09b0020amend4.pdf

Amendment No. 0004

JSE

SOLICITATION NUMBER: W912BU-09-B-0020

PROJECT TITLE: JOINT SATCOM ENGINEERING CENTER, C4ISR CAMPUS, ABERDEEN PROVING GROUND, MD

ISSUE DATE: JULY 7, 2009

BID OPENING DATE: AUGUST 14, 2009, 11:00 AM, LOCAL TIME AT PLACE OF BID OPENING

This is an unrestricted procurement. NAICS Code 237130 is applicable to this procurement.

SITE VISIT: A site visit is scheduled for July 20, 2009 beginning at 1:30 PM from the Philadelphia District APG-IPO C4ISR Office, Building 5414, Washington Loop & Boothby Hill Road, APG, MD. All interested parties must notify either Margaret Boyd-Anderson at 410-278-0202 (margaret.l.boyd-anderson@usace.army.mil) or Bobbi Schilling at 410-278-4822 (roberta.h.schilling2@usace.army.mil).

Please be advised that you will be requested to present a photo I.D. to gain access to Aberdeen Proving Ground. Other security measures may apply on the specific date of the site visit depending on force protection level in effect that day.

X

DENISE M DETITTA 215-656-6775

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED(RFP)

(IFB)

CALL:

B. TELEPHONE NO.

TEL:

(Include area code) (NO COLLECT CALLS)

US Army Corps of Engineers, Philadelphia Attention: Contracting Division, Room 643 (DeTITTA) Wanamaker Building 100 Penn Square East Philadelphia, PA 19107-3390

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442

Prescribed by GSA

(REV. 4-85)

11. The Contractor shall begin performance within ___*____calendar days and complete it within ___*_____calendar days after receiving award, X notice to proceed. This performance period is X mandatory, negotiable. (See Sect 00800, SC-1*_______________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________ copies to perform the work required are due at the place specified in Item 8 by 11:00 AM 1 local time August 14, 2009 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______ 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

8. ADDRESS OFFER TO

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

(hour) Sealed envelopes containing offers

FAX:

(If Other Than Item 7)

6. PROJECT NO.

7. ISSUED BY CODE

W912BU-09-B-0020

TEL: FAX:

5. REQUISITION/PURCHASE REQUEST NO.

W912BU

US ARMY ENGINEER DISTRICT, PHILADELPHIA

CONTRACTING DIVISION

WANAMAKER BUILDING

100 PENN SQUARE

PHILADELPHIA PA 19107-3390

FAR (48 CFR) 53.236-1(e)

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY: 26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR (Include area code) 15. TELEPHONE NO.

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your offer on this solicitation, is hereby accepted as to the items listed. This award con-to furnish and deliver all items or perform all work, requisitions identified summates the contract, which consists of (a) the Government solicitation and on this form and any continuation sheets for the consideration stated in this your offer, and (b) this contract award. No further contractual document is contract. The rights and obligations of the parties to this contract shall be necessary.

governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by refer-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

(Must be fully completed by offeror) OFFE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

14. DESCRIPTION OF AMENDMENT (continued)

a. VOLUME 1 OF 2:

(1) SF1442: Please delete current form SF1442 in its entirety and substitute revised SF1442, annotated Amendment No. 0004, attached hereto.

(2) Bid Schedule: Please delete page 00010-3 in its entirety and substitute revised page 00010-3, annotated Amendment No. 0004, attached hereto.

(3) Contract Clauses: Please delete pages 00700i and 00700-14 through 00700-17 in their entirety and substitute revised pages of the same numbers, annotated Amendment No. 0004, attached hereto.

(4) Special Contract Requirements: Please delete page 00 80 00–i in its entirety and substitute revised page 00 80 00-i annotated Amendment No, 0004, attached herto.

(5) Section 00 80 00 – SPECIAL CLAUSES: Please delete Section 00 08 00 in its entirety and substitute revised Section 00 80 00 annotated Amendment No. 0004, attached hereto.

(6) Section 00815 – WAGE RATES: Please delete Section 00815 in its entirety and substitute revised Section 00815 annotated Amendment No. 0004, attached hereto.

(7) Please delete the Project Table of Contents in its entirety and substitute the revised Project Table of Contents pages 1 and 2, annotated Amendment No. 0004, attached hereto.

87) Please delete the following sections in their entirety and substitute the revised sections of the same numbers, annotated Amendment No. 0004, attached hereto.

01 11 00 SUMMARY OF WORK

01 32 01 PROJECT SCHEDULE

01 32 33 CONSTRUCTION PHOTOGRAPHY

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENT SAFETY REQUIREMENTS

01 50 00 TEMPORARY CONSTRUCTION

01 78 00 CLOSEOUT SUBMITTALS

03 31 00 CAST-IN-PLACE CONCRETE

04 21 13 MASONRY

07 22 00 ROOF AND DECK INSULATION

07 42 13 METAL WALL PANELS

08 11 13 STEEL DOORS AND FRAMES

08 11 16 ALUMINUM DOORS AND FRAMES

08 14 00 WOOD DOORS

08 33 23 OVERHEAD COILING DOORS

08 44 10 CURTAIN WALL AND GLAZED ASSEMBLIES

08 81 00 GLAZING

09 69 13 RIDGID GRID ACCESS FLOORING

13 34 19 PRE-ENGINEERED STRUCTURAL FRAMING SYSTEM

(8) Please delete the following sections in their entirety.

08 44 00 08 51 13 07 42 63

(9) Please insert the following new sections, annotated Amendment No. 0004 attached hereto.

00 80 40 HAZARDOUS MATERIALS INVESTIGATION FINAL REPORT

02 81 00 TRANSPORTATION AND DISPOSAL OF HAZARDOUS MATERIALS

02 82 14 ASBESTOS HAZARD CONTROL ACTIVITIES

08 45 10 POLYCARBONATE WALL PANEL SYSTEM

09 29 77 WOOD VENEER WALL CLADDING SYSTEM

b. VOLUME 2 OF 2:

(1) Please delete the Project Table of Contents in its entirety and substitute the revised Project Table of Contents pages 1 and 2, annotated Amendment No. 0004, attached hereto.

(2) Please delete the following sections in their entirety and substitute the revised sections of the same numbers, annotated Amendment No. 0004, attached hereto.

23 08 00 COMMISSIONING OF HVAC SYSTEMS

23 09 23 BACnet DIRECT DIGITAL CONTROL SYSTEMS FOR HVAC

31 00 00 EARTHWORK

(3) Please delete the following section in its entirety.

32 31 00

(3) Please insert the following new sections, annotated Amendment No. 0004, attached hereto.

33 11 11 WATER MAINS

33 30 30 GRAVITY SEWER AND HOUSE CONNECTIONS

41 22 15 JIB CRANE

c. CONTRACT DRAWINGS:

(1) Please delete the following drawings in their entirety and substitute the revised drawings of the same numbers, with the latest revision date of 04 August 2009, attached hereto:

A-102 A-104 A-112 A- 113 A-114 A-401

CD-101

CP-101

CP-201

CP-301

CP-501

CP-502

CS-101

CS-501

CU-102

E-102

E-103 E-104 E-105 E-202 E-203 E-205 E-302 E-303 E-501 E-502 E-503 E-901 E-902 E-903 E-904 E-905

E-906 E-907 E-908 E-909 E-910 E-911 E-912, E-913 E-916

ES-101

G-1

GC-101

GC-102

GC-103

GC-503

GC-504

M-106 M-201 M-401 M-501 M-502 M-504 M-505 M-506 M-508

TN-102

TN-104

TN-105

TN-301

TN-505

TN-506

TY-105

(2) Please insert the following new drawings dated 03 August 2009, attached hereto:

CS103

S01 S02

SB101

SB201

SB301

SB401

SB501

SB601

SB701

SB801

ES103A

ES104

ES502

ES503

ES504

ES505

ES506

TS102A

TS502

d. RFIs with RESPONSES: RFIs with responses, annotated Amendment No. 0004 are attached to this amendment.

e. Please indicate receipt of this amendment on Standard Form 1442(SOLICITATION, OFFER, AND AWARD) as Amendment No. 0004. Failure to acknowledge all amendments may be cause for rejection of the bid.

A-304 Detail 1 on this sheet indicates waterproofing at the slab and walls where the access flooring is installed and exterior drainage requirements. Provide a Address by amendment

23 09 23

Section 23 09 23 page 8 paragraph c indicates that the DDC control system shall be an extension if the Johnson Metasys system . please clarify if the manufacture of the new DDC system for the Jsec project is to be Johnson Metasys or if alternatives are acceptable. Is Andover Bacnet system an acceptable alternative ? Addressed by amendment

No. 0004

23 09 23

Section 23 09 23 page 8 paragraph c indicates that the DDC control system shall be an extension if the Johnson Metasys system . please clarify if the manufacture of the new DDC system for the Jsec project is to be Johnson Metasys or if alternatives are acceptable. Is Andover Bacnet system an acceptable alternative ? Addressed by amendment

No. 0004

A-202

Reference Drawing No. A-202 and Specification Section 04-21-13. What is the actual material for the "stone veneer"? Addressed in Amendment

No. 0004

08-44-10 Performance Criteria on Pgs 7-9 left -out Addressed in Amendment

No. 0004

CP-301

Details 1 & 2 on this sheet do not indicate reinforcement steel or WWF in the concrete. Is this correct? Addressed in Amendment

No. 0004

23 08 00

Specification Section 23 08 00 Commissioning of HVAC Systems call for one of 3 certifications; ACG, NEEB or TABB certified. These certifications can only be held by contracting companies and not engineering firms. Most USACE Project specifications include as an acceptable means of certification for the Commissioning Specialist the following….Professional Engineer (P.E.) with a minimum of five years of HVAC design experience who is not associated with the design of this project, is licensed in the state where this project is located, and has a minimum of three years of HVAC commissioning experience and at least two projects of similar size and scope. Our firm specializes is this type of work, however would not be permitted to provide pricing if the qualifications of a Professional Engineer are not acceptable to the USACE. Our firm specializes is this type of work, however would not be permitted to provide pricing if the qualifications of a Professional Engineer are not acceptable to the USACE.

Addressed in Amendment No. 0004

A-202

Wall panel system type 4 is shown on elevations as a horizontal panel.

What type of panel is this? Addressed in amendment

No. 0004

A-202

On sheet A-202, Material legend note 17, Canopy, what type of canopy are you calling for? Are these in our scope of work? If they are, will we be issued a spec section? Addressed in Amentment

NO. 0004

A 604

Please provide glass types locations on the enlarged curtain wall elevations on A 604. Addressed in Section 08 81

00, Amendment No 0004

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm Typewritten Text Dwg/Spec Comment Response detail 1,2,and 3 each on dwgsA202, and A203 spec 07-42- 13 siding

The drawing notes 1, 2, & 3 indicate three different siding types 1 2 and 3 respectively. The siding is depicted as a vertical siding panel on the drawings. The specifications call for a 2.75" panel with an embossed finish.

Are all three types to be this same 2.75 " panel? If not, please provde the type of panel for each siding type. Please provide manufacturer used as a basis of design - similar to what was provided for interior finish schedule on A 604.

All three are the same type with different color. Basis of design Centria, Versawall Note: This section is replaced by Section 08 45 10 in Amendment No. 0004.

General

To allow for a more accurate excavation take-off will you release the Civil AutoCAD files that are associated with the Joint SATCOM Engineering Center?

AutoCAD files are not released until after award as indicated in the IFB.

00 80 00, SC-1

We were unable find an award date in the Solicitation. With a fixed date for completion a start date, on which to base the overall length of schedule, is needed to accurately price this project. Please provide an award date or the number of calendar days from the Notice to Proceed to completion.

Bid according to the IFB

TN 301 &

For the 15" ladder rack, is the tubular stringer that has 1 1/2" side rails desired? Bid ladder type per plans and specifications

Detail 1 A303

Please provide details to clarify the "bull nose" composite panel assemblies referenced on section 1 on A303. This is to help clarify the design of the composite panel assemblies around the strip curtain wall windows.

Bid per IFB

A-604 Elevation 2 interior vestibule no Details is it Aluminum or Hollow Metal

Bid per IFB. Refer to door and opening schedule on A- 602/A-603.

Please advise if borrow material will be available from a source on the Grounds, and if so provide location/distance travel. Borrow sources are the contractor's responsibility.

VF101

The Existing Conditions Plan references locations of existing foundations, bot no details are provided. No information can be drawn from the site visit as grass covers these locations. Please provide additional information/details of this concealed condition. If this information is not available, provide pictures from archives of the structures that existed on-

Buildings are believed to be WWII era one story wooden structures; no additional information is available.

A-602

Doors V.01a,V.02a and L .01a are called out Mtl Doors should they be Aluminum Correct as shown. Bid per

IFB.

CP-503 &

S-101

Sheet CP-503 shows a detail requiring footings to be undercut and backfilled with compated select fill. Confirm the only footings requiring this operation are footings F1 through F5 on sheet S-101 and not wall wall footings and grade beams. Correct. Bid according to the IFB

13 34 19

Reference Structural Drawings and Division 5 of the Specifications, and Spec Section 133419 (Pre-Engineered Structural Framing System). Is it your intention that the entire structural frame for the building be Design- Build within the parameters of Spec Section 133419 and incorporating Division 5 (Spec Sections 050523, 052113, 052116, 052119, 053000) and structural-related Miscellaneous Iron (Spec Section 055013)? And should we assume that no additional structural drawings (such as connection details or member sizes) shall be forthcoming? Correct. Bid according to the IFB.

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm

Dwg/Spec Comment Response

A-303

Provide more detail to clarify the "bull nose" composite panel assemblies referenced on section 1/A-303. This would help clarify the design of the composite panel assemblies around strip CW windows.

Details are a shop drawing submittal requirement. Bid per IFB

CS 101

At the east edge of the concrete hardstand, the edge treatment is not clear.

At the south east corner, fencing ties into it. It then travels north to a coordinate point, and then west to the building. Provide a detail of this condition. Is it a wall, fence line or another condition? Gravel mow strip as shown.

Bid per IFB

A-602

O)pening Schedule. Shouldn't these doors be aluminum and not hollow metal?

HM as per IFB

CU-101

Is the installation of the new gas line included in our scope of work? If so can we please have the WMB# or Application Reference # that was given to the Baltimore Gas and Energy for the installation of this line?

Installation will be by BGE.

Addressed in Amendment No. 0004

Standard Form 1442

Can you please direct us to were the bid will be delivered on August 6, 2009? Mail to the address shown on SF 1442.

CG101,

CP101

There is a discrepancy between the two drawings about what material is to be placed to the North of the "Future" Antenna. CG101 shows Hardstand Concrete and CP101 shows Gravel. Please clarify which of these is correct.

Material to be concrete.

Discrepancy corrected in Amendment No. 0004.

12 24 13, A-

Rolling window shades are spec'd for all exterior windows. Are the transparent and translucent polycarbonate wall panel systems classified as exterior windows? No. Only glass windows receive shades.

07 42 13

Reference Page 11, 2.2.c; The specifications required a 2.75" deep panel in 36" width providing R value of (20). Is a 2.5" deep panel in 42" width providing R value of (20) acceptable. Provide Basis of Design for Insulated Metal Wall Panels.

Please bid as shown.

A 403 &

Please provide a specification for this material and including color selection.

Refer to A 601. Bid per IFB

1/11/2000

Is the Contractor to include the cost of the General Building permit and City of Aberdeen and/or Harford County Inspection fees in the contract price?

Refer to Contract Clause "Permits and Responsibilities". Bid per

IFB

1/11/2000

Is the Contractor to include the cost of the Plumbing and HVAC trade permit and City of Aberdeen and/or Harford County Inspection fees in the contract price.

Refer to Contract Clause "Permits and Responsibilities". Bid per

IFB

1/11/2000

Is the Contractor to include the cost of the Electrical trade permit and City of Aberdeen and/or Harford County Inspection fees in the contract price.

Refer to Contract Clause "Permits and Responsibilities". Bid per

TN-102 -

TN-105

These plans indicate locations for ZP1-ZP15 but they do not indicate what each Zone Patch should be equipped to handle whether it be 2 RMU brackets or other. Please clarify.

Refer to Dwg TN 500, detail 2 and TN 504, detail 3 for additional information

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm

Dwg/Spec Comment Response

27 10 00

Section 2.3.2.2-How many strands of fiber are required for a "NIPRNET" outlet? Refer to legend on T-001 for quantities within each outlet

General

At the site visit, it was indicated that MDE approvals had not yet been received. When will these approvals be received?

Refer to Section 00 80 00, SC-1. Physical contruction will be delayed to obtain MDE approvals.

A-141

Reference Drawing No. A141. Please issue the specification, the detail drawings, and the spacing for the Fall Arrest System. Refer to section 05 50 13.

Bid per IFB

TN-503

Reference detail 9/TN-503. Is the 24" x 6" ladder cable tray aluminum or galvanized steel? What Nema rating is required?

Refer to Section 27 05 28, Para Material and Fabrication.

TN-601

Does not show zone panels. What cabling will feed zone panels? What cabling is terminated at zone panels? Refer to TN-500, detail 2 and

TN 504 Detail 3. Bid per IFB

A-305

The canopy shown on detail 3/A-305 needs more detail showing the sub-framing for the aluminum composite panels.

Requirement of Section 13 34 19. Clarified by Amendment No. 0004 detail 1/A301 spec 07-54- 19 roofing

Per Firestone and specifically FM tested and approved systems for an FM- 195 system the metal deck must be an E-Type deck The spec’s do not say anywhere that the metal deck must be an E-Deck in lieu of a C-deck.

Please verify if the deck will need to be E-type Deck.

Roof deck is part of pre-engineered structure. Deck selection is a requirement thereof. Bid according to the

IFB.

A203, spec section 08 44 00 page 8 2.1.1 e

A203 indicates two polycarbonate panels #6, and #7. The specs call out for two different light transmissions. Clear (65%) and Opal ( 34%) . Please clarify which panels are to be which.

Section replaced with section 08 45 10 by Amendment No 0004.

spec 08 44

EXTECT 3100 series has both a standard panel and also a flush face system. Which is required?

Section replaced with section 08 45 10 by Amendment No 0004.

spec 08 44

The drawings show a 4” thick dual glazed system but the specification is written for EXTECH Series 3100 16mm (5/8”) single glazed system.

EXTECH does not make a 4" dual glazed system. PLEASE CLARIFY

WHICH IS REQUIRED.

Section replaced with section 08 45 10 by Amendment No 0004.

spec 08 44

EXTECT 3100 series has both a standard panel and also a flush face system. IF EXTECH 3100 Series is still the basis for design( or approved equal) which panel system is required?

Section replaced with section 08 45 10 by Amendment No 0004.

spec 08 44

The exposed aluminum finishes section 2.5.3 call out four different coatings. Which one is required?

Section replaced with section 08 45 10 by Amendment No 0004.

Spec 07-42- Siding section 3.7.2

The specs indicate that the finished application of metal wall panels are to be subject to inspection and test for leakage by request of the Contracting Officer, Architect/Engineer. What is the extent of the testing? Will dousing the panels with a 3/4" hose with the normally available domestic water pressure on site be acceptable?

Section revised by Amendment No. 0004.

Requirement deleted.

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm

Dwg/Spec Comment Response

CS-101

Reference Drawing No. CS-101 Note No. 5. Note 5 refers to an Antenna Site Design Package "for details of antenna foundation pads, control buildings…". Is Note 5 for our coordination with another package. Or is Note 5 directing to construct antenna foundation pads, control buildings, etc?

See Amendment No 0004.

Drawings TN-601 and TY-501 are missing.

See Amendment No. 0001.

A-604 Detail Cut off See Amendment No. 0001.

CS-101

Reference Drawing No. CS-101. Will a Specification be issued for the Railroad Work?

See Amendment No. 0004.

CS-101

Reference Drawing No. CS-101, typical antenna locations. How is the typical antenna clear space finished? Paved? Grassed? What does the 5'x5' square poche' represent?

See Amendment No. 0004.

CS-101

Reference Drawing No. CS-101, the concrete pad for antenna 2.4Ku1, 2.4Ku2, 2.4Ku3, and 2.4Ka. Is that a concrete utility trench shown servicing the four (4) antenna locations?

See Amendment No. 0004.

A-602 Which overhead doors have manual and automatic operners?

See Amendment No. 0004.

CD 101,

CS101 &

CP 302

A note near the JSEC Parking Area refers to a Typical Precast Railroad Crossing, and refers to the specification. No specification for this item is provided. Amendment 1 provides a cross section, but the scope of work is not clear. CD101 indicates to remove track and rail bed in these areas. Is it intended to remove and replace rail & ties or add the crossing materials on top of the existing ties? If rail removal and replacement is required, provide specifications and details for this work. Additionally, without performing field layout, we can not determine if this will require work on the existing rail switch. Please confirm if the existing switch is to be within the crossing area. See Amendment No. 0004.

CD101

Buildings 3070 A & B are to be demolished. At the pre-bid, it was indicated that a hazardous material Survey of these building was being performed and the report would be provided by amendment. When is that report expected to be furnished?

See Amendment No. 0004.

CD101 &

A506

There are numerous references - "See Site Antenna Package". Please provide and indicate what is to be provided under the building contract.

See Amendment No. 0004.

Spec 08 44

Item 1.4.1 there is a blank where there is supposed to be a temperature given. Please provide the temperature.

See Amendment No. 0004.

Spec 08 44

Item 1.4.2.1 Is there a minimum size of mockup required?

See Amendment No. 0004.

Spec 08 44

Item 1.4.3 Are there any other alternate tests that are acceptable? There are blanks indicated for items a b and c.

See Amendment No. 0004.

Spec 08 44

Item 1.7 There are blanks for the temperature ranges for thermal movement.

Please provide the temperature range.

See Amendment No. 0004.

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm

Dwg/Spec Comment Response

A505

No information on jib crane is provided. Is it to be provided under this contract? Please provide hoist capacity, whether it is manually operated or electric, whether the jib is manually or electrically rotated and specifications for the system. Also, the steel post supporting the jib crane is not sized nor is the connection to the frame.

See Amendment No. 0004.

detail 1/A301 spec 07-54- 19 roofing

The details on the architectural drawing indicate PVC roof membrane over polyisocyanurate insulation over the metal roof deck. However, your specification ( 07-22-00 1.4.2 )indicates an added glass mat gypsum roof board thermal barrier, and 2.2 protection board thermal board over roof instulation, and 2.3 also includes a ashpalt-saturated felt base sheet vapor retarder. Does the structural design requirements allow for the additional load from these additional thermal barriers( two of them) and vapor barrier?

See Amendment No. 0004.

detail 1/A301 spec 07-54- 19 roofing

The addition of a vapor barrier, substrate board, and coverboard are not part of the approved assembly for an FM I-195. The assembly is insulation fastened to the deck, mechanically fastened roof system. Membrane can not be over 8’ wide and the fastening pattern for the system is 7.5” on center at every 6”. Please clarify if the FM-195 is the correct system requirment requested. "

See Amendment No. 0004.

detail 1,2,and 3 each on dwgsA202, and A203 spec 07-42- 13 siding

The drawing notes 1 2 3 indicate three different siding types 1 2 and 3 respectively, with different colors. What is the brand of paint from which the colors have been chosen? There is no mention of the brand of paint in the siding spec. The painting spec refers to the exterior metal table spec in division 5. But there does not appear to be any exterior metal color table in division 5. Please provide manufacturer used as a basis of design - similar to what was provided for interior finish schedule on A 604.

See Amendment No. 0004.

detail 1,2,and 3 each on dwgsA202, and A203 spec 07-42- 13 siding

The drawing note 4 indicates a fourth different siding types"metal wall panel system" which is shown differently from insulated metal panels 1 2 and 3.

The depiction of this #4 panel is in a horizontal application. The specifications call for a 2.75" panel with an embossed finish. Is this 4th panel also to be a 2.75" embossed metal panel? If not, please provide a profile of this panel. Please provide manufacturer used as a basis of design -similar to what was provided for interior finish schedule on A 604.

See Amendment No. 0004.

General

At the site visit, it was indicated that Award was expected about 2 weeks after the bid, with Notice to Proceed following about 2 weeks after that. Will submittals be reviewed in the period between Award and NTP?

See Amendment No. 0004.

08-81-00

No blast Criteria called out / All information to determine Glass type left -out Pg 5

See Amendment No. 0004.

08-44-10 No blast Criteria called out / Warranty time frame pg 11 left out

See Amendment No. 0004.

A-501

Aluminum Composite panels called out on drawing Details 1-6 but no specification is provided Please provide detailed spec and/or basis of design.

See Amendment No. 0004.

Spec 085113

Page 16, paragraph 2.7.8.6 refers to Section 090690 Color Schedule, but no color for painted aluminum is provided. Please provide.

See Amendment No. 0004.

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm

Dwg/Spec Comment Response

CU 101

Notes 15 refers to new gas line work. Site antennae drawings are to include additional information. How soon will these be provided. Is this work to include a meter to separate it from the main? If so, include include specifications and details for the piping, meter vault, and end connrections.

If a meter is not to be provided at the main, BGE will have to do the work. It has been our experience, that it will take at least 3 months for BG&E to provide pricing for the work once all design loads are provided to them. If this is to be BG&E work, it is suggested that the Corps provide an allowance value for the work for all bidders to include in the bid price. The Corps has done this on several previous projects at APG. This is the only fair way to proceed based on the time frame for BGE pricing. On other projects, this is allowance has been a line item in the bid form. Please provide this allowance.

See Amendment No. 0004.

CU 102

Note 16 refer to gas line work. Work is to be by BGE & paid for by the contractor. As indicated in the previous question, pricing from BGE is not available in the time allotted for bidding this job. An allowance for the work, as referenced above, should be provided to be included in the bid. Please provide this allowance.

See Amendment No. 0004.

Spec 084400

The spec calls for no penetration at a test pressure of 20psf. This may be very difficult and costly to attain. Should it be no water penetration of the panel U/H joint connection length at a test pressure of 12.0 PSF per ASTM E-331?

See Amendment No. 0004.

CG101

On sheet CG101, at Bioretention Area #4, there are dashed contour lines which appear to be proposed contours. No elevation is marked for these contours. The other Bioretention Areas also have these dashed contour lines but have elevations marked. Please specify the elevations or clarify the purpose of the dashed contour lines.

See Amendment No. 0004.

CG101

Pads for an Emergency Generator and 3 Chillers are shown, but no section is given to show the material or thickness of the pads. Please provide a section for these pads.

See Amendment No. 0004.

CU-102

There is an unmarked storm manhole and approximately 95 LF of pipe between Bioretention Area #4 and MH 13. Please specify the type of manhole to be used as well as what type of pipe.

See Amendment No. 0004.

A-505

Reference Spec Section 072200 Roof and Deck Insulation and Drawing No.

A505. The drawing details on A505 are not consistent with the referenced Spec Section with respect to 5/8" glass mat gypsum roof board. Is the roofing section from the metal roof deck up to be: 5/8" glass mat gypsum roof board + 35 pound vapor retarder + R-30 insulation + PVC roof membrane?

See Amendment No. 0004.

CS-101

Reference Drawing CS-101 and A-506. What is the material for the Trench Covers for the SSL and Utility Trenches? Are the trench covers in our Scope of Work?

See Amendment No. 0004.

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm

Dwg/Spec Comment Response

A-601

"PC1 and PC 2 - The finish schedule specifies Perfect Polish’s NW1 Natural Wonder Floor Level 1. Perfect Polish is a polishing contractor. The Natural Wonder Floor system is a proprietary name specific to what Perfect Polish calls their finished floors.

http://www.perfectpolishonline.com/services/NWlevel1.html Is there a specification general contrators can use to get apples to apples competitive bids? There is nothing listed in the Division 3 or Division 9 specifcations.

Attached is an example of a concrete polishing specification that is neutral and unbiased towards any contractor or manufacturer of any products from the Technical Institute of Polished Concrete.

See Amendment No. 0004.

CD-101

Reference Demolition Note #22. Provide a detail for the concrete slab cover over the existing steam vault inside building 3070A.

See Amendment No. 0004.

CU-101

Paragraph

1.2 of Spec Sec 33 11

Note 7 on Dwg CU-101 states that "New water mains shall be Class 52 cement lined ductile iron pipe …….." Para 1.2 states "Provide water distribution mains of ductile-iron or polyvinyl chloride (PVC) plastic pipe."

Can the new water mains be PVC or only ductile iron?

See Amendment No. 0004.

Paragraph 1.2.6.e of Spec Sec 33 11 00

Para 1.2.6.e states "Each change of direction device shall be protected with 3 magnesium anodes." Is a test station to be installed at each metallic change of direction device installed in a PVC main?

See Amendment No. 0004.

Spec Sec 33 11 00

Are magnesium anodes to be installed with "all" buried metallic piping/fittings/components or only to buried metallic piping/fittings/components that are associated with a "pressurized" piping system?

See Amendment No. 0004.

08 44 10

Reference Paragraph 1.4.7.c: Aluminum framing products can not be fire rated as noted. Please clarify? See Amendment No. 0004.

The following panelboards have no schedules; RU-1X, RU-2X, PP-7, PP-10, PP-11. Please clarify. See Amendment No. 0004.

33100 Specification for vapor barrier is outdated. Spec should reference ASTM E

See Amendment No. 0004.

CP503

Detail 1

This detail indicated an impervious backfill adjacent to the building. Is topsoil intended to be placed on top of this? Where is this detail to occur?

For what distance from the building does this impervious layer extend? See Amendment No. 0004.

CS-502

Is all permanent fence to be the ornamental fence as shown on CS 502? See Amendment No. 0004.

CS 101

The "Yard" on the west side of the building where the chillers, generators and transformer are located is to have what surface treatment? Concrete, asphalt paving, crushed stone? Please confirm> See Amendment No. 0004.

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm

Dwg/Spec Comment Response spec 07-42-13 siding section 3.7.2

The specs indicate that the finished application of metal wall panels are to be subject to inspection and test for leakage by request of the Contracting Officer, Architect/Engineer. What is the extent of the testing? Will dousing the panels with a 3/4" hose with the normally available domestic water pressure on site be acceptable? See Amendment No. 0004.

"6) Spec 08 44 10 is incomplete as follows: (or explain blanks) Provide requirements: -1.4.7c & d fire ratings (see note below) Provide requirements: -1.4.8 STC rating Provide requirements: -1.5.2 Framing System's) Provide requirements: -1.5.3 Thermal Range (delta) Provide requirements: -1.5.5 Structural Requirements Provide requirements: -1.5.6 Seismic Requirements Provide requirements: -1.7.1f Warranty Requirements Provide requirements: -3.3.7 Insulation Requirements Be advised that the Aluminum framing products can not be fire rated as noted - 08 44-10-1.4.7c & d Please provide /clarify requirement."

See Amendment No. 0004.

Specificatio n 08 81 00

"8) Spec 08 81 00 Glazing is incomplete as follows: (or explain blanks) Provide requirements: -2.1.2 Tempered Glass LT & SC values Provide requirements: -2.2 SHGC value Provide requirements: -2.2 STC value

See Amendment No. 0004.

Specificatio n 08 81 01

Glazing specification does not provide the glass types required for this project. Blast requirements for glazing are not provided. Please provide threat level, distance and charge load. Provide glass schedule. See Amendment No. 0004.

A-202

A601, A404

Question: The drawings, refer to a "Wood Veneer Wall Cladding System" and the Finish Legend provides some general information regarding the system to be used; however, more information is required in order to get adequate pricing on this item. Please provide the following:

1. LEED Requirements if any (FSC, NAUF, recycled content?)

2. Core material

3. Varnish specification- clear? Custom stain?

4. Wood panel veneer configurations- grade? leaf width? Slip match, book match? Panel matching?

See Amendment No. 0004.

CU-101

Reference Note 16 on CU-101. This note requires the Contractor to hire BGE to furnish and install the new gas lines for the project. BGE will not give construction costs until an Application for service is received. Has the Governement made the Application to BGE? We will not be able to get Construction costs from BGE in time to include in our bid. Please delete this requirement (the Contractor is to include trenching and backfill only) or specify an allowance to be included in the Contractor's bid for BGE's portion of the work. See Amendment No. 0004.

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm

Dwg/Spec Comment Response detail 1/A301 spec 07-54- 19 roofing

The resulting cross section from the question above would imply : ( from top to bottom). Is this correct?

PVC roof membrane Protection Board-glass mat Polyisocyanurate Insulation Thermal barrier -glass mat gypsum board Vapor barrier Metal Deck

See Amendment No. 0004.

A-604

The enlarged curtainwall elevations do not indicate glass types and locations. Provide this information. See Amendment No. 0004.

Spec Section 08 44 10.

12/24/2013

On Specification section 12 24 13 Roller Window Shades, The window shades are not shown on the drawings. Please specify where they are located.

See paragraph "Windowshade Placement Schedule"

A403, A404

Is interior glass 1/4" clear tempered glass for interior aluminum storefront systems and entrances?

See Section 08 81 00, Amendment No 0004. Also, see schedule on A 602 and A 603.

Spec 27 10

Section 3.5.1.3 (i) - #6 states that “test results must be uploaded into a cable management software package that supports AutoCAD diagrams.” Do we need to supply the cable management software, or do we just load the information into the government’s software?

Software utilized by Contractor during testing must be supplied by Contractor. Bid per IFB.

CS-101

Reference Drawing No. CS-101. Are the Solvent Storage Shed and Antenna Control Building(s) part of this contract?

g antenna control building are GFGI. See Amendment No.

0004.

Detail 3 A-

Note indicates "Entrance Canopy - Aluminum Composite panel on all exposed surfaces". Provide details and basis of design for this work. Note that no drains or gutters are provided, so that water is shed in the direction of access to the front door.

Specifications are in Section 07 42 13, Amendment No.

0004. Details are shop dwg submittal requirement. Bid per IFB and Amendment.

TS-101,

Note 3

Please provide additional information. How many fibers? Is splicing required? Splicing is not required. Bid per IFB

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm

Dwg/Spec Comment Response

23 08 00

"LEED NC 2.2 EA Pr 1 - Fundamental Commissioning states the following:

The following commissioning process activities shall be completed by the commissioning team, in accordance with the LEED-NC 2.2 Reference Guide. 1) Designate an individual as the Commissioning Authority (CxA) to lead, review and oversee the completion of the commissioning process activities. a) The CxA shall have documented commissioning authority experience in at least two building projects.

b) The individual serving as the CxA shall be independent of the project’s design and construction management, though they may be employees of the firms providing those services. The CxA may be a qualified employee or consultant of the Owner.

c) The CxA shall report results, findings and recommendations directly to the Owner.

d) For projects smaller than 50,000 gross square feet, the CxA may include qualified persons on the design or construction teams who have the required experience.

2) The Owner shall document the Owner’s Project Requirements (OPR).

The design team shall develop the Basis of Design (BOD). The CxA shall rev

3) Develop and incorporate commissioning requirements into the construction

4) Develop and implement a commissioning plan.

5) Verify the installation and performance of the systems to be commissioned

6) Complete a summary commissioning report."

As this facility is over 50,000 gsf, the CxA must be independent of the design

The CxA should developed the comissioning plan based on the guidlines included in the specifications with any changes included in the required comissioning plan submittal.

By public records, Aberdeen is listed as a superfund site. A) Will the owner take responsibility for all pre-existing conditions? B) If hazardous materials are encountered will the owner take ownership of such materials, including signing the manifests for such materials? Please understand that should this question not be clarified by an addendum, the bonding companies for the contractors will not write a bond for the project.Please provide a location map with the limits of superfund contaminated areas in relationship to this project.

Please clarify what the contractor should do if during the drilling of the geothermal wells, contaminated soils are encountered.

Please clarify what the contractor should do if during the drilling of the geothermal wells, contaminated groundwater is encountered? If the contaminated groundwater is leaching from a superfund contaminated location - please clarify who is responsible for all costs of cleanup?

The project site is outside the limits of the superfund site and no special precautions are required.

Bid per the IFB

Are there UXO present? Has the Army done a UXO survey? Is the contractor responsible to provide UXO sweeping services as part of this contract? There are no known UXO issues. Bid per IFB

27 10 00

There is no reference to what color fiber cable is to be used for the JWICS runs. Please clarify. There is no JWICS required for this project. Bid per IFB

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm Typewritten Text e5ecdbfm

Dwg/Spec Comment Response

00 80 00

Paragraph SC-14 states insurance requirements for the Contractor but does not address Builder's Risk Insurance or Railroad Protective Liability Insurance. Who is providing these insurance coverages for this project? If Railroad Protective Liability Insurance purposes, address the following question: How active is the existing track in trips per hour, trips per day, or trips per week.

These insurances are not required. Bid per the IFB. A note stating that the existing track is inactive will be added by amendment.

07 42 13

Reference Page 12, 2.2.1; The specifications require the panel steel sheet to be flush-faced with nondirectionally embossed, lightly planked texture. Does lightly planked mean vertical ribs and/or striations? This has been addressed by

Amendment.

CS-101

Reference Drawing No. CS-101 showing a Utility Trench going from the west elevation of the building out to the CSC-39 antenna pad. The note for the utility trench says "Concrete Utility Trench (TYP). What does "TYP" infer? Typical for what? Each antenna pad? Or typical for the trenches emanating from the south and east elevations?

Typical refers to trenches emanating from the south and east elevations. If no trench is shown, it is not required. Bid as per the IFB

1/11/2000

Clarify that the following permits are being obtained and payed for by the Governement as applicable for this project (some additional action may be necessary by the Contractor to become complete); Erosion & Sedimentation Control Plan, Stormwater Management Plan, NPDES, and Forest Conservation.

Yes

Is there a canopy over door #V02A? If so, please provide details as requested in previous question.

Yes. See previous response

A403 &

Is interior glass 1/4" clear tempered with aluminum frames?

Yes. Clarified in Section 08 81 00, Amendment No. 0004 Refer to door and opening schedule on A-602/A-603.

FOR INFORMATION ONLY

REQUESTS FOR INFORMATION with RESPONSES

Amendment No. 0004

IFB W912BU-09-B-0020

e5ecdbfm

Dwg/Spec Comment Response

Invitation for Bid No.

W912BU-09-B-0020

Section 00700

Contract Clauses

52.202-1 Definitions JUL 2004 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees APR 1984 52.203-7 Anti-Kickback Procedures JUL 1995 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

SEP 2007

52.204-2 Alt II Security Requirements (Aug 1996) - Alternate II APR 1984 52.204-4 Printed or Copied Double-Sided on Recycled Paper AUG 2000 52.204-7 Central Contractor Registration APR 2008 52.204-9 Personal Identity Verification of Contractor Personnel SEP 2007 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

SEP 2006

52.214-26 Audit and Records--Sealed Bidding MAR 2009 52.214-27 Price Reduction for Defective Cost or Pricing Data -

Modifications - Sealed Bidding

OCT 1997

52.214-28 Subcontracting Cost Or Pricing Data--Modifications--Sealed Bidding

OCT 1997

52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns NOTE: This clause can be found on page 00010-4

JUL 2005

52.217-7 Option For Increased Quantity—Separately Price Line ItemMAR 1989 52.219-8 Utilization of Small Business Concerns MAY 2004 52.219-9 Alt I (Dev) Small Business Subcontracting Plan (Apr 2008) Alternate I

(Deviation)

OCT 2001

52.219-28 Post-Award Small Business Program Rerepresentation JUN 2007 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation

JUL 2005

52.222-6 Davis Bacon Act JUL 2005 52.222-7 Withholding of Funds FEB 1988 52.222-8 (Dev) Payrolls and Basic Records (Deviation) FEB 1988 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) JUL 2005 52.222-12 Contract Termination-Debarment FEB 1988 52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988 52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility FEB 1988 52.222-21 Prohibition Of Segregated Facilities FEB 1999 52.222-26 Equal Opportunity MAR 2007 52.222-27 Affirmative Action Compliance Requirements for

Construction

FEB 1999

00700-index i

52.222-35 Equal Opportunity For Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans

SEP 2006

52.222-36 Affirmative Action For Workers With Disabilities JUN 1998 52.222-37 Employment Reports On Special Disabled Veterans, Veterans

Of The Vietnam Era, and Other Eligible Veterans

SEP 2006

52.222-39 Notification of Employee Rights Concerning Payment of Union Dues or Fees

DEC 2004

52.222-50 Combating Trafficking in Persons FEB 2009 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

DEC 2007

52.223-5 Pollution Prevention and Right-to-Know Information AUG 2003 52.223-11 Ozone-Depleting Substances MAY 2001 52.223-12 Refrigeration Equipment and Air Conditioners MAY 1995 52.223-14 Toxic Chemical Release Reporting AUG 2003 52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.225-11 Buy American Act--Construction Materials Under Trade Agreements

MAR 2009

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-1 Bid Guarantee SEP 1996 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets FEB 1992 52.228-14 Irrevocable Letter of Credit DEC 1999 52.228-15 Performance and Payment Bonds--Construction NOV 2006 52.229-3 Federal, State And Local Taxes APR 2003 52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002 52.232-23 Assignment Of Claims JAN 1986 52.232-27 Prompt Payment for Construction Contracts OCT 2008 52.232-33 Payment by Electronic Funds Transfer--Central Contractor

Registration

OCT 2003

52.233-1 Alt I Disputes (Jul 2002) - Alternate I DEC 1991 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-26 Preconstruction Conference FEB 1995 52.239-1 Privacy or Security Safeguards AUG 1996

00700-index ii

W912BU-09-B-0020

00700-14

(c) Any reduction in the contract price under paragraph (b) above due to defective data…