID OPENING Bidders are advised there will NOT be an in-person bid opening held for this invitation for bids. The bid opening will be held in a virtual teams bid opening room, at 3:00 pm on the date bids are due. Bidders wishing to participate in the bid opening must email a list of participants to both

W912EF25BA0170001

mailto:Jani.c.long@usace.army.mil mailto:leanne.r.walling@usace.army.mil mailto:chandra.d.crow@usace.army.mil

Contracting Officer ( ) and Contract Specialist (lJani.c.long@usace.army.mil eanne.r.walling@usace.army.

) no later than 2pm on the business day prior to the bid due date and time so a list of names can be mil provided a link to the meeting room.

Bidders are advised that only bids submitted on a firm fixed price basis will be considered, and that bids submitted on any other than firm price basis will be rejected. (FAR 14.201-2 (a)) NOTE; Bid prices must include all Federal, state, and local taxes in accordance with Contract Clause: FEDERAL, STATE, AND

LOCAL TAXES.

Bidders shall submit their bids to the email addresses indicated above no later than the date and time established in Block 13 of the Standard Form (SF) 1442, or Block 14 of the most recently issued SF 30 as applicable.

FAXED BIDS, FAXED BID MODIFICATIONS WILL NOT BE ACCEPTED.

Bid price alterations, i.e., crossed-out or white-out changes on the bid will not be accepted unless the change (s) is/are initialed by the person authorized to sign bid package.

ARITHMETIC DISCREPANCIES:

(a) For the purposes of evaluating proposals, the following will be used to resolve arithmetic discrepancies found on the face of the Bid Schedule as submitted by the offeror.

a. Obviously misplaced decimal points will be corrected.

b. In a discrepancy between unit price and extended price, the unit price will govern;

c. Calculation errors in extension of unit prices, will be corrected;

d. Calculation errors in the addition of lump-sum and extended prices will be corrected.

(b) For the purpose of proposal evaluation, the government will proceed on the assumption that the offeror intends the proposal to be evaluated on the basis of unit prices, the totals arrived at by resolution of arithmetic discrepancies as provided above the proposal will be so reflected on the abstract of offers.

(c). These correction procedures shall not be used to resolve any ambiguity in the proposal.

CONTRACTOR RESPONSIBILITY, PREAWARD SURVEY:

In order to determine a contractor's responsibility for purposes of contract award the contractor is required to provide a statement regarding previous experience and past performance in performing comparable work, information related to the business organization, financial resources, and/or plant to be used in performing the work. (See the Bidder/Offeror Solicitation Questions form included in this solicitation.) In accordance with FAR 9.104-1, to be determined responsible, a prospective contractor must -

(a) Have adequate financial resources to perform the contract, or the ability to obtain them;

(b) Be able to comply with the required or proposed delivery or performance schedule, taking into consideration all existing commercial and governmental business commitments;

(c) Have a satisfactory performance record. (A prospective contractor shall not be determined responsible or non-responsible solely on the basis of a lack of relevant performance history except as provided in FAR 9.104-2);

(d) Have a satisfactory record of integrity and business ethics;

(e) Have the necessary organization, experience, accounting and operational controls, and technical skills, or the ability to obtain them;

(f) Have the necessary production, construction, and technical equipment and facilities, or the ability to obtain them; and

(g) Be otherwise qualified and eligible to receive an award under applicable laws and regulations.

Bidder/Offeror Solicitation Questions:

All inquiries regarding this solicitation are to be submitted via Bidder Inquiry. Telephone and email inquiries will not be accepted. Bidder Inquiry is a web-site that allows bidders to post questions regarding the solicitation and view all questions by other bidders and responses by USACE. Bidder Inquiry can be accessed through ProjNet at (https://www.projnet.org)

To submit and review inquiry items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment /question will receive an acknowledgement of their comment/question via email. Another email to the same address will notify the prospective vendor once the reply is available for viewing.

TIMING OF BIDDER INQUIRIES: Bidders are encouraged to submit their bidder inquiries promptly. The Government will make every effort to answer all bidder inquiries; however, the closer to the bid or proposal due date an inquiry is received, the less likely it is that a timely response can be provided.

The Bidder Inquiry Key is: RDINXK-5SHFAX

Specific Instructions for ProjNet Bid Inquiry Access:

1. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

2. Identify the Agency. This should be marked as USACE.

3. Key. Enter the Bidder Inquiry Key listed above.

4. Email. Enter the email address you would like to use for communication.

5. Click Continue. A page will then open saying that a user account was not found and will ask you to create one using the provided form.

6. Enter your First Name, Last Name, Company, City, State, Phone, Email, Secret Question, Secret Answer, and Time Zone. Make sure to remember your Secret Question and Answer as they will be used from this point on to access the ProjNet system.

7. Click Add User. Once this is completed you are now registered within ProjNet and are currently logged into the system.

Instructions for Entering Questions:

1. After you are logged in click on the "post new inquiry", it is on the left side of the window under the Word "Submit" a.) This is the window where you will enter your questions

W912EF25BA0170001

https://www.projnet.org b.) Comment Classification: Click on the down arrow to the right of the words "Please select from below", select "Public" c.) Discipline: This is where you select who this question should be directed to. Example; if the question is about an electrical drawing or specification select: "Electrical" from the pull down list.

d.) Sheet. Enter the sheet number of the drawing you are asking about.

e.) Detail. Enter the detail name of the detail shown on the drawing that you are asking about.

f.) Specification. Enter the Specification number and paragraph number.

g.) File. Use this if you are going to attach a pdf file.

h.) Question. Enter your question here.

Specific Instructions for Future ProjNet Bid Inquiry Access:

1. For future access to ProjNet, you will not be provided any type of password. You will utilize your Secret Question and Secret Answer to log in.

2. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

3. Identify the Agency. This should be marked as USACE.

4. Key. Enter the Bidder Inquiry Key listed above.

5. Email. Enter the email address you used to register previously in ProjNet.

6. Click Continue. A page will then open asking you to enter the answer to your Secret Question.

7. Enter your Secret Answer and click Login. Once this is completed you are now logged into the system.

For questions about the ProjNet Bidder Inquiry, please contact the Call Center help desk toll free at 1-217-367- 3276 or 1-833-38-1097, which operates from 8AM to 5PM (Central US time zone).

Bidder inquiry help questions can also be emailed to the helpdesk at staff@projnet.info

Section 00 45 00 - Representations and Certifications

The following clauses were added:

W912EF25BA0170001

mailto:staff@projnet.info

FAR Clauses Incorporated by Full Text

52.204-8 Annual Representations and Certifications. (Tailored) (Jan 2025)

Annual Representations and Certifications (Jan 2025)

(a)

(1) The North American Industry Classification System (NAICS) code for this acquisition is .237990

(2) The small business size standard is .$45 Million

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519 if the acquisition-

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)

(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(i) Paragraph (d) applies.

(ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)

(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless-

(A) The acquisition is to be made under the simplified acquisition procedures in part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services-Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations-Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of biobased products in USDA-designated product categories; or include the clause at 52.223-2, Reporting of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals-Representation.

This provision applies to solicitations that include the provision at 52.204-7.

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $100,000, the provision with its Alternate II applies.

(C) If the acquisition value is $100,000 or more but is less than $102,280, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan-Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[ ]Contracting Officer check as appropriate.

52.204-17, Ownership or Control of Offeror.(i)

52.204-20, Predecessor of Offeror.(ii)

52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.(iii)

52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for (iv) Maintenance, Calibration, or Repair of Certain Equipment- Certification.

52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for (v) Certain Services-Certification.

52.227-6, Royalty Information.(vi)

Basic.(A)

Alternate I.(B)

52.227-15, Representation of Limited Rights Data and Restricted Computer Software.(vii)

(d) The offeror has completed the annual representations and certifications electronically in SAM website accessed through https://www.sam.gov. After reviewing the SAM information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ ]. These offeror to insert changes, identifying change by clause number, title, date amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

Section 00 73 00 - Supplementary Conditions

Miscellaneous text in this section has been modified to:

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

WEATHER This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with CLAUSE: DEFAULT (FIXED-PRICE CONSTRUCTION) of the CONTRACT CLAUSES. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. A weather delay day is any day when the maximum temperature does not exceed 32 degrees Fahrenheit or when 0.10 inch or more of precipitation occurs.

The Contractor's progress schedule must reflect these anticipated adverse weather delays in all-weather dependent activities.

Monthly Anticipated Adverse Weather Delay Workdays Based on (7) Day Work Week Location

Location Ja n

Feb Mar Apr May Jun Jul August Sept Oct Nov Dec

Benton County 8 3 3 2 3 2 0 1 1 2 4 12

Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number "Anticipated Adverse Weather Delay Work Days", above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days and issue a modification in accordance with the CLAUSE: DEFAULT (FIXED PRICE CONSTRUCTION) of the CONTRACT CLAUSES.

U.S. Army Corps of Engineers Safety & Health Requirements Manual (EM 385-1-1) This paragraph applies to contracts and purchase orders that require the contractor to comply with EM 385-1-1 (e.g., contracts that include the Accident Prevention clause at FAR 52.236-13 and/or other safety provisions).

EM 385-1-1 and its changes are available http://www.usace.army.mil /SafetyandOccupationalHealth.

aspx. The Contractor shall be responsible for complying with the current edition and all changes posted on the web as of the effective date of this solicitation.

Amendment 0001 updated Wage Decision

"General Decision Number: WA20250121 09/19/2025

Superseded General Decision Number: WA20240121

State: Washington

Construction Type: Heavy

County: Benton County in Washington.

HEAVY CONSTRUCTION PROJECTS

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(1).

|If the contract is entered | Executive Order 14026 |

|into on or after January 30, | generally applies to the |

|2022, or the contract is | contract. |

|renewed or extended (e.g., an | The contractor must pay |

|option is exercised) on or | all covered workers at |

|after January 30, 2022: | least $17.75 per hour (or |

| | the applicable wage rate |

| | listed on this wage |

| | determination, if it is |

| | higher) for all hours |

| | spent performing on the |

| | contract in 2025. |

|If the contract was awarded on| Executive Order 13658 |

|or between January 1, 2015 and| generally applies to the |

|January 29, 2022, and the | contract. |

|contract is not renewed or | The contractor must pay all|

|extended on or after January | covered workers at least |

|30, 2022: | $13.30 per hour (or the |

| | applicable wage rate listed|

| | on this wage determination,|

| | if it is higher) for all |

| | hours performing on that |

| | contract in 2025. |

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the

Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at http://www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/03/2025

1 02/07/2025

2 05/23/2025

3 06/06/2025

4 06/27/2025

5 07/18/2025

6 08/08/2025

7 08/29/2025

8 09/12/2025

9 09/19/2025

CARP0059-012 06/01/2023

Rates Fringes

CARPENTER........................$ 59.92 15.04

ELEC0077-002 02/01/2024

Rates Fringes

Line Construction:

LINE PERSON.................$ 64.17 23.58+1.5%

ELEC0077-003 02/01/2023

Rates Fringes

TREE TRIMMER: Ground Person......$ 22.60 16.37

TREE TRIMMER.....................$ 42.57 17.97

ELEC0077-005 02/01/2024

Rates Fringes

Line Construction:

EQUIPMENT OPERATOR..........$ 55.19 20.11+1.5%

ELEC0077-006 02/01/2023

Rates Fringes

Line Construction:

GROUND PERSON...............$ 37.53 17.74

ELEC0112-010 06/01/2025

Rates Fringes

ELECTRICIAN......................$ 60.00 27.78

ENGI0302-121 06/01/2024

Rates Fringes

OPERATOR:

Backhoe/Excavator/Trackhoe

(45,000 gw & under)..............$ 37.37 22.45

OPERATOR: Bobcat/Skid

Steer/Skid Loader................$ 36.99 22.45

OPERATOR: Loader

Overhead 4 yards including

8 yards.....................$ 37.69 22.45

Overhead under 4 yards......$ 37.18 22.45

OPERATOR: Mechanic..............$ 36.11 22.45

ENGI0302-122 06/01/2024

Rates Fringes

OPERATOR: Bulldozer (D9 & under)...........................$ 36.99 22.45

ENGI0302-123 06/01/2024

Rates Fringes

OPERATOR: Concrete Pump

Boom Truck..................$ 37.69 22.45

Squeeze-Crete, Flow-Crete, Whitman & similar...........$ 37.18 22.45

OPERATOR: Drill (Drilling

Machine,Horizontal/Directional

Drill Locator/Operator).........$ 39.88 22.45

OPERATOR: Grader/Blade..........$ 37.69 22.45

OPERATOR: Oiler

Drill Oilers: Auger Type, Truck or Crane Mount........$ 36.28 22.45

Truck Crane Oiler/Driver....$ 37.18 22.45

OPERATOR: Paver (Asphalt, Aggregate, and Concrete).........$ 37.69 22.45

OPERATOR: Roller................$ 35.91 22.45

OPERATOR: Scraper...............$ 37.69 22.45

IRON0014-010 07/07/2025

Rates Fringes

IRONWORKER.......................$ 43.40 32.77

* LABO0238-040 06/01/2025

Rates Fringes

TRAFFIC CONTROL: Flagger.......$ 34.03 16.90

LABO0242-010 06/01/2025

Rates Fringes

LABORER: Nozzle Person...........$ 52.31 17.01

* LABO0348-010 06/01/2025

Rates Fringes

LABORER: Pipelayer..............$ 37.80 16.90

PAIN0300-002 07/01/2025

Rates Fringes

PAINTER..........................$ 41.24 14.70

PLAS0072-005 06/01/2025

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 40.89 18.64

TEAM0313-001 06/01/2025

Rates Fringes

TRUCK DRIVER: Asphalt Mix.......$ 55.43 27.52

* UAVG-WA-0010 03/01/2024

Rates Fringes

OPERATOR: Crane.................$ 54.45 25.57

SUWA2018-021 03/01/2024

Rates Fringes

GRADE CHECKER....................$ 31.40 14.10

LABORER: Asphalt, Includes

Raker, Shoveler, Spreader and

Distributor......................$ 36.96 8.56

LABORER: Common or General......$ 29.27 12.01

LABORER: Concrete Saw Chain.....$ 36.24 10.89

LABORER: Hod Carrier............$ 35.06 10.94

LABORER: Mason Tender -

Cement/Concrete..................$ 27.51 2.96

LABORER: Fence Erector...........$ 30.21 0.00

OPERATOR: Forklift..............$ 45.93 19.20

TRAFFIC CONTROL:

Laborer-Cones/

Barricades/Barrels -

Setter/Mover/Sweeper.............$ 30.61 10.89

TRUCK DRIVER: Dump Truck........$ 29.55 15.38

TRUCK DRIVER: Water Truck.......$ 31.62 16.84

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the

Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses

(29CFR 5.5 (a) (1) (iii)).

The body of each wage determination lists the classifications and wage rates that have been found to be prevailing for the type(s) of construction and geographic area covered by the wage determination. The classifications are listed in alphabetical order under rate identifiers indicating whether the particular rate is a union rate (current union negotiated rate), a survey rate, a weighted union average rate, a state adopted rate, or a supplemental classification rate.

Union Rate Identifiers

A four-letter identifier beginning with characters other than

""SU"", ""UAVG"", ?SA?, or ?SC? denotes that a union rate was prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2024. PLUM is an identifier of the union whose collectively bargained rate prevailed in the survey for this classification, which in this example would be Plumbers.

0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. The date, 07/01/2024 in the example, is the effective date of the most current negotiated rate.

Union prevailing wage rates are updated to reflect all changes over time that are reported to WHD in the rates in the collective bargaining agreement (CBA) governing the classification.

Union Average Rate Identifiers

The UAVG identifier indicates that no single rate prevailed for those classifications, but that 100% of the data reported for the classifications reflected union rates. EXAMPLE:

UAVG-OH-0010 01/01/2024. UAVG indicates that the rate is a weighted union average rate. OH indicates the State of Ohio.

The next number, 0010 in the example, is an internal number used in producing the wage determination. The date, 01/01/2024 in the example, indicates the date the wage determination was updated to reflect the most current union average rate.

A UAVG rate will be updated once a year, usually in January, to reflect a weighted average of the current rates in the collective bargaining agreements on which the rate is based.

Survey Rate Identifiers

The ""SU"" identifier indicates that either a single non-union rate prevailed (as defined in 29 CFR 1.2) for this classification in the survey or that the rate was derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As a weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SUFL2022-007

6/27/2024. SU indicates the rate is a single non-union prevailing rate or a weighted average of survey data for that classification. FL indicates the State of Florida. 2022 is the year of the survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. The date, 6/27/2024 in the example, indicates the survey completion date for the classifications and rates under that identifier.

?SU? wage rates typically remain in effect until a new survey is conducted. However, the Wage and Hour Division (WHD) has the discretion to update such rates under 29 CFR 1.6(c)(1).

State Adopted Rate Identifiers

The ""SA"" identifier indicates that the classifications and prevailing wage rates set by a state (or local) government were adopted under 29 C.F.R 1.3(g)-(h). Example: SAME2023-007

01/03/2024. SA reflects that the rates are state adopted. ME refers to the State of Maine. 2023 is the year during which the state completed the survey on which the listed classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination.

The date, 01/03/2024 in the example, reflects the date on which the classifications and rates under the ?SA? identifier took effect under state law in the state from which the rates were adopted.

WAGE DETERMINATION APPEALS PROCESS

1) Has there been an initial decision in the matter? This can be:

a) a survey underlying a wage determination

b) an existing published wage determination

c) an initial WHD letter setting forth a position on a wage determination matter

d) an initial conformance (additional classification and rate) determination

On survey related matters, initial contact, including requests for summaries of surveys, should be directed to the WHD Branch of Wage Surveys. Requests can be submitted via email to davisbaconinfo@dol.gov or by mail to:

Branch of Wage Surveys

Wage and Hour Division

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

Regarding any other wage determination matter such as conformance decisions, requests for initial decisions should be directed to the WHD Branch of Construction Wage Determinations.

Requests can be submitted via email to BCWD-Office@dol.gov or by mail to:

Branch of Construction Wage Determinations

Wage and Hour Division

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

2) If an initial decision has been issued, then any interested party (those affected by the action) that disagrees with the decision can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7).

Requests for review and reconsideration can be submitted via email to dba.reconsideration@dol.gov or by mail to:

Wage and Hour Administrator

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative

Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210.

END OF GENERAL DECISION"

KO CONTRACTING DIVISION, 201 NORTH 3RD AVE

WALLA WALLA, WA 99362-1876

UNITED STATES

LEANNE WALLING, EMAIL: LEANNE.R.WALLING@USACE.ARMY.MIL TELEPHONE: 5095277230

AdminBy:

SCD: PAS:

SEE SUMMARY OF CHANGES FOR FURTHER DETAILS.

ALL OTHER TERMS AND CONDITIONS REMAIN UNCHANGED.