Station_No._2_Reroof_-_Specifications.pdf

Reroofing of Station No. 2

Murfreesboro Fire &

Rescue Department

February 12, 2026

JOHNSON + BAILEY ARCHITECTS P.C.

100 EAST VINE STREET, SUITE 700

MURFREESBORO, TENNESSEE

TELEPHONE: (615) 890-4560

FAX: (615) 890-4564

J+B NO. 2523

02/12/26

SECTION 00 01 10 TABLE OF CONTENTS

DIVISION PAGES

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION

00 01 10 - TABLE OF CONTENTS 1

00 01 15 - DRAWING INDEX 1

00 11 13 - ADVERTISEMENT FOR BIDS 1

00 21 13 - INSTRUCTIONS TO BIDDERS 8

00 41 13 - BID FORM 6

00 52 13 - CITY STANDARD FORM OF AGREEMENT BETWEEN OWNER

AND CONTRACTOR WITH EXHIBIT A 14

00 72 13 - GENERAL CONDITIONS OF THE CONTRACT FOR CONSTRUCTION WITH

ADDENDUM A & ADDENDUM B 57

DIVISION 01 - GENERAL REQUIREMENTS

SECTION

01 11 00 - SUMMARY OF WORK 1

01 21 29 - QUANTITY ALLOWANCES 1

01 21 43 - TIME ALLOWANCES 2

01 22 00 - UNIT PRICES 1

01 25 13 - SUBSTITUTIONS AND PRODUCT OPTIONS 3

01 29 00 - APPLICATIONS FOR PAYMENT 2

01 32 13 - SCHEDULING OF WORK 1

01 33 23 - SCHEDULES, REPORTS AND SUBMITTALS 2

01 41 00 - REGULATORY REQUIREMENTS 1

01 50 00 - TEMPORARY FACILITIES 1

01 70 00 - CONTRACT CLOSEOUT 2

01 78 00 - CLOSEOUT SUBMITTALS 2

DIVISION 02 - EXISTING CONDITIONS

SECTION

02 41 19 - SELECTIVE DEMOLITION 2

DIVISION 07 - THERMAL & MOISTURE PROTECTION

SECTION

07 31 13.13 - ROOFING SHINGLES 6

07 62 23 - GUTTERS AND DOWNSPOUTS 2

- END OF TABLE OF CONTENTS -

February 12, 2026 © 2026 JOHNSON + BAILEY ARCHITECTS P.C. 2523 00 01 10 - 1

SECTION 00 01 15 DRAWING INDEX

COVER SHEET WITH DRAWING INDEX

ARCHITECTURAL

A1.1 ROOF PLANS AND DETAILS

A1.2 ROOF UNDERLAYMENT PLAN AND DETAILS

- END OF SECTION -

00 01 15 - 1

February 12, 2026 @2026 JOHNSON + BAILEY ARCHITECTS P.C. 2523

00 11 13 - 1

SECTION 00 11 13 ADVERTISEMENT FOR BIDS

Reroofing of Station No. 2

Murfreesboro Fire Rescue Department

J+B No. 2523

The City of Murfreesboro is accepting bids for the Reroofing of Fire Station No. 2 until 2:00 PM local time on Thursday, April 23, 2026, at which time the Bids will be opened publicly and read aloud via Zoom.

A Zoom link will be provided to all proposers on file. Only electronic bids will be accepted. Bid documents are to be obtained online after registering with OpenGov at:

https://procurement.opengov.com/portal/murfreesborotn.com Bids received after the above time and date will be rejected.

The project consists of removal of existing asphalt shingle roofing, gutters and downspouts, and the installation of new asphalt shingle roofing system, gutters and downspouts. Refer to Specification Section 01 11 00 - SUMMARY OF WORK, for a more complete description of the work.

The issuing office is the City of Murfreesboro located at 111 West Vine Street, Murfreesboro, Tennessee 37130. Prospective Bidders shall be registered with the City of Murfreesboro through the Purchasing Department’s procurement portal, OpenGov. Bidding Documents shall be obtained from the City of Murfreesboro Purchasing Department on OpenGov’s website.

All Bidders must be registered with the City of Murfreesboro through the Purchasing Department’s procurement portal, OpenGov.

A Pre-Bid Conference will be conducted at Murfreesboro Fire Rescue Station No. 2, 2880 Runnymeade Drive, Murfreesboro, TN 37127, on Thursday, April 9, 2026, at 10:00 AM local time. Attendance at the Pre-Bid Conference is highly recommended but is not a requirement for bid submittal.

Bidders shall be licensed General Contractors by the State of Tennessee.

Each Proposal shall be accompanied by a bid security in the amount of 5% of the bid. The security is required as a guarantee that, if the bid is accepted, a bidder will enter into a contract. A copy of Bid Security must be uploaded with Bid via the OpenGov Bid Post. Physical copy of Bid Security must be in hand to the City of Murfreesboro’s Purchasing Department prior to an award being made. Bid Security should be delivered to 111 West Vine Street, Murfreesboro, TN 37130, Attn: Purchasing Dept.

A performance bond and a labor and material payment bond, each in the amount of 100% of the Contract Sum, issued by a bonding company licensed in the State of Tennessee and acceptable to Owner, will be required of successful bidder to guarantee faithful performance of Work under the Contract (see Supplement to General Conditions of the Contract). In the event the Bidder to whom the Contract is awarded fails to execute a satisfactory contract and bond, they shall be eliminated and shall forfeit their bid bond, and shall be liable for any loss occasioned to the Owner because of such failure.

BY: JOHNSON + BAILEY ARCHITECTS, P.C.

FOR: CITY OF MURFREESBORO

111 WEST VINE STREET

MURFREESBORO, TN. 37130

CATHY SMITH, PURCHASING DIRECTOR

- END OF SECTION -

https://procurement.opengov.com/portal/murfreesborotn

February 12, 2026 8 2026 JOHNSON + BAILEY ARCHITECTS P.C. 2523 00 41 13 - 1

SECTION 00 41 13 BID FORM

Reroofing at Station No. 2

Murfreesboro Fire Rescue Department

Murfreesboro Tennessee

J+B No. 2523

DATE SUBMITTED: CONTRACTOR:

TO: City of Murfreesboro

111 West Vine Street Murfreesboro, Tennessee 37130

The undersigned, as Bidder, hereby declares that the only person, or persons interested in this Proposal as principal, or principals, is or are named herein and that this Proposal is in all respects fair and in good faith without collusion or fraud.

The Bidder further declares that they have examined the site of the Work and are informed fully in regard to all conditions thereon and has examined the Drawings, Specifications, and Contractual Documents for the Work and is satisfied relative to the Work to be performed.

Time being of the essence, the Bidder proposes and agrees to commence work with an adequate force and equipment, as will be specified in a written Order of the Architect, and to complete all work by the date set forth in Section 01 32 13 - Scheduling of Work.

It is understood that the Notice to Proceed with construction will not be issued until the following documents have been delivered to the Owner through the Architect for review and execution:

- Contractor executed Standard Form of Agreement Between Owner and Contractor, AIA Document, A101, 2017 Edition.

- Performance Bond, Material and Labor Payment Bond.

- Insurance Certificate

- List of Subcontractors

- Schedule of Values

- Builders Risk Insurance (purchased for Owner by Contractor)

Whereas the Owner will suffer loss of use if the project is not complete on or before the dates stated in Section 01 32 13 - Scheduling of Work, the Contractor and their Surety shall be liable for and shall pay to the Owner the sum of Two Hundred Dollars ($200.00) as fixed and agreed liquidated damages for each calendar day of delay (in excess of the Contract Completion Date established herein) until the work is substantially complete as defined in AIA Document A201, Subparagraph 9.8.1. Architect shall issue a Certificate of Substantial Completion (AIA Document G704) to verify date work is substantially complete.

The Bidder further agrees that they will not withdraw this Proposal within a period of forty-five (45) consecutive calendar days from and including the date of this Proposal and that, if this Proposal is accepted, they will execute a Contract within said forty-five (45) day period and within five (5) consecutive calendar days after date of written notice of such acceptance. In case of failure on the Bidder's part to perform as agreed above, the monies payable on the Bid Bond accompanying this Proposal shall be paid into the funds of the Owner as liquidated damages for such failure; otherwise, the Bid Bond shall be returned to the Bidder.

The Bidder further proposes and agrees to contract with the Owner on the AIA Standard Form of Agreement between Owner and Contractor for a Lump Sum to furnish for the following sum all necessary materials, equipment, tools, apparatus, means of transportation and labor necessary to complete the construction of the Project in complete accordance with the shown, noted, described, and reasonable intended requirements of Drawings, Specifications, and Contract Documents with the definite understanding that no money will be allowed for extra work except as set forth in the Contractual Documents.

00 41 13 - 2

The Bidder further agrees that they and each subcontractor employing no less than five (5) employees will execute and submit to the Owner the attached DRUG FREE WORKPLACE AFFIDAVIT. No Contractor or Subcontractor may perform work on this project unless this form is fully executed and submitted prior to the start of the project. The General Contractor shall submit a fully executed, notarized copy of this form with this bid.

By submission of this bid, each bidder and each person signing on behalf of any bidder certifies, and in the case of a joint bid each party thereto certifies as to its own organization, under penalty of perjury, that to the best of its knowledge and belief that each bidder is not on the list created pursuant to T.C.A. '12-12-106 (The Iran Divestment Act - 2016).

By submission of this bid, each bidder and each person signing on behalf of any bidder certifies, and in the case of a joint bid each party thereto certifies as to its own organization, under penalty of perjury, that to the best of its knowledge and belief that each supplier is not boycotting Israel pursuant to T.C.A.

§ 12-4-119, and will not boycott Israel during the term of contract.

BID DOLLARS

UNIT PRICE PROPOSALS

The following unit price Proposals shall be utilized to compute additional compensation due the Contractor for additional work. Refer to Section 01 22 00 - UNIT PRICES, for definitions. Refer to Section 01 21 29, QUANTITY ALLOWANCES, for quantities to be included in base bid.

1. DOLLARS PER SQUARE FOOT ($ ).

For replacement of damaged existing ½” APA rated roof sheathing.

The undersigned states that he has received and taken into consideration.

Addenda No. Dated

EXECUTION OF AGREEMENT:

The undersigned agrees that if written notice of acceptance of this proposal is mailed, telegraphed, or delivered to them within forty-five (45) days after opening of proposals, they will promptly execute an

Agreement with the Owner in accordance with the Bid Documents.

COMPANY: DATE:

BY: TITLE:

00 41 13 - 3

FORM FOR CERTIFICATE OF COMPLIANCE

WITH

TENNESSEE LICENSING LAW

This is to certify that the undersigned has fully complied with all requirements of Chapter 135, Public Acts of 1945, and Chapter 164, Public Acts of 1947, of the General Assembly of the State of Tennessee, known as the General Contractors Licensing Law. Certificate No.

was issued to the undersigned on , 20 , by the State Board of

Licensing General Contractors.

My license limit is and my bid does not exceed this. My license classification and limit are as follows:

____________________________________________Classification

Limit

BIDDER

BY

TITLE

00 41 13 - 4

DRUG-FREE WORKPLACE PROGRAM CERTIFICATION

STATE OF

COUNTY OF

CONTRACTOR’S AFFIDAVIT ON COMPLIANCE

WITH DRUG-FREE WORKPLACE ACT AND CERTIFICATE

Bidder, after being first duly sworn, affirms that it has a Drug-Free Workplace Program that complies with

Tennessee Code Annotated, Title 50, Chapter 9, in effect at the time of submission of its bid, at least to the extent required of governmental entities. Bidder affirms that:

1. it has received a Certificate of Compliance with the applicable proportions of the Drug-Free Workplace

Act from the Department of Labor and Workforce Development and has attached a copy of such certificate to this Affidavit; or,

2. it operates a drug and alcohol testing program at least as stringent as the City of Murfreesboro’s drug and alcohol testing program as contained in Sections 3005 and 3006 of the City of Murfreesboro

Employee Handbook and shall, upon request, provide documentation of such program to the City.

Name of Bidder

Printed Name and Title of Principal Officer

Signature by Principal Officer

Sworn to and subscribed before me a Notary Public for the above state and county, on this ________ day of _____________________, 20___.

Notary Public

My Commission Expires ____________________

00 41 13 - 5

Pursuant to T.C.A. § 50-9-113, a Bidder must have a Drug-Free Workplace Program that complies with

Tennessee Code Annotated, Title 50, Chapter 9 in effect at the time of submission of its bid, at least to the extent required of governmental entities.

The City of Murfreesboro has a Drug-Free Workplace Program certified by the Tennessee Department of

Labor and Workforce Development pursuant to Title 50, Chapter 9. The City of Murfreesboro Drug-Free

Workplace Program is set forth in City of Murfreesboro Employee Handbook Sections 3005 and 3006 (copies available without charge upon request). City of Murfreesboro Employee Handbook Sections 3005 and

3006 provide for the random testing, reasonable suspicion testing, pre-employment testing, promotion or transfer testing, post-accidental testing, return-to-duty testing, and follow-up testing of all employees classified as safety sensitive or as CDL employees for alcohol and/or drugs. Additionally, Murfreesboro

Employee Handbook Section 3005 provides for reasonable suspicion testing, return-to-duty testing, and follow-up testing for non-safety sensitive employees for drugs and alcohol. Such testing is conducted using the same standards as in the United State Department of Transportation Regulations established for the drug and alcohol testing of CDL operators.

A bidder for construction services is required to submit an Affidavit, as part of its bid, that attests that such bidder operates a Drug-Free Workplace Program or other drug or alcohol testing program with requirements at least as stringent as that of the program operated by the City of Murfreesboro.

Bidder may satisfy this requirement by attaching a copy of a Certificate of Compliance with the applicable provisions of the Drug-Free Workplace Act from the Department of Labor and Workforce Development to the City to the required Affidavit.

Pursuant to T.C.A. § 50-9-114(d), unless suit is filed in Chancery Court, bidders shall have seven (7) calendar days to contest a contract entered into by contractors subject to the provisions of this section.

Bidders who do not contest such contracts within seven (7) days by filing suit in Chancery Court waive any right to challenge such contract for violating the provisions of T.C.A. § 50-9-113 and T.C.A.. § 50-9-114.

Such suits shall be brought in the Chancery Court in Rutherford County.

00 41 13 - 6

Iran Divestment Act

By submission of this bid, each bidder and each person signing on behalf of any bidder certifies, and in the case of a joint bid each party thereto certifies as to its own organization, under penalty of perjury, that to the best of its knowledge and belief that each bidder is not a person included within the list created pursuant to T.C.A. § 12-12-106.

Signature Date

Title

Non-Boycott of Israel

By submission of this bid, each bidder and each person signing on behalf of any bidder certifies, and in the case of a joint bid each party thereto certifies as to its own organization, under penalty of perjury, that to the best of its knowledge and belief that each supplier is not boycotting Israel pursuant T.C.A. § 12-4-119, and will not boycott Israel during the term of contract. This applies to contracts of $250,000 or more and to contractors with ten (10) or more employees.

Signature Date

Title

Rev. 101316

EXHIBIT A

CONTRACTOR'S INSURANCE AND BOND REQUIREMENTS

Contractor must, as a material obligation to the Owner and a condition precedent to any payment otherwise due to Contractor, furnish and maintain, and cause its Subcontractors to furnish and maintain, the insurance and bonds required by this Exhibit.

Contractor must secure and maintain such insurance coverage and bonds, without interruption, from the date of commencement of the Work until the later of the date of Final Completion, the date of final payment, or the date until which this Agreement requires any coverage to be maintained after final payment, in accordance with the requirements set forth below.

1. Commercial General Liability Insurance.

1.1 The CGL policy must be written on an occurrence basis, on ISO form CG 001 or its equivalent, providing coverage for bodily injury, broad form property damage, personal injury (including coverage for contractual and employee acts), contractual liability, incidental professional liability, the hazards commonly referred to as XCU (explosion, collapse, and underground), and products and completed operations, with a combined single limit of liability of not less than $2,000,000 for each occurrence applicable to the Work, and an annual aggregate limit of liability of not less than $2,000,000 applicable solely to the Work, and meeting all other requirements of this Exhibit.

1.2 The general liability insurance may be accomplished with a combination of a general liability and an excess/umbrella liability policy.

1.3 Each general liability policy must be endorsed or written to:

a. Include the per project aggregate endorsement;

b. Name as additional insureds the following: the City of Murfreesboro and its elected officials, officers, employees, representatives and agents (collectively, the “Additional Insureds”);

c. Stipulate that the insurance afforded by the policies furnished by Contractor will be primary insurance and that any insurance, self-insured retention, deductibles, or risk retention programs maintained or participated in by the Additional Insureds, or their agents, officials or employees will be excess and not contributory to the liability insurance furnished by Contractor and by its Subcontractors;

d. Includes a severability of interest clause; and

e. Waive all rights of recovery against the Additional Insureds.

2. Workers' Compensation Insurance. Workers’ Compensation policy must meet all Tennessee statutory requirements, including Employers' Liability Insurance with limits of at least $ 1,000,000 per accident or disease per employee, both policies endorsed to waive subrogation against the Additional Insureds.

3. Auto Liability Insurance

3.1 Commercial auto liability must be carried with minimum combined single limit of $1,000,000 per occurrence.

3.2 This policy must include a duty to defend and cover all owned, non-owned, leased, hired, assigned or borrowed vehicles.

3.3 This policy must be endorsed, by specific or blanket endorsement, to name the Additional Insureds as such, stipulate that any insurance carried by the Additional Insureds must be excess and not contributory, and to waive subrogation against the Additional Insureds.

4. Environmental Liability. Contractor must secure, pay for, and maintain Contractor’s Pollution Liability (CPL) coverage, including mold coverage, in an amount not less than $1,000,000 and endorsing the Owner as an Additional Insured. Contractor must also provide to the Owner proof of Contractor’s Pollution Legal Liability (PLL) for sites owned or operated by Contractors and by any Subcontractors handling hazardous or potentially hazardous materials. Environmental liability coverage may be part of a package policy.

5. Professional Liability. Contractor must secure, pay for, and maintain professional liability coverage in the amount of not less than $1,000,000 on a form acceptable to the Owner and with tail coverage of not less than two years.

6. Umbrella Coverage. Contractor must secure, pay for, and maintain professional liability coverage in the amount of not less than $5,000,000 on a form acceptable to the Owner. Umbrella coverage must not be limited to excess coverage that merely follows form of underlying coverages.

7. Equipment Property Insurance. Contractor must secure, pay for, and maintain all-risk insurance as necessary and without exceptions in order to protect the Owner against loss of owned, non-owned, rented, or leased capital equipment and tools, equipment and scaffolding, staging, towers and forms owned or rented by Contractor, its Subcontractors, or Lower Tier Entities and any construction material in transit (unless shipped FOB destination Project Site or (Incoterm) DAP Project site) or materials stored in any location other than the Site.

8. Builder’s Risk. Unless otherwise instructed by the Owner, Contractor will secure a completed value, all-risk Builder’s Risk policy in manuscript form acceptable to Owner for the Project (not merely the Work), including appropriate, as determinate by the Owner, coverages, coverage amounts and limits, deductibles, and exclusions. The Owner must be a named insured and the policy may not terminate until Substantial Final Completion or a certificate of occupancy applicable to the entire property is issued, whichever is latest.

9. Waiver of Subrogation. Contractor hereby waives, and will require each of its Subcontractors and Lower Tier Entities to waive, all rights of subrogation under all polices against the Owner and other Additional Insureds for losses or damages covered by any policy of insurance. Contractor, Subcontractors, and Lower Tier Entities must provide notice of waiver to all insurance carriers.

10. Term of Coverage

10.1 The products and completed operations liability coverage required by this Agreement must extend for a period of not less than five years after the earlier of Final Payment for the Work, or the termination of the Agreement (the “Completed Operations Term”).

10.2 If at any time during the Completed Operations Term Contractor cannot obtain equivalent coverage by replacement or renewal, Contractor must acquire a tail policy prior to expiration of the existing policy that will extend coverage until the end of the Completed Operations Term.

10.3 Contractor will furnish certificates of insurance and other evidence that the Owner may reasonably require during the Completed Operations Term to establish compliance with the requirements of this paragraph.

10.4 All other policies of insurance must be maintained continuously in force from commencement of the Work until the date of Final Payment.

11. Subcontractor and Lower-Tier Entities Insurance Requirements

11.1 Contractor must require all of Contractor's Subcontractors and must require its Subcontractors to require their Lower Tier Entities, as a condition of working on the Project, and of receiving payment, to:

a. Purchase and maintain Commercial General Liability, Workers' Compensation and Employer's Liability, and Automotive insurance policies, with the same coverages, endorsements, terms of coverage and other provisions as are required of Contractor under by this Exhibit, EXCEPT THAT the combined coverage limits of the general liability insurance to be furnished by Lower Tier Entities must be $ 1,000,000 per occurrence, and $ 1,000,000 as the annual aggregate limit; and

b. Timely furnish to the Owner proper certificates, endorsements, copies of declarations pages, and other documents necessary to establish the Subcontractor's compliance with this Exhibit.

c. The Lower Tier Entities’ general liability policy must also be endorsed to provide the policy must be primary insurance, the general liability insurance furnished by Contractor must be the secondary and non-contributory, and any insurance carried by the Additional Insureds must be excess, tertiary and non-contributory to the insurance furnished by Contractor and Subcontractor.

d. The Owner has the right to inspect and copy all such certificates, endorsements, or other proof at any reasonable time.

12. Other Policy Provisions. Each policy to be furnished by Contractor and each Subcontractor must:

12.1 Be issued by an insurance carrier having a rating from A.M. Best Company of at least A- VII or better;

12.2 Provide that attorney’s fees are outside of the policy's limits and be unlimited;

12.3 Include the Project per aggregate endorsement;

12.4 Waive all rights of subrogation against the Owner;

12.5 Provide a Certificate that contains a provision that coverages afforded under the policies will not be canceled, allowed to expire, or reduced in amount until at least thirty (30) days' prior written Notice has been given to the Owner; and

12.6 Be otherwise satisfactory to the Owner. The Owner agrees to consider alternatives to the requirements imposed by this Exhibit but only to the extent that the Owner is satisfied the insurance is not commercially available to the insured. In such event, the Owner has the right to set conditions for such waiver, including, but not limited to, additional indemnities, and the request that the Owner be a loss-payee under the policy.

13. Certificates and Endorsements

13.1 Within 10 days after the execution of this Agreement, Contractor must provide the Owner with certificates and endorsements;

13.2 Upon the Owner request, Contractor must provide the Owner with certificates and endorsements from each of its Subcontractors, in all cases evidencing compliance by Contractor, each Subcontractor, and Lower Tier Entities with the requirements of this Exhibit together with letters from the respective carriers (including, but not limited to, the Errors and Omissions insurance carriers) that there are no known or pending claims or incidents which have resulted in the establishment of a reserve or otherwise have reduced the amount of coverage potentially available to the Owner under the policy and that available coverage has not been reduced because of revised limits or payments made (or, in the event such representations cannot be given, Contractor, its Subcontractors, and its Lower Tier Entities must furnish the particulars thereof to the Owner.

13.3 If any of the foregoing insurance coverages are required to remain in force after Final Completion, Contractor must submit an additional certificate evidencing continuation of such coverage with its application for final payment.

14. Reduction in Coverage. Contractor must promptly inform the Owner of any reduction of coverage resulting from revised limits, claims paid, or both and must require its Subcontractors and Lower Tier Entities to promptly inform Contractor of same. The Owner has the right to require Contractor or the applicable Subcontractor to obtain supplemental or replacement coverage to offset such reduced coverage, at the sole cost or expense of Contractor or the applicable Subcontractor.

15. Suppliers and Materialmen Coverages

15.1 Contractor will endeavor to cause all suppliers and materialmen to deliver any equipment, machinery or other goods FOB Site.

15.2 With respect to any equipment, machinery or other goods for which the Owner or Contractor has paid a deposit, Contractor will cause the respective suppliers and materialmen to maintain personal property insurance in an amount equal to the value of such equipment, machinery or other goods (but in no event less than the amount of the applicable deposit) during fabrication, storage and transit, naming the Owner and Contractor as loss payee as their interests appear.

16. Condition Precedent to Starting Work

16.1 Prior to, and as a condition of its right to begin performing any Work on the Site, Contractor and each Subcontractor and Lower Tier Entities must deliver to the Owner certificates of insurance representing that the required insurance is in force, together with the additional insured endorsements and waivers of subrogation required above, and such other proof satisfactory to the Owner that the required insurance is in place; together with the original of each bond required under this Agreement. Contractor and each Subcontractor and Lower Tier Entities hereby authorize the Owner to communicate directly with the respective insurance agents, brokers and/or carriers and sureties to verify their insurance and bond coverage;

16.2 The Owner is under no obligation or duty to make any such inquiry and the Owner is entitled to rely on any proofs of insurance tendered by Contractor or its Subcontractors and Lower Tier Entities. The Owner's acceptance of any proof of insurance and bonds offered by Contractor or any Subcontractor or Lower Tier Entities will not be deemed a waiver of the obligations of Contractor and Subcontractors and Lower Tier Entities to furnish the insurance and bonds required by this Exhibit.

17. Additional Proofs of Insurance. Contractor must, within 10 days after request, provide the Owner with certified copies of all policies and endorsements obtained in compliance with this Agreement.

18. Indemnity. The fact that Contractor and its Subcontractors are required by this Agreement to purchase and maintain insurance in no way limits or restricts any other obligations or duties Contractor and its Subcontractors and Lower Tier Entities may have to indemnify, defend or hold harmless the Owner and the other Additional Insureds from and against any and all demands, liabilities, losses or expenses of whatever kind or nature.

19. Interpretation. In the event of any inconsistency between the provisions of this Exhibit and those of the other provisions of the Agreement, the terms of this Exhibit will govern.

20. Performance Bond and Payment Bond.

20.1 The Contractor shall provide surety bonds as follows:

Type Penal Sum ($0.00) Performance Bond 100% of Contract Sum Labor and Material Payment Bond 100% of Contract Sum

20.2 Bonds shall be issued by a surety licensed in the State of Tennessee and satisfactory to the Owner.

20.3 The Contractor must provide evidence of Bonds prior to the beginning of work. If the Performance and Payment Bonds are not furnished within ten (10) days of execution of the Agreement, the Owner, in its sole discretion, may elect to terminate the Agreement and award the Project to an alternate contractor.

20.4 The Owner will require the Contractor to increase the Performance and Payment Bonds to accommodate Change Orders that individually or cumulatively exceed 10% of the original Contract Sum. The Contractor shall furnish to the Owner and keep in force during the term of the Contract, performance and labor and material payment bonds guaranteeing that the Contractor will perform its obligations under the Contract and will pay for all labor and materials furnished for the Work.

20.5 Upon the request of any person or entity appearing to be a potential beneficiary of bonds covering payment of obligations arising under the Agreement, the Contractor shall promptly furnish a copy of the bonds or shall permit a copy to be made.

Rev. 01/09/2020

ADDENDUM A

Contractor’s Standard Form Subcontract

[Cover page – See attached]

ADDENDUM B

DISPUTE RESOLUTION PROCEDURES

1. Disputes

1.1 Each Dispute arising out of or related to this Agreement (including Disputes regarding any alleged breaches of this Agreement) must be initiated and decided under the provisions of this Exhibit.

1.2 Contractor and the Owner will each designate in writing to the other Party, from time to time, a member of senior management who is authorized to attempt to expeditiously resolve any Dispute relating to the subject matter of this Agreement in an equitable manner.

1.3 A Party initiates a Dispute by delivery of written Notice to the members of management designated by the respective parties under Section 1.2 hereof.

1.4 The parties must:

a. Attempt to resolve all Disputes promptly, equitably and in a good faith manner, and

b. Provide each other with reasonable access during normal business hours to any and all non-privileged records, information and data pertaining to any such Dispute.

1.5 With respect to matters concerning Change Orders for modification of the Guaranteed Maximum Price or Project Schedule, Contractor must first follow the provisions of any Claim procedure established by the Contractor Agreement before seeking relief under these Procedures.

2. Emergency Arbitration

2.1 If the parties are unable to accomplish resolution of a Dispute, the expedited resolution of which either Party considers necessary to prevent or mitigate a material delay to the critical path of the Construction Services (a “Time Sensitive Dispute”) within two days after the Time Sensitive Dispute has been initiated by a Party, either Party may thereafter seek emergency relief before an emergency arbitrator (the “Emergency Arbitrator”) appointed as follows:

a. The parties will exercise best efforts to pre-select an Emergency Arbitrator within 20 days after entering into this Agreement;

b. If the Emergency Arbitrator has not been selected at the time a Party delivers Notice of a Time Sensitive Dispute, the parties will each select a representative within one day after the Notice is delivered and the two representatives will then select the Emergency Arbitrator by the third day following delivery of the Notice.

c. The Emergency Arbitrator must be an attorney with at least 10 years’ experience with commercial construction legal matters in Tennessee, be independent, impartial, and not have engaged in any business for or adverse to either Party for at least 10 years.

2.2 The Emergency Arbitrator will conduct a hearing and render a written determination on the Dispute to both parties within five business days of the matter being referred to him or her, all in accordance with Rules O-1 to O-8 of the American Arbitration Association (“AAA”) Commercial Rules-Optional Rules for Emergency Protection Commercial Rules (“AAA Emergency Rules”)

2.3 Although the hearing will be conducted using AAA rules, unless both parties agree otherwise, this dispute process will not be administered by the AAA but will be conducted by the parties in accordance with these procedures.

2.4 If, however, an Emergency Arbitrator has not selected within three days after delivery of the Notice, either Party may upon three days’ additional notice, thereafter seek emergency relief before the AAA, in accordance with the AAA Emergency Rules, provided that the Emergency Arbitrator meets the qualifications set forth above.

2.5 All proceedings to arbitrate Time Sensitive Disputes will be conducted in Rutherford, Davidson, or Williamson counties, Tennessee.

2.6 Presentation, request for determination (i.e., a Party’s prayer), and the Emergency Arbitrators decision will adhere to the procedures required in Section 3.5 hereof.

2.7 The finding of the Emergency Arbitrator with respect to any Time Sensitive Dispute will be binding upon the parties on an interim basis during progress of the Construction Services, subject to review de novo by arbitration after the Project Substantial Completion Date.

2.8 The time and extent of discovery will be as determined by the Emergency Arbitrator.

a. Discovery orders of the Emergency Arbitrator will consider the time sensitivity of the matter and the parties desire to resolve the issue in the most time and costs efficient manner;

b. The parties are obligated to cooperate fully and completely in the provision of documents and other information, including joint interviews of individuals with knowledge such that the matter moves toward resolution in the most time and costs efficient manner and the Emergency Arbitrator is empowered to fashion any equitable penalty against a Party that fail to meet this obligation

3. Non-Emergency Arbitration

3.1 Except as provided in Section 5 hereof, any Dispute that is either a non-emergency Dispute that has not been resolved by negotiation, or a de novo review of an emergency arbitration will be decided by binding arbitration by a panel of three arbitrators in accordance with, but not necessarily administered by, the Construction Industry Rules of the AAA.

a. The parties each select an arbitrator within 15 days after Notice that a Party desire to resolve a dispute by arbitration.

b. The two arbitrators then each select a third arbitrator.

c. The arbitrator(s) must meet the qualifications of Emergency Arbitrators as provided in Section 2 hereof.

3.2 The arbitrators do not have the authority to consider or award punitive damages as part of the arbitrators' award.

3.3 In connection with such arbitration, each Party is entitled to conduct up to five depositions, and, no less than 90 days prior to the date of the arbitration hearing, each Party will deliver to the other Party copies of all documents in the delivering Party's possession that are relevant to the dispute.

3.4 The arbitration hearing must be held within 150 days of the appointment of the arbitrators.

3.5 At the arbitration hearing, each Party will argue its position to the arbitrators in support of one proposed resolution to the dispute (a “Proposed Resolution”).

a. Each Party’s Proposed Resolution must be fully dispositive of the dispute.

b. The arbitrators must select one of Proposed Resolution by majority consent and are not free to fashion any alternative resolutions.

c. The parties must submit their Proposed Resolution of the matter to the arbitrators and the other Party 15 days prior to the date set for commencement of the arbitration proceeding.

d. The decision of the arbitrators will be forwarded to the parties within 15 days after the conclusion of the arbitration hearing.

e. The decision of the arbitration panel is final and binding on the parties and may be entered in any court of competent jurisdiction for the purpose of securing an enforceable judgment.

f. All costs and expenses associated with the arbitration, including the reasonable legal fees and costs incurred by the prevailing Party, must be paid by the Party whose position was not selected by the arbitrators.

4. Continuing Work. Unless otherwise agreed to in writing, Contractor must continue to perform and maintain progress of the Work during any Dispute resolution or arbitration proceedings, and the Owner will continue to make payment to Contractor in accordance with the Contractor Agreement.

5. Exceptions

5.1 Neither the Owner nor Contractor are not be required to arbitrate any third-party claim, cross-claim, counter claim, or other claim or defenses in any action that is commenced by a third-party who is not obligated by contract to arbitrate disputes with the Owner and Contractor.

5.2 The Owner or Contractor may commence and prosecute a civil action to contest a lien or stop notice, or enforce any lien or stop notice (but only to the extent the lien or stop notice the Party seeks to enforce is enforceable under Tennessee law), without the necessity of initiating or exhausting the procedures of this Exhibit.

5.3 This Exhibit does not apply to, and may not be construed to require arbitration of, any claims, actions or other process undertaken, filed, or issued by the City of Murfreesboro Building Safety Department, Code Compliance Department, Police Department, Fire Department, or any other agency of the Owner (the City) acting in its governmental permitting, for the benefit of public health, safety, and welfare, or other regulatory capacity.

5.4 In connection with any arbitration, the arbitrators do not have the authority to, and may not enforce, any provision of the Federal or Tennessee Rules of Civil Procedure.

SECTION 01 11 00 SUMMARY OF WORK

1.1 SCOPE OF WORK

A. Roof Replacement work under this Contract includes, but is not limited to, the following:

1. Demolition:

a. Removal of existing asphalt shingle roofing and underlayment.

b. Removal of existing plumbing vent pipe seals/flashing.

c. Removal of existing roofing and re-roofing operations shall be performed in a manner which will maintain the use and integrity of the building, without water infiltration, and prevent rainfall or moisture onto the existing plywood roof deck prior to installation of the new roofing system. The Contractor will be responsible for restoration of any damage, including damage to interior finishes, caused by failure to take proper precautions.

d. Removal of existing gutters and downspouts.

2. New Construction:

a. Repair of damaged roof sheathing.

b. Installation of new leak barrier, roof underlayment, and flashings.

c. Installation of new asphalt shingle roofing.

d. Installation of new plumbing pipe seals at existing plumbing vent roof penetrations.

h. Installation of new gutters and downspouts

B. .At the conclusion of work, any existing construction damaged during the course of renovation operations, including landscaping, lawn, sidewalks, curbs, pavement and the existing building components shall be restored to preconstruction conditions.

- END OF SECTION -

01 11 00 - 1

01 21 29 QUANTITY ALLOWANCES

PART 1 - GENERAL

1.1 Article 3.8, ALLOWANCES, of AIA Document A201, GENERAL CONDITIONS OF THE CONTRACT FOR CONSTRUCTION, bound herein, is applicable to these allowances except as modified below:

1.2 Allowance amounts shall be for actual quantity of materials required. Invoices shall be submitted to confirm quantities purchased.

A. Make a quantity allowance of 300 square feet for removal and replacement of existing ½" APA rated plywood roof sheathing.

1.3 Any quantity allowances not used for items noted above shall be returned to the Owner as a credit based upon the cost listed in the Unit Prices section in the Proposal multiplied by the unused quantity.

- END OF SECTION -

01 21 29 - 1

SECTION 01 21 43 TIME ALLOWANCES

1.1 EXTENSIONS OF CONTRACT TIME

A. If the basis exists for an extension of time in accordance with paragraph 8.3 of the General Conditions, an extension of time on the basis of weather may be granted only for the number of Weather Delay Days in excess of the number of days listed as the Standard Baseline for that month.

1.2 STANDARD BASELINE FOR AVERAGE CLIMATIC RANGE

A. The Owner has reviewed weather data available from the National Oceanic and Atmospheric Administration and determined a Standard Baseline of average climatic range for the State of Tennessee.

B. Standard Baseline shall be regarded as the normal and anticipatable number of calendar days for each month during which construction activity shall be expected to be prevented and suspended by cause of adverse weather. Suspension of construction activity for the number of days each month as listed in the Standard Baseline is included in the Work and is not eligible for extension of Contract Time.

C. Standard Baseline is as follows:

Jan Feb Mar Apr May Jun Jul Aug Sep Oct Nov Dec 12 11 8 7 7 6 7 5 4 5 6 11

1.3 ADVERSE WEATHER AND WEATHER DELAYS

A. Adverse Weather is defined as the occurrence of one or more of the following conditions which prevents exterior construction activity or access to the site within twenty-four (24) hours:

1. Precipitation (rain, snow, or ice) in excess of one-tenth inch (0.10") liquid measure.

2. Temperatures which do not rise above 32 degrees F by 10:00 a.m.

3. Temperatures which do not rise above that specified for the day’s construction activity by 10:00 a.m., if any is specified

4. Sustained wind in excess of twenty-five (25) m.p.h.

5. Standing snow in excess of one inch (1.00").

B. Adverse Weather may include, if appropriate, “dry-out” or “mud” days:

1. For rain days above the standard baseline;

2. Only if there is a hindrance to site access or sitework, such as excavation, backfill, and footings; and,

3. At a rate no greater than 1 make-up day for each day or consecutive days of rain beyond the standard baseline that total 0.10 inch or more, liquid measure, unless specifically recommended otherwise by the Designer.

C. A Weather Delay may be counted if adverse weather prevents work on the project for fifty percent (50%) or more of the Contractor’s scheduled work day, including a weekend day or holiday, if Contractor has scheduled construction activity that day.

01 21 43 - 1

1.4 DOCUMENTATION AND SUBMITTALS

A. Submit daily jobsite work logs showing which and to what extent construction activities have been affected by weather on a monthly basis.

B. Submit actual weather data to support claim for time extension obtained from nearest NOAA weather station or other independently verified source approved by Architect at beginning of project.

C. Use Standard Baseline data provided in this Section when documenting actual delays due to weather in excess of the average climatic range.

D. Organize claim and documentation to facilitate evaluation on a basis of calendar month periods, and submit in accordance with the procedures for Claims established in Article 4.3 of the General Conditions.

E. If an extension of the Contract Time is appropriate, it shall be documented by Change Order in accordance with the provisions of Article 7 of the General Conditions, and the applicable General Requirements.

- END OF SECTION -

01 21 43 - 2

SECTION 01 22 00 UNIT PRICES

PART I - GENERAL

1.1 MEASUREMENT OF QUANTITIES

A. Measurement by volume: Measured by cubic dimension using mean length, width and height or thickness.

B. Measurement by area: Measure by square dimension using mean length and width or radius.

C. Linear measurement: Measured by linear dimension, at the centerline or mean chord.

1.2 PAYMENT

A. Payment includes full compensation for:

1. Products and materials, required labor, tools, equipment, plant, transportation, services and incidentals.

2. Erection, application or installation of an item of the Work.

3. Overhead and profit.

4. All other direct and indirect costs.

B. Unless specified otherwise, final payment for work items governed by unit prices will be made on the basis of the actual measurements and quantities accepted by the Architect multiplied by the unit price for the work item which is incorporated in the Owner-Contractor Agreement.

PART 2 - PRODUCTS

OMITTED

PART 3 - EXECUTION

OMITTED

- END OF SECTION -

01 22 00 - 1

SECTION 01 25 13 SUBSTITUTIONS & PRODUCT OPTIONS

1. When several materials are specified by name for one use, Contractor may select any of those so specified. However, installation requirements may differ from material to material or product to product. The Contractor is responsible for coordination of all installation differences required by a listed Equal product.

2. Wherever an item or class of material is specified exclusively by trade name, name of maker, or by catalog reference, use such item only unless Architect's approval for a substitution is documented in an Addendum issued before bid opening time.

3. Wherever words "Approved by", "Satisfactory to", "submitted to", or similar phrases are used in this Specification, they shall be understood to mean that the material or item referred to shall be approved by, be satisfactory to, or submitted to the Architect.

4. The term "or equal" means "an equal approved by the Architect" wherever the term is used in conjunction with a product or trade name, (i.e. X manufacturer, X brand "or equal") the Architect shall be the sole judge of the products acceptability for use in the project. If the Contractor or Sub- Contractor desires to bid an item as "equal" to that specified, he shall obtain the Architect's approval for the substitution and documented in an Addendum issued before bid opening time. The Architect will confirm approval of the product being equal to the manufacturer(s) specified by issuance of an Addendum to all prospective bidders of record.

01 25 13 - 1

SUBSTITUTION REQUEST FORM

(Per AIA Instructions to Bidders, Article 3.3.2, no substitution request will be considered unless written request for approval is received by the Architect at least ten (10) days prior to the date for receipt of bids)

TO: Johnson+Bailey Architects, P.C. PROJECT: Reroofing of 100 East Vine St., Suite 700 Station No. 2 Murfreesboro, TN 37130 Murfreesboro Fire &

Resources Department ATTN: Keaton Pettit J+B No. 2523

E-mail: kpettit@jbarchitects.com Fax: (615) 890-4564

SPECIFIED ITEM: ______________________ PROPOSED SUBSTITUTE: _________________________

1. The following are attached (Mark all that apply):

[ ] Complete Description [ ] Catalog [ ] Laboratory Tests [ ] Spec Data

2. This substitution will have the following effects on dimensions, gauges, weights, etc.:

3. This substitution will have the following effects on wiring, piping, ductwork, etc.:

4. This substitution will have the following effects on other trades:

5. This substitution will have the following effect on construction schedules:

6. The proposed substitute(s) differs from the specified product(s) in quality and performance as follows:

7. Manufacturers guarantees for the substitute(s) and the specified product(s) are (check one):

[ ] The Same [ ] Different (If Different, Explain Below)

8. Information on the availability of maintenance services and replacement materials for proposed substitute(s) is provided on an attached sheet if applicable. This attachment is:

[ ] attached [ ] not applicable

9. Names, addresses, and phone numbers of fabricators and suppliers for proposed substitute(s) are provided on an attached sheet if applicable. This attachment is:

[ ] attached [ ] not applicable

February 12, 2026 © 2026 JOHNSON + BAILEY ARCHITECTS P.C. 2523 01 25 13 - 2 mailto:kpettit@jbarchitects.com

10. If the proposed substitution is accepted, it will result in:

[ ] no cost impact [ ] a cost increase of ______________________________________________ [ ] a cost decrease of _____________________________________________

(If change in cost is indicated, itemization is attached)

11. License fees or royalties are pending on the proposed substitute.

[ ] No [ ] Yes (If yes, explain below)

12. The undersigned or the firm represented shall pay for additional studies, investigations, submittals, redesign, and analysis by the Architect necessitated by this substitution request.

Substitutions must be requested in accordance with applicable Contract requirements.

SUBMITTED BY: DATE:

Sign Here:

NAME: TELEPHONE:

Type or Print: FAX:

For:

Name of Firm:

ADDRESS:

Street Address:

and mailing address if different:

City, State, and Zip Code:

ARCHITECT’S REVIEW COMMENTS:

[ ] Accepted [ ] Rejected [ ] Accepted as Noted [ ] Rejected (Received too late)

[ ] Rejected (Submittal Incomplete)

Additional Comments:

For the Architect: Date:

Signature Here:

- END OF SECTION -

01 25 13 - 3

SECTION 01 29 00 APPLICATIONS FOR PAYMENT

1.1 RELATED REQUIREMENTS

A. AIA Document A201 - GENERAL CONDITIONS

B. Section 00 72 13 - GENERAL CONDITIONS OF THE CONTRACT FOR CONSTRUCTION.

General requirements for the following:

1. Contract Sum and Unit Prices

2. Amounts of Progress Payments

3. Times for Submittals

C. Section 01 70 00 - CONTRACT CLOSEOUT

1.2 FORMAT

A. Application Form: AIA Document G702 - Application and Certificate for Payment

B. Continuation Sheets: AIA Document G703 - Continuation Sheet

1.3 PREPARATION OF APPLICATIONS

A. Present…