16b1-Am2.pdf

1. CONTRACT ID CODE PAGE OF PAGES

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1 2

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

AM-0002 19 Feb 16

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

CECT – Contracting Division USACE, Honolulu District Bldg 252 (CECT-POH) Ft Shafter, HI 96858-5440

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State, and Zip Code) (x) 9A. AMENDMENT OF SOLICITATION NO.

W9128A-16-B-0001 X

9B. DATED (SEE ITEM 11)

01/27/2016

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

[ X ]The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers [ ] is extended, [ X ] is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning __1__ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

(x) A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor [ ] is not, [ ] is required to sign this document and return _ copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

FY16 PN80412 Health Clinic Parking Structure, Phase 1, Schofield Barracks, Oahu, Hawaii

See Page 2 of 2 Pages

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION UNUSABLE

30-105 STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Am-0002 Standard Form 30

RFP No. W9128A-16-B-0001 Page 2 of 2 Pages

Item No. 14 (Continued)

1. CHANGES TO SPECIFICATIONS. Attached hereto are revised pages/paragraphs to the specifications.

Revised pages replace like-numbered pages. The revision mark (Am-0002) is shown on each revised page.

A. REVISED SECTIONS / PARAGRAPHS. The following are revised sections / paragraphs to the specifications. Changes are indicated in bold and highlighted in yellow.

SF-30, Am-0001, Block 6.

Section 00 73 00, AT/OPSEC, iWatch

Section 00 73 00, clause S-36.5, Time for Unusually Severe Weather

B. REPLACED SECTION: The following sections are to be replaced in its entirety.

Section 00 72 00, Appendix A, Davis Bacon Wage Determination

C. REVISED SECTIONS / PARAGRAPHS. The following are revised sections / paragraphs to the specifications. Changes are indicated in bold.

Section 00 01 00, HUBZone Preference, Note 4, Note 6

Section 03 30 00.00 10, paragraphs 1.2, 1.5.1, 2.1.6 and 2.3

Section 32 05 33, paragraphs 2.2, 3.1, 3.2, 3.2.1, 3.3 and 3.4.4

D. NEW SECTIONS. The following sections are added.

Section 00 21 13, Sample Subcontracting Plan

Section 00 22 16, Map to Bldg 252, Fort Shafter

Section 00 73 00, Submittal of Bids

Section 00 73 00, Appendix C, Site Visit Attendees

Section 00 73 00, Appendix D, Requests for Information (RFIs)

2. CHANGES TO DRAWINGS.

A. REVISED DRAWINGS (ISSUED). The following revised drawings replace like-numbered drawings and are issued herewith:

Sheet ID Sheet Number: Mark: Revision Date:

G-003 3 OF 4 2 19 Feb 2016

G-004 4 OF 4 2 19 Feb 2016

CD101 14 OF 58 2 19 Feb 2016

CD102 15 OF 58 2 19 Feb 2016

CS104 20 OF 58 2 19 Feb 2016

CS503 25 OF 58 2 19 Feb 2016

CU101 32 OF 58 2 19 Feb 2016

CU103 34 OF 58 2 19 Feb 2016

CU301 35 OF 58 2 19 Feb 2016

M-502 11 OF 14 2 19 Feb 2016

M-601 12 OF 14 2 19 Feb 2016

3. The last date to submit RFIs is Tuesday, February 23, 2016 to dayna.n.matsumura@usace.army.mil and kent.a.tamai@usace.army.mil.

4. The bid opening date remains unchanged (See SF 1442, Page 1, Block 13A).

mailto:dayna.n.matsumura@usace.army.mil mailto:kent.a.tamai@usace.army.mil

(Am-0002)

1. CONTRACT ID CODE PAGE OF PAGES

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1 2

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

AM-0001 01 Feb 16

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

CECT – Contracting Division USACE, Honolulu District

Bldg 252 (CECT-POH)

Ft Shafter, HI 96858-5440

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State, and Zip Code) (x) 9A. AMENDMENT OF SOLICITATION NO.

X

9B. DATED (SEE ITEM 11)

01/27/2016

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

[ X ]The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers [ ] is extended, [ X ] is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning __1__ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

(x) A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor [ ] is not, [ ] is required to sign this document and return _ copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

FY16 PN80412 Health Clinic Parking Structure, Phase 1, Schofield Barracks, Oahu, Hawaii

See Page 2 of 2 Pages

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION UNUSABLE

30-105 STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

W9128A-16-B-0001

J3CT9DNM

Highlight

Section 00 73 00 - 1

(Am-0002)

AT-OPSEC

IWatch Training. IWATCH within the Army is a nation-wide modern version of a neighborhood watch program focused on the threat of terrorist activity. It is an antiterrorism awareness program that the contractors workforce, while on Army installations, must all be familiar with to promote and enhance reporting suspicious activity or behavior. The program has two elements: “passive” and “active.” The passive element is an individual’s situational awareness of his or her surroundings. The active element of iWATCH involves individuals taking action to report suspicious behavior or activities to law enforcement for more investigation.

Contractor personnel, to include subcontractors, performing on or within an Army controlled facility, area or on an Army installation are required to brief and train their personnel on the IWatch program for that area, facility or installation. Training standards will be provided by the COR with 5 calendar days of contract award. Contractor personnel are train all personnel within 30 days of award or within 30 days of a hiring action. Contractors are to report training to the COR within 45 days of contract award or a hiring action.

LEVEL I ANTITERRORISM (AT) STANDARDS

(a) Pursuant to Department of Defense Instruction Number 2000, “DoD Antiterrorism (AT) Standards,” dated October 2, 2006, each contractor employee requiring access to a Federally-controlled installation, facility and/or Federally-controlled information system(s) shall complete Level I AT Awareness Training on an annual basis and receive a certificate of completion. The training is accessible from any computer and is available at https://jkodirect.jten.mil (Course #JS-US007-14). The contractor is responsible for ensuring that all applicable employees have completed antiterrorism awareness training and shall certify that their workforce has completed the training through the submission of completion certificate (s) to the

Contracting Officer and the Contracting Officer’s Representative (if appointed) within five working days after contract award or prior to access to a Federally-controlled installation or information system.

(b) In the event that the automated system at https://jkodirect.jten.mil (Course #JS-US007-14) is not available (e.g., server problems), Level I AT Awareness Training can be provided by a qualified instructor.

However, if the training is not completed online, the Level I AT Awareness Instructor qualification must be coordinated with the Installation Antiterrorism Officer (or Installation Security equivalent) and the resultant name(s) of approved instructors shall be provided the contracting officer or designee along with all associated cost or schedule impacts to the contract. Antiterrorism performance (Level 1 AT Awareness

Training attendance and compliance) may be documented as a performance metric under the resultant contract, and be part of past performance information in support of future source selections.

ACCESS TO ARMY INSTALLATIONS – PERSONNEL and VEHICLES

(a) Commercial businesses must possess and present a contractor IAP to gain entry at any access control point (ACP). Installation Access Passes (IAP) are processed by the Installation Access Pass Office, Building 6508, Leilehua Golf Course.

(b) In order to obtain a contractor IAP, the A-E shall submit a hard copy spreadsheet, applied to a CD, with names and pertinent data of personnel requiring access to the base (sample attached). Letters signed by the prime A-E and its subconsultants, certifying that the information is current and accurate, shall accompany this request. USACE will submit an approved IAP application with the personnel information sheet to the

Installation Access Office. After the office has processed the paperwork (typically two days), the contractor may pick up his or her pass at the office. The contractor must bring some form of identification with proof of his or her social security number.

(c) Vendors and contractors with commercial vehicles who do business on Army installations on a regular https://jkodirect.jten.mil/ https://jkodirect.jten.mil/

Section 00 73 00 - 2

(Am-0002) basis can receive extended passes for individual and fleet vehicles, for periods stipulated by the

COR/sponsor, by registering their vehicles at the IAP Office. Company “Multiple Operator” memorandums will be presented to IAP personnel upon requesting a vehicle IAP.

(d) The Contractor shall provide to the Contracting Officer Representative the names and Social security

Numbers of individuals requiring access in performance of the contract no later than 14 days prior to start of performance. The Army Organization or Directorate for whom the contractor is working is responsible for processing the paperwork to obtain passes.

(e) The Contractor is responsible for assuring personnel required to access any installation in performance of the contract obtain the required identification. Costs for employees to travel to the Government location will be borne by the contractor. Failure to obtain required identification will not relieve the contractor from contract performance. Contractor shall be responsible for the return of identification cards upon the expiration of the contract or when an employee is no longer performing work under the contract.

(f) The Contractor will provide a list of the names of all employees and subcontractor employees who will access any Army facility in the performance of this contract. Contractor will provide written document used to verify employees and subcontractor's employees compliance with FAR 52.222-54, Employment

Eligibility Verification (clause that requires contractor to do background check.) The contractor will provide written proof from the Immigration and Naturalization Service that all employees listed are approved for employment within the US.

(g) At any time contractor employees are operating contractor-owned vehicles on an Army Installation, they shall have in their possession a letter signed by a corporate officer authorizing the individual to drive the vehicle.

(h) The Contracting Officer and the Provost Marshal office shall be notified of any changes in vehicles within three business days of the change.

(i) Lost vehicle passes shall be reported immediately in order to obtain new passes. All vehicle passes issued shall be returned to the Installation Access Office upon completion of the contract, termination of an employee or discontinued use of the registered vehicles.

(j) Failure to follow the procedures outlined above may result in delays in entering Army Installations. The

Government is not responsible for any adverse impact on the contractor or its operation as a result of delays due to the failure to register vehicles.

(k) Contractors operating vehicles on an Army post will not use cell phones unless used with a hands-free device. This applies to ALL personnel driving privately-owned and Government vehicles on Army installations and housing areas. Failure to comply will result in the loss of on-post driving privileges:

First offense – 14 days

Second offense – 30 days

Third offense – 180 days

If caught driving while privileges are suspended, your privileges may be further suspended for a 5-year period.

(l) The Provost Marshall has the authority to change the above procedures without notice. Contractors shall adhere to any changes in security procedures

[End of Statement]

Section 00 73 00

S-36.5 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the contract clause entitled DEFAULT (FIXED-PRICE CONSTRUCTION). In order for the

Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

2. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and

Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON 07 DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

4 5 6 4 3 3 3 4 3 5 4 7

3. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the

Contractor's scheduled work day. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph 2, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled DEFAULT (FIXED-PRICE CONSTRUCTION). [ER 415-1-15, 31 Oct

89]

00 72 00, Appendix A - 1

APPENDIX A - WAGE RATES

General Decision Number: HI160001 02/05/2016 HI1

Superseded General Decision Number: HI20150001

State: Hawaii

Construction Types: Building, Heavy (Heavy and Dredging), Highway and Residential

Counties: Hawaii Statewide.

BUILDING CONSTRUCTION PROJECTS; RESIDENTIAL CONSTRUCTION

PROJECTS (consisting of single family homes and apartments up to and including 4 stories); HEAVY AND HIGHWAY CONSTRUCTION

PROJECTS AND DREDGING

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.15 for calendar year 2016 applies to all contracts subject to the Davis-Bacon Act for which the solicitation was issued on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least

$10.15 (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2016. The EO minimum wage rate will be adjusted annually. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/08/2016

1 01/15/2016

2 01/22/2016

3 02/05/2016

ASBE0132-001 08/29/2010

Rates Fringes

Asbestos Workers/Insulator

Includes application of all insulating materials, protective coverings, coatings and finishes to all types of mechanical systems. Also the application of fire stopping material for wall openings and penetrations in walls, floors, ceilings and curtain walls...............$ 36.65 22.24

BOIL0627-005 01/01/2013

00 72 00, Appendix A - 2

BOILERMAKER......................$ 35.20 27.35

BRHI0001-001 09/03/2012

BRICKLAYER

Bricklayers and Stonemasons.$ 35.35 22.92

Pointers, Caulkers and

Weatherproofers.............$ 35.60 22.92

BRHI0001-002 09/02/2013

Tile, Marble & Terrazzo Worker

Terrazzo Base Grinders......$ 35.29 23.22

Terrazzo Floor Grinders and Tenders.................$ 32.24 23.22

Tile, Marble and Terrazzo

Workers.....................$ 37.10 23.22

CARP0745-001 08/31/2015

Carpenters:

Carpenters; Hardwood Floor

Layers; Patent Scaffold

Erectors (14 ft. and over); Piledrivers;

Pneumatic Nailers; Wood

Shinglers and Transit and/or Layout Man...........$ 43.90 20.92

Millwrights and Machine

Erectors....................$ 44.15 20.92

Power Saw Operators (2 h.p. and over)..............$ 44.05 20.92

CARP0745-002 08/31/2015

Drywall and Acoustical

Workers and Lathers..............$ 44.15 20.92

ELEC1186-001 08/22/2015

Electricians:

Cable Splicers..............$ 47.36 28.53

Electricians................$ 43.05 27.22

Telecommunication worker....$ 26.30 11.58

00 72 00, Appendix A - 3

ELEC1186-002 08/22/2015

Line Construction:

Cable Splicers..............$ 47.36 28.53

Groundmen/Truck Drivers.....$ 32.29 23.93

Heavy Equipment Operators...$ 38.75 25.91

Linemen.....................$ 43.05 27.22

Telecommunication worker....$ 26.30 11.58

ELEV0126-001 01/01/2015

ELEVATOR MECHANIC................$ 53.07 28.38

a. VACATION: Employer contributes 8% of basic hourly rate for

5 years service and 6% of basic hourly rate for 6 months to

5 years service as vacation pay credit.

b. PAID HOLIDAYS: New Year's Day, Memorial Day, Independence

Day, Labor Day, Veterans' Day, Thanksgiving Day, the Friday after Thanksgiving Day and Christmas Day.

* ENGI0003-002 08/31/2015

Diver (Aqua Lung) (Scuba))

Diver (Aqua Lung) (Scuba)

(over a depth of 30 feet)...$ 62.50 27.98

Diver (Aqua Lung) (Scuba)

(up to a depth of 30 feet)..$ 53.13 27.98

Stand-by Diver (Aqua Lung)

(Scuba)....................$ 43.75 27.98

Diver (Other than Aqua Lung)

Diver (Other than Aqua

Lung).......................$ 62.50 27.98

Diver Tender (Other than

Aqua Lung)..................$ 40.72 27.98

Stand-by Diver (Other than

Aqua Lung)..................$ 43.75 27.98

Helicopter Work

Airborne Hoist Operator for Helicopter..............$ 42.30 27.98

Co-Pilot of Helicopter......$ 42.44 27.98

Pilot of Helicopter.........$ 42.61 27.98

Power equipment operator -tunnel work

GROUP 1....................$ 38.74 27.98

GROUP 2....................$ 38.85 27.98

GROUP 3....................$ 39.02 27.98

GROUP 4....................$ 39.29 27.98

GROUP 5....................$ 39.60 27.98

00 72 00, Appendix A - 4

GROUP 6....................$ 40.25 27.98

GROUP 7....................$ 40.57 27.98

GROUP 8....................$ 40.68 27.98

GROUP 9....................$ 40.79 27.98

GROUP 9A...................$ 41.02 27.98

GROUP 10....................$ 41.08 27.98

GROUP 10A...................$ 41.23 27.98

GROUP 11....................$ 41.38 27.98

GROUP 12....................$ 41.74 27.98

GROUP 12A...................$ 42.10 27.98

Power equipment operators:

GROUP 1....................$ 38.44 27.98

GROUP 2....................$ 38.55 27.98

GROUP 3....................$ 38.72 27.98

GROUP 4....................$ 38.99 27.98

GROUP 5....................$ 39.30 27.98

GROUP 6....................$ 39.95 27.98

GROUP 7....................$ 40.27 27.98

GROUP 8....................$ 40.38 27.98

GROUP 9....................$ 40.49 27.98

GROUP 9A...................$ 40.72 27.98

GROUP 10....................$ 40.78 27.98

GROUP 10A...................$ 40.93 27.98

GROUP 11....................$ 41.08 27.98

GROUP 12....................$ 41.44 27.98

GROUP 12A...................$ 41.80 27.98

GROUP 13....................$ 38.72 27.98

GROUP 13A...................$ 38.99 27.98

GROUP 13B...................$ 39.30 27.98

GROUP 13C...................$ 39.95 27.98

GROUP 13D...................$ 40.27 27.98

GROUP 13E...................$ 40.38 27.98

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Fork Lift (up to and including 10 tons); Partsman

(heavy duty repair shop parts room when needed).

GROUP 2: Conveyor Operator (Handling building material);

Hydraulic Monitor; Mixer Box Operator (Concrete Plant).

GROUP 3: Brakeman; Deckhand; Fireman; Oiler;

Oiler/Gradechecker; Signalman; Switchman; Highline Cableway

Signalman; Bargeman; Bunkerman; Concrete Curing Machine

(self-propelled, automatically applied unit on streets, highways, airports and canals); Leveeman; Roller (5 tons and under); Tugger Hoist.

GROUP 4: Boom Truck or dual purpose "A" Frame Truck (5 tons or less); Concrete Placing Boom (Building Construction);

Dinky Operator; Elevator Operator; Hoist and/or Winch (one drum); Straddle Truck (Ross Carrier, Hyster and similar).

GROUP 5: Asphalt Plant Fireman; Compressors, Pumps, Generators and Welding Machines ("Bank" of 9 or more, individually or collectively); Concrete Pumps or Pumpcrete

Guns; Lubrication and Service Engineer (Grease Rack);

00 72 00, Appendix A - 5

Screedman.

GROUP 6: Boom Truck or Dual Purpose "A" Frame Truck (over 5 tons); Combination Loader/Backhoe (up to and including 3/4

cu. yd.); Concrete Batch Plants (wet or dry); Concrete

Cutter, Groover and/or Grinder (self-propelled unit on streets, highways, airports, and canals); Conveyor or

Concrete Pump (Truck or Equipment Mounted); Drilling

Machinery (not to apply to waterliners, wagon drills or jack hammers); Fork Lift (over 10 tons); Loader (up to and including 3 and 1/2 cu. yds); Lull High Lift (under 40 feet); Lubrication and Service Engineer (Mobile); Maginnis

Internal Full Slab Vibrator (on airports, highways, canals and warehouses); Man or Material Hoist; Mechanical Concrete

Finisher (Large Clary, Johnson Bidwell, Bridge Deck and similar); Mobile Truck Crane Driver; Portable Shotblast

Concrete Cleaning Machine; Portable Boring Machine (under streets, highways, etc.); Portable Crusher; Power Jumbo

Operator (setting slip forms, etc., in tunnels); Rollers

(over 5 tons); Self-propelled Compactor (single engine);

Self-propelled Pavement Breaker; Skidsteer Loader with attachments; Slip Form Pumps (Power driven by hydraulic, electric, air, gas, etc., lifting device for concrete forms); Small Rubber Tired Tractors; Trencher (up to and including 6 feet); Underbridge Personnel Aerial Platform

(50 feet of platform or less).

GROUP 7: Crusher Plant Engineer, Dozer (D-4, Case 450, John

Deere 450, and similar); Dual Drum Mixer, Extend Lift;

Hoist and/or Winch (2 drums); Loader (over 3 and 1/2 cu.

yds. up to and including 6 yards.); Mechanical Finisher or

Spreader Machine (asphalt), (Barber Greene and similar)

(Screedman required); Mine or Shaft Hoist; Mobile Concrete

Mixer (over 5 tons); Pipe Bending Machine (pipelines only);

Pipe Cleaning Machine (tractor propelled and supported);

Pipe Wrapping Machine (tractor propelled and supported);

Roller Operator (Asphalt); Self-Propelled Elevating Grade

Plane; Slusher Operator; Tractor (with boom) (D-6, or similar); Trencher (over 6 feet and less than 200 h.p.);

Water Tanker (pulled by Euclids, T-Pulls, DW-10, 20 or 21, or similar); Winchman (Stern Winch on Dredge).

GROUP 8: Asphalt Plant Operator; Barge Mate (Seagoing);

Cast-in-Place Pipe Laying Machine; Concrete Batch Plant

(multiple units); Conveyor Operator (tunnel); Deckmate;

Dozer (D-6 and similar); Finishing Machine Operator

(airports and highways); Grade setter; Kolman Loader (and similar); Mucking Machine (Crawler-type); Mucking Machine

(Conveyor-type); No-Joint Pipe Laying Machine; Portable

Crushing and Screening Plant; Power Blade Operator (under

12); Saurman Type Dragline (up to and including 5 yds.);

Stationary Pipe Wrapping, Cleaning and Bending Machine;

Surface Heater and Planer Operator, Tractor (D-6 and similar); Tri-Batch Paver; Tunnel Badger; Tunnel Mole and/or Boring Machine Operator Underbridge Personnel Aerial

Platform (over 50 feet of platform).

00 72 00, Appendix A - 6

GROUP 9: Combination Mixer and Compressor (gunite); Do-Mor

Loader and Adams Elegrader; Dozer (D-7 or equal); Wheel and/or Ladder Trencher (over 6 feet and 200 to 749 h.p.).

GROUP 9A: Dozer (D-8 and similar); Gradesetter (when required by the Contractor to work from drawings, plans or specifications without the direct supervision of a foreman or superintendent); Push Cat; Scrapers (up to and including

20 cu. yds); Self-propelled Compactor with Dozer;

Self-Propelled, Rubber-Tired Earthmoving Equipment (up to and including 20 cu. yds) (621 Band and similar); Sheep's

Foot; Tractor (D-8 and similar); Tractors with boom (larger than D-6, and similar).

GROUP 10: Chicago Boom; Cold Planers; Heavy Duty Repairman or

Welder; Hoist and/or Winch (3 drums); Hydraulic Skooper

(Koehring and similar); Loader (over 6 cu. yds. up to and including 12 cu. yds.); Saurman type Dragline (over 5 cu.

yds.); Self-propelled, rubber-tired Earthmoving Equipment

(over 20 cu. yds. up to and including 31 cu. yds.) (637D and similar); Soil Stabilizer (P & H or equal); Sub-Grader

(Gurries or other automatic type); Tractors (D-9 or equivalent, all attachments); Tractor (Tandem Scraper);

Watch Engineer.

GROUP 10A: Boat Operator; Cable-operated Crawler Crane (up to and including 25 tons); Cable-operated Power Shovel, Clamshell, Dragline and Backhoe (up to and including 1 cu.

yd.); Dozer D9-L; Dozer (D-10, HD41 and similar) (all attachments); Gradall (up to and including 1 cu. yd.);

Hydraulic Backhoe (over 3/4 cu. yds. up to and including 2

cu. yds.); Mobile Truck Crane Operator (up to and including

25 tons) (Mobile Truck Crane Driver Required);

Self-propelled Boom Type Lifting Device (Center Mount) (up to and including 25 tons) (Grove, Drott, P&H, Pettibone and similar; Trencher (over 6 feet and 750 h.p. or more); Watch

Engineer (steam or electric).

GROUP 11: Automatic Slip Form Paver (concrete or asphalt);

Band Wagon (in conjunction with Wheel Excavator);

Cable-operated Crawler Cranes (over 25 tons but less than

50 tons); Cable-operated Power Shovel, Clamshell, Dragline and Backhoe (over 1 cu. yd. up to 7 cu. yds.); Gradall

(over 1 cu. yds. up to 7 cu. yds.); DW-10, 20, etc.

(Tandem); Earthmoving Machines (multiple propulsion power units and 2 or more Scrapers) (up to and including 35 cu.

yds.," struck" m.r.c.); Highline Cableway; Hydraulic

Backhoe (over 2 cu. yds. up to and including 4 cu. yds.);

Leverman; Lift Slab Machine; Loader (over 12 cu. yds);

Master Boat Operator; Mobile Truck Crane Operator (over 25 tons but less than 50 tons); (Mobile Truck Crane Driver required); Pre-stress Wire Wrapping Machine; Self-propelled

Boom-type Lifting Device (Center Mount) (over 25 tons m.r.c); Self-propelled Compactor (with multiple-propulsion power units); Single Engine Rubber Tired Earthmoving

Machine (with Tandem Scraper); Tandem Cats; Trencher

(pulling attached shield).

00 72 00, Appendix A - 7

GROUP 12: Clamshell or Dipper Operator; Derricks; Drill Rigs;

Multi-Propulsion Earthmoving Machines (2 or more Scrapers)

(over 35 cu. yds "struck" m.r.c.); Operators (Derricks, Piledrivers and Cranes); Power Shovels and Draglines (7 cu.

yds. m.r.c. and over); Self-propelled rubber-tired

Earthmoving equipment (over 31 cu. yds.) (657B and similar); Wheel Excavator (up to and including 750 cu. yds.

per hour); Wheel Excavator (over 750 cu. yds. per hour).

GROUP 12A: Dozer (D-11 or similar or larger); Hydraulic

Excavators (over 4 cu. yds.); Lifting cranes (50 tons and over); Pioneering Dozer/Backhoe (initial clearing and excavation for the purpose of providing access for other equipment where the terrain worked involves 1-to-1 slopes that are 50 feet in height or depth, the scope of this work does not include normal clearing and grubbing on usual hilly terrain nor the excavation work once the access is provided); Power Blade Operator (Cat 12 or equivalent or over); Straddle Lifts (over 50 tons); Tower Crane, Mobile;

Traveling Truss Cranes; Universal, Liebher, Linden, and similar types of Tower Cranes (in the erection, dismantling, and moving of equipment there shall be an additional Operating Engineer or Heavy Duty Repairman);

Yo-Yo Cat or Dozer.

GROUP 13: Truck Driver (Utility, Flatbed, etc.)

GROUP 13A: Dump Truck, 8 cu. yds. and under (water level);

Water Truck (up to and including 2,000 gallons).

GROUP 13B: Water Truck (over 2,000 gallons); Tandem Dump

Truck, over 8 cu. yds. (water level).

GROUP 13C: Truck Driver (Semi-trailer. Rock Cans, Semi-Dump or Roll-Offs).

GROUP 13D: Truck Driver (Slip-In or Pup).

GROUP 13E: End Dumps, Unlicensed (Euclid, Mack, Caterpillar or similar); Tractor Trailer (Hauling Equipment); Tandem

Trucks hooked up to Trailer (Hauling Equipment)

BOOMS AND/OR LEADS (HOURLY PREMIUMS):

The Operator of a crane (under 50 tons) with a boom of 80 feet or more (including jib), or of a crane (under 50 tons) with leads of 100 feet or more, shall receive a per hour premium for each hour worked on said crane (under 50 tons) in accordance with the following schedule:

Booms of 80 feet up to but not including 130 feet or

Leads of 100 feet up to but not including 130 feet 0.50

Booms and/or Leads of 130 feet

00 72 00, Appendix A - 8 up to but not including 180 feet 0.75

Booms and/or Leads of 180 feet up to and including 250 feet 1.15

Booms and/or Leads over 250 feet 1.50

The Operator of a crane (50 tons and over) with a boom of 180 feet or more (including jib) shall receive a per hour premium for each hour worked on said crane (50 tons and over) in accordance with the following schedule:

Booms of 180 feet up to and including 250 feet 1.25

Booms over 250 feet 1.75

* ENGI0003-004 09/01/2015

Dredging: (Boat Operators)

Boat Deckhand...............$ 38.72 27.98

Boat Operator...............$ 40.93 27.98

Master Boat Operator........$ 41.08 27.98

Dredging: (Clamshell or

Dipper Dredging)

GROUP 1.....................$ 41.44 27.98

GROUP 2.....................$ 40.78 27.98

GROUP 3.....................$ 40.38 27.98

GROUP 4.....................$ 38.72 27.98

Dredging: (Derricks)

GROUP 1.....................$ 41.44 27.98

GROUP 2.....................$ 40.78 27.98

GROUP 3.....................$ 40.38 27.98

GROUP 4.....................$ 38.72 27.98

Dredging: (Hydraulic Suction

Dredges)

GROUP 1.....................$ 41.08 27.98

GROUP 2.....................$ 40.93 27.98

GROUP 3.....................$ 40.78 27.98

GROUP 4.....................$ 40.72 27.98

GROUP 5.....................$ 37.88 26.76

Group 5.....................$ 40.38 27.98

GROUP 6.....................$ 37.77 26.76

Group 6.....................$ 40.27 27.98

GROUP 7.....................$ 36.22 26.76

Group 7.....................$ 38.72 27.98

CLAMSHELL OR DIPPER DREDGING CLASSIFICATIONS

GROUP 1: Clamshell or Dipper Operator.

GROUP 2: Mechanic or Welder; Watch Engineer.

GROUP 3: Barge Mate; Deckmate.

GROUP 4: Bargeman; Deckhand; Fireman; Oiler.

HYDRAULIC SUCTION DREDGING CLASSIFICATIONS

GROUP 1: Leverman.

00 72 00, Appendix A - 9

GROUP 2: Watch Engineer (steam or electric).

GROUP 3: Mechanic or Welder.

GROUP 4: Dozer Operator.

GROUP 5: Deckmate.

GROUP 6: Winchman (Stern Winch on Dredge)

GROUP 7: Deckhand (can operate anchor scow under direction of

Deckmate); Fireman; Leveeman; Oiler.

DERRICK CLASSIFICATIONS

GROUP 1: Operators (Derricks, Piledrivers and Cranes).

GROUP 2: Saurman Type Dragline (over 5 cubic yards).

GROUP 3: Deckmate; Saurman Type Dragline (up to and including 5 yards).

GROUP 4: Deckhand, Fireman, Oiler.

* ENGI0003-044 08/31/2015

Power Equipment Operators

(PAVING)

(10) Cold Planer............$ 40.25 27.87

(10)Loader (2 1/2 cu. yds.

and under)..................$ 39.42 27.87

(10)Soil Stabilizer.........$ 40.25 27.87

(11)Loader (over 2 1/2 cu.

yds. to and including 5

cu. yds.)...................$ 39.74 27.87

(3)Roller Operator (five tons and under).............$ 38.19 27.87

(5)Screed Person............$ 39.42 27.87

(6)Combination

Loader/Backhoe (up to 3/4 cu.yd.).....................$ 37.48 27.87

(6)Concrete Saws and/or

Grinder (self-propelled unit on streets, highways, airports and canals)........$ 39.42 27.87

(6)Roller Operator (over five tons)..................$ 39.62 27.87

(7)Combination

Loader/Backhoe (over 3/4 cu.yd.).....................$ 38.46 27.87

(8) Asphalt Plant Operator..$ 39.89 27.87

Asphalt Concrete Material

Transfer....................$ 39.42 27.87

Asphalt Raker...............$ 38.46 27.87

Asphalt Spreader Operator...$ 39.94 27.87

Grader......................$ 40.25 27.87

Laborer, Hand Roller........$ 37.96 27.87

IRON0625-001 09/01/2014

00 72 00, Appendix A - 10

Ironworkers:.....................$ 35.75 29.01

a. Employees will be paid $.50 per hour more while working in tunnels and coffer dams; $1.00 per hour more when required to work under or are covered with water (submerged) and when they are required to work on the summit of Mauna Kea, Mauna Loa or

Haleakala.

LABO0368-001 08/31/2015

Laborers:

Driller.....................$ 35.35 17.51

Final Clean Up..............$ 25.75 13.34

Gunite/Shotcrete Operator and High Scaler.............$ 34.85 17.51

Laborer I...................$ 34.35 17.51

Laborer II..................$ 31.75 17.51

Mason Tender/Hod Carrier....$ 34.85 17.51

Powderman...................$ 35.35 17.51

Window Washer (bosun chair).$ 33.85 17.51

LABORERS CLASSIFICATIONS

Laborer I: Air Blasting run by electric or pneumatic compressor; Asphalt Laborer, Ironer, Raker, Luteman, and

Handroller, and all types of Asphalt Spreader Boxes;

Asphalt Shoveler; Assembly and Installation of Multiplates, Liner Plates, Rings, Mesh, Mats; Batching Plant (portable and temporary); Boring Machine Operator (under streets and sidewalks); Buggy mobile; Burning and Welding; Chainsaw, Faller, Log loader, and Bucker; Compactors (Jackson Jumping

Jack and similar); Concrete Bucket Dumpman; Concrete

Chipping; Concrete Chuteman/Hoseman (pouring concrete) (the handling of the chute from ready-mix trucks for such jobs as walls, slabs, decks, floors, foundations, footings, curbs, gutters, and sidewalks); Concrete Core Cutter

(Walls, Floors, and Ceiling); Concrete Grinding or Sanding;

Concrete: Hooking on, signaling, dumping of concrete for extreme work over water on caissons, pilings, abutments, etc.; Concrete: Mixing, handling, conveying, pouring, vibrating, otherwise placing of concrete or aggregates or by any other process; Concrete: Operation of motorized wheelbarrows or buggies or machines of similar character, whether run by gas, diesel, or electric power; Concrete

Placement Machine Operator: operation of Somero Hammerhead, Copperheads, or similar machines; Concrete Pump Machine

(laying, coupling, uncoupling of all connections and cleaning of equipment); Concrete and/or Asphalt Saw

(Walking or Handtype) (cutting walls or flatwork) (scoring old or new concrete and/or asphalt) (cutting for expansion joints) (streets and ways for laying of pipe, cable or conduit for all purposes); Concrete Shovelers/Laborers (Wet or Dry); Concrete Screeding for Rough Strike-Off: Rodding or striking-off, by hand or mechanical means prior to finishing; Concrete Vibrator Operator; Coring Holes: Walls, footings, piers or other obstructions for passage of pipes

00 72 00, Appendix A - 11 or conduits for any purpose and the pouring of concrete to secure the hole; Cribbers, Shorer, Lagging, Sheeting, and

Trench Jacking and Bracing, Hand-Guided Lagging Hammer

Whaling Bracing; Curbing (Concrete and Asphalt); Curing of

Concrete (impervious membrane and form oiler) mortar and other materials by any mode or method; Cut Granite Curb

Setter (setting, leveling and grouting of all precast concrete or stone curbs); Cutting and Burning Torch

(demolition); Dri Pak-It Machine; Environmental Abatement:

removal of asbestos, lead, and bio hazardous materials (EPA and/or OSHA certified); Falling, bucking, yarding, loading or burning of all trees or timber on construction site;

Forklift (9 ft. and under); Gas, Pneumatic, and Electric tools; Grating and Grill work for drains or other purposes;

Green Cutter of concrete or aggregate in any form, by hand, mechanical means, grindstone or air and/or water; Grout:

Spreading for any purpose; Guinea Chaser (Grade Checker) for general utility trenches, sitework, and excavation;

Headerboard Man (Asphalt or Concrete); Heat Welder of

Plastic (Laborers' AGC certified workers) (when work involves waterproofing for waterponds, artificial lakes and reservoir) heat welding for sewer pipes and fusion of HDPE pipes; Heavy Highway Laborer (Rigging, signaling, handling, and installation of pre-cast catch basins, manholes, curbs and gutters); High Pressure Nozzleman - Hydraulic Monitor

(over 100# pressure); Jackhammer Operator; Jacking of slip forms: All semi and unskilled work connected there within;

Laying of all multi-cell conduit or multi-purpose pipe;

Magnesite and Mastic Workers (Wet or Dry)(including mixer operator);Mortar Man; Mortar Mixer (Block, Brick, Masonry, and Plastering); Nozzleman (Sandblasting and/or Water

Blasting): handling, placing and operation of nozzle;

Operation, Manual or Hydraulic jacking of shields and the use of such other mechanical equipment as may be necessary;

Pavement Breakers; Paving, curbing and surfacing of streets, ways, courts, under and overpasses, bridges, approaches, slope walls, and all other labor connected therewith; Pilecutters; Pipe Accessment in place, bolting and lining up of sectional metal or other pipe including corrugated pipe; Pipelayer performing all services in the laying and installation of pipe from the point of receiving pipe in the ditch until completion of operation, including any and all forms of tubular material, whether pipe, HDPE, metallic or non-metallic, conduit, and any other stationary-type of tubular device used for conveying of any substance or element, whether water, sewage, solid, gas, air, or other product whatsoever and without regard to the nature of material from which tubular material is fabricated; No-joint pipe and stripping of same, Pipewrapper, Caulker, Bander, Kettlemen, and men applying asphalt, Laykold, treating Creosote and similar-type materials (6-inch) pipe and over); Piping: resurfacing and paving of all ditches in preparation for laying of all pipes; Pipe laying of lateral sewer pipe from main or side sewer to buildings or structure (except Contactor may direct work be done under proper supervision); Pipe laying, leveling and marking of the joint used for main or side

00 72 00, Appendix A - 12 sewers and storm sewers; Laying of all clay, terra cotta, ironstone, vitrified concrete, HDPE or other pipe for drainage; Placing and setting of water mains, gas mains and all pipe including removal of skids; Plaster Mortar

Mixer/Pump; Pneumatic Impact Wrench; Portable Sawmill

Operation: Choker setters, off bearers, and lumber handlers connected with clearing; Posthole Digger (Hand Held, Gas, Air and Electric); Powderman's Tender; Power Broom Sweepers

(Small); Preparation and Compaction of roadbeds for railroad track laying, highway construction, and the preparation of trenches, footings, etc., for cross-country transmission by pipelines, electrical transmission or underground lines or cables (by mechanical means); Raising of structure by manual or hydraulic jacks or other methods and resetting of structure in new locations, including all concrete work; Ramming or compaction; Rigging in connection with Laborers' work (except demolition), Signaling

(including the use of walkie talkie) Choke Setting, tag line usage; Tagging and Signaling of building materials into high rise units; Riprap, Stonepaver, and Rock Slinger

(includes placement of stacked concrete, wet or dry and loading, unloading, signaling, slinging and setting of other similar materials); Rotary Scarifier (including multiple head concrete chipping Scarifier); Salamander

Heater, Drying of plaster, concrete mortar or other aggregate; Scaffold Erector Leadman; Scaffolds: (Swing and hanging) including maintenance thereof; Scaler; Septic

Tank/Cesspool and Drain Fields Digger and Installer;

Shredder/Chipper (tree branches, brush, etc.); Stripping and Setting Forms; Stripping of Forms: Other than panel forms which are to be re-used in their original form, and stripping of forms on all flat arch work; Tampers (Barko, Wacker, and similar type); Tank Scaler and Cleaners;

Tarman; Tree Climbers and Trimmers; Trencher (includes hand-held, Davis T-66 and similar type); Trucks (flatbed up to and including 2 1/2 tons when used in connection with on-site Laborers' work; Trucks (Refuse and Garbage Disposal)

(from job site to dump); Vibra-Screed (Bull Float in connection with Laborers' work); Well Points, Installation of or any other dewatering system.

Laborer II: Asphalt Plant Laborer; Boring Machine Tender;

Bridge Laborer; Burning of all debris (crates, boxes, packaging waste materials); Chainman, Rodmen, and Grade

Markers; Cleaning, clearing, grading and/or removal for streets, highways, roadways, aprons, runways, sidewalks, parking areas, airports, approaches, and other similar installations; Cleaning or reconditioning of streets, ways, sewers and waterlines, all maintenance work and work of an unskilled and semi-skilled nature; Concrete Bucket Tender

(Groundman) hooking and unhooking of bucket; Concrete

Forms; moving, cleaning, oiling and carrying to the next point of erection of all forms; Concrete Products Plant

Laborers; Conveyor Tender (conveying of building materials); Crushed Stone Yards and Gravel and Sand Pit

Laborers and all other similar plants; Demolition, Wrecking and Salvage Laborers: Wrecking and dismantling of buildings

00 72 00, Appendix A - 13 and all structures, with use of cutting or wrecking tools, breaking away, cleaning and removal of all fixtures, All hooking, unhooking, signaling of materials for salvage or scrap removed by crane or derrick; Digging under streets, roadways, aprons or other paved surfaces; Driller's Tender;

Chuck Tender, Outside Nipper; Dry-packing of concrete

(plugging and filling of she-bolt holes); Fence and/or

Guardrail Erector: Dismantling and/or re-installation of all fence; Finegrader; Firewatcher; Flagman (Coning, preparing, establishing and removing portable roadway barricade devices); Signal Men on all construction work defined herein, including Traffic Control Signal Men at construction site; General Excavation; Backfilling, Grading and all other labor connected therewith; Digging of trenches, ditches and manholes and the leveling, grading and other preparation prior to laying pipe or conduit for any purpose; Excavations and foundations for buildings, piers, foundations and holes, and all other construction.

Preparation of street ways and bridges; General Laborer:

Cleaning and Clearing of all debris and surplus material.

Clean-up of right-of-way. Clearing and slashing of brush or trees by hand or mechanical cutting. General Clean up:

sweeping, cleaning, wash-down, wiping of construction facility and equipment (other than "Light Clean up

(Janitorial) Laborer. Garbage and Debris Handlers and

Cleaners. Appliance Handling (job site) (after delivery unlading in storage area); Ground and Soil Treatment Work

(Pest Control); Gunite/Shotcrete Operator Tender; Junk Yard

Laborers (same as Salvage Yard); Laser Beam "Target Man" in connection with Laborers' work; Layout Person for Plastic

(when work involves waterproofing for waterponds, artificial lakes and reservoirs); Limbers, Brush Loaders, and Pilers; Loading, Unloading, carrying, distributing and handling of all rods and material for use in reinforcing concrete construction (except when a derrick or outrigger operated by other than hand power is used); Loading, unloading, sorting, stockpiling, handling and distribution of water mains, gas mains and all pipes; Loading and unloading of all materials, fixtures, furnishings and appliances from point of delivery to stockpile to point of installation; hooking and signaling from truck, conveyance or stockpile; Material Yard Laborers; Pipelayer Tender;

Pipewrapper, Caulker, Bander, Kettlemen, and men applying asphalt, Laykold, Creosote, and similar-type materials

(pipe under 6 inches); Plasterer Laborer; Preparation, construction and maintenance of roadbeds and sub-grade for all paving, including excavation, dumping, and spreading of sub-grade material; Prestressed or precast concrete slabs, walls, or sections: all loading, unloading, stockpiling, hooking on of such slabs, walls or sections; Quarry

Laborers; Railroad, Streetcar, and Rail Transit Maintenance and Repair; Roustabout; Rubbish Trucks in connection with

Building Construction Projects (excluding clearing, grubbing, and excavating); Salvage Yard: All work connected with cutting, cleaning, storing, stockpiling or handling of materials, all cleanup, removal of debris, burning, back-filling and landscaping of the site; Sandblasting

00 72 00, Appendix A - 14

Tender (Pot Tender): Hoses and pots or markers; Scaffolds:

Erection, planking and removal of all scaffolds used for support for lathers, plasters, brick layers, masons, and other construction trades crafts; Scaffolds: (Specially designed by carpenters) laborers shall tend said carpenter on erection and dismantling thereof, preparation for foundation or mudsills, maintenance; Scraping of floors;

Screeds: Handling of all screeds to be reused; handling, dismantling and conveyance of screeds; Setting, leveling and securing or bracing of metal or other road forms and expansion joints; Sheeting Piling/trench shoring (handling and placing of skip sheet or wood plank trench shoring);

Ship Scalers; Shipwright Tender; Sign Erector (subdivision traffic, regulatory, and street-name signs); Sloper; Slurry

Seal Crews (Mixer Operator, Applicator, Squeegee Man, Shuttle Man, Top Man); Snapping of wall ties and removal of tie rods; Soil Test operations of semi and unskilled labor such as filling sand bags; Striper (Asphalt, Concrete or other Paved Surfaces); Tool Room Attendant (Job Site);

Traffic Delineating Device Applicator; Underpinning, lagging, bracing, propping and shoring, loading, signaling, right-of-way clearance along the route of movement, The clearance of new site, excavation of foundation when moving a house or structure from old site to new site; Utilities employees; Water Man; Waterscape/Hardscape Laborers; Wire

Mesh Pulling (all concrete pouring operations); Wrecking, stripping, dismantling and handling concrete forms an false work.

LABO0368-002 09/01/2015

Landscape & Irrigation

Laborers

GROUP 1.....................$ 23.70 10.67

GROUP 2.....................$ 24.30 10.67

GROUP 3.....................$ 19.95 10.67

LABORERS CLASSIFICATIONS

GROUP 1: Installation of non-potable permanent or temporary irrigation water systems performed for the purposes of

Landscaping and…