T10 RFP Instructions 47PE0724R0024 Fire Alarm System CPFB Miami 2024 07 23.pdf
PDF 176 KB Posted
- Attached to
- Fire Alarm System Replacement - Claude Pepper Fed Bldg, Miami - Amendment 0002 Federal contract opportunity
- Solicitation number
- 47PE0724R0024
About this file
This document is the Request for Proposal (RFP) Instructions for the GSA Solicitation Number 47PE0724R0024, titled "Fire Alarm System Replacement" at the Claude Pepper Federal Building in Miami, Florida.
The solicitation is a 100% Small Business Set-Aside design-build project to completely replace the existing antiquated fire alarm system. The new system must comply with PBS-P100, NFPA 72, IFC, and IBC requirements. The construction performance period is 330 calendar days after issuance of the Notice to Proceed, with liquidated damages of $886.36 per calendar day for late completion. The contract magnitude is between $1,000,000 - $5,000,000. Proposals are due by 5:00 PM EDT on 8/23/2024 and will be evaluated using the Lowest Price Technically Acceptable (LPTA) source selection method. Offerors must be registered in the System for Award Management (SAM) and are required to submit an SF 1442 Solicitation, Offer, and Award, price proposal, technical proposal, and bid guarantee. A pre-proposal site visit was held on 7/16/2022.
View the file
Other files for this federal contract opportunity
Show all 16
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Southeast Sunbelt Region 4 Public Buildings Service Acquisition Management Division (AMD)
Gulf Coast Branch
REQUEST FOR PROPOSAL (RFP) INSTRUCTIONS
GSA Solicitation Number: 47PE0724R0024
Title: Fire Alarm System Replacement Location/Address: Claude Pepper Federal Bldg, Miami FL 51 SW 1ST Avenue Miami, Florida 33130 Contracting Officer (CO): Ric Sochor, 813-215-6989 ric.sochor@gsa.gov
Who Can Participate in This Procurement?
This procurement is a Total Small Business Set-Aside
IAW 52.219-6
Site Visit & Pre-Proposal Conference:
A pre-proposal site visit was held on:
July 16, 2022, at 10:00 am Eastern Offerors are highly encouraged to inspect the site where the work will be performed. See Solicitation Section I.G. FAR 52.236-27 Site Visit – Construction. RFIs due on 7/30/2024
Bonds & Insurance Requirements
Bid Bond (Provision - FAR 52.228-1) Performance Bond (Clause - FAR 52.228-15) Payment Bond (Clause - FAR 52.228-15) Insurance (Clause - FAR 52.228-5)
Performance Time & Liquidated Damages
The construction performance period is 330 calendar days after issuance of the NTP.
The liquidated damages for each calendar day beyond the performance period completion date: $886.36
Construction Magnitude
Between $1,000,000 - $5,000,000
System for Award Management As prescribed in FAR 4.1100, contractors are required to register in the System for Award Management (SAM) database. Please be sure your record is current!
What D o c u me n t s Do I Submit?
Document
SF 1442 (complete blocks 14 through 20c and price schedule.) Include DUNS/UEI # (blk 14).
Price Proposal – Reference Solicitation Section II.C.
Tech. Proposal – Reference Solicitation Section II.D.
Bid Guarantee – Reference Solicitation Section I.F.
Bond form (SF 24) can be provided upon request.
Offeror’s Representations and Certifications Reference Solicitation Section II.E.
When Is My Offer Due?
Unless changed by amendment, your proposal is due by the date and time specified in Block 13 of the Standard Form 1442, Solicitation, Offer, and Award which is currently:
Date: 8/23/2024 Time: 5:00 PM (EDT)
Check and acknowledge all amendments for offer due date extensions.
What method of award will be used?
LPTA IAW FAR 15.101-2
Reference Solicitation Section VI.
Where Do I Submit My Offer?
Send your electronic proposal documents to the Contracting Officer (see POC Info above)
THIS DOCUMENT IS FOR INFORMATIONAL PURPOSES ONLY to assist in proposal preparation and submission. The solicitation (RFP) contains official information and requirements.
File details come from the government source that posted it. Updated .