am2.pdf

AMENDMENT NO. 0002 FUEL SYSTEM MAINTENANCE HANGAR

W912BV-08-R-2014 VANCE AFB, OK

AMENDMENT OF SOLICITATION

1. CONTRACTOR ID CODE

NOT APPLICABLE (NA) PAGE 1 OF

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If Applicable)

0002 8 Jul 08 NA NA

6. ISSUED BY

CODE

7. ADMINISTERED BY (If other than Item 6)

CODE

DISTRICT ENGINEER

TULSA DISTRICT, CORPS OF ENGINEERS

1645 SOUTH 101ST EAST AVENUE

TULSA, OK 74128-4609

NA

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (%) 9A. AMENDMENT OF SOLICITATION NO.

W912BV-08-R-2014

% 9B. DATED (SEE ITEM 11)

26 Jun 08

10A. MODIFICATION OF CONTRACT/ORDER NO.

NA

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE NA

11. THIS ITEM APPLIES ONLY TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, X is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (if required)

NA

NA 13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14

(%) A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b)

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not; is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

SEE ATTACHED CONTINUATION SHEET

NOTE: IN THIS AMENDMENT “SOLICITATION NO.”, “OFFER”, AND “OFFEROR” MEAN “INVITATION NO.”, “BID”, AND “BIDDER”, RESPECTIVELY Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as hertofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

NA

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

NA NA

(Signature of person authorized to sign) (Signature of person authorized to sign)

NSN 7540-01-162-8070 30-105-02 STANDARD FORM 30 (REV. 10-8)

PREVIOUS EDITION UNUSABLE Prescribed by GSA

AMENDMENT 0002

FUEL SYSTEM MAINTENANCE HANGAR

VANCE AFB, OK

W912BV-08-R-2014

The Request for Proposal documents are revised as follows:

Section 00100, paragraph 1. PREPROPOSAL CONFERENCE:

a. 1st subparagraph: Delete “9 July 2008”; replace with “16 July 2008”.

b. 4th subparagraph: Delete “7 July 2008”; replace with “14 July 2008”.

Section 00110, paragraph 1.13.1: Delete “$6,539,690”; replace with “$7,072,000 (Base Proposal Only)”.

Section 00800: Paragraph 2, SCR 52.0000-4002 WAGE RATES: Delete the existing paragraph and associated Wage Rates; replace with the attached revised paragraph and associated Wage Rates.

Section 01 04 00, paragraph 1.2: Delete “directed”; replace with “allowed”.

Section 01 44 00, paragraph 3.4.2: Delete “The CQC Manager shall be assigned as system Manager but may have duties as project superintendent in addition to quality control.” Replace with “The CQC Manger shall be assigned no other duties.”

Attachment 1 – Distribution Schedule: Delete the existing Attachment 1; replace with the attached revised Attachment 1.

00800-1 W912BV-08-R-2014

SECTION 00800

SPECIAL CONTRACT REQUIREMENTS

CLAUSES INCORPORATED BY FULL TEXT

1. 52.0000-4001 CONTRACTING OFFICER

The Contracting Officer signing this contract is the primary Contracting

Officer on this contract. However, any Contracting Officer assigned to the

Tulsa District and acting within his authority may take formal action on this contract when a contract action needs to be taken and the primary

Contracting Officer is away from the office. The e-mail address for all

Contracting Officers in the Tulsa District is:

Cheryl.Wickson@usace.army.mil.

2. 52.0000-4002 WAGE RATES

The following Wage Determination No.(s) are attached and made a part hereof:

General Decision Nos: OK080014, with 7 modifications, dated 07/04/2008, and OK080001, dated 02/08/2008

(End of clause)

3. 52.0000-4020 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 1989)

(ER 415-1-15)

1. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the contract clause entitled "Default: (Fixed Price Construction)". In order for the

Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

2. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

4 1 3 4 4 4 4 3 4 3 2 3

Revised by Am 0002

Revised by AM 0002 00800-5

SOLICITATION NO. W912BV-08-R-2014

DESIGN AND CONSTRUCT FUEL MAINTENANCE HANGAR

VANCE AIR FORCE BASE, GARFIELD COUNTY, OKLAHOMA

APPLICABILITY OF WAGE RATES

Wage Decision No. OK080014, Building Construction, with seven modifications, dated 07/04/2008, is applicable to construction, demolition, renovation, alteration, or repair of buildings, installations within buildings, appurtenances to buildings, foundations for buildings, excavation and fill for buildings, landscaping incidental to building construction, and utilities within 5 feet of building.

Wage Decision No. OK080001, Heavy Sewer and Water Line and Highway Construction, dated 02/08/2008, is applicable to construction work beyond 5 feet of the building.

PLEASE NOTE: The applicable wage decision must be referenced on each payroll.

Revised by AM 0002 00800-6

Revised by AM 0002 00800-7

General Decision Number: OK080014 07/04/2008 OK14

Superseded General Decision Number: OK20070014

State: Oklahoma

Construction Type: Building

Counties: Alfalfa, Beckham, Blaine, Caddo, Carter, Comanche, Cotton, Custer, Dewey, Ellis, Garfield, Garvin, Grady, Grant, Greer, Harmon, Harper, Jackson, Jefferson, Johnston, Kay, Kingfisher, Kiowa, Love, Major, Marshall, Murray, Noble, Pontotoc, Roger Mills, Stephens, Tillman, Washita, Woods and

Woodward Counties in Oklahoma.

BUILDING CONSTRUCTION PROJECTS (does not include residential construction consisting of single family homes and apartments up to and including 4 stories)

Modification Number Publication Date

0 02/08/2008

1 02/15/2008

2 04/18/2008

3 05/09/2008

4 05/30/2008

5 06/06/2008

6 06/27/2008

7 07/04/2008

W912BV-08-R-2014, DESIGN AND CONSTRUCT FUEL MAINTENANCE HANGAR, VANCE AIR

FORCE BASE, GARFIELD COUNTY, OKLAHOMA

OK080014 – 1 07/04/2008

Revised by AM 0002 00800-8

ASBE0064-002 07/16/2002

KAY COUNTY

Rates Fringes

Asbestos Workers/Insulator.......$ 18.15 5.89

SCOPE OF WORK:

Includes application of all insulating materials, protective coverings, coatings and finishings to all types of mechanical systems.

ASBE0066-002 03/01/2008

BECKHAM, ELLIS, GREER, HARMON, HARPER AND ROGER MILLS COUNTIES

Rates Fringes

Asbestos Workers/Insulator.......$ 17.84 8.13

Scope of Work:

Includes application of all insulation materials, protective coverings, coatings and finishings to all types of mechanical systems.

ASBE0094-003 07/16/2006

REMAINING COUNTIES

Rates Fringes

Asbestos Workers/Insulator.......$ 23.49 10.26

SCOPE OF WORK:

Includes application of all insulation materials, protective coverings and finishings to all types of mechanical systems.

BOIL0592-001 08/08/2006

Rates Fringes

BOILERMAKER......................$ 23.47 13.91

BROK0005-012 06/01/2007

BECKHAM, CADDO, CARTER, COMANCHE, COTTON, CUSTER, DEWEY,

GARVIN, GRADY, GREER, HARMON, JACKSON, JEFFERSON, JOHNSTON,

KIOWA, LOVE, MARSHALL, PONTOTOC, ROGER MILLS, STEPHENS, TILLMAN

AND WASHITA COUNTIES

Rates Fringes

Bricklayer, Stonemason...........$ 22.61 8.30

BROK0005-013 06/01/2007

ALFALFA, BLAINE, ELLIS, GARFIELD, GRANT, HARPER, KINGFISHER,

MAJOR, WOODS AND WOODWARD COUNTIES

Rates Fringes

Bricklayer, Stonemason...........$ 22.61 8.30

BROK0005-014 06/01/2007

KAY AND NOBLE COUNTIES

Rates Fringes

Bricklayer, Stonemason...........$ 22.61 8.30

CARP0329-002 06/01/1997

BECKHAM, BLAINE, CADDO, COMANCHE, COTTON, DEWEY, GARVIN

(Remainder of County), GRADY, GREER, HARMON, JACKSON, JEFFERSON, KINGFISHER (South of the Cimmarron River), KIOWA, STEPHENS, TILLMAN AND WASHITA COUNTIES

Rates Fringes

Carpenters:

CARPENTERS & POWER SAW

OPERATORS...................$ 15.50 2.80

MILLWRIGHTS & PILEDRIVERMEN.$ 16.90 2.80

OK080014 – 2 07/04/2008

Revised by AM 0002 00800-9

CARP1362-002 01/01/1995

CARTER, GARVIN ( Northern half of Garvin including the Towns of

Pauls Valley and Wynnwood), JOHNSTON, LOVE, MARSHALL, MURRAY

AND PONTOTOC COUNTIES

Rates Fringes

Carpenters:......................$ 13.40 2.85

MILLWRIGHT.......................$ 15.50 2.85

PILEDRIVERMAN....................$ 13.65 2.85

CARP1686-004 06/11/1994

NOBLE COUNTY (East of Interstate #35 and South of Black Bear

Creek)

Rates Fringes

Carpenters:

CARPENTERS..................$ 14.40 .80

MILLWRIGHTS.................$ 15.05 .80

PILEDRIVERMEN...............$ 14.40 .80

POWER SAW OPERATOR..........$ 14.40 .80

CARP1894-001 06/01/1993

ELLIS, HARPER, ROGER MILLS, WOODS AND WOODWARD COUNTIES

Rates Fringes

Carpenters:

CARPENTERS..................$ 11.55 1.40

MILLWRIGHTS.................$ 12.425 1.40

PILEDRIVERMEN...............$ 12.425 1.40

POWER SAW OPERATOR..........$ 11.85 1.40

CARP2008-001 06/01/1994

ALFALFA, GARFIELD, GRANT, KAY, MAJOR, NOBLE (West of Interstate

# 35 and North of Black Bear Creek) COUNTIES

Rates Fringes

Carpenter; Millwright;

Piledrivermen....................$ 12.30 .30

CARP2008-002 06/01/1994

ALFALFA, GARFIELD, GRANT AND MAJOR COUNTIES

Rates Fringes

LATHER...........................$ 12.30 .30

ELEC0020-002 06/01/2003

MARSHALL COUNTY

Rates Fringes

ELECTRICIAN......................$ 21.40 4.25%+4.19

ELEC0444-002 08/29/2007

KAY AND NOBLE COUNTIES

Rates Fringes

ELECTRICIAN......................$ 23.75 7.55+3.5%

ELEC1002-002 09/01/2007

Rates Fringes

Line Construction

Cable Splicer...............$ 27.00 4.75+25.5%

Groundman...................$ 16.75 4.75+25.5%

Hole Digger, Heavy

Equipment Op., (Pole Cat

Equivalent).................$ 22.25 4.75+25.5%

OK080014 – 3 07/04/2008

Revised by AM 0002 00800-10

Jackhammer Op...............$ 17.50 4.75+25.5%

Line Truck Driver (Winch op.)........................$ 19.50 4.75+25.5%

Lineman.....................$ 25.00 4.75+25.5%

Powderman...................$ 21.50 4.75+25.5%

Truck Driver (Flat Bed, Ton & 1/2) and Under).....$ 16.75 4.75+25.5%

ELEC1141-004 05/28/2008

ALFALFA, BECKHAM, BLAINE, CADDO, CARTER, CUSTER, DEWEY, ELLIS,

GARFIELD, GARVIN, GRADY, GRANT, HARPER, JOHNSON, KINGFISHER,

LOVE, MAJOR, MURRY, PONTOTOC, ROGER MILLS, WASHITA, WOODS AND

WOODWARD COUNTIES

Rates Fringes

ELECTRICIAN......................$ 24.40 17.25%+4.50

ELEC1141-005 12/01/2004

ALFALFA, BECKHAM, BLAINE, CADDO, CARTER, COMANCHE, CUSTER,

DEWEY, ELLIS, GARFIELD, GARVIN, GRADY, GRANT, HARPER, JOHNSON,

KINGFISHER, LOVE, MAJOR, MURRAY, PONTOTOC, ROGER MILLS,

WASHITA, WOODS AND WOODWARD COUNTIES

Rates Fringes

Electricians:

Sound & Communication

Technicians.................$ 21.70 17.25%+4.50

ELEC1141-008 05/28/2008

COMANCHE, COTTON, GREER, HARMON, JACKSON, JEFFERSON, KIOWA,

STEPHENS AND TILLMAN

Rates Fringes

Electricians:....................$ 24.40 17.25%4.50

ELEV0063-003 01/01/2005

Rates Fringes

Elevator Constructor

Mechanic....................$ 26.885 12.115+a

FOOTNOTE:

a. Paid Holidays: New Year's Day; Memorial Day; July 4th;

Labor Day; Thanksgiving Day; Friday after Thanksgiving

Day; Christmas Day., Vacation Pay Credit: Employer contributes 8% of the basic hourly rate for employees with

5 years or more of service or 6% of the basic hourly rate for employees with 6 months to 5 years of service.

ENGI0627-005 06/01/2007

Rates Fringes

Power Equipment Operator

GROUP 1:...................$ 22.70 9.00

GROUP 2:...................$ 21.95 9.00

GROUP 3:...................$ 21.45 9.00

GROUP 4:...................$ 20.95 9.00

GROUP 5:...................$ 20.45 9.00

GROUP 6:...................$ 20.20 9.00

GROUP 7:...................$ 19.80 9.00

GROUP 8:...................$ 18.20 9.00

GROUP 9:...................$ 17.70 9.00

GROUP 10:...................$ 17.20 9.00

GROUP 1: All crane type equipment with at least 300 feet of boom and over (including jib)

OK080014 – 4 07/04/2008

Revised by AM 0002 00800-11

GROUP 2: All crane type equipment with at least 200 feet and less than 300 feet of boom (including jib)

GROUP 3: All crane type equipment with at least 100 feet and less than 200 feet of boom (including jib); all tower cranes; crane equipment (as rated by mfg.) 3 cu. yd. and over; guy derrick; whirley; power driven hole digger (with

30 feet and longer mast)

GROUP 4: Cranes with less than 100 feet of boom with jib and cranes (as rated by mfg.) less than 3 cu. yd.; heavy duty mechanic; overhead monorail type crane; panel board batch plant op.; piledriver engineer; dragline; clamshell;

backhoe (3/4 yd. and over); sideboom or similar type equipment; gradall; cherry picker; hoist (while operating two or more drums); all hoist (while doing stack and chimmey work); power driven hole digger with less than 30

ft. mast; motor patrol (boom type)

GROUP 5: Dozer (engine r.p. 65 or over); roller and compactors with dozer blade; backhoe under 3/4 yd., all scraper type equipment; water wagons under the jurisdiction of this craft; loader of hi-lift (engine h.p. 65 or over);

asphalt laying machine; conveyor-multiple, panel board central; trenching machine; concrete pump (boom type)

GROUP 6: Rollers, all types; oil distributor; pulvimixer;

screed operator; concrete pump (trailer type); rotary drilling machine when operated from console; greaser; tilt top trailer operator.

GROUP 7: Greaser; tilt top trailer operator

GROUP 8: Locomotive engineer; boring machine; tug boat; mixer

- 18 cu. ft. and over; sand barge; dredging machine;

tugger; hoist (operating one drum); air compressor - 3 to 6

- size 500 cu. ft. and under; air compressor - over 500 cu.

ft. (1); pump, battery - 3 to 6; all fork-lift, bobcat and similar equipment; generator plant engineer, diesel elect;

winch truck with A frame; concrete buster buster or tamper;

heater under jurisdiction of operating engineers; fireman;

boiler operator; crushing plants; farm tractor with or without attachments; batch plant opperator - (portable);

conveyor operator - continuous belt bulking handling; form grader; screening plant; well point pump operator; signal man on whirley when and if required; outside, side elevator or construction type hoist personel.

GROUP 9: Concrete mixers, less than 18 cu. ft.; air compressor, 500 cu. ft. and under (1 or 2); fuelman;

asphalt lay machine backend man.

GROUP 10: Truck crane oiler and driver; crane oiler;

permanent building type elevator operator.

* IRON0048-002 06/01/2008

BLAINE, CADDO, CARTER, COMANCHE, CUSTER, DEWEY, GARFIELD,

GARVIN, GRADY, JOHNSTON, KINGFISHER, KIOWA, MAJOR, MURRAY,

OK080014 – 5 07/04/2008

Revised by AM 0002 00800-12

NOBLE, PONTOTOC, ROGER MILLS, STEPHENS, WASHITA AND WOODWARD

COUNTIES

Rates Fringes

Ironworkers:.....................$ 22.10 10.01

IRON0263-005 06/01/2007

MARSHALL COUNTY

Rates Fringes

Ironworkers:.....................$ 20.10 4.60

IRON0263-006 06/01/2007

BECKHAM, COTTON, ELLIS, GREER, HARMON, HARPER, JACKSON

JEFFERSON, LOVE AND TILLMAN COUNTIES

Rates Fringes

Ironworkers:.....................$ 20.10 4.90

* IRON0584-006 06/01/2008

KAY COUNTY (The southern portion to a line running east and west at the South City limits of Ponca City), Rates Fringes

Ironworkers:.....................$ 22.10 10.01

IRON0606-003 06/01/2008

ALFALFA, GRANT, KAY (Remainder of County), AND WOODS COUNTIES

Rates Fringes

Ironworkers:.....................$ 20.15 8.70

LABO0462-002 06/01/1993

Rates Fringes

Laborers:

ALFALFA, BECKHAM, BLAINE,

CADDO, CARTER, COMANCHE,

COTTON, CUSTER, DEWEY,

ELLIS, GARFIELD, GARVIN,

GRADY, GRANT, GREER,

HARMON, HARPER, JACKSON,

JEFFERSON, KINGFISHER,

KIOWA, LOVE, MAJOR,

MARSHALL, MURRAY, ROGER

MILLS, STEPHENS, TILLMAN,

WASHITA, WOODS AND

WOODWARD COUNTIES

GROUP 1....................$ 7.50 1.31

GROUP 2....................$ 8.00 1.31

JOHNSTON, KAY, NOBILE AND

PONTOTOC COUNTIES

GROUP 1....................$ 8.00 1.31

GROUP 2....................$ 8.50 1.31

LABORER CLASSIFICATION

GROUP 1 - All digging and dirt work; Firing of salamanders and portable space heaters; All loading and unloading ofthe materials and equipment to and from hoist or cages for stock piling only; Wheeling and placing of concrete;

Handling of lumber, steel, cement and distribution of materials; All cleaning including windows; All wrecking and razing of buildings and all structures; Cleaning and clearing of derbis; Loading and unloading of materials, OK080014 – 6 07/04/2008

Revised by AM 0002 00800-13 hoist or cages, except when the man is directly tending lathers, masons or plasterers; Water boys when used;

Carpenters tenders.

GROUP 2 - All machine tool operators that come under the jurisdiction of the laborers; All sewer and draintile layers and handling at the ditch, excluding distribution;

Operators of water pumps up to four inches and slip form jackets; All men erecting scaffolds and directly tending lathers, masons, cement masons and plasterers, Mortar mixers, hod carriers and dry mixers; High work over 30 feet from ground or floors; Cement finisher tender; Work on swinging scaffold; All kettle and pot men; Tank cleaning;

All pipe doping, treating and wrapping including all men working with dope; Mortar and plaster mixing machine pumpcrete machine and gunite mixing machines; including placing of concrete; Handling creosoted or treated materials liquid acid or like materials when injurious to health, eyes, skin or clothes; All newly developed mechanical equipment which replaces wheel-barrows or buggies previously used by loaders; All scale men on batch plants and tool crib men; All laborers screening sand, running sand drier and feeding operating sand blaster, except nozzle; Flaggers; Concrete graders and cutting torch operators in connection with laborers' work.

PAIN0807-001 06/15/2004

Rates Fringes

Painters:

Brush & Roller..............$ 18.00 2.35

Paper Hanging...............$ 19.00 2.35

Spray, Sandblasting &

Water blasting over 30 ft.$ 19.00 2.35

Spray, Sandblasting &

Water blasting under 30 ft..........................$ 18.00 2.35

Tapers using machine tools..$ 18.00 2.35

PLAS0690-001 06/01/1985

JOHNSTON AND MARSHALL COUNTIES

Rates Fringes

Cement Masons:...................$ 13.70 .76

PLAS0786-001 06/01/1993

KAY COUNTY

Rates Fringes

Cement Masons:...................$ 10.80

Power Tool Operator..............$ 11.05

PLAS0807-001 06/01/1990

ALFALFA, BECKHAM, BLAINE, CADDO, CARTER, COMANCHE, COTTON,

CUSTER, DEWEY, ELLIS, GARFIELD, GARVIN, GRADY, GRANT, GREER,

HARMON, HARPER, JACKSON, JEFFERSON, JOHNSTON, KINGFISHER,

KIOWA, LOVE, MAJOR, MARSHALL, MURRAY, NOBLE, ROGER MILLS,

STEPHENS, TILLMAN, WASHITA, WOODS AND WOODWARD COUNTIES

Rates Fringes

PLASTERER........................$ 15.60 .95

OK080014 – 7 07/04/2008

Revised by AM 0002 00800-14

* PLUM0344-003 07/01/2008

REMAINING COUNTIES

Rates Fringes

PLUMBER/PIPEFITTER...............$ 25.88 10.92

* PLUM0430-005 07/01/2008

KAY COUNTY

Rates Fringes

PLUMBER/PIPEFITTER...............$ 25.71 0.00

ROOF0143-001 06/01/2008

Rates Fringes

ROOFER, Including Built Up, Composition and Single Ply

Roofs............................$ 19.32 5.03

SHEE0124-001 07/01/2001

Rates Fringes

Sheet metal worker (Including

Duct Work).......................$ 21.62 6.04

TEAM0516-001 06/01/1993

MARSHALL COUNTY:

Rates Fringes

Truck drivers:

GROUP 1:....................$ 10.43

GROUP 2:....................$ 10.53

GROUP 3:....................$ 10.63

GROUP 4:....................$ 10.58

GROUP 5:....................$ 10.73

TRUCK DRIVER CLASSIFICATIONS

GROUP 1 - Pick-up, 1-1/2 tons or 2-1/2 yards and up to but not including 3 tons or 4 yards, such as dump trucks, flat beds, stake bodies and buses.

GROUP 2 - 3 tons or 4 yards and up to but not including 4 tons or 6 yards.

GROUP 3 - 5 tons or 6 yards and over including heavy equipment such as pole trucks, winch trucks, euclids, mississippi wagons, semi-dumps, turner pulls or other heavy material moving equipment, tractor trailor drivers and similar equipment such as tractors, ten wheelers.

GROUP 4 - Ready mix concrete trucks up to but not including 3 yards and over.

GROUP 5 - Ready mix concrete truck 3 yards and over.

TEAM0523-001 06/01/1993

KAY AND NOBLE COUNTIES

Rates Fringes

Truck drivers:

GROUP 1:....................$ 12.80

GROUP 2:....................$ 12.85

GROUP 3:....................$ 12.95

OK080014 – 8 07/04/2008

Revised by AM 0002 00800-15

TRUCK DRIVER CLASSIFICATION

GROUP 1 - Truck Drivers, Including pick-up, 1- 1/2 tons to

2-1/2 yards up to but not including 3 tons or 4 yards, such as dump trucks, flat beds, stake body or bus driver.

GROUP 2 - 3 tons or 4 yards up to but not including 4 tons or

6 yards.

GROUP 3 - Ready mix concrete truck, tractor trailer and similar equipment.

TEAM0886-001 06/01/1980

ALFALFA, BECKHAM, BLAINE, CADDO, CARTER, COMANCHE, COTTON,

CUSTER, DEWEY, ELLIS, GARFIELD, GARVIN, GRADY, GRANT, GREER,

HARMON, HARPER, JACKSON, JEFFERSON, JOHNSTON, KINGFISHER,

KIOWA, LOGAN, LOVE, MAJOR, MURRAY, PONTOTOC, ROGER MILLS,

STEPHENS, TILLMAN, WASHITA, WOOD AND WOODWARD COUNTIES.

Rates Fringes

Truck drivers:

GROUP 1:....................$ 9.70

GROUP 2:....................$ 9.40

TRUCK DRIVER CLASSIFICATION

GROUP 1 - Truck Drivers for heavy equipment such as lowboys, heavy winch and floats, heavy earth moving equipment such as dump trucks and euclids.

GROUP 2 - Truck Drivers and swampers, such as dump trucks, flat beds, stakebodies and 3/4 and 1/2 ton pick-up trucks.

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses

(29CFR 5.5 (a) (1) (ii)).

In the listing above, the "SU" designation means that rates listed under the identifier do not reflect collectively bargained wage and fringe benefit rates. Other designations indicate unions whose rates have been determined to be prevailing.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

OK080014 – 9 07/04/2008

Revised by AM 0002 00800-16

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour

Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the

Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the

Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations

Wage and Hour Division

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator

(See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative

Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

OK080014 – 10 07/04/2008

Revised by AM 0002 00800-17

General Decision Number: OK080001 02/08/2008 OK1

Superseded General Decision Number: OK20070001

State: Oklahoma

Construction Types: Heavy Sewer and Water Line and Highway

Counties: Comanche, Garfield and Sequoyah Counties in

Oklahoma.

Construction, alteration, and/or repair of streets, highways, runways, erosion control structures, and water and sewer utilities, (but does not include building structures on highway rest areas).

Modification Number Publication Date

0 02/08/2008

W912BV-08-R-2014, DESIGN AND CONSTRUCT FUEL MAINTENANCE HANGAR, VANCE AIR

FORCE BASE, GARFIELD COUNTY. OKLAHOMA

OK080001 - 1 02/08/2008

Revised by AM 0002 00800-18

SUOK1991-002 12/12/1991

Rates Fringes

Air Tool Operator..............$ 6.50

Blaster........................$ 8.75

Carpenter......................$ 8.50

Concrete Finisher-Paving.......$ 8.60

Concrete Finisher-Structures...$ 8.00

Concrete Rubber................$ 6.50

Flag Person....................$ 6.25

Form Builder (Structures)......$ 7.50

Form Setter - Paving & Curb....$ 7.50

Form Setter-Structures.........$ 7.50

Labor Common...................$ 6.25

Manhole Inlet Builder..........$ 7.25

Mechanic.......................$ 9.00

Painter-Structures.............$ 7.00

Pile Driver....................$ 7.50

Pipelayer......................$ 7.50

Power equipment operators:

ASPHALT DISTRIBUTOR.........$ 7.55

ASPHALT HOT MIX PLANT.......$ 8.50

ASPHALT PAVING MACHINE......$ 8.55

ASPHALT PAVING MACHINE

SCREED......................$ 8.55

BACKHOE LOADER..............$ 8.30

BOX BLADE LOADER............$ 7.55

BROOM/SWEEPER...............$ 7.00

BULLDOZER (150 H.P. &

LESS).......................$ 8.40

BULLDOZER (OVER 150

H.P.).......................$ 8.75

CONCRETE MIXING PLANT.......$ 8.50

CONCRETE PAVING

CURING/TEXTURE/FLOAT........$ 8.50

CONCRETE PAVING

FINISHING MACHINE...........$ 8.55

CONCRETE PAVING FORM

GRADER......................$ 8.20

CONCRETE PAVING GRINDER.....$ 7.60

CONCRETE PAVING JOINT

SEALER......................$ 7.75

CONCRETE PAVING SPREADER....$ 8.50

CONCRETE SAW OPERATOR.......$ 7.40

CONCRETE SCREED MACHINE.....$ 7.75

CRANE, CLAMSHELL,

DERRICK, DRAGLINE,

SHOVEL (1 1/2 C.Y.&

LESS).......................$ 7.95

SHOVEL (OVER 1 1/2 C.Y.)....$ 8.50

CRUSHER & SCREENING

PLANT.......................$ 8.25

CURB MACHINE (SLIPFORM).....$ 8.30

FOUNDATION DRILL, TRUCK

MOUNTED.....................$ 11.85

FRONT END LOADER (2 1/2

C.Y. & LESS)................$ 7.75

FRONT END LOADER (OVER

2 1/2 C.Y.).................$ 8.45

OK080001 - 2 02/08/2008

Revised by AM 0002 00800-19

HYDRAULIC EXCAVATOR.........$ 8.65

MOTOR GRADER (FINE

GRADE)......................$ 9.05

MOTOR GRADER (ROUGH)........$ 8.00

PAVEMENT MARKING MACHINE....$ 8.00

PLANER, MILLING MACHINE.....$ 8.25

PUGMILL MIXING PLANT........$ 7.15

PUMPCRETE...................$ 7.15

REINFORCING STEEL

MACHINE.....................$ 7.40

ROLLER PNEUMATIC

(SELF-PROPELLED)............$ 7.45

ROLLER STEEL WHEEL

(OTHER).....................$ 7.45

(PLANT-MIX).................$ 7.85

SCRAPER (17 C.Y & LESS).....$ 8.30

SCRAPER (OVER 17 C.Y.)......$ 8.55

SELF-PROPELLED HAMMER.......$ 7.20

SIDE-BOOM...................$ 7.65

TRACTOR; (OVER 80 H.P.).....$ 7.65

TRACTOR; CRAWLER (150

H.P. & LESS)................$ 7.15

TRACTOR; CRAWLER (OVER

150 H.P.)...................$ 7.50

TRACTOR; PNEUMATIC (80

H.P. OR LESS)...............$ 7.45

TRAVELING MIXER.............$ 7.25

TRENCHING MACHINE...........$ 8.25

WAGON DRILL, BORING

MACHINE OR POST HOLE........$ 6.60

Reinforcing Steel Setter

Paving.........................$ 7.50

Reinforcing Steel Setter

Structures.....................$ 7.50

Servicer.......................$ 7.75

Sign Erector...................$ 8.00

Spreader Box Person............$ 7.00

Steel Worker Structures........$ 7.50

Traffic Control Device

Monitor........................$ 7.00

Traffic Signal Installer.......$ 11.50

Truck drivers:

LOWBOY, FLOAT...............$ 8.60

SINGLE AXLE, 2 TONS AND

UNDER.......................$ 6.85

SINGLE AXLE, OVER 2 TONS....$ 7.05

TANDEM AXLE AND SEMI

TRAILER.....................$ 7.30

Vibrator Operator - Hand

Type...........................$ 6.25

Welders - Receive rate prescribed for craft performing operation to which welding is incidental.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses

(29CFR 5.5 (a) (1) (ii)).

OK080001 - 3 02/08/2008

Revised by AM 0002 00800-20

In the listing above, the "SU" designation means that rates listed under the identifier do not reflect collectively bargained wage and fringe benefit rates. Other designations indicate unions whose rates have been determined to be prevailing.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour

Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the

Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the

Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations

Wage and Hour Division

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator

(See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative

Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

OK080001 - 4 02/08/2008

ATTACHMENT 1

DISTRIBUTION SCHEDULE

Activity and Address Drawing

Size (Fullsize)

Design Analysis &

Specs

Drawing Size

(Halfsize)

CD-ROM

(PDF &

CADD)

Structural Interior Design

Rory Wale U.S Army Corps of Engineers

ATTN: CESWT-EC-DM

1645 South 101st East Avenue Tulsa, OK 74128-4609

0 5 5 5 5

Patrick Beard U.S Army Corps of Engineers

ATTN: CESWT-EC-DM

1645 South 101st East Avenue Tulsa, OK 74128-4609

0 1 1 1 1

Mr. Lew Hollis 140 Channel St., Suite 102 Vance AFB, OK 73705-5611

0 7 7 4 7

Mr. Dan Harris CSC Civil Engineering 140 Channel Street, Suite 201 Vance AFB, OK 73705-5621

1 7 7 4 7

HQ AFCEE/CMW

ATTN: Mr. Joe Hockaday 330 Sidney Brooks Books City-Base, TX 78235-5122

0 3 3 1 3

USACE Central OK Resident Office Attn: Jerry Grosz 140 Channel Street Vance AFB, OK 73705-5610

C.H. Guernsey & Co.

ATTN: Bill Cupp, AIA 5555 N. Grand Blvd Oklahoma City, OK 73112-5507

0 6 6 6 6

Note: The Distribution Schedule gives the number and type of copies due at each submittal stage.

m5ecdckd Typewritten Text m5ecdckd Typewritten Text m5ecdckd Typewritten Text m5ecdckd Typewritten Text m5ecdckd Typewritten Text Revised by Am 0002