W912DS24B0001.pdf

Project: Invitation for Bids (IFB) – Joseph G. Minish Passaic River Waterfront Park and Historic Area Project

1. 100% Unrestricted Full and Open Competition w ith Hubzone Price Evaluation preference.

2. NAICS Code 237990, Size Standard $45,000,000

3. Project is estimated at Project Magnitude Range: $10,000,000-$25,000,000 4.Contract Specialist is Jordan Moran, jordan.k.moran@usace.army.mil Submit bids no later than 2:00PM EST on 16 May 2024 (or as amended) to:

U.S. Army Corps of Engineers New York District, Contracting Division, Room 16-300, 26 Federal Plaza, New York, NY 10278-0090 Due to hightened Security at U.S. Government installations, all Bidders are instructed to allow ample time to get through the security checkpoint in order to have their bids delivered before 2:00PM EST on the date of the bid opening

X

JORDAN A MORAN 917-908-8121

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

16-Apr-2024

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________425 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________16 May 2024 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

US ARMY CORPS OF ENGINEERS, NEW YORK

26 FEDERAL PLAZA, RM 16-300

NEW YORK NY 10278-0090

W912DS

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

212-264-3013FAX:TEL: 917-790-8026 TEL: FAX:

W912DS24B0001 48

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912DS24B0001

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Construction of Steel Sheet Piles

FFP

See Priced SubCLINs 0001AA, 0001AB, and 0001AC

NET AMT

0001AA 905 Linear

Foot

Construction of Steel Sheet Piling

Steel for Bulkhead System - Steel Sheet Piling for construction of bulkhead for Stations 0+00 through 9+05, complete, in accordance with the drawings and specifications, but not including Items 0002- 0014 on the bid schedule.

[ESTIMATED QUANTITY]

FOB: Destination

PSC CD: Y1KZ

0001AB 1 Job Construction of Cap, Tie-Back & Drainage

FFP

Concrete Cap, and Tie-Back rod system - All work, excluding steel costs stated in SubCLIN 0001AA, for construction of bulkhead, which includes concrete cap and related work, including drainage structures, for Stations 0+00 through 9+05, complete, in accordance with the drawings and specifications, but not including Items 0002-0014 on the bid schedule.

0001AC 1 Job Mobilization / Demobilization

FFP

All mobilization and demobilization work for construction of bulkhead.

0002 1 Job Drawing Set

FFP

Contractor shall complete the Record ("As-Builts") CAD submittal as required by Specification Section 01 78 00 CLOSEOUT SUBMITTALS for Record Drawings (“as-Builts”) Requirements and for CADD standards and compliance.

Prepriced CLIN in the amount of $100,000. The amount paid will be actual cost

NOT TO EXCEED THE PREPRICED AMOUNT

0003 1 Job Report and Drawing Set

FFP

Archaeological monitoring for historical structures.

FOB: Destination

0004 1 Job Report and Drawing set

FFP

Development of Landscape seeding plan with two coordination meetings with DLUR and Development of Tree Survey, Protection, and Restitution plan with two coordination meetings with representatives of State of New Jersey

0005 4,000 Cubic

Yard

Displacement Stone Material

Material for Displacement Stone. [ESTIMATED QUANTITY]

0006 905 Linear

OPTION OPTIONAL ITEM 1- Railings

All Work for Installation of Railings. A small amount of railing fabrication is required for bends, change in direction, and point of inflections. [ESTIMATED QUANTITY] Option 1 may be awarded within 120 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

0007 100 Cubic

OPTION OPTIONAL ITEM 2 - Excavation, Transport

All Work for Excavation, Testing, Transport, Treatment and Off-Site Disposal of Upland Material Exceeding NJDEP Non-Residential Soil Cleanup Criteria and classified as Contaminated Non-Hazardous (ID 27 Waste) not suitable for landfill cover, etc. for Stations 0+00 through 9+05, complete. [ESTIMATED QUANTITY] Option 2 may be awarded within 210 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

0008 100 Cubic

OPTION OPTIONAL ITEM 3 - Excavation, Transport

All Work for Excavation, Testing, Transport, Treatment and Off-Site Disposal of Upland Material Exceeding NJDEP Non-Residential Soil Cleanup Criteria and classified as Contaminated Hazardous or material not suitable for landfill cover, etc. for Stations 0+00 through 9+05, complete. [ESTIMATED QUANTITY] Option 3 may be awarded within 210 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

0009 1 Job OPTION OPTIONAL ITEM 4 – Implementation Plan

FFP

All work for implementation of landscape and seeding plan. Prepriced CLIN in the amount of $100,000. The amount paid will be actual cost NOT TO EXCEED THE PREPRICED AMOUNT. Option 4 may be awarded within 270 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

0010 1 Job OPTION OPTIONAL ITEM 5 – Implementation Plan

FFP

All Work for stabilization of historic structures. Prepriced CLIN in the amount of $100,000. The amount paid will be actual cost NOT TO EXCEED THE PREPRICED AMOUNT. may be awarded within 270 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

0011 100 Linear

OPTION OPTIONAL ITEM 6 – Additional materials

Additional furnishing and placing steel wide flange beams/sheet pile connections.

[ESTIMATED QUANTITY] Option 11 may be awarded within 180 calendar days of issuance of the Base Bid NTP. Additional 90 days will be added to the scheduled.

0012 100 Cubic

OPTION OPTIONAL ITEM 7 – Additional materials

Additional 100 CY material for displacement stone [ESTIMATED QUANTITY] Option 7 may be awarded within 180 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

0013 1 Job OPTION OPTIONAL ITEM 8 - Gravel Tracking

FFP

All Work and Materials for construction of temporary Gravel Tracking Pad from Access Point 2 to Staging Area while protecting historic structures and bringing back to initial conditions. Option 8 may be awarded within 15 calendar days of issuance of the Base Bid NTP. Additional 30 days will be added to the schedule.

0014 1 Job OPTION OPTIONAL ITEM 9 - Liability Insurance

FFP

Liability insurance for New Jersey Department of Environmental Protection (NJDEP), City of Newark and their officers, employees and agents.

NON-FED FUNDS. The amount bid will be the maximum amount payable. Actual payment will be based on actual costs. Option 9 may be awarded within 60 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

TOTALS

TOTALS SECTION

BASE TOTAL AMOUNT (CLIN 0001-0005)

TOTAL OPTIONAL (CLIN 0006-0014)

TOTAL BASE PLUS OPTIONAL CLINS 0001-0014

NOTES

BID SCHEDULE NOTES

1. Bidders are required to bid on all items in the Price Schedule or their bid will be rejected.

2. Low bidder for the purpose of award will be the conforming responsible bidder offering the lowest amount for the Grand Total Bid Items.

3. Any bid which is materially unbalanced as to prices for the bid items may be rejected. An unbalanced bid is one which is based on prices significantly less than cost for some work, and prices which are significantly overstated for other work.

4. Bidders are reminded that they must bid on the issued plans and specifications as amended. Any deviations, conditions, or attachments made by the bidders thereto may render the bid non- responsive and may be cause for its rejection.

5. If awarded, the options would be exercised as follows:

Option #1, Bid Item No. 0006, Installation of Railings, and a small amount of railing fabrication required for bends, change in direction, and point of inflections, may be awarded within 120 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

Option #2, Bid Item No. 0007, Contaminated Non-Hazardous Material (ID27), may be awarded within 210 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

Option #3, Bid Item No. 0008, Contaminated Hazardous Material, may be awarded within 210 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

Option #4, Bid Item No. 0009, Implementation of Landscape Plan may be awarded within 270 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

Option #5, Bid Item No. 0010, Implementation of Treatment Plan, may be awarded within 270 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

Option #6, Bid Item No. 0011, Additional Materials, may be awarded within 180 calendar days of issuance of the Base Bid NTP. Additional 90 days will be added to the scheduled.

Option #7, Bid Item No. 0012, Additional Materials, may be awarded within 180 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

Option #8, Bid Item No. 0013, Gravel Tracking Pad, may be awarded within 15 calendar days of issuance of the Base Bid NTP. Additional 30 days will be added to the schedule.

Option #9, Bid Item No. 0014, Liability Insurance, may be awarded within 60 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract performance period.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 N/A N/A N/A N/A

0001AA 425 dys. ANP 905 FRM & ECOSYSTEMS RESTOR. SECT

JASON SHEA

USACOE-NYD 26 FEDERAL PLAZA

CENAN-PL-FF

NEW YORK NY 10278-0090

917-790-8727

W912DS

0001AB 425 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0001AC 425 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0002 425 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0003 425 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0004 425 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0005 425 dys. ANP 4,000 (SAME AS PREVIOUS LOCATION)

0006 425 dys. ANP 905 (SAME AS PREVIOUS LOCATION)

0007 425 dys. ANP 100 (SAME AS PREVIOUS LOCATION)

0008 425 dys. ANP 100 (SAME AS PREVIOUS LOCATION)

0009 425 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0010 425 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0011 425 dys. ANP 100 (SAME AS PREVIOUS LOCATION)

0012 425 dys. ANP 100 (SAME AS PREVIOUS LOCATION)

0013 425 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0014 425 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

Section 00 21 00 - Instructions

CPARS

CPARS

The Federal Acquisition Regulation (FAR) requires that Past Performance Information (PPI) be collected on DoD contracts. The Contractor Performance Assessment Reporting System (CPARS) is a web enabled application the supports the completion, distribution and retrieval of all contract performance evaluations. Contractor Representative are responsible for reviewing and commenting on evaluations submitted on the Contractor Performance Assessment Reporting System (CPARS) website at https://www.cpars.gov/index.htm.

NOTICE REGARDING BID BONDS, PEFORMANCE BONDS, AND PAYMENT BONDS

The Standard Forms (SF24, SF25, and SF25A) for these bonds have been revised as of August 2016. When including your bid/offer, contractors/sureties shall use the revised versions. No other version will be valid and thus may render your bid/offer nonresponsive

AT-OPSEC REQUIREMENTS

AT/OPSEC Requirements Pre-screen Candidates Using E-Verify Program – The Contractor must pre-screen Candidates using the E-Verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-Verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

CLAUSES INCORPORATED BY REFERENCE

52.225-11 Buy American--Construction Materials Under Trade

Agreements

DEC 2022

CLAUSES INCORPORATED BY FULL TEXT

52.225-2 BUY AMERICAN CERTIFICATE (OCT 2022)

(a)(1) The Offeror certifies that each end product, except those listed in paragraph (b) of this provision, is a domestic end product and that each domestic end product listed in paragraph (c) of this provision contains a critical component.

(2) The Offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products. For those foreign end products that do not consist wholly or predominantly of iron or steel or a combination of both, the Offeror shall also indicate whether these foreign end products exceed 55 percent domestic content, except for those that are COTS items. If the percentage of the domestic content is unknown, select "no''.

(3) The Offeror shall separately list the line item numbers of domestic end products that contain a critical component (see FAR 25.105).

(4) The terms "commercially available off-the-shelf (COTS) item,'' "critical component,'' "domestic end product," "end product," and "foreign end product" are defined in the clause of this solicitation entitled "Buy American-- Supplies."

(b) Foreign End Products:

[List as necessary.]

(c) Domestic end products containing a critical component:

Line Item No. ___

[List as necessary]

(d) The Government will evaluate offers in accordance with the policies and procedures of part 25 of the Federal Acquisition Regulation.

(End of provision)

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be ___20____ percent of the bid price or $__3,000,000______, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of provision)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (NOV 2020)

Line item No. Country of origin Exceeds 55% domestic content (yes/no)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Defense Federal Regulation Supplement (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of clause)

Section 00 70 00 - Conditions of the Contract

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 N/A N/A N/A N/A 0001AA N/A N/A N/A Government 0001AB N/A N/A N/A Government 0001AC N/A N/A N/A Government 0002 N/A N/A N/A Government 0003 N/A N/A N/A Government 0004 N/A N/A N/A Government 0005 N/A N/A N/A Government 0006 N/A N/A N/A Government 0007 N/A N/A N/A Government 0008 N/A N/A N/A Government 0009 N/A N/A N/A Government 0010 N/A N/A N/A Government 0011 N/A N/A N/A Government 0012 N/A N/A N/A Government 0013 N/A N/A N/A Government 0014 N/A N/A N/A Government

Section 00 72 00 - General Conditions

52.202-1 Definitions JUN 2020 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government JUN 2020 52.203-7 Anti-Kickback Procedures JUN 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-13 Contractor Code of Business Ethics and Conduct NOV 2021 52.203-14 Display of Hotline Poster(s) NOV 2021 52.203-16 Preventing Personal Conflicts of Interest JUN 2020 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

JUN 2020

52.204-2 Alt I Security Requirements (MAR 2021) - Alternate I APR 1984 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities

NOV 2021

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

NOV 2021

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.210-1 Market Research NOV 2021 52.211-3 Availability of Specifications Not Listed in the GSA Index of

Federal Specifications, Standards, and Commercial Item Descriptions

JUN 1988

52.211-18 Variation in Estimated Quantity APR 1984 52.214-26 Audit and Records--Sealed Bidding JUN 2020 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data -

Modifications - Sealed Bidding

JUN 2020

52.214-28 Subcontractor Certified Cost Or Pricing Data--Modifications- -Sealed Bidding

JUN 2020

52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.215-15 Pension Adjustments and Asset Reversions OCT 2010 52.215-19 Notification of Ownership Changes OCT 1997

52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns

OCT 2022

52.219-8 Utilization of Small Business Concerns OCT 2022 52.219-9 Alt I Small Business Subcontracting Plan (OCT 2022) Alternate I NOV 2016 52.219-14 Limitations On Subcontracting OCT 2022 52.219-16 Liquidated Damages-Subcontracting Plan SEP 2021 52.219-28 Post-Award Small Business Program Rerepresentation MAR 2023 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-19 Child Labor -- Cooperation with Authorities and Remedies DEC 2022 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons NOV 2021 52.222-54 Employment Eligibility Verification MAY 2022 52.222-55 Minimum Wages for Contractor Workers Under Executive

Order 14026

JAN 2022

52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2022 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-3 Hazardous Material Identification And Material Safety Data FEB 2021 52.223-6 Drug-Free Workplace MAY 2001 52.223-10 Waste Reduction Program MAY 2011 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.227-1 Authorization and Consent JUN 2020 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-11 Individual Surety--Pledge of Assets FEB 2021 52.228-12 Prospective Subcontractor Requests for Bonds DEC 2022 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.229-3 Federal, State And Local Taxes FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-16 (Dev) Progress Payments (DEVIATION 2020-O0010) NOV 2021 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

MAR 2023

52.233-1 Disputes MAY 2014 52.233-1 Alt I Disputes (May 2014) - Alternate I DEC 1991 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-16 Quantity Surveys APR 1984 52.236-16 Alt I Quantity Surveys (Apr 1984) - Alternate I APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-5 Payments to Small Business Subcontractors JAN 2017 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.244-6 Subcontracts for Commercial Products and Commercial

Services

JUN 2023

52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.247-34 F.O.B. Destination NOV 1991 52.248-3 Value Engineering-Construction OCT 2020 52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-10 Default (Fixed-Price Construction) APR 1984 52.252-4 Alterations in Contract APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

JAN 2023

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.203-7003 Agency Office of the Inspector General AUG 2019 252.203-7004 Display of Hotline Posters JAN 2023

252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7006 Billing Instructions--Cost Vouchers MAY 2023 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

JAN 2023

252.204-7014 Limitations on the Use or Disclosure of Information by Litigation Support Contractors

JAN 2023

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

JAN 2023

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2023

252.205-7000 Provision Of Information To Cooperative Agreement Holders JUN 2023 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.219-7003 Small Business Subcontracting Plan (DOD Contracts) DEC 2019 252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements JAN 2023 252.223-7004 Drug Free Work Force SEP 1988 252.223-7008 Prohibition of Hexavalent Chromium JAN 2023 252.225-7048 Export-Controlled Items JUN 2013 252.227-7013 Rights in Technical Data--Other Than Commercial Products and Commercial Services

MAR 2023

252.227-7016 Rights in Bid or Proposal Information JAN 2023 252.227-7022 Government Rights (Unlimited) MAR 1979 252.227-7023 Drawings and Other Data to become Property of Government MAR 1979 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7002 Obstruction of Navigable Waterways DEC 1991 252.239-7001 Information Assurance Contractor Training and Certification JAN 2008 252.239-7002 Access DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.247-7023 Transportation of Supplies by Sea JAN 2023

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 425 days after Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $5131.00 for each calendar day of delay until the work is completed or accepted.

This amount is the “first tier” demurrage based upon costs incurred in administration of the contract past the completion date. This amount does not include any liquidated damages for each day of delay that would accrue to the using service from exclusion of beneficial occupancy.

The “second tier” demurrage shall be assessed at the rate calculated below in the event the contractor fails to complete documented punchlist items after the date of beneficial occupancy:: $1,283.00/day

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.222-8 PAYROLLS AND BASIC RECORDS (JUL 2021)

(a) Payrolls and basic records relating thereto shall be maintained by the Contractor during the course of the work and preserved for a period of 3 years thereafter for all laborers and mechanics working at the site of the work. Such records shall contain the name, address, and social security number of each such worker, his or her correct classification, hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in 40 U.S.C. 3141(2)(B) (Construction Wage Rate Requirement statute)), daily and weekly number of hours worked, deductions made, and actual wages paid.

Whenever the Secretary of Labor has found, under paragraph (d) of the clause entitled Construction Wage Rate Requirements, that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in 40 U.S.C. 3141(2)(B), the Contractor shall maintain records which show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits. Contractors employing apprentices or trainees under approved programs shall maintain written evidence of the registration of apprenticeship programs and certification of trainee programs, the registration of the apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs.

(b)(1) The Contractor shall submit weekly for each week in which any contract work is performed a copy of all payrolls to the Contracting Officer. The payrolls submitted shall set out accurately and completely all of the information required to be maintained under paragraph(a) of this clause, except that full social security numbers and home addresses shall not be included on weekly transmittals. Instead the payrolls shall only need to include an individually identifying number for each employee (e.g., the last four digits of the employee's social security number). The required weekly payroll information may be submitted in any form desired. Optional Form WH-347 is available for this purpose and may be obtained from the U.S. Department of Labor Wage and Hour Division website at https://www.dol.gov/agencies/whd/forms. The Prime Contractor is responsible for the submission of copies of payrolls by all subcontractors. Contractors and subcontractors shall maintain the full social security number and current address of each covered worker, and shall provide them upon request to the Contracting Officer, the Contractor, or the Wage and Hour Division of the Department of Labor for purposes of an investigation or audit of compliance with prevailing wage requirements. It is not a violation of this section for a Prime Contractor to require a subcontractor to provide addresses and social security numbers to the Prime Contractor for its own records, without weekly submission to the Contracting Officer.

(2) Each payroll submitted shall be accompanied by a "Statement of Compliance," signed by the Contractor or subcontractor or his or her agent who pays or supervises the payment of the persons employed under the contract and shall certify--

(i) That the payroll for the payroll period contains the information required to be maintained under paragraph (a) of this clause and that such information is correct and complete;

(ii) That each laborer or mechanic (including each helper, apprentice, and trainee) employed on the contract during the payroll period has been paid the full weekly wages earned, without rebate, either directly or indirectly, and that no deductions have been made either directly or indirectly from the full wages earned, other than permissible deductions as set forth in the Regulations, 29 CFR Part 3; and

(iii) That each laborer or mechanic has been paid not less than the applicable wage rates and fringe benefits or cash equivalents for the classification of work performed, as specified in the applicable wage determination incorporated into the contract.

(3) The weekly submission of a properly executed certification set forth on the reverse side of Optional Form WH- 347 shall satisfy the requirement for submission of the "Statement of Compliance" required by subparagraph (b)(2) of this clause.

(4) The falsification of any of the certifications in this clause may subject the Contractor or subcontractor to civil or criminal prosecution under Section 1001 of Title 18 and Section 3729 of Title 31 of the United States Code.

(c) The Contractor or subcontractor shall make the records required under paragraph (a) of this clause available for inspection, copying, or transcription by the Contracting Officer or authorized representatives of the Contracting Officer or the Department of Labor. The Contractor or subcontractor shall permit the Contracting Officer or representatives of the Contracting Officer or the Department of Labor to interview employees during working hours on the job. If the Contractor or subcontractor fails to submit required records or to make them available, the Contracting Officer may, after written notice to the Contractor, take such action as may be necessary to cause the suspension of any further payment. Furthermore, failure to submit the required records upon request or to make such records available may be grounds for debarment action pursuant to 29 CFR 5.12.

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED ITEMS (MAY 2008)

(a) Definitions. As used in this clause--

Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall--

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to Nicholas Emanuel, nicholas.p.emanuel@usace.army.mil.

52.232-16 PROGRESS PAYMENTS (NOV 2021)

The Government will make progress payments to the Contractor when requested as work progresses, but not more frequently than monthly, in amounts of $2,500 or more approved by the Contracting Officer, under the following conditions:

(a) Computation of amounts.

(1) Unless the Contractor requests a smaller amount, the Government will compute each progress payment as 80 percent of the Contractor's total costs incurred under this contract whether or not actually paid, plus financing payments to subcontractors (see paragraph (j) of this clause), less the sum of all previous progress payments made by the Government under this contract. The Contracting Officer will consider cost of money that would be allowable under Federal Acquisition Regulation (FAR) 31.205-10 as an incurred cost for progress payment purposes.

(2) The amount of financing and other payments for supplies and services purchased directly for the contract are limited to the amounts that have been paid by cash, check, or other forms of payment, or that are determined due and will be paid to subcontractors--

(i) In accordance with the terms and conditions of a subcontract or invoice; and

(ii) Ordinarily within 30 days of the submission of the Contractor's payment request to the Government.

(3) The Government will exclude accrued costs of Contractor contributions under employee pension plans until actually paid unless--

(i) The Contractor's practice is to make contributions to the retirement fund quarterly or more frequently; and

(ii) The contribution does not remain unpaid 30 days after the end of the applicable quarter or shorter payment period (any contribution remaining unpaid shall be excluded from the Contractor's total costs for progress payments until paid).

(4) The Contractor shall not include the following in total costs for progress payment purposes in paragraph (a)(1) of this clause:

(i) Costs that are not reasonable, allocable to this contract, and consistent with sound and generally accepted accounting principles and practices.

(ii) Costs incurred by subcontractors or suppliers.

(iii) Costs ordinarily capitalized and subject to depreciation or amortization except for the properly depreciated or amortized portion of such costs.

(iv) Payments made or amounts payable to subcontractors or suppliers, except for --

(A) Completed work, including partial deliveries, to which the Contractor has acquired title; and

(B) Work under cost-reimbursement or time-and-material subcontracts to which the Contractor has acquired title.

(5) The amount of unliquidated progress payments may exceed neither (i) the progress payments made against incomplete work (including allowable unliquidated progress payments to subcontractors) nor

(ii) the value, for progress payment purposes, of the incomplete work. Incomplete work shall be considered to be the supplies and services required by this contract, for which delivery and invoicing by the Contractor and acceptance by the Government are incomplete.

(6) The total amount of progress payments shall not exceed 80 percent of the total contract price.

(7) If a progress payment or the unliquidated progress payments exceed the amounts permitted by subparagraphs (a)(4) or (a)(5) of this clause, the Contractor shall repay the amount of such excess to the Government on demand.

(8) Notwithstanding any other terms of the contract, the Contractor agrees not to request progress payments in dollar amounts of less than $2,500. The Contracting Officer may make exceptions.

(9) The costs applicable to items delivered, invoiced, and accepted shall not include costs in excess of the contract price of the items.

(b) Liquidation. Except as provided in the Termination for Convenience of the Government clause, all progress payments shall be liquidated by deducting from any payment under this contract, other than advance or progress payments, the unliquidated progress payments, or 80 percent of the amount invoiced, whichever is less. The Contractor shall repay to the Government any amounts required by a retroactive price reduction, after computing liquidations and payments on past invoices at the reduced prices and adjusting the unliquidated progress payments accordingly. The Government reserves the right to unilaterally change from the ordinary liquidation rate to an alternate rate when deemed appropriate for proper contract financing.

(c) Reduction or suspension. The Contracting Officer may reduce or suspend progress payments, increase the rate of liquidation, or take a combination of these actions, after finding on substantial evidence any of the following conditions:

(1) The Contractor failed to comply with any material requirement of this contract (which includes paragraphs (f) and (g) of this clause).

(2) Performance of this contract is endangered by the Contractor's --

(i) Failure to make progress or

(ii) Unsatisfactory financial condition.

(3) Inventory allocated to this contract substantially exceeds reasonable requirements.

(4) The Contractor is delinquent in payment of the costs of performing this contract in the ordinary course of business.

(5) The fair value of the undelivered work is less than the amount of unliquidated progress payments for that work.

(6) The Contractor is realizing less profit than that reflected in the establishment of any alternate liquidation rate in paragraph (b) of this clause, and that rate is less than the progress payment rate stated in subparagraph (a)(1) of this clause.

(d) Title.

(1) Title to the property described in this paragraph (d) shall vest in the Government. Vestiture shall be immediately upon the date of this contract, for property acquired or produced before that date. Otherwise, vestiture shall occur when the property is or should have been allocable or properly chargeable to this contract.

(2) "Property," as used in this clause, includes all of the below-described items acquired or produced by the Contractor that are or should be allocable or properly chargeable to this contract under sound and generally accepted accounting principles and practices.

(i) Parts, materials, inventories, and work in process;

(ii) Special tooling and special test equipment to which the Government is to acquire title;

(iii) Nondurable (i.e., noncapital) tools, jigs, dies, fixtures, molds, patterns, taps, gauges, test equipment, and other similar manufacturing aids, title to which would not be obtained as special tooling under paragraph (d) (2)(ii) of this clause; and

(iv) Drawings and technical data, to the extent the Contractor or subcontractors are required to deliver them to the Government by other clauses of this contract.

(3) Although title to property is in the Government under this clause, other applicable clauses of this contract; e.g., the termination clauses, shall determine the handling and disposition of the property.

(4) The Contractor may sell any scrap resulting from production under this contract without requesting the Contracting Officer's approval, but the proceeds shall be credited against the costs of performance.

(5) To acquire for its own use or dispose of property to which title is vested in the Government under this clause, the Contractor must obtain the Contracting Officer's advance approval of the action and the terms. The Contractor shall

(i) exclude the allocable costs of the property from the costs of contract performance, and (ii) repay to the Government any amount of unliquidated progress payments allocable to the property. Repayment may be by cash or credit memorandum.

(6) When the Contractor completes all of the obligations under this contract, including liquidation of all progress payments, title shall vest in the Contractor for all property (or the proceeds thereof) not--

(i) Delivered to, and accepted by, the Government under this contract; or

(ii) Incorporated in supplies delivered to, and accepted by, the Government under this contract and to which title is vested in the Government under this clause.

(7) The terms of this contract concerning liability for Government-furnished property shall not apply to property to which the Government acquired title solely under this clause.

(e) Risk of loss. Before delivery to and acceptance by the Government, the Contractor shall bear the risk of loss for property, the title to which vests in the Government under this clause, except to the extent the Government expressly assumes the risk. The Contractor shall repay the Government an amount equal to the unliquidated progress payments that are based on costs allocable to property that is lost (see 45.101).

(f) Control of costs and property. The Contractor shall maintain an accounting system and controls adequate for the proper administration of this clause.

(g) Reports, forms, and access to records. (1) The Contractor shall promptly furnish reports, certificates, financial statements, and other pertinent information (including estimates to complete) reasonably requested by the Contracting Officer for the administration of this clause. Also, the Contractor shall give the Government reasonable opportunity to examine and verify the Contractor's books, records, and accounts.

(2) The Contractor shall furnish estimates to complete that have been developed or updated within six months of the date of the progress payment request. The estimates to complete shall represent the Contractor's best estimate of total costs to complete all remaining contract work required under the contract. The estimates shall include sufficient detail to permit Government verification.

(3) Each Contractor request for progress payment shall:

(i) Be submitted on Standard Form 1443, Contractor's Request for Progress Payment, or the electronic equivalent as required by agency regulations, in accordance with the form instructions and the contract terms; and

(ii) Include any additional supporting documentation requested by the Contracting Officer.

(h) Special terms regarding default. If this contract is terminated under the Default clause, (i) the Contractor shall, on demand, repay to the Government the amount of unliquidated progress payments and (ii) title shall vest in the Contractor, on full liquidation of progress payments, for all property for which the Government elects not to require delivery under the Default clause. The Government shall be liable for no payment except as provided by the Default clause.

(i) Reservations of rights.

(1) No payment or vesting of title under this clause shall --

(i) Excuse the Contractor from performance of obligations under this contract or

(ii) Constitute a waiver of any of the rights or remedies of the parties under the contract.

(2) The Government's rights and remedies under this clause

(i) Shall not be exclusive but rather shall be in addition to any other rights and remedies provided by law or this contract and

(ii) Shall not be affected by delayed, partial, or omitted exercise of any right, remedy, power, or privilege, nor shall such exercise or any single exercise preclude or impair any further exercise under this clause or the exercise of any other right, power, or privilege of the Government.

(j) Financing payments to subcontractors. The financing payments to subcontractors mentioned in paragraphs (a)(1) and (a)(2) of this clause shall be all financing payments to subcontractors or divisions, if the following conditions are met:

(1) The amounts…