W911WN-14-T-0021-Conformed.pdf

U.S. ARMY ENGINEER DISTRICT, PITTSBURGH

ATTN CECT-LRP

W S MOORHEAD FEDERAL BUILDING

1000 LIBERTY AVENUE ROOM 2203

PITTSBURGH PA 15222-4186

412-644-5109

UNDER DPAS (15 CFR 700)

11. DELIVERY FOR FOB

RFQ

SEE SCHEDULE

14. METHOD OF SOLICITATION

IFB RFP

CODE

SEE ADDENDUM

BLOCK IS MARKED

DESTINATION UNLESS

12. DISCOUNT TERMS

(No Collect Calls)

$7.0 M

13b. RATING

13a. THIS CONTRACT IS A RATED ORDER

X

CODE

W911WN-14-T-0021 03-Jun-2014

b. TELEPHONE NUMBER

412-395-7549

8. OFFER DUE DATE/LOCAL TIME

11:00 AM 24 Jun 2014

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV 3/2005)

Prescribed by GSA

FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER) 31c. DATE SIGNED

ADDENDA X ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

22. UNIT 23. UNIT PRICE 24. AMOUNT21. QUANTITY

CODE 10. THIS ACQUISITION IS

UNRESTRICTED

FAX: NAICS:

TEL:

CODE 18a. PAYMENT WILL BE MADE BYOFFEROR

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TEL.

W911WN

SIZE STD:

9. ISSUED BY

FACILITY

CODE

17a.CONTRACTOR/

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

DONNA YON

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

1 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.X

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

19. ITEM NO. 20. SCHEDULE OF SUPPLIES/ SERVICES

SEE SCHEDULE

561730

TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER ALL ITEMS

SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL SHEETS

SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED HEREIN.

SB

HUBZONE SB

SET ASIDE: 100 % FOR

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

W81ET432100852

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

TEL: EMAIL:

0 COPIES

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

.OFFER DATED YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN 29. AWARD OF CONTRACT: REFERENCE

8(A)

SVC-DISABLED VET-OWNED SB

EMERGING SB

X

X

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

SEE SCHEDULE

19. ITEM NO. 20. SCHEDULE OF SUPPLIES/ SERVICES 21. QUANTITY 22. UNIT 24. AMOUNT

PAGE 2 OF

23. UNIT PRICE

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV 3/2005) BACK

Prescribed by GSA

FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

W911WN-14-T-0021

Section SF 30 - BLOCK 14 CONTINUATION PAGE

AMENDMENT 01

Request for Information (RFI)

RFI 1: How will you evaluate the proposals? Will you consider the price or any other factors to determine the winner?

RFI 1 RESPONSE:

This solicitation is a Request for Quote (RFQ), Firm Fixed Price, Lowest Price Technically Acceptable procurement. There are no evaluation factors requested.

Prior to award of the contract, the technically acceptable low offeror will be required to furnish the following information:

(a) Financial ability to perform the contract. Offeror shall provide the name of the bank and/or lending institution POC and phone number with whom you do business with as to your credit regarding your ability to perform the work.

(b) The names and addresses of three companies/government agencies for whom work has been performed recently along with a brief description of the projects and the dollar value of each.

References for work performed that is similar to the proposed work is preferred.

(c) A brief history of business experience, including length of time in present business.

(d) Indicate total dollar amount of all business in progress (military and commercial) with brief description of major projects and locations of same.

(e) A statement of facilities and materials, together with a list of key personnel and their qualifications available for performance of proposed contract.

(f) Names and address of any proposed subcontractors.

RFI 2: What documents are required by the response date?

RFI 2 RESPONSE: The following documents are required for the RFQ:

- SF1449

- Price Schedule

- Amendment acknowledgements – 1 signed copy of each amendment shall accompany the RFQ.

RFI 3: Do you want Pesticide Application Service performed each year or every other year?

RFI 3 RESPONSE: Services will be ordered each year.

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 9 Each

Mowing, Type I, Site 1, FFP

Admin/Maintenance Buildings - July through September, three (3) times per month

FOB: Destination

MILSTRIP: W81ET432100852

PURCHASE REQUEST NUMBER: W81ET432100852

NET AMT

0002 4 Each

Mowing, Type I, Site 2, FFP

Overlook Picnic Area - July and August, two (2) times per month

FOB: Destination

0003 4 Each

Mowing, Type I, Site 3, FFP

East Branch Campground -July and August, two (2) times per month

0004 9 Each

Mowing, Type I, Site 4, FFP

Boat Launch - July through September, three (3) times per month

0005 3 Each

Mowing, Type II, Site 5

FFP

Miscellaneous Areas - July through September, one (1) time per month

0006 3 Each

Mowing, Type II, Site 6

FFP

Dam and Communication Area - July through September, one (1) time per month

0007 58,158 Square Yard

Brush Cutting/Removal, FFP

Site 1, 4 & 6

0008 27 Each

Project Office Cleaning, Site 1

FFP

One (1) time each week, from July through 31 Dec 2014.

0009 27 Each

Maintenance Office Cleaning, Site 1

FFP

One (1) time each week from July through 31 Dec 2014.

0010 1 Each

Restroom Cleaning, Site 2, FFP

Overlook Picnic Area *The East Branch Cutoff Wall Construction project will impact the quantity of work ordered under this CLIN as well as the scheduling of these efforts. The quantity may (1) increase due to delay of the Cutoff Wall construction project or (2) decrease during the East Branch Cutoff Wall construction period when this area will be closed. Similarly, the scheduling of the efforts will depend on whether construction is ongoing.

0011 1 Each

Restroom Cleaning, Site 3, FFP

East Branch Campground *The East Branch Cutoff Wall Construction project will impact the quantity of work ordered under this CLIN as well as the scheduling of these efforts. The quantity may (1) increase due to delay of the Cutoff Wall construction project or (2) decrease during the East Branch Cutoff Wall construction period when this area will be closed. Similarly, the scheduling of the

0012 52 Each

Restroom Cleaning, Site 4, FFP

Boat Launch - Four (4) times per week from July through September 30, 2014

0013 1 Each

Carpet Cleaning, Site 1, FFP

Shampooing/Steamcleaning of carpeted floors, Project Office - One (1) time in October 2014

0014 Each

Pressure Washing, Restrooms

FFP

Sites 2, 3 and 4, one (1) time per year - Not used during the base year

0015 26 Each

Solid Waste Removal, FFP

Site 1 (One Dumpsters) - One (1) time per week, for 52 weeks in a year

0016 1 Each

Solid Waste Removal, FFP

Site 3 (One Dumpster) *The East Branch Cutoff Wall Construction project will impact the quantity of work ordered under this CLIN as well as the scheduling of these efforts. The quantity may (1) increase due to delay of the Cutoff Wall construction project or (2) decrease during the East Branch Cutoff Wall construction period when this area will be closed. Similarly, the scheduling of the

0017 13 Each

Solid Waste Removal, FFP

Site 4 (One Dumpster) - One (1) time per week during July through September

0018 5,000 Gallon

Raw Sewage Removal

FFP

Site 4 Boat Launch

0019 57,112 Square

Pesticide Application

Site 2, 3 & 6

1001 18 Each

OPTION Mowing, Type I, Site 1, FFP

Admin/Maintenance Buildings - April through September, three (3) times per month

1002 8 Each

OPTION Mowing, Type I, Site 2

FFP

Overlook Picnic Area - May through August, two (2) times per month

1003 8 Each

OPTION Mowing, Type I, Site 3

FFP

East Branch Campground -May through August, two (2) times per month

1004 18 Each

OPTION Mowing, Type I, Site 4

FFP

Boat Launch - April through September, three (3) times per month. The East Branch Cutoff Wall Construction project will impact the quantity of work ordered under this CLIN as well as the scheduling of these efforts. The quantity may (1) increase due to delay of the Cutoff Wall construction project or (2) decrease during the East Branch Cutoff Wall construction period when this area will be closed. Similarly, the scheduling of the

1005 6 Each

OPTION Mowing, Type II, Site 5, FFP

Miscellaneous Areas - April through September, one (1) time per month

1006 6 Each

OPTION Mowing, Type II, Site 6

FFP

Dam and Communication Area - April through September, one (1) time per month

1007 58,158 Square

OPTION Brush Cutting/Removal Site 1, 4 and 6

1008 52 Each

OPTION Project Office Cleaning, Site 1

FFP

One (1) time each week, from January through December

1009 52 Each

OPTION Maintenance Office Cleaning, Site 1

FFP

One (1) time each week from January through December

1010 1 Each

OPTION Restroom Cleaning, Site 2, FFP

Overlook Picnic Area *The East Branch Cutoff Wall Construction project will impact the quantity of work ordered under this CLIN as well as the scheduling of these efforts. The quantity may (1) increase due to delay of the Cutoff Wall construction project or (2) decrease during the East Branch Cutoff Wall construction period when this area will be closed. Similarly, the scheduling of the

1011 1 Each

OPTION Restroom Cleaning, Site 3, FFP

East Branch Campground *The East Branch Cutoff Wall Construction project will impact the quantity of work ordered under this CLIN as well as the scheduling of these efforts. The quantity may (1) increase due to delay of the Cutoff Wall construction project or (2) decrease during the East Branch Cutoff Wall construction period when this area will be closed. Similarly, the scheduling of the

1012 104 Each

OPTION Restroom Cleaning, Site 4, FFP

Boat Launch - Four (4) times per week from April through September

1013 2 Each

OPTION Carpet Cleaning, Site 1, FFP

Shampooing/Steamcleaning of Carpeted Floors, Project Office - Two (2) times a year, Spring and Fall.

1014 1 Each

OPTION Pressure Washing Restrooms, FFP

Sites 2, 3 and 4, one (1) time per year

1015 52 Each

OPTION Solid Waste Removal, Site 1

FFP

(Two Dumpsters) - One (1) time per week, for 52 weeks in a year

1016 1 Each

OPTION Solid Waste Removal, Site 3, FFP

(One Dumpster) *The East Branch Cutoff Wall Construction project will impact the quantity of work ordered under this CLIN as well as the scheduling of these efforts. The quantity may (1) increase due to delay of the Cutoff Wall construction project or (2) decrease during the East Branch Cutoff Wall construction period when this area will be closed. Similarly, the scheduling of the efforts will depend on whether construction is ongoing.

1017 26 Each

OPTION Solid Waste Removal, Site 4

FFP

(One Dumpster) - One (1) time per week during April through September

1018 5,000 Each

OPTION Raw Sewage Removal, FFP

Site 4, Boat Launch

1019 57,112 Square

OPTION Pesticide Application Site 2, 3 & 6

2001 18 Each

OPTION Mowing, Type I, Site 1, FFP

Admin/Maintenance Buildings - April through September, three (3) times per month

2002 8 Each

OPTION Mowing, Type I, Site 2, FFP

Overlook Picnic Area - May through August, two (2) times per month

2003 8 Each

OPTION Mowing, Type I, Site 3

FFP

East Branch Campground -May through August, two (2) times per month

2004 18 Each

OPTION Mowing, Type I, Site 4, FFP

Boat Launch April through September, three (3) times per month.

2005 6 Each

OPTION Mowing, Type II, Site 5, FFP

Miscellaneous Areas - April through September, one (1) time per month

2006 6 Each

OPTION Mowing, Type II, Site 6, FFP

Dam and Communication Area - April through September, one (1) time per month

2007 58,158 Square

OPTION Brush Cutting/Removal Site 1, 4 & 6

2008 52 Each

OPTION Project Office Cleaning, Site 1

FFP

One (1) time each week, from January through December

2009 52 Each

OPTION Maintenance Office Cleaning, Site 1

FFP

One (1) time each week from January through December

2010 1 Each

OPTION Restroom Cleaning, Site 1, FFP

Overlook Picnic Area *The East Branch Cutoff Wall Construction project will impact the quantity of work ordered under this CLIN as well as the scheduling of these efforts. The quantity may (1) increase due to delay of the Cutoff Wall construction project or (2) decrease during the East Branch Cutoff Wall construction period when this area will be closed. Similarly, the scheduling of the

2011 1 Each

OPTION Restroom Cleaning, Site 3, FFP

East Branch Campground *The East Branch Cutoff Wall Construction project will impact the quantity of work ordered under this CLIN as well as the scheduling of these efforts. The quantity may (1) increase due to delay of the Cutoff Wall construction project or (2) decrease during the East Branch Cutoff Wall construction period when this area will be closed. Similarly, the scheduling of the

2012 104 Each

OPTION Restroom Cleaning, Site 4, FFP

Boat Launch - Four (4) times per week from April through September

2013 2 Each

OPTION Carpet Cleaning, Site 1

FFP

Shampooing/Steamcleaning of Carpeted Floors, Project Office - Two (2) times a year, Spring and Fall.

2014 1 Each

OPTION Pressure Washing Restrooms

FFP

Sites 2, 3 and 4, one (1) time per year

2015 52 Each

OPTION Solid Waste Removal, Site 1 and 4, FFP

(Two Dumpters) - One (1) time per week, for 52 weeks in a year

2016 1 Each

OPTION Solid Waste Removal, Site 3

FFP

Site 3 (One Dumpster) *The East Branch Cutoff Wall Construction project will impact the quantity of work ordered under this CLIN as well as the scheduling of these efforts. The quantity may (1) increase due to delay of the Cutoff Wall construction project or (2) decrease during the East Branch Cutoff Wall construction period when this area will be closed. Similarly, the scheduling of the

2017 26 Each

OPTION Solid Waste Removal, Site 4

FFP

Site 4 (One Dumpster) - One (1) time per week during April through September

2018 5,000 Each

OPTION Raw Sewage Removal, FFP

Site 4 Boat Launch

2019 57,112 Square

OPTION Pesticide Application Site 2, 3 & 6

PRICE SCHEDULE

BASE YEAR (Line Items 0001-0018) $_______________________ Base Year Period of Performance will be 1 July 2014 through 31 December 2014

OPTION YEAR 1 (Line Items 1001-1018) $_______________________ Option Year 1 Period of Performance will be 1 January 2015 through 31 December 2015

OPTION YEAR 2 (Line Items 2001-2018) $_______________________ Option Year 2 Period of Performance will be 1 January 2016 through 31 December 2016

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 POP 01-JUL-2014 TO

31-DEC-2014

N/A EAST BRANCH CLARION RIVER

RESOURCE MANAGER

US ARMY CORPS OF ENGINEER 631 EAST

BRANCH

WILCOX PA 15870

9624BA

0002 POP 01-JUL-2014 TO

31-DEC-2014

N/A (SAME AS PREVIOUS LOCATION)

0003 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0004 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0005 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0006 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0007 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0008 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0009 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0010 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0011 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0012 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0013 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0014 POP 01-JUL-2014 TO

N/A EAST BRANCH RESIDENT OFFICE

KIMBERLY M WARNER

US ARMY CORPS OF ENGINEER 631C

EAST BRANC

WILCOX PA 15870

270-343-6067

963634

0015 POP 01-JUL-2014 TO

N/A EAST BRANCH CLARION RIVER

RESOURCE MANAGER

US ARMY CORPS OF ENGINEER 631 EAST

BRANCH

WILCOX PA 15870

0016 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0017 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0018 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

0019 POP 01-JUL-2014 TO

N/A (SAME AS PREVIOUS LOCATION)

1001 POP 01-JAN-2015 TO

31-DEC-2015

N/A (SAME AS PREVIOUS LOCATION)

1002 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1003 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1004 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1005 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1006 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1007 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1008 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1009 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1010 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1011 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1012 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1013 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1014 POP 01-JAN-2015 TO

N/A EAST BRANCH RESIDENT OFFICE

KIMBERLY M WARNER

US ARMY CORPS OF ENGINEER 631C

EAST BRANC

WILCOX PA 15870

270-343-6067

1015 POP 01-JAN-2015 TO

N/A EAST BRANCH CLARION RIVER

RESOURCE MANAGER

US ARMY CORPS OF ENGINEER 631 EAST

BRANCH

WILCOX PA 15870

1016 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1017 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1018 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

1019 POP 01-JAN-2015 TO

N/A (SAME AS PREVIOUS LOCATION)

2001 POP 01-JAN-2016 TO

31-DEC-2016

N/A (SAME AS PREVIOUS LOCATION)

2002 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2003 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2004 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2005 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2006 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2007 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2008 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2009 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2010 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2011 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2012 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2013 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2014 POP 01-JAN-2016 TO

N/A EAST BRANCH RESIDENT OFFICE

KIMBERLY M WARNER

US ARMY CORPS OF ENGINEER 631C

EAST BRANC

WILCOX PA 15870

270-343-6067

2015 POP 01-JAN-2016 TO

N/A EAST BRANCH CLARION RIVER

RESOURCE MANAGER

US ARMY CORPS OF ENGINEER 631 EAST

BRANCH

WILCOX PA 15870

2016 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2017 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2018 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

2019 POP 01-JAN-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.212-4 Contract Terms and Conditions--Commercial Items MAY 2014

ADDENDUM TO 52.212-4

The following clauses are hereby included as an addendum for FAR 52.212-4, Contract Terms and Conditions – Commercial Items:

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-13 System for Award Management Maintenance JUL 2013 52.212-1 Instructions to Offerors--Commercial Items APR 2014 52.217-5 Evaluation Of Options JUL 1990 52.223-1 Biobased Product Certification MAY 2012 52.223-10 Waste Reduction Program MAY 2011 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.228-5 Insurance - Work On A Government Installation JAN 1997 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.237-1 Site Visit APR 1984 52.237-2 Protection Of Government Buildings, Equipment, And

Vegetation

APR 1984

52.246-4 Inspection Of Services--Fixed Price AUG 1996 252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7000 Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7004 Alt A System for Award Management Alternate A MAR 2014 252.204-7006 Billing Instructions OCT 2005 252.209-7001 Disclosure of Ownership or Control by the Government of a

Terrorist Country

JAN 2009

252.223-7006 Prohibition On Storage And Disposal Of Toxic And Hazardous Materials

APR 2012

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7048 Export-Controlled Items JUN 2013 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.237-7010 Prohibition on Interrogation of Detainees by Contractor

Personnel

JUN 2013

252.243-7002 Requests for Equitable Adjustment DEC 2012 252.247-7023 Transportation of Supplies by Sea APR 2014

CLAUSES INCORPORATED BY FULL TEXT

52.204-7 SYSTEM FOR AWARD MANAGEMENT (JULY 2013)

(a) Definitions. As used in this provision--

Data Universal Numbering System (DUNS) number means the 9-digit number assigned by Dun and Bradstreet, Inc.

(D&B) to identify unique business entities.

Data Universal Numbering System +4 (DUNS+4) number means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional System for

Award Management records for identifying alternative Electronic Funds Transfer (EFT) accounts (see the FAR at Subpart 32.11) for the same parent concern.

Registered in the System for Award Management SAM database means that--

(1) The offeror has entered all mandatory information, including the DUNS number or the DUNS+4 number, the Contractor and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see Subpart 4.14) into the SAM database;

(2) The offeror has completed the Core, Assertions, and Representations and Certifications, and Points of Contact sections of the registration in the SAM database;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and

(4) The Government has marked the record ``Active''.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “DUNS” or “DUNS +4” followed by the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number--

(i) Via the Internet at http://fedgov.dnb.com/webform or if the offeror does not have internet access, it may call Dun and Bradstreet at 1-866-705-5711 if located within the United States; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office. The offeror should indicate that it is an offeror for a U.S. Government contract when contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and Zip Code.

(iv) Company Mailing Address, City, State and Zip Code (if separate from physical).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) Offerors may obtain information on registration at https://www.acquisition.gov.

(End of clause)

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (NOV 2013)

An offeror shall complete only paragraph (b) of this provision if the offeror has completed the annual representations and certifications electronically via http://www.acquisition.gov. If an offeror has not completed the annual representations and certifications electronically at the System for Award Management (SAM) website, the offeror shall complete only paragraphs (c) through (o) of this provision.

(a) Definitions. As used in this provision --

“Economically disadvantaged women-owned small business (EDWOSB) Concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

"Forced or indentured child labor" means all work or service-

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

Inverted domestic corporation, as used in this section, means a foreign incorporated entity which is treated as an inverted domestic corporation under 6 U.S.C. 395(b), i.e., a corporation that used to be incorporated in the United States, or used to be a partnership in the United States, but now is incorporated in a foreign country, or is a subsidiary whose parent corporation is incorporated in a foreign country, that meets the criteria specified in 6 U.S.C.

395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). An inverted domestic corporation as herein defined does not meet the definition of an inverted domestic corporation as defined by the Internal Revenue Code at 26 U.S.C. 7874.

Manufactured end product means any end product in Federal Supply Classes (FSC) 1000-9999, except--

(1) FSC 5510, Lumber and Related Basic Wood Materials;

(2) Federal Supply Group (FSG) 87, Agricultural Supplies;

(3) FSG 88, Live Animals;

(4) FSG 89, Food and Related Consumables;

(5) FSC 9410, Crude Grades of Plant Materials;

(6) FSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) FSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) FSC 9610, Ores;

(9) FSC 9620, Minerals, Natural and Synthetic; and

(10) FSC 9630, Additive Metal Materials.

Place of manufacture means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

Restricted business operations means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate--

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology--

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically--

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

"Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

Subsidiary means an entity in which more than 50 percent of the entity is owned--

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

Veteran-owned small business concern means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

"Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

"Women-owned small business concern" means a small business concern--

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; or

(2) Whose management and daily business operations are controlled by one or more women.

Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)”, means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

(b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted electronically on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212- 3, Offeror Representations and Certifications--Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ----------.

[Offeror to identify the applicable paragraphs at (c) through (o) of this provision that the offeror has completed for the purposes of this solicitation only, if any.) These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on ORCA.]

(c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it ( ) is, ( ) is not a small business concern.

(2) Veteran-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. (Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents, for general statistical purposes, that it ( ___ ) is, ( ___ ) is not a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ) is, ( ) is not a women-owned small business concern.

Note to paragraphs (c)(8) and (9): Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that--

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ----------.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that--

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ----------.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(8) Women-owned business concern (other than small business concern). (Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

(10) (Complete only if the solicitation contains the clause at FAR 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns or FAR 52.219-25, Small Disadvantaged Business Participation Program-Disadvantaged Status and Reporting, and the offeror desires a benefit based on its disadvantaged status.)

(i) General. The offeror represents that either--

(A) It ( ___ ) is, ( ___ ) is not certified by the Small Business Administration as a small disadvantaged business concern and identified, on the date of this representation, as a certified small disadvantaged business concern in the SAM Dynamic Small Business Search database maintained by the Small Business Administration, and that no material change in disadvantaged ownership and control has occurred since its certification, and, where the concern is owned by one or more individuals claiming disadvantaged status, the net worth of each individual upon whom the certification is based does not exceed $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); or

(B) It ( ___ ) has, ( ___ ) has not submitted a completed application to the Small Business Administration or a Private Certifier to be certified as a small disadvantaged business concern in accordance with 13 CFR 124, Subpart B, and a decision on that application is pending, and that no material change in disadvantaged ownership and control has occurred since its application was submitted.

(ii) Joint Ventures under the Price Evaluation Adjustment for Small Disadvantaged Business Concerns. The offeror represents, as part of its offer, that it is a joint venture that complies with the requirements in 13 CFR 124.1002(f) and that the representation in paragraph (c)(10)(i) of this provision is accurate for the small disadvantaged business concern that is participating in the joint venture. (The offeror shall enter the name of the small disadvantaged business concern that is participating in the joint venture: ____________.)

(11) HUBZone small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(11)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: _______.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Certifications and representations required to implement provisions of Executive Order 11246--

(1) Previous Contracts and Compliance. The offeror represents that--

(i) It ( ___ ) has, ( ___ ) has not, participated in a previous contract or subcontract subject either to the Equal Opportunity clause of this solicitation, the and

(ii) It ( ___ ) has, ( ___ ) has not, filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that--

(i) It ( ___ ) has developed and has on file, ( ___ ) has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR Subparts 60-1 and 60-2), or

(ii) It ( ___ ) has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Act Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American Act --Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American Act--Supplies.”

(2) Foreign End Products:

Line Item No. Country of Origin

(List as necessary)

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(g)(1) Buy American Act--Free Trade Agreements--Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American Act--Free Trade Agreements--Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms ``Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,'' ``commercially available off-the-shelf (COTS) item,'' ``component,'' ``domestic end product,'' ``end product,'' ``foreign end product,'' ``Free Trade Agreement country,'' ``Free Trade Agreement country end product,'' ``Israeli end product,'' and ``United States'' are defined in the clause of this solicitation entitled ``Buy American Act--Free Trade Agreements--Israeli Trade Act.''

(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled ``Buy American Act--Free Trade Agreements--Israeli Trade Act'':

Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

[List as necessary]

(iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) of this provision) as defined in the clause of this solicitation entitled "Buy American Act-Free Trade Agreements- Israeli Trade Act." The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.”

Other Foreign End Products:

Line Item No. Country of Origin

(iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(2) Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate, Alternate I (Jan 2004). If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled "Buy American Act-Free Trade Agreements-Israeli Trade Act":

Canadian End Products:

Line Item No.

(3) Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate, Alternate II (Jan 2004). If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled "Buy American Act-Free Trade Agreements-Israeli Trade Act":

Canadian or Israeli End Products:

Line Item No. Country of Origin

(4) Buy American Act--Free Trade Agreements--Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled ``Buy American Act--Free Trade Agreements--Israeli Trade Act'':

Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

(5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product, as defined in the clause of this solicitation entitled ``Trade Agreements''.

(ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products.

Other End Products:

(iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American Act. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation.

(h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that --

(1) The offeror and/or any of its principals ( ___ ) are, ( ___ ) are not presently debarred, suspended, proposed for…