EJCDC® C‐800, Supplementary Conditions of the Construction Contract.

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the controlling Laws and Regulations.

SUPPLEMENTARY CONDITIONS

OF THE CONSTRUCTION CONTRACT

Prepared By

Endorsed By

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

Copyright© 2018

National Society of Professional Engineers

1420 King Street, Alexandria, VA 22314‐2794

(703) 684‐2882 www.nspe.org

American Council of Engineering Companies

1015 15th Street N.W., Washington, DC 20005

(202) 347‐7474 www.acec.org

American Society of Civil Engineers

1801 Alexander Bell Drive, Reston, VA 20191‐4400

(800) 548‐2723 www.asce.org

The copyright for this EJCDC document is owned jointly by the three sponsoring organizations listed above. The National Society of Professional Engineers is the Copyright Administrator for the EJCDC documents; please direct all inquiries regarding EJCDC copyrights to NSPE.

NOTE: EJCDC publications may be purchased at www.ejcdc.org, or from any of the sponsoring organizations above.

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

TOC Page 1 of 1

SUPPLEMENTARY CONDITIONS OF THE CONSTRUCTION CONTRACT

TABLE OF CONTENTS

Page

Article 1— Definitions and Terminology

Article 2— Preliminary Matters

Article 3— Contract Documents: Intent, Requirements, Reuse

Article 4— Commencement and Progress of the Work

Article 5— Site, Subsurface and Physical Conditions, Hazardoud Environmental Conditions

Article 6— Bonds and Insurance

Article 7— Contractor’s Responsibilities

Article 8— Other Work at the Site

Article 9— Owner’s Responsibilities

Article 10— Engineer’s Status During Construction

Article 11— Changes to the Contract

Article 12— Claims

Article 13— Cost of Work; Allowances, Unit Price Work

Article 14— Tests and Inspections; Correction, Removal, or Accceptance of Defective Work

Article 15— Payments to Contractor, Set Offs; Completions; Correction Period

Article 16— Suspension of Work and Termination

Article 17— Final Resolutions of Disputes

Article 18— Miscellaneous

Exhibit A— Software Requirements for Electronic Document Exchange ...... Error! Bookmark not defined.

Exhibit B— Foreseeable Bad Weather Days .................................................. Error! Bookmark not defined.

Exhibit C— Geotechnical Baseline Report Supplement to the Supplementary Conditions Error! Bookmark not defined.

Exhibit C—Geotechnical Baseline Report Supplement to the Supplementary Conditions.

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

SUPPLEMENTARY CONDITIONS OF THE CONSTRUCTION CONTRACT

These Supplementary Conditions amend or supplement EJCDC® C‐700, Standard General Conditions of the Construction Contract (2018). The General Conditions remain in full force and effect except as amended.

The terms used in these Supplementary Conditions have the meanings stated in the General Conditions.

Additional terms used in these Supplementary Conditions have the meanings stated below, which are applicable to both the singular and plural thereof.

The address system used in these Supplementary Conditions is the same as the address system used in the General Conditions, with the prefix "SC" added—for example, “Paragraph SC‐4.05.”

ARTICLE 1—DEFINITIONS AND TERMINOLOGY

No suggested Supplementary Conditions in this Article.

ARTICLE 2—PRELIMINARY MATTERS

2.01 Delivery of Bonds and Evidence of Insurance

SC‐2.01 Delete Paragraphs 2.01.B. and C. in their entirety and insert the following in their place:

B. Evidence of Contractor’s Insurance: When Contractor delivers the signed counterparts of the Agreement to Owner, Contractor shall also deliver to Owner copies of the policies (including all endorsements, and identification of applicable self‐insured retentions and deductibles) of insurance required to be provided by Contractor in this Contract. Contractor may block out (redact) any confidential premium or pricing information contained in any policy or endorsement furnished under this provision.

C. Evidence of Owner’s Insurance: After receipt from Contractor of the signed counterparts of the Agreement and all required bonds and insurance documentation, Owner shall promptly deliver to Contractor copies of the policies of insurance to be provided by Owner in this Contract (if any). Owner may block out (redact) any confidential premium or pricing information contained in any policy or endorsement furnished under this provision.

ARTICLE 3—CONTRACT DOCUMENTS: INTENT, REQUIREMENTS, REUSE

ARTICLE 4—COMMENCEMENT AND PROGRESS OF THE WORK

4.05 Delays in Contractor’s Progress

SC‐4.05 Amend Paragraph 4.05.C by adding the following subparagraphs:

5. Weather‐Related Delays

a. All time delays encountered during the construction process caused by adverse weather conditions shall be determined utilizing the following methodology.

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(6) (5) (4) (4) (4) (5) (5) (5) (8) (6) (5) (5)

Upon acknowledgment of the Notice to Proceed and continuing throughout the contract, the Contractor will record on the daily report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse occurred in previous month), be calculated chronologically for the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in the previous paragraph, above, the Architect will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the appropriate contract clause.

ARTICLE 5—SITE, SUBSURFACE AND PHYSICAL CONDITIONS, HAZARDOUS ENVIRONMENTAL

CONDITIONS

SC 5.02 Remove wording from Paragraph 5.02 A.2 “or otherwise resolve the claim by arbitration or other dispute resolution proceeding.”

5.03 Subsurface and Physical Conditions

ARTICLE 6—BONDS AND INSURANCE

6.01 Performance, Payment, and Other Bonds

SC‐6.01 Add the following paragraphs immediately after Paragraph 6.01.A:

1. Required Performance Bond Form: The performance bond that Contractor furnishes will be in the form of EJCDC® C‐610, Performance Bond (2010, 2013, or 2018 edition).

2. Required Payment Bond Form: The payment bond that Contractor furnishes will be in the form of EJCDC® C‐615, Payment Bond (2010, 2013, or 2018 edition).

SC‐6.01 Add the following paragraphs immediately after Paragraph 6.01.B:

1. After Substantial Completion, Contractor shall furnish a warranty bond issued in the form of EJCDC® C‐612, Warranty Bond (2018). The warranty bond must be in a bond amount of 15 percent of the final Contract Price.

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

2. The warranty bond must be issued by the same surety that issues the performance bond required under Paragraph 6.01.A of the General Conditions.

6.03 Contractor’s Insurance

SC‐6.03 Supplement Paragraph 6.03 with the following provisions after Paragraph 6.03.C:

E. Workers’ Compensation and Employer’s Liability: Contractor shall purchase and maintain workers’ compensation and employer’s liability insurance, including, as applicable, United States Longshoreman and Harbor Workers’ Compensation Act, Jones Act, stop‐gap employer’s liability coverage for monopolistic states, and foreign voluntary workers’ compensation (from available sources, notwithstanding the jurisdictional requirement of Paragraph 6.02.B of the General Conditions).

Workers’ Compensation and Related Policies Policy limits of not less than:

Workers’ Compensation

State Statutory

Applicable Federal (e.g., Longshoreman’s) Statutory

Foreign voluntary workers’ compensation (employer’s responsibility coverage), if applicable

Statutory

Jones Act (if applicable)

Bodily injury by accident—each accident $100,000.00

Bodily injury by disease—aggregate $500,000.00

Employer’s Liability

Each accident $100,000.00

Each employee $100,000.00

Policy limit $500,000.00

Stop‐gap Liability Coverage

For work performed in monopolistic states, stop‐gap liability coverage must be endorsed to either the worker’s compensation or commercial general liability policy with a minimum limit of:

$500,000.00

F. Commercial General Liability—Claims Covered: Contractor shall purchase and maintain commercial general liability insurance, covering all operations by or on behalf of Contractor, on an occurrence basis, against claims for:

1. damages because of bodily injury, sickness or disease, or death of any person other than Contractor’s employees,

2. damages insured by reasonably available personal injury liability coverage, and

3. damages because of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom.

G. Commercial General Liability—Form and Content: Contractor’s commercial liability policy must be written on a 1996 (or later) Insurance Services Organization, Inc. (ISO) commercial general liability form (occurrence form) and include the following coverages and endorsements:

1. Products and completed operations coverage.

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

a. Such insurance must be maintained for three years after final payment.

b. Contractor shall furnish Owner and each other additional insured (as identified in the Supplementary Conditions or elsewhere in the Contract) evidence of continuation of such insurance at final payment and three years thereafter.

2. Blanket contractual liability coverage, including but not limited to coverage of Contractor’s contractual indemnity obligations in Paragraph 7.18.

3. Severability of interests and no insured‐versus‐insured or cross‐liability exclusions.

4. Underground, explosion, and collapse coverage.

5. Personal injury coverage.

6. Additional insured endorsements that include both ongoing operations and products and completed operations coverage through ISO Endorsements CG 20 10 10 01 and CG 20 37 10 01 (together). If Contractor demonstrates to Owner that the specified ISO endorsements are not commercially available, then Contractor may satisfy this requirement by providing equivalent endorsements.

7. For design professional additional insureds, ISO Endorsement CG 20 32 07 04 “Additional Insured—Engineers, Architects or Surveyors Not Engaged by the Named Insured” or its equivalent.

H. Commercial General Liability—Excluded Content: The commercial general liability insurance policy, including its coverages, endorsements, and incorporated provisions, must not include any of the following:

1. Any modification of the standard definition of “insured contract” (except to delete the railroad protective liability exclusion if Contractor is required to indemnify a railroad or others with respect to Work within 50 feet of railroad property).

2. Any exclusion for water intrusion or water damage.

3. Any provisions resulting in the erosion of insurance limits by defense costs other than those already incorporated in ISO form CG 00 01.

4. Any exclusion of coverage relating to earth subsidence or movement.

5. Any exclusion for the insured’s vicarious liability, strict liability, or statutory liability (other than worker’s compensation).

6. Any limitation or exclusion based on the nature of Contractor’s work.

7. Any professional liability exclusion broader in effect than the most recent edition of ISO form CG 22 79.

I. Commercial General Liability—Minimum Policy Limits

Commercial General Liability Policy limits of not less than:

General Aggregate $500,000.00

Products—Completed Operations Aggregate $100,000.00

Personal and Advertising Injury $250,000.00

Bodily Injury and Property Damage—Each Occurrence $500,000.00

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

J. Automobile Liability: Contractor shall purchase and maintain automobile liability insurance for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance, or use of any motor vehicle. The automobile liability policy must be written on an occurrence basis.

Automobile Liability Policy limits of not less than:

Bodily Injury

Each Person $100,000.00

Each Accident $500,000.00

Property Damage

Each Accident $100,000.00

[or]

Combined Single Limit

Combined Single Limit (Bodily Injury and Property Damage) $500,000.00

K. Umbrella or Excess Liability: Contractor shall purchase and maintain umbrella or excess liability insurance written over the underlying employer’s liability, commercial general liability, and automobile liability insurance described in the Paragraphs above. The coverage afforded must be at least as broad as that of each and every one of the underlying policies.

Excess or Umbrella Liability Policy limits of not less than:

Each Occurrence $250,000.00

General Aggregate $500,000.00

L. Using Umbrella or Excess Liability Insurance to Meet CGL and Other Policy Limit Requirements: Contractor may meet the policy limits specified for employer’s liability, commercial general liability, and automobile liability through the primary policies alone, or through combinations of the primary insurance policy’s policy limits and partial attribution of the policy limits of an umbrella or excess liability policy that is at least as broad in coverage as that of the underlying policy, as specified herein. If such umbrella or excess liability policy was required under this Contract, at a specified minimum policy limit, such umbrella or excess policy must retain a minimum limit of $500,000.00 after accounting for partial attribution of its limits to underlying policies, as allowed above.

M. Contractor’s Pollution Liability Insurance: Contractor shall purchase and maintain a policy covering third‐party injury and property damage, including cleanup costs, as a result of pollution conditions arising from Contractor’s operations and completed operations. This insurance must be maintained for no less than three years after final completion.

Contractor’s Pollution Liability Policy limits of not less than:

Each Occurrence/Claim $100,000.00

General Aggregate $100,000.00

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

N. Contractor’s Professional Liability Insurance: If Contractor will provide or furnish professional services under this Contract, through a delegation of professional design services or otherwise, then Contractor shall be responsible for purchasing and maintaining applicable professional liability insurance. This insurance must cover negligent acts, errors, or omissions in the performance of professional design or related services by the insured or others for whom the insured is legally liable. The insurance must be maintained throughout the duration of the Contract and for a minimum of two years after Substantial Completion. The retroactive date on the policy must pre‐date the commencement of furnishing services on the Project.

Contractor’s Professional Liability Policy limits of not less than:

Each Claim $500,000.00

Annual Aggregate $1,000,000.00

ARTICLE 7—CONTRACTOR’S RESPONSIBILITIES

7.03 Labor; Working Hours

SC‐7.03 Add the following new subparagraphs immediately after Paragraph 7.03.C:

1. Regular working hours will be Monday‐Friday 8:00 am to 5:00 pm.

2. Owner's legal holidays are Federal recognized holidays.

SC‐7.03 Add the following new paragraph immediately after Paragraph 7.03.C:

D. Contractor shall be responsible for the cost of any overtime pay or other expense incurred by the Owner for Engineer’s services (including those of the Resident Project Representative, if any), Owner's representative, and construction observation services, occasioned by the performance of Work on Saturday, Sunday, any legal holiday, or as overtime on any regular work day. If Contractor is responsible but does not pay, or if the parties are unable to agree as to the amount owed, then Owner may impose a reasonable set‐off against payments due under Article 15.

7.13 Safety and Protection

SC‐7.13 Insert the following at the end of the last sentence of Paragraph 7.13.F:

“with at least a 48‐hour notice.”

SC‐7.18 Delete the following from Paragraph 7.18.A:

“or arbitration”

ARTICLE 8—OTHER WORK AT THE SITE

8.03 Legal Relationships

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

SC‐8.03 Delete the following from Paragraph 8.03.C:

“or otherwise resolve the claim by arbitration or other dispute resolution proceeding”

ARTICLE 9—OWNER’S RESPONSIBILITIES

ARTICLE 10—ENGINEER’S STATUS DURING CONSTRUCTION

10.03 Resident Project Representative

SC‐10.03 Add the following new paragraphs immediately after Paragraph 10.03.B:

C. The Resident Project Representative (RPR) will be Engineer's representative at the Site. RPR's dealings in matters pertaining to the Work in general will be with Engineer and Contractor.

RPR's dealings with Subcontractors will only be through or with the full knowledge or approval of Contractor. The RPR will:

1. Conferences and Meetings: Attend meetings with Contractor, such as preconstruction conferences, progress meetings, job conferences, and other Project‐related meetings (but not including Contractor’s safety meetings), and as appropriate prepare and circulate copies of minutes thereof.

2. Safety Compliance: Comply with Site safety programs, as they apply to RPR, and if required to do so by such safety programs, receive safety training specifically related to RPR’s own personal safety while at the Site.

3. Liaison

a. Serve as Engineer’s liaison with Contractor. Working principally through Contractor’s authorized representative or designee, assist in providing information regarding the provisions and intent of the Contract Documents.

b. Assist Engineer in serving as Owner’s liaison with Contractor when Contractor’s operations affect Owner’s on‐Site operations.

c. Assist in obtaining from Owner additional details or information, when required for Contractor’s proper execution of the Work.

4. Review of Work; Defective Work

a. Conduct on‐Site observations of the Work to assist Engineer in determining, to the extent set forth in Paragraph 10.02, if the Work is in general proceeding in accordance with the Contract Documents.

b. Observe whether any Work in place appears to be defective.

c. Observe whether any Work in place should be uncovered for observation, or requires special testing, inspection or approval.

5. Inspections and Tests

a. Observe Contractor‐arranged inspections required by Laws and Regulations, including but not limited to those performed by public or other agencies having jurisdiction over the Work.

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

b. Accompany visiting inspectors representing public or other agencies having jurisdiction over the Work.

6. Payment Requests: Review Applications for Payment with Contractor.

7. Completion

a. Participate in Engineer’s visits regarding Substantial Completion.

b. Assist in the preparation of a punch list of items to be completed or corrected.

c. Participate in Engineer’s visit to the Site in the company of Owner and Contractor regarding completion of the Work, and prepare a final punch list of items to be completed or corrected by Contractor.

d. Observe whether items on the final punch list have been completed or corrected.

D. The RPR will not:

1. Authorize any deviation from the Contract Documents or substitution of materials or equipment (including “or‐equal” items).

2. Exceed limitations of Engineer’s authority as set forth in the Contract Documents.

3. Undertake any of the responsibilities of Contractor, Subcontractors, or Suppliers.

4. Advise on, issue directions relative to, or assume control over any aspect of the means, methods, techniques, sequences or procedures of construction.

5 Advise on, issue directions regarding, or assume control over security or safety practices, precautions, and programs in connection with the activities or operations of Owner or Contractor.

6. Participate in specialized field or laboratory tests or inspections conducted off‐site by others except as specifically authorized by Engineer.

7. Authorize Owner to occupy the Project in whole or in part.

ARTICLE 11—CHANGES TO THE CONTRACT

No suggested Supplementary Conditions in this Article.

ARTICLE 12—CLAIMS

No suggested Supplementary Conditions in this Article.

ARTICLE 13—COST OF WORK; ALLOWANCES, UNIT PRICE WORK

13.01 Cost of the Work

SC‐13.01 Supplement Paragraph 13.01.B.5.c.(2) by adding the following sentence:

The equipment rental rate book that governs the included costs for the rental of machinery and equipment owned by Contractor (or a related entity) under the Cost of the Work

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

provisions of this Contract is the most current edition of Rental Rate Blue Book for Construction Equipment.

13.03 Unit Price Work

SC‐13.03 Delete Paragraph 13.03.E in its entirety and insert the following in its place:

E. Adjustments in Unit Price

1. Contractor or Owner shall be entitled to an adjustment in the unit price with respect to an item of Unit Price Work if:

a. the extended price of a particular item of Unit Price Work amounts to 5 percent or more of the Contract Price (based on estimated quantities at the time of Contract formation) and the variation in the quantity of that particular item of Unit Price Work actually furnished or performed by Contractor differs by more than 15 percent from the estimated quantity of such item indicated in the Agreement; and

b. Contractor’s unit costs to perform the item of Unit Price Work have changed materially and significantly as a result of the quantity change.

2. The adjustment in unit price will account for and be coordinated with any related changes in quantities of other items of Work, and in Contractor’s costs to perform such other Work, such that the resulting overall change in Contract Price is equitable to Owner and Contractor.

3. Adjusted unit prices will apply to all units of that item.

ARTICLE 14—TESTS AND INSPECTIONS; CORRECTION, REMOVAL, OR ACCCEPTANCE OF DEFECTIVE

WORK

No suggested Supplementary Conditions in this Article.

ARTICLE 15—PAYMENTS TO CONTRACTOR, SET OFFS; COMPLETIONS; CORRECTION PERIOD

15.03 Substantial Completion

SC‐15.03 Add the following new subparagraph to Paragraph 15.03.B:

1. If some or all of the Work has been determined not to be at a point of Substantial Completion and will require re‐inspection or re‐testing by Engineer, the cost of such re‐ inspection or re‐testing, including the cost of time, travel and living expenses, will be paid by Contractor to Owner. If Contractor does not pay, or the parties are unable to agree as to the amount owed, then Owner may impose a reasonable set‐off against payments due under this Article 15.

ARTICLE 16—SUSPENSION OF WORK AND TERMINATION

16.01 Owner May Suspend Work

A. A. At any time and without cause, Owner may suspend the Work or any portion thereof by giving written notice to Contractor and Engineer. Contractor shall resume the Work when

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

directed to do so by the City. Contractor shall not be entitled to an adjustment in the

Contract Price. Contractor may be entitled to an extension of the Contract Times as a result of any such suspension. Any Change Proposal seeking such adjustments must be submitted no later than 30 days after the date of resumption of Work. Owner shall have no liability to Contractor except for charges for Work performed by Contractor and accepted by the Owner prior to receipt of notice of suspension of Services. If only a portion of the Work is suspended, Contractor shall be compensated only for Work of which are not suspended and are actually performed during such suspension.

16.02 Owner May Terminate for Cause

A. The occurrence of any one or more of the following events will constitute a default by Contractor and justify termination for cause:

1. Contractor’s persistent failure to perform the Work in accordance with the Contract Documents (including, but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment, failure to satisfy milestones, or failure to adhere to the Progress Schedule);

2. Failure of Contractor to perform or otherwise to comply with a material term of the Contract Documents;

3. Contractor’s disregard of Laws or Regulations of any public body having jurisdiction; or

4. Contractor’s repeated disregard of the authority of Owner or Engineer.

B. If Owner determines in its sole discretion that any one or more of the events identified in Paragraph 16.02.A occur, Owner shall have the right, upon written notice, to terminate this Agreement immediately. Owner may enforce the rights available to Owner under any applicable performance bond.

C. Subject to the terms and operation of any applicable performance bond, if Owner has terminated the Contract for cause, Owner may exclude Contractor from the Site, take possession of the Work, incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere, and complete the Work as Owner may deem expedient.

D. If Owner proceeds as provided in Paragraph 16.02.B, Contractor shall not be entitled to receive any further payment. Owner shall have no liability to Contractor except for charges for Work performed by Contractor and accepted by the Owner prior to receipt of notice of termination.

E. If the cost to complete the Work including such related claims, costs, losses, and damages exceeds any unpaid balance to Contractor, Contractor shall pay the difference to Owner.

Such claims, costs, losses, and damages incurred by Owner will be reviewed by Engineer as to their reasonableness and, when so approved by Engineer, incorporated in a Change Order.

When exercising any rights or remedies under this paragraph, Owner shall not be required to obtain the lowest price for the Work performed.

F. Where Contractor’s services have been so terminated by Owner, the termination will not affect any rights or remedies of Owner against Contractor then existing or which may thereafter accrue, or any rights or remedies of Owner against Contractor or any surety under

Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

any payment bond or performance bond. Any retention or payment of money due Contractor by Owner will not release Contractor from liability.

16.03 Owner May Terminate for Convenience

A. Upon 7 days’ written notice to Contractor and Engineer, Owner may, without cause and without prejudice to any other right or remedy of Owner, terminate the Contract. Owner shall have no liability to Contractor except for charges for Work performed by Contractor and accepted by the Owner prior to receipt of notice of termination.

B. Contractor shall not be paid for any loss of anticipated profits or revenue, post‐termination overhead costs, or other economic loss arising out of or resulting from such termination.

16.04 Contractor May Stop Work or Terminate

This Section is deleted in its entirety.

ARTICLE 17—FINAL RESOLUTIONS OF DISPUTES

SC‐17.02 Add the following new paragraph immediately after Paragraph 17.01.

17.02 Arbitration

A. Arbitration as a dispute resolution is deleted in its entirety in the Contract Documents and General Conditions. All matters subject to final resolution under this Article shall be filed in a Court of competent jurisdiction in Hidalgo County, Texas.

SC‐17.03 Add the following new paragraph immediately after Paragraph 17.02.

17.03 Attorneys’ Fees

A. For any matter subject to final resolution under this Article and filed by the Owner, the Owner shall be entitled to an award of its reasonable attorneys’ fees and costs incurred through the claim and litigation process.

ARTICLE 18—MISCELLANEOUS

No suggested Supplementary Conditions in this Article