sf30-20b1-am3.pdf

1. CONTRACT ID CODE PAGE OF PAGES

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1 2

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

AM-0003 26 Mar 2020

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

CECT – Contracting Division USACE, Honolulu District Bldg 252 (CECT-POH) Ft Shafter, HI 96858-5440

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State, and Zip Code) (x) 9A. AMENDMENT OF SOLICITATION NO.

W9128A-20-B-0001 X

9B. DATED (SEE ITEM 11)

02/14/2020

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

[ X ]The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers [ X ] is extended, [ ] is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning __1__ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

(x) A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor [ ] is not, [ ] is required to sign this document and return _ copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Honolulu Harbor Maintenance Dredging, Honolulu, Island of Oahu, State of Hawaii

See Page 2 of 2 Pages

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION UNUSABLE

30-105 STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Am-0003 Standard Form 30

IFB No. W9128A20B0001 Page 2 of 2 Pages

Item No. 14 (Continued)

1. CHANGES TO SPECIFICATIONS. Attached hereto are new, revised and deleted sections to the specifications. Revised pages replace like-numbered pages. The revision mark (Am-0003) is shown on each revised page.

A. DELETED CLAUSE. The following clause was deleted and indicated with a bold strikethrough:

N/A

B. REVISED SECTIONS. The following sections were revised and indicated in bold:

N/A

C. ADDITIONS TO SECTIONS: The following was added to sections:

Section 01 32 00, Project Schedule, Section Table of Contents

Section 01 33 00, Submittal Procedures, Section Table of Contents

Section 01 35 26, Government Safety Requirements, Section Table of Contents

Section 01 45 00, RMS3 – Contractor Mode (RMS3/CM), Section Table of Contents

Section 01 45 04, Contractor Quality Control, Section Table of Contents

Section 01 57 19, Temporary Environmental Controls, Section Table of Contents

Section 01 62 35, Recycled / Recovered Materials, Section Table of Contents

Section 01 78 00, Closeout Submittals, Section Table of Contents

Section 01 90 00, Miscellaneous Provisions, Section Table of Contents

Section 35 20 23, Dredging, Section Table of Contents

Section 35 20 23.13, National Dredging Quality Management Program SCOW – Ullage Prifle, Section Table of Contents

Section 01 57 19, Temporary Environmental Controls, Attachment 5 (continuation)

Section 00 73 00, Appendix B, Answer to RFIs #24 to 29

D. REPLACED SECTION: The following section is to be replaced in its entirety:

N/A

2. Requests for Information is due March 31, 2020.

3. The proposal due date remains unchanged. See Am-0003, SF1442, Block 13.

Honolulu Harbor Maintenance Dredging, Oahu, Haw aii

X

COLIN K WAKI 808-835-4393

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED (RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______7 calendar days and complete it w ithin ________ calendar days after receiving aw ard, X notice to proceed. This performance period is mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

CECT - CONTRACTING DIVISION

USACE, HONOLULU DISTRICT

BLDG 252 (CECT-POH)

FT. SHAFTER HI 96858-5440

W9128A

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

(hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W9128A19B0003 72

14 Apr 2020

(Am-0003)

2:00 PM (HST)

O&M DREDGING W9128A-20-B-0001

HONOLULU HARBOR

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 32 00

PROJECT SCHEDULE

03/17

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 PROJECT SCHEDULER QUALIFICATIONS

PART 2 PRODUCTS

2.1 SOFTWARE

2.1.1 Government Default Software

2.1.2 Contractor Software

2.1.2.1 Primavera

2.1.2.2 Other Than Primavera

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

3.2 BASIS FOR PAYMENT AND COST LOADING

3.2.1 Activity Cost Loading

3.2.2 Withholdings / Payment Rejection

3.3 PROJECT SCHEDULE DETAILED REQUIREMENTS

3.3.1 Level of Detail Required

3.3.2 Activity Durations

3.3.3 Permit Activities

3.3.4 Procurement Activities

3.3.5 Mandatory Tasks

3.3.6 Government Activities

3.3.7 Standard Activity Coding Dictionary

3.3.7.1 Workers Per Day (WRKP)

3.3.7.2 Responsible Party Coding (RESP)

3.3.7.3 Area of Work Coding (AREA)

3.3.7.4 Modification Number (MODF)

3.3.7.5 Bid Item Coding (BIDI)

3.3.7.6 Phase of Work Coding (PHAS)

3.3.7.7 Category of Work Coding (CATW)

3.3.7.8 Feature of Work Coding (FOW)

3.3.8 Contract Milestones and Constraints

3.3.8.1 Project Start Date Milestone and Constraint

3.3.8.2 End Project Finish Milestone and Constraint

3.3.8.3 Interim Completion Dates and Constraints

3.3.8.3.1 Start Phase

3.3.8.3.2 End Phase

3.3.9 Calendars

3.3.10 Open Ended Logic

3.3.11 Default Progress Data Disallowed

3.3.12 Out-of-Sequence Progress

SECTION 01 32 00 Page 1

3.3.13 Added and Deleted Activities

3.3.14 Original Durations

3.3.15 Leads, Lags, and Start to Finish Relationships

3.3.16 Retained Logic

3.3.17 Percent Complete

3.3.18 Remaining Duration

3.3.19 Cost Loading of Closeout Activities

3.3.19.1 As-Built Drawings

3.3.20 Anticipated Adverse Weather

3.3.21 Early Completion Schedule and the Right to Finish Early

3.4 PROJECT SCHEDULE SUBMISSIONS

3.4.1 Preliminary Project Schedule Submission

3.4.2 Initial Project Schedule Submission

3.4.3 Periodic Schedule Updates

3.5 SUBMISSION REQUIREMENTS

3.5.1 Data CD/DVDs

3.5.2 Narrative Report

3.5.3 Schedule Reports

3.5.3.1 Activity Report

3.5.3.2 Logic Report

3.5.3.3 Total Float Report

3.5.3.4 Earnings Report by CLIN

3.5.3.5 Schedule Log

3.5.4 Network Diagram

3.5.4.1 Continuous Flow

3.5.4.2 Project Milestone Dates

3.5.4.3 Critical Path

3.5.4.4 Banding

3.5.4.5 Cash Flow / Schedule Variance Control (SVC) Diagram

3.6 PERIODIC SCHEDULE UPDATE

3.6.1 Periodic Schedule Update Meetings

3.6.2 Update Submission Following Progress Meeting

3.7 WEEKLY PROGRESS MEETINGS

3.8 REQUESTS FOR TIME EXTENSIONS

3.8.1 Justification of Delay

3.8.2 Time Impact Analysis (Prospective Analysis)

3.8.3 Forensic Schedule Analysis (Retrospective Analysis)

3.8.4 Fragmentary Network (Fragnet)

3.8.5 Time Extension

3.8.6 Impact to Early Completion Schedule

3.9 FAILURE TO ACHIEVE PROGRESS

3.9.1 Artificially Improving Progress

3.9.2 Failure to Perform

3.9.3 Recovery Schedule

3.10 OWNERSHIP OF FLOAT

3.11 TRANSFER OF SCHEDULE DATA INTO RMS3/CM

3.12 PRIMAVERA P6 MANDATORY REQUIREMENTS

-- End of Section Table of Contents --

SECTION 01 32 00 Page 2

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

03/17

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

1.1.2 Approving Authority

1.1.3 Work

1.2 SUBMITTALS

1.3 SUBMITTAL CLASSIFICATION

1.3.1 Government Approved (G)

1.3.2 Information Only

1.4 QUANTITY OF SUBMITTALS

1.4.1 Number Copies of Government Approved Submittals: 4

1.4.2 Number of Copies of For Information Only Submittals: 3

1.4.3 Electronic Copies

1.5 APPROVED/ACCEPTED SUBMITTALS

1.6 APPROVED SAMPLES

1.7 DISAPPROVED OR REJECTED SUBMITTALS

1.8 INFORMATION ONLY SUBMITTALS

1.9 GOVERNMENT APPROVING AUTHORITY

1.9.1 Government Review Action Codes

1.9.2 Review Notations

1.10 WITHHOLDING OF PAYMENT

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION

3.1 SUBMITTAL REGISTER

3.2 SCHEDULING

3.3 TRANSMITTAL FORM

3.3.1 Numbering

3.4 SUBMITTAL PROCEDURE

3.4.1 Procedures

3.4.2 Variations / Substitution Requests

3.4.2.1 Considering Variations

3.4.2.2 Proposing Variations

3.4.2.3 Warranting That Variations Are Compatible

3.4.2.4 Review Schedule Is Modified

3.5 CONTROL OF SUBMITTALS

3.5.1 Monthly Updates of Submittal Register

-- End of Section Table of Contents --

SECTION 01 33 00 Page 1

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 35 26

GOVERNMENTAL SAFETY REQUIREMENTS

03/17

PART 1 GENERAL

1.1 REFERENCES

1.2 DEFINITIONS

1.2.1 Competent Person (CP)

1.2.2 Competent Person, Confined Space

1.2.3 Competent Person, Cranes and Rigging

1.2.4 Competent Person, Excavation/Trenching

1.2.5 Competent Person, Fall Protection

1.2.6 Competent Person, Scaffolding

1.2.7 Competent Person (CP) Trainer

1.2.8 High Risk Activities

1.2.9 High Visibility Accident

1.2.10 Load Handling Equipment (LHE)

1.2.11 Medical Treatment

1.2.12 Near Miss

1.2.13 Operating Envelope

1.2.14 Qualified Person (QP)

1.2.15 Qualified Person, Fall Protection (QP for FP)

1.2.16 Recordable Injuries or Illnesses

1.2.17 USACE Property and Equipment

1.2.18 Load Handling Equipment (LHE) Accident or Load Handling

Equipment Mishap

1.3 SUBMITTALS

1.4 MONTHLY EXPOSURE REPORTS

1.5 REGULATORY REQUIREMENTS

1.6 SITE QUALIFICATIONS, DUTIES, AND MEETINGS

1.6.1 Personnel Qualifications

1.6.1.1 Site Safety and Health Officer (SSHO)

1.6.1.2 Contractor Quality Control (QC) Manager:

1.6.1.3 Competent Person Qualifications

1.6.1.3.1 Competent Person for Confined Space Entry

1.6.1.3.2 Competent Person for Scaffolding

1.6.1.3.3 Competent Person for Fall Protection

1.6.1.4 Qualified Trainer Requirements

1.6.1.5 Crane Operators/Riggers

1.6.2 Personnel Duties

1.6.2.1 Duties of the Site Safety and Health Officer (SSHO)

1.6.3 Meetings

1.6.3.1 Preconstruction Conference

1.6.3.2 Safety Meetings

1.7 ACCIDENT PREVENTION PLAN (APP)

1.7.1 Names and Qualifications

1.7.2 Plans

1.7.2.1 Confined Space Entry Plan

1.7.2.2 Standard Lift Plan (SLP)

SECTION 01 35 26 Page 1

1.7.2.3 Critical Lift Plan - Crane or Load Handling Equipment

1.7.2.4 Fall Protection and Prevention (FP&P) Plan

1.7.2.5 Rescue and Evacuation Plan

1.7.2.6 Hazardous Energy Control Program (HECP)

1.7.2.7 Excavation Plan

1.8 ACTIVITY HAZARD ANALYSIS (AHA)

1.8.1 AHA Management

1.8.2 AHA Signature Log

1.9 DISPLAY OF SAFETY INFORMATION

1.9.1 Safety Bulletin Board

1.9.2 Safety and Occupational Health (SOH) Deficiency Tracking System

1.10 SITE SAFETY REFERENCE MATERIALS

1.11 EMERGENCY MEDICAL TREATMENT

1.12 NOTIFICATIONS and REPORTS

1.12.1 Mishap Notification

1.12.2 Accident Reports

1.12.3 LHE Inspection Reports

1.12.4 Certificate of Compliance and Pre-lift Plan/Checklist for LHE and Rigging

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 CONSTRUCTION AND OTHER WORK

3.1.1 Worksite Communication

3.1.2 Hazardous Material Exclusions

3.1.3 Unforeseen Hazardous Material

3.2 PRE-OUTAGE COORDINATION MEETING

3.3 CONTROL OF HAZARDOUS ENERGY (LOCKOUT/TAGOUT)

3.4 FALL PROTECTION PROGRAM

3.4.1 Training

3.4.2 Fall Protection Equipment and Systems

3.4.2.1 Additional Personal Fall Protection

3.4.2.2 Personal Fall Protection Harnesses

3.4.3 Horizontal Lifelines (HLL)

3.4.4 Guardrails and Safety Nets

3.4.5 Rescue and Evacuation Plan and Procedures

3.5 EQUIPMENT

3.5.1 Material Handling Equipment (MHE)

3.5.2 Load Handling Equipment (LHE)

3.5.3 Machinery and Mechanized Equipment

3.5.4 USE OF EXPLOSIVES

3.6 EXCAVATIONS

3.6.1 Utility Locations

3.6.2 Utility Location Verification

3.6.3 Utilities Within and Under Concrete, Bituminous Asphalt, and

Other Impervious Surfaces

3.7 ELECTRICAL

3.7.1 Conduct of Electrical Work

3.7.2 Qualifications

3.7.3 Arc Flash

3.7.4 Grounding

3.7.5 Testing

-- End of Section Table of Contents --

SECTION 01 35 26 Page 2

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 45 00

RMS3 - CONTRACTOR MODE (RMS3/CM)

03/17

PART 1 GENERAL

1.1 Contract Administration

1.1.1 Correspondence and Electronic Communications

1.1.2 Other Factors

1.2 RMS3/CM SOFTWARE

1.3 SYSTEM REQUIREMENTS

1.4 RELATED INFORMATION

1.4.1 RMS3/CM User Guide

1.4.2 Contractor Quality Control (CQC) Training

1.5 CONTRACT DATABASE

1.6 DATABASE MAINTENANCE

1.6.1 Administration

1.6.1.1 Contractor Information

1.6.1.2 Subcontractor Information

1.6.1.3 Correspondence

1.6.1.4 Equipment

1.6.1.5 Management Reporting

1.6.1.6 Request For Information (RFI)

1.6.2 Finances

1.6.2.1 Pay Activity Data

1.6.2.2 Payment Requests

1.6.3 Quality Control (QC)

1.6.3.1 Daily Contractor Quality Control (CQC) Reports.

1.6.3.2 Deficiency Tracking.

1.6.3.3 QC Requirements

1.6.3.4 Three-Phase Control Meetings

1.6.3.5 Labor and Equipment Hours

1.6.3.6 Accident/Safety Reporting

1.6.3.7 Features of Work

1.6.3.8 Hazard Analysis

1.6.4 Submittal Management

1.6.5 Schedule

1.7 IMPLEMENTATION

1.8 MONTHLY COORDINATION MEETING

1.9 NOTIFICATION OF NONCOMPLIANCE

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 45 00 Page 1

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 45 04

CONTRACTOR QUALITY CONTROL

03/17

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 PAYMENT

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

3.2 CONTRACTOR QUALITY CONTROL PLAN

3.2.1 Content of the CQC Plan

3.2.2 Acceptance of Plans

3.2.3 Notification of Changes

3.3 COORDINATION MEETING

3.4 QUALITY CONTROL ORGANIZATION

3.4.1 Personnel Requirements

3.4.2 CQC System Manager

3.4.3 CQC Personnel

3.4.4 Additional Requirement

3.4.5 Organizational Changes

3.5 SUBMITTALS AND DELIVERABLES

3.6 CONTROL

3.6.1 Preparatory Phase

3.6.2 Initial Phase

3.6.3 Follow-up Phase

3.6.4 Additional Preparatory and Initial Phases

3.7 TESTS

3.7.1 Testing Procedure

3.7.2 Testing Laboratories

3.7.2.1 Validation Requirements

3.7.2.2 Capability Check

3.7.2.3 Capability Recheck

3.7.3 Onsite Laboratory

3.7.4 Furnishing or Transportation of Samples for Testing

3.8 COMPLETION INSPECTION

3.8.1 Punch-Out Inspection

3.8.2 Pre-Final Inspection

3.8.3 Final Acceptance Inspection

3.9 DOCUMENTATION

3.10 NOTIFICATION OF NONCOMPLIANCE

-- End of Section Table of Contents --

SECTION 01 45 04 Page 1

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 57 19

TEMPORARY ENVIRONMENTAL CONTROLS

11/15

PART 1 GENERAL

1.1 REFERENCES

1.2 DEFINITIONS

1.2.1 Class I and II Ozone Depleting Substance (ODS)

1.2.2 Contractor Generated Hazardous Waste

1.2.3 Electronics Waste

1.2.4 Environmental Pollution and Damage

1.2.5 Environmental Protection

1.2.6 Hazardous Debris

1.2.7 Hazardous Materials

1.2.8 Hazardous Waste

1.2.9 Land Application

1.2.10 Municipal Separate Storm Sewer System (MS4) Permit

1.2.11 National Pollutant Discharge Elimination System (NPDES)

1.2.12 Oily Waste

1.2.13 Regulated Waste

1.2.14 Sediment

1.2.15 Solid Waste

1.2.15.1 Debris

1.2.15.2 Green Waste

1.2.15.3 Material not regulated as solid waste

1.2.15.4 Non-Hazardous Waste

1.2.15.5 Recyclables

1.2.15.6 Surplus Soil

1.2.15.7 Scrap Metal

1.2.15.8 Wood

1.2.16 Surface Discharge

1.2.17 Wastewater

1.2.17.1 Stormwater

1.2.18 Waters of the United States

1.2.19 Wetlands

1.2.20 Universal Waste

1.3 SUBMITTALS

1.4 ENVIRONMENTAL PROTECTION REQUIREMENTS

1.5 SPECIAL ENVIRONMENTAL REQUIREMENTS

1.6 QUALITY ASSURANCE

1.6.1 Preconstruction Survey and Protection of Features

1.6.2 Regulatory Notifications

1.6.3 Environmental Brief

1.6.4 Environmental Manager

1.6.5 Employee Training Records

1.6.6 Non-Compliance Notifications

1.7 ENVIRONMENTAL PROTECTION PLAN

1.7.1 General Overview and Purpose

1.7.1.1 Descriptions

SECTION 01 57 19 Page 1

1.7.1.2 Duties

1.7.1.3 Procedures

1.7.1.4 Communications

1.7.1.5 Contact Information

1.7.2 General Site Information

1.7.2.1 Drawings

1.7.2.2 Work Area

1.7.2.3 Documentation

1.7.3 Management of Natural Resources

1.7.4 Protection of Historical and Archaeological Resources

1.7.5 Stormwater Management and Control

1.7.6 Protection of the Environment from Waste Derived from

Contractor Operations

1.7.7 Prevention of Releases to the Environment

1.7.8 Regulatory Notification and Permits

1.7.9 Clean Air Act Compliance

1.7.9.1 Haul Route

1.7.9.2 Pollution Generating Equipment

1.7.9.3 Stationary Internal Combustion Engines

1.7.9.4 Refrigerants

1.7.9.5 Air Pollution-engineering Processes

1.7.9.6 Compliant Materials

1.8 LICENSES AND PERMITS

1.9 ENVIRONMENTAL RECORDS BINDER

1.10 SOLID WASTE MANAGEMENT PERMIT

1.10.1 Solid Waste Management Report

PART 2 PRODUCTS

2.1 TURBIDITY AND SILT CURTAIN

2.1.1 Turbidity Barrier/Curtain

2.1.2 Floatation

2.1.3 Load Lines

2.1.4 Mooring Lines

2.1.5 Adjustment Lines and Tie Downs

2.1.6 Ballast

2.1.7 Anchors

2.1.8 Mooring Buoys

2.1.9 Lighted Buoys

PART 3 EXECUTION

3.1 PROTECTION OF NATURAL RESOURCES

3.1.1 Endangered Species Act (ESA)

3.1.1.1 General Conditions for ESA Compliance

3.1.1.2 Project-Specific Best Management Practices for ESA

Compliance

3.1.2 Essential Fish Habitat

3.1.2.1 Measures for EFH Compliance

3.1.3 Clean Water Act

3.1.3.1 Water Quality Monitoring

3.1.4 Flow Ways

3.1.5 Vegetation

3.1.6 Streams

3.2 STORMWATER

3.2.1 Construction General Permit

3.2.1.1 Stormwater Pollution Prevention Plan

3.2.1.2 Stormwater Notice of Intent for Construction Activities

3.2.1.3 Inspection Reports

SECTION 01 57 19 Page 2

3.2.1.4 Stormwater Pollution Prevention Plan Compliance Notebook

3.2.1.5 Stormwater Notice of Cessation for Construction Activities

3.2.2 Erosion and Sediment Control Measures

3.2.2.1 Erosion Control

3.2.2.2 Sediment Control Practices

3.2.3 Work Area Limits

3.2.4 Contractor Facilities and Work Areas

3.2.5 Municipal Separate Storm Sewer System (MS4) Management

3.3 SURFACE AND GROUNDWATER

3.3.1 Cofferdams, Diversions, and Dewatering

3.3.2 Waters of the United States

3.4 PROTECTION OF CULTURAL RESOURCES

3.4.1 Archaeological Resources

3.5 AIR RESOURCES

3.5.1 Oil or Dual-fuel Boilers and Furnaces

3.5.2 Accidental Venting of Refrigerant

3.5.3 EPA Certification Requirements

3.5.4 Dust Control

3.5.4.1 Particulates

3.5.4.2 Abrasive Blasting

3.5.5 Odors

3.6 WASTE MINIMIZATION

3.6.1 Salvage, Reuse and Recycle

3.7 DREDGED MATERIAL MANAGEMENT AND DISPOSAL

3.7.1 Dredged Material Determination Documentation

3.7.1.1 Sampling and Analysis of Dredged Material for Upland

Disposal

3.7.1.1.1 Dredged Material Sampling

3.7.1.1.2 Laboratory Analysis

3.7.1.2 Ocean Disposal for Dredged Material

3.7.2 Dredged Material Management

3.7.2.1 Dredged Material Management Report

3.7.3 Control and Management of Hazardous Waste

3.7.3.1 Hazardous Waste/Debris Management

3.7.3.2 Waste Storage/Satellite Accumulation/90 Day Storage Areas

3.7.3.3 Universal Waste Management

3.7.3.4 Electronics End-of-Life Management

3.7.3.5 Disposal Documentation for Hazardous and Regulated Waste

3.7.4 Releases/Spills of Oil and Hazardous Substances

3.7.4.1 Response and Notifications

3.7.4.2 Clean Up

3.7.5 Mercury Materials

3.7.6 Wastewater

3.7.6.1 Treatment

3.7.6.2 Surface Discharge

3.8 HAZARDOUS MATERIAL MANAGEMENT

3.9 PREVIOUSLY USED EQUIPMENT

3.10 CONTROL AND MANAGEMENT OF POLYCHLORINATED BIPHENYLS (PCBS)

3.11 CONTROL AND MANAGEMENT OF LIGHTING BALLAST AND LAMPS CONTAINING

PCBS

3.12 MILITARY MUNITIONS

3.13 PETROLEUM, OIL, LUBRICANT (POL) STORAGE AND FUELING

3.13.1 Used Oil Management

3.13.2 Oil Storage Including Fuel Tanks

3.14 INADVERTENT DISCOVERY OF PETROLEUM-CONTAMINATED SOIL OR HAZARDOUS

WASTES

3.15 CHLORDANE

3.16 SOUND INTRUSION

3.17 TURBIDITY/SILT CURTAIN CONSTRUCTION

SECTION 01 57 19 Page 3

3.18 DREDGE MATERIAL FOR UPLAND DISPOSAL

3.19 POST CONSTRUCTION CLEANUP

-- End of Section Table of Contents --

SECTION 01 57 19 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 62 35

RECYCLED / RECOVERED MATERIALS

03/17

PART 1 GENERAL

1.1 REFERENCES

1.2 OBJECTIVES

1.3 EPA DESIGNATED ITEMS INCORPORATED IN THE WORK

1.4 EPA PROPOSED ITEMS INCORPORATED IN THE WORK

1.5 EPA LISTED ITEMS USED IN CONDUCT OF THE WORK BUT NOT INCORPORATED

IN THE WORK

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

-- End of Section Table of Contents --

SECTION 01 62 35 Page 1

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 78 00

CLOSEOUT SUBMITTALS

03/17

PART 1 GENERAL

1.1 SUBMITTALS

1.2 PROJECT RECORD DOCUMENTS

1.2.1 Record Drawings

1.2.1.1 Government Furnished Materials

1.2.1.2 Working Record and Final Record Drawings

1.2.1.3 Drawing Preparation

1.2.1.4 Computer Aided Design and Drafting (CADD)

1.2.1.5 Payment

1.2.2 Final Approved Shop Drawings

1.2.3 Construction Contract Specifications

1.3 CLEANUP

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

-- End of Section Table of Contents --

SECTION 01 78 00 Page 1

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 90 00

MISCELLANEOUS PROVISIONS

02/12

PART 1 GENERAL

1.1 SUBMITTALS

1.2 PROJECT MANAGEMENT ORGANIZATION

1.2.1 General

1.2.2 Organization Plan

1.2.3 Organizational Changes

1.2.4 Project Manager

1.2.5 Project Superintendent

1.2.6 Booking Agent for Coordination with DOT Harbors

1.3 DOCUMENTATION OF MEETINGS

1.4 CONTRACTOR QUALITY CONTROL

1.5 AS-BUILT DRAWINGS

1.6 INSPECTION OF EXISTING CONDITIONS

1.7 PROTECTION

1.7.1 Warning Signs and Barricades

1.8 RESTORATION WORK

1.9 TITLE TO MATERIALS

1.10 RUBBISH AND DEBRIS

1.11 INTERFERENCE WITH GOVERNMENT OPERATIONS

1.11.1 Coordination

1.11.2 Materials and Equipment

1.11.3 Utilities and Facilities

1.11.4 Security

1.12 CONTRACTOR'S OPERATIONS AND STORAGE AREA (COSA)

1.13 GOVERNMENT PROJECT OFFICE

1.14 WORKING HOURS

1.15 WATER AND ENERGY CONSERVATION

1.16 ELECTRONIC FILES

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

-- End of Section Table of Contents --

SECTION 01 90 00 Page 1

SECTION TABLE OF CONTENTS

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

SECTION 35 20 23

DREDGING

04/06

PART 1 GENERAL

1.1 GENERAL SCOPE OF WORK

1.2 SUBMITTALS

1.2.1 Supplementary Submittal Descriptions

1.2.1.1 Subcontractor Qualifications (Hydrographic Surveyor)

1.2.1.2 Survey Control Plan

1.2.1.3 Pre-Construction and Post-Construction Bathymetric Survey

1.3 MATERIAL TO BE REMOVED

1.3.1 Hard Material

1.4 ARTIFICIAL OBSTRUCTIONS

1.5 QUANTITY OF MATERIAL

1.6 SIDE SLOPES

1.7 PERMIT

1.8 ENVIRONMENTAL PROTECTION

1.9 BASIS FOR BIDS

1.10 WIND, WAVE AND CURRENT DATA SOURCES

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 INSPECTION

3.2 CONDUCT OF DREDGING WORK

3.2.1 Order of Work

3.2.2 Interference with Navigation

3.2.2.1 Interruption of Operations

3.2.3 Lights

3.2.4 Ranges, Gages, and Lines

3.2.5 Plant

3.2.6 Offloading

3.2.7 Dewatering

3.2.8 Disposal of Excavated Material

3.2.9 Method of Disposal

3.2.10 Navigation Warnings

3.2.11 Method of Communication

3.2.12 Salvaged Material

3.2.13 Safety of Structures

3.2.14 Plant Removal

3.2.15 Coordination with Harbor Master

3.2.16 Removal of Artificial Obstructions

3.3 MEASUREMENT

3.3.1 Method of Measurement

3.3.2 Surveys During Progress of Work

3.3.3 Monthly Estimates

SECTION 35 20 23 Page 1

3.4 PROGRESS PAYMENT

3.5 FINAL EXAMINATION AND ACCEPTANCE

3.5.1 Sweeping and Post-Dredge Survey

3.5.2 Final Acceptance

-- End of Section Table of Contents --

SECTION 35 20 23 Page 2

SECTION TABLE OF CONTENTS

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

SECTION 35 20 23.13

NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SCOW - ULLAGE PROFILE

30 August 2019

PART 1 GENERAL

1.1 DESCRIPTION

1.2 SUBMITTALS

1.3 PAYMENT

1.4 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM CERTIFICATION

1.5 DREDGE PLANT INSTRUMENTATION PLAN (DPIP)

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION

3.1 REQUIREMENTS FOR REPORTED DATA

3.1.1 Scow Name

3.1.2 Contract Number

3.1.3 Load Number

3.1.4 Horizontal Positioning

3.1.5 Date and Time

3.1.6 Hull Status

3.1.6.1 Open-Water Disposal

3.1.6.2 Offloading

3.1.7 Course

3.1.8 Speed

3.1.9 Heading

3.1.10 Draft

3.1.11 Displacement

3.1.12 Bin Ullage Sounding

3.1.13 Bin Volume

3.2 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SYSTEM REQUIREMENTS

3.2.1 Telemetry

3.2.2 Data Reporting Frequency

3.2.3 Data Transmission to the Web Service

3.2.4 XML-Formatted Sensor Data String

3.2.5 Contractor Data Backup

3.3 PERFORMANCE REQUIREMENTS

3.4 LIST OF ITEMS TO BE PROVIDED BY THE CONTRACTOR

-- End of Section Table of Contents --

SECTION 35 20 23.13 Page 1

Honolulu Harbor Maintenance Dredge Sediment Characterization March 2015 Final Sediment Sampling Study Page 31

5.0 ANALYTICAL RESULTS

This section presents analytical results of sediment samples from eight DMMUs in Honolulu Harbor, and the reference samples from Lanikai Beach and South Oahu. Refer to Appendix C for a complete summary of the field sediment sample analyses in tabular format.

5.1 Physical Analyses

Sediment particle size showed the greatest amount of gravel and sand (primarily fine sand) at sites U1 and U7, the sites closest to the open ocean (Table 5-1). The gravel-size class material in DMMU U1 was comprised of broken coral reef fragments. Silt and clay made up between 61.1% and 83.9% (respectively) of the material at sites U2, U3a, U3b, U4, U5 and U6. DMMU U5, at the mouth of Nuuanu Stream, contained the highest percent of silt and clay (83.9%).

Table 5-1. Particle Size Distribution

Parameter Units Lanikai

Sand Reference

South Oahu

Reference U1 U2 U3a U3b U4 U5 U6 U7

Gravel % 0 0.2 0 0.6 0 2.4 8.8 0 0.1 0 Coarse Sand % 0.2 1.9 0.5 0.9 0.8 2.7 3 0.2 1.4 0.2 Medium Sand % 21.1 37.4 4.2 5.1 2.7 4.4 6.8 1.7 7.5 14.7 Fine Sand % 80.5 40.8 64.8 17.9 22.2 21.7 18.1 14.1 29.8 69.1 Silt % -4.1 13.1 9.2 37.9 30.2 25.9 29.9 43.7 30.3 0.7 Clay % 2.4 6.5 21.3 37.5 44 42.9 33.4 40.2 30.8 15.3

USCS

Classification None Sand Sand Sand Silty

Clay Clayey

Silt Clayey

Silt Clayey

Silt Silty Clay

Clayey Silt Sand

Notes:

% – Percent USCS – Unified Soil Classification System

O&M DREDGING

W9128A-20-B-0001

HONOLULU HARBOR

Section 01 57 19 - Page 1

(Am-0003)

ATTACHMENT 5

(CONTINUATION)

Notes: * Grain Size analysis was not conducted in the higher resolution analysis of U3a-2. Results from initial grain size analyses will be used to characterize the sub-DMMUs of U3a-2. USCS- Unified Soil Classification System

O&M DREDGING

W9128A-20-B-0001

HONOLULU HARBOR

Section 01 57 19 - Page 2

Honolulu Harbor Maintenance Dredging, Island of Oahu, State of Hawaii

W9128A-20-B-0001

RFI # Question Issued Response

There are several dredge areas immediately adjacent to the Federal Project Limit and Dredge Zone Limit line that are designated as suitable for ocean disposal. Please advise if the dredge material located within the 3 to 1 side slope areas that are located beyond the Federal Project Limit and Dredge Zone Limit line is also suitable for ocean disposal? If not, please confirm if the dredge material located beyond the Federal Project Limit and Dredge Zone Limit line is designated as unsuitable material and shall be disposed of at the upland facility

In all suitable dredge areas, the surrounding areas are also presumed suitable and accounted for in EPA's authorized dredged material disposal volume.

The side slopes surrounding unsuitable areas is presumed unsuitable and must be disposed of accordingly.

25 Is USACE able to provide soil characterizations for the project? See Am-0003, Section 01 57 19, Attachment 5, Continuation

Per Section 01 90 00 Page 6 paragraph 1.14b:

All work can be performed 24 hours a day, seven days a week with the following exceptions:

b. Within the Honolulu Harbor entrance channel, which shall be nighttime dredging to occur 8 days per month for 10- to 12-hour shifts.

Is this requirement per calendar month or 30-day time period?

The requirement is per month.

Per Section 01 90 00 Page 6 paragraph 1.14b:

All work can be performed 24 hours a day, seven days a week with the following exceptions:

b. Within the Honolulu Harbor entrance channel, which shall be nighttime dredging to occur 8 days per month for 10- to 12-hour shifts.

Can the 8 days be any otherwise approved 8 days out of the month period or are they a specific 8 days?

The 8 days per months are when night time dredging is allowed, are NOT specific days, and may NOT be consecutive days.

The schedule for work in the entrance channel will be coordinated between the Contractor, the Government, DOT Harbors Division, and harbor users based on the upcoming schedule of vessle calls.

Refer to information on coordnation meetings in Section 01 90 00, paragraph 1.3.

Will the trucking of dredge material from Pier 1 – Barge Offloading site at Kalaeloa Harbor to the designated Kalaeloa Barbers Point Harbor Contractor Operations and Storage and Dewatering Area be considered onsite hauling and be subject to the complying with the Davis Bacon Wage Determination document included in the specifications?

Ths solicitation requires the work to be in compliance with the most current Davis Bacon Wage Determination.

Will the trucking of dredge material from the designated Kalaeloa Barbers Point Harbor Contractor Operations and Storage and Dewatering Area to the PVT Landfill be considered offsite hauling and NOT be subject to the complying with the Davis Bacon Wage Determination document included in the specifications?

See response to RFI #28.

Section 00 73 00, Appendix B, Requests for Information - Page 1