Amendment_0001_17R0002dated16Jun2017.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

1. This amendment is issued to provide updated and revisied infomation according to the attached documents for Solicitation No .W91243-17-R-0002, Repair Building 600 at the Lincoln ANG Base, Lincoln, NE.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 16-Jun-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W91243-17-R-0002

X 9B. DATED (SEE ITEM 11)

08-Jun-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

16-Jun-2017

CODE

USPFO FOR NEBRASKA

2433 NW 24TH ST

LINCOLN NE 68524

W91243 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W91243-17-R-0002

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0001

See the attached documents for all updates and revisions to the solicitation.

Document Name Amendment 0001_16June2017 Specification Section 07_22_70 fall protection devices Specification Section 21_13_40 Hangar Foam with UFC4-211-01 dated 6-09-2017 Specification Section 28_31_00 Master Fire Alarm Specification dated 6-09-2017 Drawing E503 date stamped 6/14/2017 Drawing FA000 - Notes only dated 6/14/2017 Drawing FA001 dated 6/14/2017 Drawing FP501 dated 6/14/2017 Drawing SDP-01 dated 6/14/2017

Incorporate all information as per the document Amendment 0001 dated 16 June 2017.

NOTHING FOLLOWS.

SECTION 00700 - CONTRACT CLAUSES

The following have been deleted:

52.228-11 Pledges Of Assets JAN 2012 52.228-14 Irrevocable Letter of Credit NOV 2014

(End of Summary of Changes)

Amendment 0001 16 June 2017 Solicitation No. W9124317R0002 Repair Building 600, Maintenance Hangar

This information is provided as Amendment 0001. See the Attachments for the specifications and drawings referred to in the below information.

Architectural & Civil

1) Question: Proposed PCC pavement interface with existing PCC pavement is to be doweled. Do the joints match?

Response: If doweled and joints do not match, this will create influence cracking across this interface, therefore the doweled joints shall match.

2) Clarification: Referenced Construction Note 28 on Sheet C1-01 shall be revised to read “CONTRACTOR SHALL FIELD VERIFY EXISTING

PAVEMENT SECTION AT PROPOSED DRIVEWAY

LOCATIONS. IF EXISTING PAVEMENT SECTION IS FULL

DEPTH ASPHALT, CONTRACTOR SHALL CONSTRUCT A

THICKENED EDGE WITH NO DOWELING. IF EXISTING

PAVEMENT SECTION IS CONCRETE WITH AN ASPHALT

OVERLAY, CONTRACTOR SHALL CONSTRUCT THICKENED

EDGE WITH DOWELING, SEE 5/C1-01. CONTRACTOR SHALL

FIELD VERIFY EXISTING JOINT LOCATIONS AND ALIGN

PROPOSED PAVING JOINTS WITH EXISTING PAVING

JOINTS.”

Fall Protection

3) Sheet A1-12 - Information related to fall protection devices noted on Roof Plan A1-12 are for coordination only. See attached Spec Section 072270 Fall Protection Devices for requirements and installation of these fall protection devices.

Fire Protection

1. Replace Notes on Sheet FA000 dated 5/09/17 with Sheet FA000 – Notes Only dated 6/14/2017

2. Replace Sheet FA001 dated 5/09/2017 with attached Sheet dated 6/14/2017

3. Replace Sheet FP501 dated 5/09/2017 with attached Sheet dated 6/14/2017

4. Replace Specification Section 21_13_40 Hangar Foam Specs with revised 6/09/2017

5. Replace Specification Section 28_31_00 Master Fire Alarm with revised 6/09/2017

MECHANICAL

Section 012300 – Options – Bid Option 3 Clarification

Drawings M1-10 through M1-16 show the additional work in this bid option to provide ducted return.

Supply and Exhaust Air are also shown on these sheets for convenience but may not include all keyed notes or drawing information for those systems. The Base Bid Supply and Exhaust systems are to remain unchanged from what is shown on the plans that are not related to Bid Option 3 unless otherwise noted. Referenced mechanical demo note 7 on sheet M0-05 is one example of the “otherwise noted” instance.

All ducted return will have manual balance dampers at each take off to a ducted return grill.

MECHANICAL & PLUMBING DRAWINGS

Item No. DM-1, First Floor Area A

a. In Corr W149 change the 24x14 OV duct to 20x14. Change the duct serving VAV- W151 from 8”dia to 10” dia. (M1-01, M2-10).

b. In AFE W151 move the transition from 28x14 OV to 12” dia to the left just after the 18”dia take-off (M1-01, M1-10 at the 16”x10” duct crossing).

c. A fire damper is not required at the supply duct existing the chase at column line 3-J.

(M1-01).

d. Return duct sizes on the ducted return in the VAV-W148B zone to be 12x8, typical 5 places (M1-01 transfer, M1-10 ducted).

e. The smoke damper shown above the Elec W141 door will be located above the door to Corr W142. It is fire rated in a 3 hour wall (M1-01 return transfer, M1-10 ducted in 36”x12” duct).

f. Add 36”x12” from area B to Area A (M1-01).

Item No. DM-2, First Floor Area B

a. Delete the 12x12 R-1 from Corr 140. Replace with wall mounted 12x12 R-3 at the SFD location and move return transfer duct to this location (M1-02).

b. Add 12x12 R-3 and transfer duct between mask 134A and AFE Shop 139 (M1-02).

c. Change “RA” to R-3 in 3 locations on sheet M1-11 (MASK 139A, Corr 140, Shop 135A).

d. Add 36x12 R-3 for return air from AFE Shop 139 (M1-01 RA transfer intake).

e. Add 24x12 R-3 with manual damper for 600 cfm ducted return from AFE Shop 139 (M1-

11).

Item No. DM-3, First Floor Area D

a. Add 16x16 return transfer duct with 90 degree elbow in Inter E114B ceiling space.

Extend across Corridor to Area B. 3 hour smoke fire damper in rated corridor wall (M1- 04).

b. Add 3 hour rated smoke damper in the 16x16 return duct above Inter E114B (M1-13).

c. The 33x14 OV supply duct will remain that size past the take-off to VAV-E106 before reducing to 31x12 OV (M1-04, M1-13).

d. The R-1 ceiling grilles in Women E107 and Men E105 are to be relabeled as E-1 (M1-

13). Copy this condition for exhaust in the base bid (M1-04).

Item No. DP-1, Sheet P5-01

Replace the plumbing fixture schedule with a new plumbing fixture schedule in supplemental drawing SDP-01 dated 6/14/2017.

ELECTRICAL

Addendum Item #1: Add Drawing sheet E5-03 dated 6/14/2017 to show the classified areas.

Addendum Item #2: Specification section 265119, paragraph 2.2. C: Change to read “CRI of minimum 80.” Add paragraph 2.2. H: to read “Maximum CCT of 4100 K per UFC-3-530-10 paragraph 2-4.1.”

Addendum Item #3: Add paragraph 2.2. L. to specification section 265119 to read “Maximum CCT of 4100 K per UFC-3-530-10 paragraph 2-4.1.”

Addendum Item #4: Drawing E5-01, LUMINAIRE SCHEDULE: Type W4 luminaire, change the color temperature from “840” to “830”.

Addendum Item #5: Specification section 262416 add 2.5 F. to read “Panels serving interior or exterior loads shall have a surge protection device (SPD) installed as indicated on the drawings, per UFC 3-530-01 paragraphs 2-4.3 and 4-4.4.

Addendum Item #6: Sheet E6-02:

Add Keynote #32 to read: ‘PROVIDE SURGE PROTECTION AT

PANELS SERVING LIGHTING LOADS. SPD TO BE INTEGRAL

TO PANEL. PROTECTION TO BE MINIMUM 200KA PER

PHASE, 100KA L-N, L-G, N-G.

At panels EPWL, ME, H1E, H2E, H3E, H4E, H5E, H1W, H2W, H3W, and H4W, add keynote marker #32.

Addendum Item #7: Add paragraph 2.2. M. to specification section 265119 to read “Provide MOV type SPD integral with luminaire, per UFC-3-530-01 paragraph 4-4.2.1.”

Attachments

1. Specification section 072270 Fall Protection Devices dated June 2017

2. Specification section 21_13_40 Hangar Foam with UFC4-211-01 dated 6/09/2017

3. Specification section 28_31_00 Master Fire Alarm dated 6/09/2017

4. Drawing FA000 – notes only dated 6/14/2017

5. Drawing FA001 dated 6/14/2017

6. Drawing FP501 dated 6/14/2017

7. Drawing SDP-01 Plumbing Schedule dated 6/14/2017

8. Drawing E503 dated 6/14/2017

Changes to the solicitation:

1. Section 00120

Clause 52.228-1 is changed to read: Only SF 24, Bid Bond, shall be an acceptable as per FAR FAR Part 28.101-1 -- Only separate bid guarantees are acceptable in connection with construction contracts. Agencies may specify that only separate bid bonds are acceptable in connection with construction contracts.

2. Section 00700

Clause 52.228-11 Pledges of Assets is removed from the solicitation.

Clause 52.228-14 Irrevocable Letter of Credit is removed from the solicitation.

END OF AMENDMENT.

NEANG BUILDING 600 06565.002 JUNE 2017 (by Amendment)

FALL PROTECTION DEVICES 072270 - 1

SECTION 072270

FALL PROTECTION DEVICES

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes fall protection systems and devices as follows:

1. Fall protection lifeline systems.

2. Moveable guardrail systems.

3. Fix steel roof access ladder.

1.2 ACTION SUBMITTALS

A. Product Data: For each type of product indicated.

1.3 QUALITY ASSURANCE

A. Preinstallation Conference: Conduct conference at Project site.

1.4 COORDINATION

A. Fall Protection Devices: Are indicated on the Roof Plan, Sheet A1-12. Roof plan shows and notes the location of the fall protection devices. Roof Note G. and box notes shown directly below Roof Notes are for coordination purposes only refer to specified information herein.

1.5 WARRANTY

A. Provide manufacturer’s standard warranty to guarantee products will be free from defects for a period of 12 months. Warranty period shall become effective on date of substantial completion.

PART 2 - PRODUCTS

2.1 FALL PROTECTION LIFELINE SYSTEM

A. Brand Name or Equal Product: Subject to compliance with requirements, provide SÖLL Engineering Systems; Model Xenon Horizontal Lifeline or equal. Salient characteristics are as follows:

1. Cables: Stainless Steel.

2. Shuttle: Stainless Steel with no movable internal parts.

3. Shock Absorber: Serves four functions: which are Shock Absorber, Turnbuckle, Tension

Indicator, and Fall Indicator.

4. Intermediate Brackets: Single-Bolt Design.

B. Other equal manufacturers to the Brand Name or Equal Product include but are not limited to the following:

a. Capital Safety.

b. Fall Protection Systems.

c. Fall Tech Fall Protection.

FALL PROTECTION DEVICES 072270 - 2

d. Fix Fast USA.

e. Guardian Fall Protection Inc.

f. Latchways Fall Protection.

g. Miller by Honeywell Fall Projection.

h. Safety Rail Company.

i. 3M Fall Protection.

2.2 MOVEABLE GUARDRAIL SYSTEM

A. Brand Name or Equal Product: Subject to compliance with requirements, provide BlueWater Mfg., LLC, Model: Safetyrail 2000 Guardrail System, or equal. Salient characteristics are as follows:

1. Railing Type: Non-Penetrating System.

2. Railing Height: 42 inch minimum.

3. Rails: Top and mid rail per OSHA Standards.

4. Capacity: Any point along the top rail must withstand 200 pound force in any direction per

OSHA Standard.

5. Installation: place bases on EPDM protective pads provided by Guardrail System

Manufacturer, minimum thickness approximately 5 mm (3/16 inch).

6. Finish: Base & Guard Color: Gray Powder coat to match existing roof ladder.

7. Lifteline Fall Protection System: As indicated in the contract documents for the existing

Barrel Vault Roof shall be design and sealed by a Registered Fall Protection Engineer.

B. Other equal manufacturers to the Brand Name or Equal Product include but are not limited to the following:

a. Fall Protection Systems.

b. Fix Fast USA.

c. Safety Rail Company.

d. Simplified Safety.

2.3 FIXED STEEL ROOF ACCESS LADDER

A. Brand Name or Equal Product: Subject to compliance with requirements, provide Safety Rail Company, Model: SRC – Fixed Access Ladder (cut to required length), or equal. Salient characteristics are as follows:

1. Construction: 1-5/8 inch x 14 gauge steel construction tubular access ladder rungs and runners.

2. Finish: Galvanized.

3. Rungs: No slip finish on rungs.

4. Walk-Through Handrails: OSHA compliant safe walk-through handrails at top roof level.

5. Capacity: Any point along the top rail must withstand 200 pound force in any direction per

OSHA Standard.

6. Installation: Anchor to wall with fasteners as recommended by the manufacturer.

B. Other equal manufacturers to the Brand Name or Equal Product include but are not limited to the following:

a. Fall Protection Systems.

b. Fix Fast USA.

c. Simplified Safety.

FALL PROTECTION DEVICES 072270 - 3

PART 3 - EXECUTION

3.1 EXAMINATION

A. Examine substrates, areas, framing and conditions comply with structural and manufacturer written requirements for proper system performance.

B. Proceed with installation of anchors only after verifying conditions are satisfactory.

3.2 PREPARATION

A. General: Installation of anchor points to be performed by contractor according to manufacturer’s instruction and recommendations.

B. Provide on-site inspection and supervision of installation of lifeline components by factory-trained representative.

C. Install according to the approved shop drawings and manufacturer’s instructions. Fall Protection Systems shall be installed by manufacturer’s authorized, and trained personnel. Install anchorage and fasteners in accordance with manufacturer’s recommendation to obtain the allowable working loads published in the product literature and in accordance with the registered fall protection engineers design. Do not load or stress Fall Protection Systems until all materials and fasteners are properly installed and ready for service.

3.3 TRAINING

A. Instruct Owner’s designed safety engineer in proper use of fall protection safety devices.

B. Adjust system devices as required by manufacturer. Replace damaged or malfunctioning items.

C. Provide a minimum of 4 hours of operating training after systems have been installed and proof tested. Training is to be for the users of the system conducted at the installation site.

3.4 CLEANING

A. All fall protection devices installed shall have clean surfaces and surfaces soiled or damaged as work progresses shall be clean before completion of the install, and correct or replace as required damage items.

END OF SECTION

HIGH EXPANSION FOAM AND FIRE DETECTION SYSTEMS

NEANG BUILDING 600 HANGAR AREAS

SECTION 21 13 40

NEBRASKA NATIONAL GUARD LINCOLN

BUILDING 600 HANGAR AREA

SPECIFICATIONS FOR THE DESIGN AND

INSTALLATION OF HIGH EXPANSION FOAM

AND FIRE DETECTION SYSTEMS

Prepared for:

THE SCHEMMER GROUP

November 1, 2016 Revised January 26, 2017 Revised April 5, 2017 Revised June 9, 2017

HIGH EXPANSION FOAM AND FIRE DETECTION SYSTEMS

NEANG BUILDING 600 HANGAR AREAS

SECTION 21 13 40

HEF FOAM FIRE PROTECTION SPECIFICATION

PART 1 GENERAL

1.1 SCOPE OF WORK

a. Drawings and general provisions of the Contract, including General and Supplementary Conditions, Federal Acquisition Regulations, and Division 1 Specification Sections, apply to this Section.

b. Connect the work specified in this section to the existing fire protection water main in the hangar.

c. The high expansion foam calculations shall be based on the existing water supply in the hangar. The water supply comes from two existing fire pumps which provide water to Building 600 to serve this project.

d. Provide a high expansion foam (HEF) system to protect all areas of the hangar bay (aircraft servicing and storage area), as shown on the Drawings.

1. HEF system design is based on the system and products available from the Buckeye Equipment Company (Kings Mountain, North Carolina), as specified herein. The intent of these specifications is not to limit system selection to Buckeye products.

2. Provide a new flow control valve with valves and appurtenances as shown on the drawings.

3. Relocate existing HEF generators, mounted and supported as shown on the

Drawings. Quantity of foam generators and generator capacity shall be as shown on the Drawings. Verify mounting of the generator with a structural engineer.

4. Contractor shall not reduce the quantity of foam generators, or foam generator capacity in accordance with foam quantity calculation methods of NFPA 409 or NFPA 11. The high expansion foam capacity is to exceed those requirements per military criteria.

5. The HEF system shall produce a minimum discharge rate to satisfy the following calculation method which varies from NFPA 409: HEF Discharge Rate = ((Volume/Time) + RS) * CN * CL, where:

i. Leakage coefficient CL = 3.0.

ii. Shrinkage coefficient CN = 1.15.

iii. Volume = hangar floor area (ft2) by 3.2 feet of depth = volume

(ft3). Hangar floor area shall be set = 36,000 ft2 (3,345 m2).

FIRE DETECTION AND MASS NOTIFICATION SYSTEM

NEANG BUILDING 600

SECTION 28 31 00

NEBRASKA NATIONAL GUARD LINCOLN

BUILDING 600

SPECIFICATIONS FOR THE DESIGN AND

INSTALLATION OF AN AUTOMATIC

FIRE DETECTION AND MASS NOTIFICATION

SYSTEM

Prepared for:

THE SCHEMMER GROUP

November 1, 2016 Revised January 26, 2017 Revised June 9, 2017

FIRE DETECTION AND MASS NOTIFICATION SYSTEM

PART 1 GENERAL

1.1 Related Documents

Drawings and general provisions of contract, including general and supplemental conditions and Division 1 specification sections apply to work of this section.

A. Electrical General Provisions

B. Automatic Sprinkler Specifications and Drawings

C. Basic Electrical Materials and Methods

D. Mechanical Specifications and Drawings

1.2 Description

A. This section describes the requirements for furnishing and installing all materials and labor for the design, engineering and installation of a new automatic fire detection, alarm and mass notification system for the renovated building 600, hereafter referred to as the Work (or System). All building alarm and supervisory devices shall be connected to the new building fire alarm/mass notification control panel by intelligent, addressable loops installed throughout the renovated building. The building fire alarm mass communication control panel will be a standalone system. All connected devices shall be identified by type of device, location of device, and/or the area of the property affected (e.g. water flow switch, second Floor, etc.). Each floor or area shall have supervised notification appliance circuit power panel(s) (SNAC) and audible zone to provide adequate power for the audible and visual alarms. Alarm silence and reset functions shall be accomplished at the control panel. The building will have its fire alarm control panel with microphone located at the grade level main entrance. A graphic annunciator will be adjacent to the fire alarm control panel. All control and release functions shall be activated by the building control panel. The Signal Line Circuits (SLC) and notification circuits shall be routed in a class “A” manner in all areas to all alarm initiating devices and alarm indicating devices.

B. Work in the existing building will include the installation of new smoke detectors, speakers, speaker strobes, monitor modules and power supply SNAC panels connected to the new fire alarm system.

C. All work shall be performed in accordance with these specifications. No modifications to these specifications will be accepted without the express written approval of the Contracting Officer/General Contractor. It is the Contractor's

FIRE DETECTION AND ALARM SYSTEM

28 31 00-3 responsibility to document Contracting Officer/General Contractor’s approval of any such modifications prior to the execution of work. Any deviation from these specifications must be approved in writing, by the Contracting Officer/General Contractor.

D. Drawings provided for this work show the general intent for device layout and coverage. The Contractor shall provide proper coverage and layout in accordance with these specifications and all applicable Codes and Standards.

Devices installed in public or finished areas shall be fully coordinated with reflected ceiling plans, mechanical, and electrical components as shown on the electrical and mechanical drawings and specifications. The Contractor will be responsible for the complete design, installation and commissioning of the new fire detection and alarm system as required by UFC 3-600-01, City of Lincoln Building Department and Fire Department. These specifications do not necessarily contain all information required for installation of the system, but are intended to be used as a guide by the Contractor for the purpose of designing the system and preparing his bid. As such, they indicate:

1. Requirements for approximate device locations.

2. Types of initiating devices.

3. Locations of new fire alarm system control panel equipment and annunciators.

D. The Contractor shall verify all information contained on the project bid drawings and is responsible for design and installation of the system in accordance with the specifications.

1.3 Intent of Specifications

A. It is intended that the work performed pursuant to these specifications be complete in every respect, resulting in a System installed entirely in accordance with the applicable codes, standards, manufacturer's recommendations and UL listings while providing the minimum requirements of these specifications.

B. It is further intended that upon completion of this Work, the Contractor provide the Contracting Officer/General Contractor with:

1. Complete information and drawings describing and depicting the entire System as installed, including all information necessary for maintaining, troubleshooting and/or expanding the system at a future date.

28 31 00-4

2. Complete documentation of system testing.

3. Certification that the entire system has been inspected and tested is installed entirely in accordance with the specifications, applicable codes, standards, manufacturer's recommendations and UL listings, and is in proper working order. Contractor shall use the "Certification of Completion" document as outlined in NFPA 72 - The National Fire Alarm Code.

4. A copy of the final software program, both in written and digital format, including any and all necessary passwords.

1.4 Work Included

The work shall include, but shall not be limited to:

A. Providing new addressable mass notification/ fire detection and alarm system control panel (FACP) within the building to accommodate all required devices and circuits, and remote interface panels to distribute fire alarm circuits and controls throughout the building.

B. Providing new addressable type smoke detectors as required by code and identified on the approved bid drawings in an area detection configuration.

C. Control relays for the operation of the elevator recall circuits shall be provided under this work. Final connections to be provided by the elevator contractor.

Work shall include both primary and alternate floor recall function as well as Red Cap activation elevator power shunt trips.

D. New addressable in-duct type smoke detectors in each main building air handling system supply duct on all fans over 2,000 cfm as required by these specifications. Work shall include interface to fan unit motor control panel to affect fan shutdown including damper control and door release. Refer to mechanical and electrical design documents for coordination of dampers, door holders, panels and power.

E. Providing emergency voice communication system control panels and equipment, with the control panel located in the fire protection room to allow for automatic activation of evacuation signals and to provide mass notification voice communication as shown on the bid drawings throughout the building.

F. New alarm speakers and visual alarms (strobes) throughout the building areas, including corridors, staff areas, meeting rooms, stairways, elevators, hangar

28 31 00-5 and other areas as required meeting local and national codes and ANSI standards, as required by these specifications and drawings.

G. New addressable monitor/control modules to monitor the activation of contact closing devices, such as sprinkler system valve supervisory switches, high expansion foam system and waterflow indicators. Contractor shall be required to coordinate work with the automatic sprinkler contractor to install, test and adjust new sprinkler system monitoring devices. Contractor shall be required to coordinate work with the mechanical and electrical contractors to install, test and adjust stairway pressurization and smoke control fan controls, smoke evacuation fan controls and smoke control functions.

I. Devices, equipment and wiring necessary to monitor activation of special fire suppression systems, including the hangar HEF system and emergency power. Emergency power shall be monitored for normal and emergency power conditions.

J. Devices, equipment and wiring to release door hold-open assemblies (door holders) and door security unlock. Fire alarm contractor shall provide activation of magnetic door holders and shall be responsible for interface to door release circuits. Electrical contractor to provide all necessary power for the door hold open magnets.

K. Test and adjust all new equipment and systems.

L. Prepare and submit shop drawings, contractor record drawings and other submittals required herein.

M. Guarantee all new equipment, systems, wiring, and conduit for one year after final acceptance of the System by the Contracting Officer/General Contractor.

The system shall be tested in accordance with the requirements of NFPA 72 during the Guarantee period.

N. Provide all cutting and patching to accommodate the installation of the fire detection and alarm system. Coordinate all work with the Contracting Officer/General Contractor. All penetrations/holes in fire rated walls and floor assemblies shall be repaired by the Contractor to maintain the fire rating.

O. Coordinate all work with the Contracting Officer/General Contractor and other

Contractors working in the building.

P. All new equipment, wiring, conduit, junction boxes, terminal boxes and terminal strips, etc. for a complete operable system.

28 31 00-6

1.5 Basic Performance

A. Alarm and trouble signals from each alarm initiation or supervisory device shall be digitally encoded by listed electronic devices onto a NFPA 72, Class A looped multiplex communication system.

B. Signaling Line Circuits (SLC) shall be wired Class A with a separation of not less than six feet.

C. Digitized electronic signals shall employ check digits or multiple polling.

D. Response time between alarm initiation and recording is not to exceed five (5) seconds.

E. Fire alarm/mass notification control panels are to consist of low current, solid state integrated circuits and shall be powered from local critical power source and standby battery power source.

F. Power for initiating devices and notification appliances must be from the building fire alarm/mass notification control panel and/or the SNAC panel to which they are connected.

G. Alarm signals arriving at the building FACP shall not be lost following a power failure (or outage) until the alarm signal is processed and recorded.

H. Speaker circuits shall be arranged such that there is a minimum of one speaker circuit per smoke zone.

I. Speaker circuits shall be electronically supervised for open and short circuit conditions.

1.6 Working Conditions

A. The Contractor shall be responsible for prior coordination of all work with the Contracting Officer/General Contractor.

B. New fire alarm system initiating devices, sprinkler system monitoring devices and alarm indicating devices shall be put into service as soon as they are functional.

Ongoing construction may be considered in activating certain types of alarm initiating devices (e.g. smoke detectors in elevator lobbies). Equipment installed, but not yet functional, shall be tagged or clearly labeled "Inoperable". Once put into service, they shall not be removed from service without approval by the Fire

28 31 00-7

Department and the Contracting Officer/General Contractor’s written authorization.

1.7 Quality Assurance

A. All work shall conform to the requirements of the Lincoln Building and Fire Codes and all applicable portions of the following codes and standards:

1. NFPA 70 - National Electrical Code.2013 edition

2. NFPA 72 - National Fire Alarm Code, 2013 edition

3. NFPA 101 – The Life safety Code, 2012 Edition

4. International Building Code, 2012 Edition with City of Lincoln

Amendments

5. International Fire Code. 2012, Edition with City of Lincoln Amendments

6. Uniform Mechanical Code, 2012 Edition with City of Lincoln Amendments

7. Final Rule of the Americans with Disabilities Act (ADA) - Public Law 101-

336.

8. UFC 3-600-01 Change 3 Dated 1 March 3013

9. UFC 4-021-01 Dated 9 April 2008

10. ANGETL 15-01-03 Dated 1 May 2015

B. All work and materials shall conform to all Federal, State and local codes and regulations governing the installation.

C. If there is a conflict between the referenced NFPA standards, federal, state or local codes, and this specification, it is the Contractor's responsibility to immediately bring the conflict to the attention of the Contracting Officer/General Contractor for resolution. Contractor shall not attempt to resolve conflicts directly with the local authorities unless specifically authorized by the Contracting Officer/General Contractor.

D. All devices, systems, equipment and materials furnished and installed shall be new and listed by ULI for the intended use. All new equipment shall be installed in accordance with the manufacturer's recommendations and the ULI listing limitations. Compatibility listing requirements for separate fire alarm systems

28 31 00-8 and all connected devices shall be met. The Contractor shall provide evidence, with the submittals, of listings of all proposed equipment.

E. All devices, systems, equipment and materials furnished and installed shall be of types or models approved by the NEANG Fire Department for use in systems and occupancies of this type.

F. The Contractor shall be responsible for filing of all documents, securing all permits, inspections and approvals necessary for conducting this work. Fees, charges and other costs associated with the foregoing shall be borne by the Contractor. Upon receipt of approved drawings, executed permits, and inspection reports from the authority having jurisdiction, the Contractor shall immediately forward two sets to the Contracting Officer/General Contractor.

These documents shall either be drawings stamped approved or a copy of a letter from the authority having jurisdiction stating approval of this work.

1.8 Contractor Qualification

A. The Contractor Shall:

1. Hold all licenses and permits necessary to perform this work.

2. Have at least five years of experience in the installation of systems of this type and be familiar with all applicable local, state and federal laws and regulations.

3. Be regularly engaged in the design, servicing, installation and testing of fire detection and alarm systems.

4. Have worked on one or more large, new construction projects in the last five years.

5. Be a licensed fire alarm contractor qualified to install fire detection and alarm systems in the City of Lincoln.

6. Provide a job site supervisor who is to be present full-time on-site each day that work is actively in progress. This individual shall be the same person throughout the course of the project. The job site supervisor shall be certified by the City of Lincoln, shall be subject to prior approval by the Contracting Officer/General Contractor and may be requested to be replaced by the Contracting Officer/General Contractor at any time during the course of the project.

28 31 00-9

7. Provide all prior coordination and supervision of all trades and sub-contractors to ensure a "turn-key" project. No additional compensation will be provided by the Contracting Officer/General Contractor due to oversights or lack of coordination between trades and sub-contractors during the bid or installation phases.

B. The Fire Alarm Equipment Vender/Sub-Contractor shall be an authorized branch office, “Strategic Partner” or Platinum Distributer of the system being supplied and shall demonstrate recent significant experience in Military projects. All new equipment installed under this phase shall be fully compatible.

C. The fire alarm equipment vender/sub-contractor shall certify the system installation using forms from the National Fire Alarm Code, NFPA 72.

D. The fire alarm equipment vender/sub-contractor shall provide system shop drawings for all fire detection and alarm system work associated with the building, including interface to building electrical power circuits, smoke control system, smoke evacuation system and mechanical air handling units (AHU) systems.

1.9 Submittals

A. The contractor shall make submittals in accordance with these requirements. All submittals shall be complete. Incomplete submittals will not be reviewed.

B. Concurrent reviews: Two copies of all submittals shall be simultaneously submitted to the Contracting Officer/General Contractor and the owner’s Fire Protection Consultant for review and comment.

C. The Contracting Officer/General Contractor and the Fire Protection Consultant shall review and recommend approval/disapproval or take other appropriate action on the Contractor's submittals including shop drawings, samples, documentation and record drawings. This review is to verify conformance to project specifications and design concepts expressed in the Contract Documents. This action shall be taken with all reasonable promptness as to cause no delay in the work, while allowing adequate time to permit adequate review. Review of such submittals is not conducted for the purpose of determining the accuracy and completeness of other details (e.g., dimensions) or for substantiating installation or performance of equipment or systems designed by the Contractor, all of which remain the Contractor's responsibility to the extent required by the Contract Documents. The Fire Protection Consultant's review shall not constitute approval of safety precautions for construction, means, method, techniques, sequences of procedures or approval of a specific assembly of which the item is a part.

28 31 00-10

D. If submittals, upon review by the Contracting Officer/General Contractor or the

Fire Protection Consultant are found not to conform to the requirements of these specifications; the Contractor shall be required to resubmit with modifications within 14 calendar days. The Contractor shall be responsible for the Contracting Officer/General Contractor’s extra expenses for subsequent review(s) of rejected submittals necessitated by the Contractor's failure to make the requested modifications. Such extra fees shall be deducted from payments by the Contracting Officer/General Contractor to the Contractor. Approval of the submittals by the Contracting Officer/General Contractor shall, in no case, relieve the Contractor of his responsibility to meet the requirements of this specification.

E. The Contracting Officer/General Contractor shall review all submittals prior to submittal to local authorities for review.

1.10 Substitutions

A. The Contract is based on the standards of quality established in the Contract Documents.

B. The following products do not require further approval except for interface within the Work:

1. Products specified by reference to standard specifications such as ASTM and similar standards.

2. Products specified by manufacturer's name and catalog model number.

C. Do not substitute materials, equipment, or methods unless such substitution has been specifically approved in writing for this Work by the Contracting

D. Where the phrase "or equal" or "or approved equal" occurs in the Contract

Documents, do not assume that the materials, equipment, or methods will be approved as equal unless the item has been specifically so approved for this Work in writing by the Contracting Officer/General Contractor.

1.11 Equipment List

A. The Contractor shall submit with the bid a detailed equipment list, identifying types, models and quantities of all materials, devices and equipment proposed.

This submittal shall include manufacturers' data sheets showing the types and

28 31 00-11 models of all equipment, devices, material and wire proposed. Evidence of ULI listings and local approvals, if required, shall be submitted with the data sheets.

B. When a data sheet shows more than one product, the proposed product shall be clearly indicated by arrows or other suitable means.

1.12 Work Schedule

A. The Contractor shall submit with the bid a proposed work schedule. This schedule shall indicate the time necessary for:

1. Project start up.

2. Shop drawing submittals.

3. Installation.

4. Final acceptance tests.

B. The proposed work schedule will be reviewed by the Contracting Officer/General Contractor and finalized during the pre-construction meeting and will be updated at each construction coordination meeting.

1.13 Samples

A. Contractor shall submit samples of all proposed alarm initiating devices, audible/visual alarm indicating appliances, wire and cable to the Contracting Officer for approval.

1.14 Permits, Licenses and Certificates

A. Prior to start of installation, the Contractor shall obtain and submit copies of all permits, licenses, certificates and approvals necessary to conduct this work to the Contracting Officer/General Contractor.

1.15 Shop Drawings

A. Prior to the start of any installation, but within 45 days after awarding of the contract, the Contractor shall submit four full sets of shop drawings, one CD of Auto CAD 2012 or higher with the description of the software and revision number of the CAD program used to create the drawings, five full sets of data sheets and installation manuals/instructions detailing the manufacturer's installation recommendations for all equipment to be installed, to the Contracting

28 31 00-12

Officer/General Contractor for approval. Installation prior to receipt of approved shop drawings shall be at the risk of the Contractor.

B. The shop drawings shall consist of the following:

1. A legend sheet, match lines, site plan, north indication.

2. Clean floor plans drawn to minimum 1/8-inch scale except as otherwise noted hereinafter and a system riser diagram in 1/8-inch scale with a title block on each drawing. Title block to contain name, address and phone number of Contractor, Subcontractor (s) (if applicable) and name and location of work.

a. The floor plan drawings shall indicate:

1) Location of all devices and interface to system equipment, circuits, equipment, risers and electrical power connections and interface to system network.

2) The digital address or sequential zone/device number of all initiating devices shall be shown.

3) Power calculations shall be provided for all panels.

4) A schedule(s) outlining the number, size and type of each conductor and conduit used. Conduit percentage fill calculations shall be provided for all conduits.

5) Standby battery capacity calculations including the number, size, type and location of all batteries. List the type of powered devices and modules, quantities, unit and extended amperage draw for quiescent and alarm conditions, total amperage draw and battery amp/hour rating. For design criteria, the battery amp/hour rating listed by the manufacturer shall be de-rated by 20%.

6) Primary power supply calculations which include all system requirements including any requirements for electrical door unlocking systems, visual signaling appliances, or any other auxiliary function powered by the system. The quantity, location, model or part number, rated capacity and loaded capacity shall be included for each power supply. The power requirements shall be increased by 20%.

28 31 00-13

7) Point-to-point wiring connections showing individual circuits and circuit/conduit routing, number, type and size of conductors used and unique identification for each circuit.

8) Typical wiring diagrams for all alarm initiating devices and notification appliances, showing the number, size and type of conductors, wiring terminations and terminal identifications.

9) Detailed internal and external wiring diagrams for all control panels, remote transmitting panels, SNAC panels, Main Fire Alarm interconnection equipment, auxiliary function relays and remote annunciation equipment showing size and type of conductors, wiring terminations and terminal identifications.

10) When any panel power is derived from a "local" source of building emergency power, the shop drawings shall show wire routing and point of connection (location, panel number, description and circuit breaker number) to the building emergency circuit.

b. The riser diagram shall indicate:

1) Location, number and size of riser conduits.

2) Location, number, type and size of conductors in each riser.

3) Location and number of each type of device corresponding to the legend sheet on each circuit on each floor, wherever else installed.

4) Location and circuit breaker identification number for A C power feed through an Electrical Surge Protector (TVSS).

c. Main fire alarm control panel module layout, configurations and terminations.

3. Schedules for wire type, conduit fill, and circuit voltage drop calculations.

Voltage drop calculations shall start at 21.6 volts

28 31 00-14

C. Each drawing shall be cross-referenced to all related drawings and specific drawing details as necessary for the submittal as a whole to clearly depict the proposed installation. Each drawing shall show revision number and date indicated in the title block with revisions described or indicated. Name and signature of the individual making the revision shall be included.

D. The Contractor will not be authorized to start installation on each phase until all of the shop drawings and data sheets are received, reviewed and approved in writing by the Contracting Officer/General Contractor and the NEANG Fire Department.

1.16 Operation and Maintenance Manual

A. The Contractor shall provide the Contracting Officer/General Contractor with two three-ring loose-leaf manuals containing:

1. A detailed description of the system.

2. A detailed description of routine maintenance required or recommended or as would be provided under a maintenance contract including a maintenance schedule and detailed maintenance instructions for each type of device installed.

3. Manufacturers' data sheets and installation manuals/instructions for all equipment installed.

4. A list of recommended spare parts.

5. Service directory which includes the main 24-hour emergency service number and at least three alternate numbers which are monitored on a 24-hour basis.

6. Small scale (11 inches by 17 inches) contractor record drawings of the system.

7. A detailed description of the operation of the system, including operator responses. The approved sequence of operation shall be placed in, or adjacent to, the operator's control panel.

B. Within 60 days of authorization to proceed, the Contractor shall submit to the

Contracting Officer/General Contractor four (4) copies of the draft manual for approval.

28 31 00-15

C. Within 30 days of the completion of the Work, six (6) copies of the approved manual shall be delivered to the Contracting Officer/General Contractor.

1.17 Contractor Record Drawings

A. The Contractor shall provide and maintain on the site an up-to-date record set of approved shop drawing prints which shall be marked to show each and every change made to the fire alarm system from the original approved shop drawings.

This shall not be construed as authorization to deviate from or make changes to the shop drawings approved by the Contracting Officer/General Contractor without written instruction from the Contracting Officer/General Contractor in each case. This set of drawings shall be used only as a record set. This record drawing set shall be used by the contractor to compile a correct AS-BUILT drawing set for submittal to the Contracting Officer/General Contractor as a complete record set of the complex-wide network. The Contractor record drawings are required to show and identify quantities of junction boxes, spare conductors, splices, terminal strip junction boxes, and device backboxes. This submittal shall include a schedule of all connections/terminations, indexed by junction box, device backbox and terminal strip and shall reference wire tag numbers as installed.

B. Upon completion of the work, the record set of prints shall be used to prepare complete, accurate final record drawings reflecting any and all changes and deviations made to the fire alarm system.

C. Upon completion of the work, two sets of record drawings shall be submitted to the Contracting Officer/General Contractor for review.

D. Upon review of the record drawings and before final approval, four (4) sets of corrected or amended as necessary drawings and AutoCAD 2012 or higher CD shall be delivered to the Contracting Officer/General Contractor.

1.18 Test Record

A. System certification and documentation of system testing required by Specification Section 3.4.1 shall be submitted to the Contracting Officer/General Contractor for review and approval at least 14 days prior to the final acceptance test. This certification shall include certification with Underwriters Laboratories, as well as local and National Codes and Standards.

B. Two weeks prior to final inspection, deliver to the Contracting Officer/General

Contractor the following certifications:

1. Certificate of installation as required in NFPA 72.

28 31 00-16

2. Certificate by the authorized representative of the manufacturer of the major fire alarm system equipment that the system has been properly installed, adjusted, and tested in accordance with the manufacturer’s requirements and recommendations.

3. Certification of any required Third Party inspections.

1.19 Guarantee

A. The Contractor shall guarantee all materials and workmanship during the installation period and for a period of one year, beginning with the date of final acceptance of the entire system by the Contracting Officer/General Contractor.

The Contractor shall be responsible during the design, installation, testing and guarantee periods for any damage caused by the Contractor, Subcontractors or by defects in the Contractor's or Subcontractors' work, materials or equipment.

B. During the guarantee period, the Contractor shall inspect and test the entire fire alarm system in conformance with NFPA 72. All devices shall be tested at minimum intervals as required by these standards, with a written report after each test. The guarantee period shall include the first annual inspection and test.

1.20 Emergency Service

A. The Contractor shall provide normal and overtime emergency repair service for the system, at no cost to the Contracting Officer/General Contractor, within four hours of a request for such service by the Contracting Officer/General Contractor during both the installation and the guarantee periods. This service shall be provided on a 24-hour per day, seven days per week basis.

B. The system must be operational before the responding service person leaves the property.

1.22 Spurious Alarms

A. If the Contracting Officer/General Contractor experiences an unacceptable number of spurious or unexplained false alarms during the installation and guarantee periods, the Contractor shall be responsible for providing the necessary labor, material and technical expertise to correct the problem to the satisfaction of the Contracting Officer/General Contractor.

B. The following number of spurious alarms, calculated as a ratio of false alarms to number of initiation devices, shall be considered unacceptable:

28 31 00-17

1. Automatic photo-electric type (system connected) smoke detectors -

More than two spurious alarms per six months during the system guarantee period.

2. Automatic duct-type smoke detectors - More than two spurious alarms per six months during the system installation and guarantee periods.

C. Any spurious alarms shall be considered unacceptable for the following types of equipment:

1. Manual pull stations.

2. Sprinkler or standpipe system waterflow monitoring devices.

3. Sprinkler or standpipe system valve monitoring devices.

4. Monitoring…