T10 RFP Instructions 47PE0722R0009 02 04 2022.pdf
PDF 128 KB Posted
- Solicitation number
- 47PE0722R0009
About this file
This document provides instructions for a request for proposal for vehicle barrier and gate replacement work at two courthouses in Tallahassee, Florida. The General Services Administration Public Buildings Service is seeking to replace four existing active vehicle barriers with new M30 systems, refurbish and replace existing vehicular sliding gates, install a new guard booth, pedestrian gate, bollards and security infrastructure through a small business set-aside contract between $1 million to $5 million. Offerors must submit pricing and technical proposals by March 11, 2022. The construction performance period is 300 calendar days following notice to proceed with liquidated damages of $427.12 per day for delays. A pre-proposal site visit will be held on February 16, 2022 and the System for Award Management registration is required.
View the file
Other files
Show all 13
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
GSA Southeast Sunbelt Region 4 - Public Buildings Service
REQUEST FOR PROPOSAL (RFP) INSTRUCTIONS
Solicitation Number: 47PE0722R0009
Description/Title: USMS Vehicle Barriers & Gate Replacement
Place of Performance: U.S. Courthouse Annex & U.S. Bankruptcy Courthouse, Tallahassee FL
Contracting Officer (CO): Kay Bent, 404-394-4682 kay.bent@gsa.gov Contract Specialist (CS): Ric Sochor, 813-215-6989 ric.sochor@gsa.gov Project Manager/COR: Dominic Pafundi, 813-486-9370 dominic.pafundi@gsa.gov
Who Can Participate in This Procurement?
This procurement is a 100% Small Business set-aside
IAW 52.219-6
Site Visit & Pre-Proposal Conference:
A pre-proposal site visit has been scheduled for:
February 16, 2022, at 10:00 am EDT.
Offerors are highly encouraged to inspect the site where the work will be performed. See Solicitation Section I.G. FAR 52.236-27 Site Visit – Construction
Bonds & Insurance Requirements
Bid Bond (Provision - FAR 52.228-1) Performance Bond (Clause - FAR 52.228-15) Payment Bond (Clause - FAR 52.228-15) Insurance (Clause - FAR 52.228-5)
Performance Time & Liquidated Damages
The construction performance period is 300 calendar days after issuance of the NTP.
The liquidated damages for each calendar day beyond the performance period completion date: $427.12
Construction Magnitude
Between $1,000,000 - $5,000,000
System for Award Management As prescribed in FAR 4.1100, contractors are required to register in the System for Award Management (SAM) database. Please be sure your record is current!
What D o c u me n t s Do I Submit?
Document
SF 1442 (complete blk 14 - 20c and price schedule). Include DUNS/UEI # (blk 14).
Price Proposal – Reference Solicitation Section II.C.
Tech. Proposal – Reference Solicitation Section
II.D.
Bid Guarantee – Reference Solicitation Section I.F.
Bond form (SF 24) can be provided upon request.
Offeror’s Representations and Certifications Reference Solicitation Section II.E.
When Is My Offer Due?
Unless changed by amendment, your proposal is due by the date and time specified in Block 13 of the Standard Form 1442, Solicitation, Offer, and Award which is currently:
Date: 3/11/2022 Time: 5:00 PM (EDT)
Check and acknowledge all amendments for offer due date extensions.
What method of award will be used?
LPTA IAW FAR 15.101-2
Reference Solicitation Section VI.
Where Do I Submit My Offer?
Send your electronic proposal documents to the Contract Specialist and Contracting Officer (see POC Info above)
THIS DOCUMENT IS FOR INFORMATIONAL PURPOSES ONLY to assist in proposal submission. The solicitation (RFP) contains the official data and requirements.
mailto:kay.bent@gsa.gov mailto:ric.sochor@gsa.gov mailto:dominic.pafundi@gsa.gov
File details come from the government source that posted it. Updated .