Solicitation - N6264926RL015.pdf

SECTION

15A. NAME AND

ADDRESS

OF OFFEROR

SOLICITATION, OFFER, AND AWARD 1. This Contract is a Rated Order under the Defense Priorities and Allocations System (DPAS) - Code of Federal Regulations - at 15 CFR 700.

RATING PAGE OF PAGES

2. CONTRACT NUMBER 3. SOLICITATION NUMBER 4. TYPE OF SOLICITATION 5. DATE ISSUED 6. REQUISITION/PURCHASE NUMBER

CODE7. ISSUED BY 8. ADDRESS OFFER TO (If other than item 7)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

9. Sealed offers in original and copies for furnishings the supplies or services in the Schedule will be received at the place specified in item 8, or if hand carried, in the depository located in until local time

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision Number 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR

INFORMATION

CALL:

A. NAME B. TELEPHONE (NO COLLECT CALLS)

AREA CODE NUMBER EXTENSION

C. EMAIL ADDRESS

11. TABLE OF CONTENTS

(X) DESCRIPTION PAGE(S) (X) SECTION PAGE(S)DESCRIPTION

A B C D E F G H

I

J

K

L

M EVALUATION FACTORS FOR AWARD

INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

REPRESENTATIONS, CERTIFICATIONS AND OTHER

STATEMENTS OF OFFERORS

PART IV - REPRESENTATIONS AND INSTRUCTIONS

LIST OF ATTACHMENTS

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

CONTRACT CLAUSESSOLICITATION/CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/COSTS

DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

PACKAGING AND MARKING

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

CONTRACT ADMINISTRATION DATA

SPECIAL CONTRACT REQUIREMENTS

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

OFFER (Must be fully completed by offeror)

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause Number 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the SOLICITATION for offerors and related documents numbered and dated):

10 CALENDAR DAYS (%) 20 CALENDAR DAYS (%) 30 CALENDAR DAYS (%) CALENDAR DAYS (%)

DATEAMENDMENT NUMBERAMENDMENT NUMBER DATE

CODE FACILITY 16. NAME AND THE TITLE OF PERSON AUTHORIZED TO SIGN OFFER

(Type or print)

15B. TELEPHONE NUMBER

AREA CODE NUMBER EXTENSION

15C. CHECK IF REMITTANCE ADDRESS IS

DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

17. SIGNATURE 18. OFFER DATE

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL OPEN COMPETITION UNDER THE

UNITED STATES CODE AT:

10 U.S.C. 3204(a) ( )41 U.S.C. 3304(a)

24. ADMINISTERED BY (If other than Item 7)

26. NAME OF CONTRACTING OFFICER (Type or print)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition is unusable

23. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

25. PAYMENT WILL BE MADE BY

27. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

28. AWARD DATE

CODE

ITEM

STANDARD FORM 33 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.214 (c)

SEALED BID (IFB) INVITATION FOR BID

NEGOTIATED (RFP) REQUEST FOR

PROPOSAL

(Hour) (Date)

PART I - THE SCHEDULE PART II - CONTRACT CLAUSES

Section A - Solicitation/Contract Form

USS JOHN CANLEY (ESB 6) Mid-Term Availability

USS JOHN CANLEY (ESB 6) MID-TERM AVAILABILITY (MTA)

1. USS JOHN CANLEY (ESB 6): NAVSUP Fleet Logistics Center Yokosuka (NAVSUP FLCY), Site Singapore has a new requirement in support of the USS JOHN CANLEY (ESB 6). The repair and maintenance package of work items are included as Work Item Specification Package MSC SSU 27-008 and SRF SING 005-27.

2. PERIOD OF PERFORMANCE: 01 March 2027 – 15 April 2027 (16 April – 30 April 2027 with option)

3. PLACE OF PERFORMANCE: U.S. 7th Fleet Area of Responsibility (AOR) with geographical restriction excluding performance in India.

4. OFFER: Offerors must provide all information required by this solicitation no later than 20 July 2026 at 10:00 AM Singapore Standard Time.

5. WORK ITEM INFORMATION:

a. Any work item priced based on an estimated quantity/scope will be balanced at the completion of the availability via a contract modification.

b. References in the Work Items will be provided to offerors via DoD safe (a web-based tool that provides users the capability to securely send and receive large files, including files that are too large to be transmitted via email.) Please email request for references to: Katharine Lamphier, Contracting Officer, Katharine.s.lamphier.

civ@us.navy.mil/Kesavan.krishnansingh.ln@us.navy.mil

6. CONDITIONAL PROVISIONS AND CLAUSES: This solicitation contains the mandatory provisions and clauses, as well as conditional provisions and clauses (e.g., clause at H-2.0 Applicable to Contracts Performed in Japan; clause at H-3.0, Applicable to Contracts Performed in Korea). Conditional provisions and clauses are self deleting if they do not apply

7. SMALL BUSINESS CONCERNS: If the government receives offers from two or more responsible U.S. (or U.S. territories) small business concerns that are competitive in terms of market price, quality and delivery, no offers received from other than small business concerns will be considered for award. In such event, FAR provision 52.219-6 (Notice of Total Small Business Set-Aside) shall be considered incorporated by reference.

If the government does not receive offers from two or more responsible U.S. (or U.S. territories) small business concerns that are competitive in terms of market price, quality and delivery, all offers, including offers from other than small business concerns, will be considered for award.

N6264926RL015

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

NOTE A: FIXED SHIP REPAIR LABOR AND MATERIAL HANDLING RATES FOR GROWTH, NEW WORK, AND TIME

AND MATERIALS (T&M)

1. The Contractor's fully burdened ship repair labor rate will be used for negotiating growth, new work, and T&M to be performed under this Contract. The fully burdened labor rate and material rate identified in Attachment J-3 (Contractor Price Breakdown). The Contractor agrees that the number of hours included in its price proposal submitted in response to Contract Change Order (CCO), shall include only direct production hours. For these purposes, direct production hours are for skilled labor at the journeyman level expended in direct production including but not limited to the following functions:

Abrasive cleaning/blasting

Fire Watch

Welding

Burning

Brazing

Carpentry

Machinists (inside and outside)

Electrical Work

Electronic Work

Engineering

Design Support

Lagging

Ship-fitting

Boiler-making

Painting

Sheet-metal Work

Pipefitting

Rigging

General Labor

Staging/Scaffolding

Diesel Mechanics

2. The fully burdened ship repair labor rate proposed by the contractor and identified in Attachment J-3, includes all costs associated with support functions (whether charged directly or indirectly by the Contractor's accounting systems) provided in support of the direct production functions listed in Note B paragraph 1 above. Support functions are considered to be included in the Contractor's fully burdened ship repair labor rate for direct production hours. Labor hours for the below support functions shall not be separately proposed, including in support of subcontractors. Support functions include, and are not limited to, those types listed below:

Testing

Quality Assurance

Execution Planning

Cleaning (except tank cleaning)

Supervision (all types, including, but not limited to supervision of trades, support personnel and subcontractors)

Security

Surveying

Administration

Transportation

Purchasing Staff

Lofting

Other indirect support

Handling & Warehousing

Safety/Environmental

Program Management

3. The fully burdened ship repair labor rate is a fixed hourly rate that includes all wages, (i.e. straight time, overtime, shift differential, holiday time, etc.), overhead, all other indirect costs, general and administrative expenses, Facilities Capital Cost of Money (FCCOM) and profit. The fully burdened ship repair labor rate represents a blended rate including labor transferred between divisions, subsidiaries or affiliates of the contractor under a common control.

4. Consumable materials are goods used in the ordinary course of work performance such as office supplies, paper, rags, vehicle or equipment fuel costs, cleaning chemicals, disposable tools, welding rods, paints buckets, paint brushes, protective clothing, etc., that are consumed/used in the process of repair and do not become an integral part of the repaired vessel. Consumable material shall be included in the Contractor's fully burdened ship repair labor rate and not separately priced.

5. Physical materials are goods that become incorporated into the repaired vessel in the course of the repair, such as replacement steel, pipes, paint, and fasteners. The material handling rate applies to physical materials but not to consumable materials. The material handling rate will applied to the actual cost of the physical material. Actual cost does not include handling charges, general and administrative cost, overhead, profit, or any other indirect cost.

6. For contract changes involving subcontractors, subcontractor quotes will only be subject to the material handling fee rate identified in Attachment J-3. Subcontractor quotes must be competitively acquired, and submitted with the contractor's pricing proposal in response to CCOs, if applicable, issued by the Contracting Officer (KO). At no time will the proposed total to be performed by the prime contractor combined with subcontractor quote, material quote, and applicable material handling fee be allowed to cost more than it would have, had the prime contractor directly provided all material and labor. If the Contractor intends to subcontract a CCO for procurement of material only, the Contractor shall notify the KO prior to submitting its CCO pricing stating the reason subcontracting the CCO is the best value to the Government. The proposed total pricing restriction addressed in the preceding sentence does not apply in any case where the work is required to be performed by Original Equipment Manufacturers (OEMs), or Government directed subcontractors. CCOs that are subcontracted for material only (no associated labor required within the CCO) shall not be subject to the material handling fee. Any material handling fee rate applied to new work shall be approved at the discretion of the KO, upon receipt of supporting documentation in accordance with FAR 15.404-3.

7. The Contract fixed fully burdened ship repair labor rate and material handling rate identified in Attachment J-3 shall be used for negotiating growth, new work, and T&M during the availability and up to three (3) months after the Contract Complete date.

NOTE B : AVAILABILITY SCHEDULE PERFORMANCE

1. The Contractor shall schedule the performance of all items in the work package, including all Base and Option items, so as to permit a contract scope increase which includes the total contract wide number of labor hours and material dollars to complete growth work as described in T&M CLINs.

2. The Contractor agrees that these labor hours and materials, if tasked, shall be performed, purchased and installed concurrently with the work items, without impacting, accelerating, or causing delay or disruption to the work required by the base and option work items, to any other Government contract, or to any other work in progress for the Government.

Item Supplies/Service Quantity Unit Unit Price Amount

USS JOHN CANLEY MTA CAT A

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

Option Line Item

USS JOHN CANLEY MTA CAT B

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

USS JOHN CANLEY MTA Growth Work for CAT A - Prime Labor

Time and Materials (T&M) Not-to-Exceed (NTE)

Unit Hourly Labor Rate: $___________/ Hour Qty. in Hours: 17,497 Extended Price $____________ (Hourly Labor Rate x 17,497)

*Contractor shall not incur any costs under this CLIN until a formal written authorization is issued by the Contracting Officer.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

17,497 Hours

Pricing Arrangement: Time and Material

Pricing Arrangement: Time and Materials

USS JOHN CANLEY MTA Growth Work for CAT A - Material/Subcontractor/Other Costs

Time and Materials (T&M) Not-to-Exceed (NTE) Material /Subcontractor/Other Direct Costs without markup:

$689,201 Qty: 1 Material Handling/Percent Markup: __________% Extended Price $ _____________________ ($689,201 x % markup) *Contractor shall not incur any costs under this CLIN until a formal written authorization is issued by the Contracting Officer.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

Pricing Arrangement: Time and Materials

Pricing Arrangement: Time and Materials

689,201 Each

USS JOHN CANLEY MTA SRF

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Ship Repair Facility (SRF) specification, SING 005-27, under Section J, Attachment J-1. This is a total of sub-line items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

Option Line Item

USS JOHN CANLEY MTA WI 0120 MSC

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

USS JOHN CANLEY MTA WI 0121 MSC

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, Option Line Item under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

Option Line Item

USS JOHN CANLEY MTA WI 0122 MSC

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

Option Line Item

USS JOHN CANLEY MTA WI 0123 MSC

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

Option Line Item

USS JOHN CANLEY MTA WI 0320 MSC

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

1 Job

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

Option Line Item

USS JOHN CANLEY MTA WI 0321 MSC

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

Option Line Item

USS JOHN CANLEY MTA WI 0404 MSC

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

Option Line Item

USS JOHN CANLEY MTA WI 0596 MSC

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

USS JOHN CANLEY MTA WI 0597 MSC

Complete the Mid-Term Availability (MTA) of USS JOHN CANLEY (ESB 6) as described in accordance with Military Sealift Command (MSC) specification, SSU SN 27- 008, under Section J, Attachment J-1. This is a total of subline items as described in Attachment J-3 Contractor Price Breakdown.

0014 All prices stated shall be in NET US Dollars inclusive of all applicable charges.

The contractor shall submit an itemized breakdown of the price for each work item on the form provided in Section J, Attachment J-3.

Pricing Arrangement: Firm Fixed Price

Pricing Arrangement: Firm Fixed Price

1 Job

Section C - Description/Specifications/Statement of Work

C-1 GENERAL

The Contractor shall prepare for and accomplish the attached work items as specified herein and in accordance with the Specification Package Military Sealift Command (MSC) as provided herein, test procedures and other detailed data provided by the Government.

The Contractor shall perform planning, document preparation, engineering, procurement, prefabrication and shipyard production work, and/or any other work necessary to prepare for and accomplish the alterations, repairs, maintenance and routine work specified herein.

These requirements include, but are not limited to, the following:

(a) Provide the management, procurement, production, testing, quality assurance, technical capability and resources necessary to prepare for and accomplish the repairs and alterations in accordance with the requirements stated herein, the contract work specifications, and the additional work specifications if necessary within the availability time period specified in Section F.

(b) Accomplish planning and scheduling to ensure timely procurement of Contractor Furnished Material/Contractor Furnished Property (CFM/CFP) and receipt, storage, and installation of Government Furnished Material/Government Furnished Property (GFM /GFP) and CFM /CFP.

(c) Apply progress measurement systems to determine the physical progress of completed work for each of the elements in the contractor's scheduling plan, including material and manpower control, engineering, production, tests and trials in accordance with the Contractor's own Technical Proposal, and the work item package. The progressing system shall permit a direct comparison of the physical progress of completed work to the planned performance measurement baseline for each of the elements in the scheduling plan.

(d) Establish management procedure and systems to identify behind schedule conditions and unfavorable schedule variance, using the scheduling plan performance measurement baseline, each of the elements in the baseline, and the progress measurement systems. The applied systems and procedures shall provide timely identification of scheduling problem areas to permit prompt management action to correct unsatisfactory conditions.

(e) Develop a performance milestone schedule/critical path chart to measure scheduled performance. Deviations from the milestone schedule/critical path chart must be submitted to and approved by the Contracting Officer. The Contractor warrants that all work required by Section C of this contract shall be completed within the performance period stated in Section F of the Contract. A performance milestone schedule and critical path chart shall be developed and submitted in accordance with the Work Item Package.

(f) Apply approved quality control procedures as required by this contract and the work item package to ensure procured material and performed production work conforms to the required quality standards.

(g) Apply procedures to ensure that the ship's equipment and systems remain configured to existing baselines with regard to procured material, production work, and software.

(h) Apply stringent configuration control procedures to ensure that configuration baselines are maintained for procured material and production work.

(i) Provide for staging and storing of Long Lead Time Material (LLTM) for use in the availabilities, as required by the Work Item Package.

(j) Comply with all security requirements and measures called for on the DD Form 254, if the form is listed in Section J and attached hereto.

(k)DATAREQUIREDFORCONTRACTCHANGEORDER (CCO):

For all generated CCOs, the Contractor shall provide all CCO pricing proposals to the KO within five (5) calendar days of receipt, unless otherwise specified on an individual CCOA Contractor's CCOs price proposal shall remain valid for a minimum of 14 calendar days, unless otherwise specified on an individual CCO. If the Contractor intends to request settlement of a CCOs price prior to 14 calendar days, the Contractor shall notify the KO, in writing, prior to submitting the CCOs price proposal stating the reason the CCOs price proposal must be settled in less than 14 calendar days and propose a revised timeline. The request will be accepted or rejected at the discretion of the KO. The Contractor shall list as part of the CCOs price proposal any specific terms and conditions related to completion of the change order to include impact to milestones, sequencing of adjacent work items, and revised completion date(s) for impacted work item(s).Any proposed change to a schedule milestones shall include a proposed revised date. If such items are not included as part of the CCOs price proposal (where applicable), the CCOs price proposal will not be considered timely received.

The pricing of the CCOs proposal shall include at a minimum:

a. Labor hours to be performed by the Contractor$_________________________________

b. Subcontractor Quote (If applicable)$_________________________________

c. Material Quote (If applicable)$_________________________________

Note1-Labor Hours: Proposed labor hours to be performed by the Contractor shall be provided broken down by paragraph and/or task, trade and labor hour mix as contained in the J-3 pricing attachment(s).

Note 2-Material: Material pricing shall include a list detailing the source, part number, description, unit cost, quantities, total cost and underlying vendor quotes for each line item.

Note3-Subcontractor Quotes: Subcontractor quotes shall include labor hours, labor rate, material (part number, description, unit cost, quantity, total cost, and vendor quotes for each line item),and tiered subcontractor quotes (if applicable). The Contractor shall submit documentation establishing the price reasonableness of each subcontractor quote per FAR 15.404-3(b).

Note4-Supporting Documentation:The requirements for complete submission of a CCOs price stated above represents the minimum and does not limit the Government from requesting additional information. In the event the KO is unable to make a fair and reasonable determination based on the original CCO pricing submission, the Contractor shall comply withFAR15.402(a)(2)which requires the Contractor provide data the KO needs in order to determine a fair and reasonable price.

Note5-Late Submissions: The above documentation must accompany the CCO proposal to be considered submitted to the KO. The number of days a Contractor's CCO's price proposal remains valid does not begin until the CCOs price proposal is considered by the KO

If circumstances arise where the Contractor is unable to submit a CCO's proposal within the number of days specified in paragraph above, the Contractor shall notify the KO,in writing,of the specific circumstances and provide a revised date on which a CCOs price proposal will be submitted. Additional time required to complete a CCO's price proposal may be granted solely at the discretion of the KO. The new time frame granted solely at the discretion of the KO and which may differ from the Contractor's request, shall be met by the Contractor. Notification of a late CCO's price proposal does not exempt the Contractor from meeting its requirement,but may be considered by the Government when conducting a CPARS evaluation and utilized for past performance ratings on future contracts.

Note 6 -Requests for Clarification: If clarification is needed in response to a CCO, the Contractor must submit a Request for Clarification (RFC) within two (2) business days of receipt of the Government's CCOs. Once a RFC is submitted, the Contractor, KO and Principle Port Engineer (PPE) and/or Project Manager (PM) will meet the following business day to clarify the scope of work. If, as a result of the meeting, a CCOs revision is required, the Contractor's CCOs price submission will run from the date of receipt of the revised CCO. If a RFC is received after the two (2) business day deadline, it is at the KO's discretion whether to accept the submission.

(l) DESCOPINGOFREQUIREMENTS: The Government reserves the right to change or terminate this contract. CCO changes to descope work specifications are incorporated in to the contract via descope CCOs and can either be a partial deletion of paragraph(s) from the work specification or deletion of a work item in its entirety. The Government will rely on the labor rates and prices entered in Attachment J-3( Contractor Price Breakdown), for negotiating and settling CCOs.

1.Pricing of Deletion CCOs: The Contractor agrees to descope changes CCOs at the same labor rate awarded in Attachment J-3 ( Contractor Price Breakdown), as follows:

a.Partial or full work item descoping of CCOs from the basic work package will be descoped at the awarded labor rate a Work Item Index tab of Attachment J-3 (Contractor Price Breakdown).

b. Partial or full work item descoping of CCOs from settled growth work or new work will be descoped at the agreed upon labor rate as entered in the Labor tab of Attachment J-3 (Contractor Price Breakdown).

(m)AUTHORIZEDCHANGESONLYBYTHECONTRACTINGOFFICER:Except as specified in the paragraph below, no order, statement, or conduct of Government personnel who visit the Contractor's facilities or in any other manner communicates with Contractor personnel during the performance of this contract shall constitute a change under the "Changes" clause of this contract.

The Contractor shall not comply with any order, direction or request of Government personnel unless it is issued in writing and signed by the Contracting Officer, or is pursuant to specific authority otherwise included as a part of this contract.

The Contracting Officer is the only person authorized to approve changesin any of the requirements of this contract and, notwithstanding provisions contained elsewhere in this contract, said authority remains solely the Contracting Officer's.In the event the Contractor effects any change at the direction of any person other than the Contracting Officer,the change will be considered to have been made without authority and no adjustment will be made in the contract price and/or schedule to cover any increase in charges incurred as a result there of. The only exception to this is if the Contractor is ordered to stop work for a safety reason. In the event the Contractor is asked to stop work for safety reasons, the Contractor shall notify the Contracting Officer in writing of the circumstances surrounding the stop work.

If the Contractor believes it has been directed to perform work outside the scope of the contract, it must notify the Contracting Officer immediately.

C-2 TESTING AND QUALITY CONTROL

Provide and maintain an inspection system acceptable to the Government in accordance with the Specification Package Military Sealift Command (MSC) as provided herein and additional requirements contained herein.

A. Nonconforming Material

The Contractor shall establish and maintain a positive system for controlling material which is not in conformance with contractor requirements. The system shall identify and segregate nonconforming material.

B. Subcontractor Control and Evaluation

1. The Contractor shall require subcontractors and suppliers to invoke adequate inspection systems that ensure the required quality of materials, parts, components, and services for end-use in this ship repair. The Government shall be permitted to monitor the Contractor's system for inspecting subcontractors.

2. Contractor is reminded of the requirements associated with subcontracting with contractors that are debarred, suspended or proposed for debarment contained at FAR 52.209-6. As with all FAR requirements, please ensure familiarity with those requirements prior to submitting its offer.

C. Calibration

1. Only calibrated equipment shall be used to perform tests and inspections.

2. Test and measuring equipment shall be within industry standard limits and shall be calibrated against standards traceable to the National Bureau of Standards.

3. Calibrated equipment shall be identified with a label stating date of calibration, due date and certifying agency.

4. Calibrated equipment shall be used for all pressure and weight testing, measurements of electrical waves, balancing operations, tachometers and other indirect measuring devices used for inspection or to record data or dimensions required by specifications.

C-3 MANAGEMENT/STAFFING PLAN

Provide an organization chart of the significant positions who will be assigned for this availability within 10 days after award. The chart shall include the positions in upper management, program managers, negotiators, estimators, scheduling personnel, engineering personnel, key production personnel by trade, and the lead position in the shipyard safety organization, testing organization, and the quality control organization.

C-4 GENERAL TECHNICAL REQUIREMENTS

The following COMSC Instruction is hereby incorporated into this Contract by reference: COMSC Instruction 4700.16 Series, "General Technical Requirements." Copies of this instruction are available at https://flankspeed.sharepoint-mil.us/sites/USFF-MSC via search for "COMSC Instruction 4700.16 Series." In the event that the instruction cannot be found, please reach out to the Contracting Officer: katharine.s.lamphier.civ@us.navy.mil

Requirements USS JOHN CANLEY (ESB 6) Mid-Term Availability FY27

N6264926RL015

mailto:katharine.s.lamphier.civ@us.navy.mil

Section D - Packaging and Marking

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.246-16 Responsibility for Supplies. Apr 1984

FAR Clauses Incorporated by Full Text

52.246-11 Higher-Level Contract Quality Requirement. (Dec 2014)

Higher-Level Contract Quality Requirement (Dec 2014)

(a) The Contractor shall comply with the higher-level quality standard(s) listed below.

Higher level quality requirements are detailed in the individual work items and include ABS standards.

(b) The Contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts, in-

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require-

(i) Control of such things as design, work operations, in-process control, testing, and inspection; or

(ii) Attention to such factors as organization, planning, work instructions, documentation control, and advanced metrology.

(End of clause)

Overall Contract Inspection/Acceptance Locations

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract.

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Option Line Item

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract.

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Inspection and Acceptance Location

Both Other Instructions: The PM will be responsible for all acceptance for this CLIN

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Kelly Morrow, Program Manager (PM) Email: kelly.r.morrow2.civ@us.navy.mil

Option Line Item

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract.

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Option Line Item

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract.

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Option Line Item

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract.

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Option Line Item

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract.

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Option Line Item

Inspection and Acceptance Location

Both Other

Instructions: The PPE will be responsible for all acceptance for this contract.

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Option Line Item

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract.

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Option Line Item

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract.

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Option Line Item

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Inspection and Acceptance Location

Both Other Instructions: The PPE will be responsible for all acceptance for this contract.

DoDAAC: N4098B CountryCode: USA

USNS JOHN L. CANLEY T-ESB-6

2798 HARBOR DR, BLDG 15 RM 200

SAN DIEGO, CA 92113

UNITED STATES

Bradley Thompson, Principal Port Engineer (PPE) Email: bradley.g.thompson.civ@us.navy.mil Telephone: +1 (757) 528-3511

Section F - Deliveries or Performance

Overall Contract Delivery Period

Contractor Other

Line Item Delivery Schedule Quantity Address and POC

Period of Performance From 01 Mar 2027 To 15 Apr 2027

1 Job

Option Line Item

Period of Performance From 16 Apr 2027 To 30 Apr 2027

1 Job

Period of Performance From 01 Mar 2027 To 30 Apr 2027

17,497 Hours

Period of Performance From 01 Mar 2027 To 30 Apr 2027

689,201 Each

Period of Performance From 01 Mar 2027 To 15 Apr 2027

1 Job

Option Line Item

Period of Performance From 01 Mar 2027 To 15 Apr 2027

1 Job

Option Line Item

Period of Performance From 01 Mar 2027 To 15 Apr 2027

1 Job

Option Line Item

Period of Performance From 01 Mar 2027 To 15 Apr 2027

1 Job

Period of Performance From

1 Job

01 Mar 2027 To 15 Apr 2027

Option Line Item

Period of Performance From 01 Mar 2027 To 15 Apr 2027

1 Job

Option Line Item

Period of Performance From 01 Mar 2027 To 15 Apr 2027

1 Job

Option Line Item

Period of Performance From 01 Mar 2027 To 15 Apr 2027

1 Job

Option Line Item

Period of Performance From 01 Mar 2027 To 15 Apr 2027

1 Job

Option Line Item

Period of Performance From 01 Mar 2027 To 15 Apr 2027

1 Job

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.242-15 Stop-Work Order. Aug 1989 52.247-29 F.o.b. Origin. Feb 2006

Section G - Contract Administration Data

Section G - Contract Administration Data

G-1.0 Designated Invoice Office

The Contractor shall submit its invoice, as described in "Invoice Information" below, and Material Inspection and Completion Report as part of submission of payment request made using Wide Area Work Flow (WAWF). In addition, Contractor shall submit its invoice and documents via email to the following:

MSC

Mr. Bradley Thompson, bradley.g.thompson.civ@us.navy.mil

MSCFE-Singapore-N8@us.navy.mil

SRF

Mr. Kelly R Morrow, kelly.r.morrow2.civ@us.navy.mil

Invoice Information

Pursuant to the requirements of FAR 52.232-25 Prompt Payment (JAN 2017), a proper invoice must include following information:

(a) Name and address of the Contractor;

(b) Invoice date;

(c) Invoice number;

(d) Contract number or other authorization for supplies delivered or services performed (including order number, contract line item number (CLIN) and, if applicable, the contract subline item number (SLIN);

(e) Description, quantity, unit of measure, unit price, and extended price of supplies delivered or services performed;

(f) Shipping and payment terms (e.g., shipment number and date of shipment, prompt payment discount terms) and the accounting classification reference number (ACRN) as identified on the financial accounting data sheets. The bill of lading number and weight of shipment will be shown for shipments on Government bills of lading;

(g) Name and address of Contractor official to whom payment is to be sent (must be the same as that in the contract or in a proper notice of assignment);

(h) Name (where practicable), title, phone number and mailing address of person to be notified in event of a defective invoice; and

(i) Any other information or documentation required by other requirements of the contract (such as evidence of shipment).

G-2.0 Designated Payment Office

Payment will be made by the following office or as otherwise specified in the contract at each Site

N50082

ACCOUNTS PAYABLE NAVY ERP

N6264926RL015

mailto:bradley.g.thompson.civ@us.navy.mil mailto:kelly.r.morrow2.civ@us.navy.mil

PO BOX 2050

5450 CARLISLE PIKE

MECHANICSBURG, PA 17055-0791

G-3.0 Payment Method

(a) Payment will be made by Wide Area Work Flow (WAWF).

(b) If payment by WAWF applies, payment shall be made in accordance with DFARS 252.232-7006 Wide Area Work Flow Payment Instructions, PGI 232.70 Electronic Submission and Processing of Payment Requests and Receiving Reports, and https://piee.eb.mil.

ELECTRONIC TRANSFER OF FUNDS PAYMENTS - FEDERAL RESERVE WIRE TRANSFER SYSTEM (NAVSUPFLCY MAR 2026)

(a) Definitions.

Beneficiary, as used in this clause, means the name of the owner of the bank account designated to receive the payment. This name must exactly match the name on the bank's account records.

International Bank Account Number (IBAN), as used in this clause, means and international standard for identifying a specific bank account, used for transactions involving European, Middle Eastern, and other participating countries.

Recipient, as used in this clause, means the contractor who is the legal entity entitled to payment under the terms of this contract.

Sort Code, as used in this clause, means a six-digit number that identifies a specific bank and branch location within the United Kingdom.

SWIFT Code, as used in this clause, means the Society for Worldwide Interbank Financial Telecommunication code, an 8 or 11-character code that identifies a specific bank for international transactions. This may also be known as the Bank Identifier Code (BIC).

Unique Entity ID (UEI), as used in this clause, means the official identifier assigned by the System for Award Management (SAM.gov) to all entities doing business with the federal government.

(b) Information Submission. The Contractor shall supply the following information to the Contracting Officer no later than 5 days after contract award and before submission of the first request for payment. The bank designated as the receiving bank must be capable of receiving Federal wire transactions via either a SWIFT Code or an IBAN.

(c) Changes to Information. Any change by the Contractor in the designation of the bank account to receive electronic transfer of funds in accordance with this provision must be received by the Contracting Officer no later than 30 days prior to the date the change is to become effective.

(d) No Assignment of Funds. The electronic transfer of funds does not constitute an assignment of such funds in any form or fashion.

N6264926RL015

https://piee.eb.mil/

COMPLETE THE FOLLOWING INFORMATION (TYPE WRITTEN OR CLEAR PRINTING)

RECIPIENT'S NAME: ______________________________________________

(DO NOT EXCEED 25 CHARACTERS)

CONTRACT NUMBER: ______________________________________________ (Contracting Officer fill-in)

RECIPIENT'S CAGE CODE: __________________

[ ] CHECKING TYPE 22 (Payment is a standard ACH credit to a checking account)

[ ] SAVINGS TYPE 32 (Payment is a standard ACH credit to a savings account)

RECIPIENT'S UEI NUMBER: ______________________________________________

BENEFICIARY'S BANK NAME: ______________________________________________

(DO NOT EXCEED 29 CHARACTERS)

BENEFICIARY'S BANK ADDRESS: ______________________________________________

(DO NOT EXCEED 25 CHARACTERS)

(DO NOT EXCEED 25 CHARACTERS)

BENEFICIARY'S BANK ACCOUNT NUMBER: ______________________________________________

BENEFICIARY'S BANK SWIFT NUMBER: ______________________________________________

(EITHER 8 OR 11 CHARACTERS ONLY)

IBAN NUMBER: ______________________________________ (If applicable)

BENEFICIARY'S BANK SORT CODE: __________________ (If applicable)

(6 CHARACTERS ONLY)

(e) CONTRACTOR'S DESIGNATED OFFICIAL SUBMITTING ELECTRONIC FUNDS TRANSFER INFORMATION.

NAME: ______________________________________________

(DO NOT EXCEED 25 CHARACTERS)

TITLE: ______________________________________________

(DO NOT EXCEED 25 CHARACTERS)

TELEPHONE NUMBER: ______________________________________________

SIGNATURE _______________________________________________________

(f) Notwithstanding any other provision of the contract, the requirements of this provision shall control.

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.204-7006 Billing Instructions-Cost Vouchers May 2023 252.217-7007 Payments. Dec 1991 252.217-7008 Bonds. Dec 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018 252.232-7008 Assignment of Claims (Overseas). Jun 1997

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. (Jan 2023)

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) As used in this clause-Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process vendor payment requests and receiving reports, asElectronic invoicing.

authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) To access WAWF, the Contractor shall-WAWF access.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the PracticeWAWF training.

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web entry, Electronic Data Interchange, or File TransferWAWF methods of document submission.

Protocol.

(f) The Contractor shall use the following information when submitting payment requests and receiving reports inWAWF payment instructions.

WAWF for this…