Solicitation - FA302225R0008.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

Created On:

05 Jun 2025, 07:30 AM Central Daylight Time

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Section A - Solicitation/Contract Form Install Mx Hanger Fans - B995 & 450

Product Service Code: Z2JZ

North American Industry Classification System (NAICS): 236220 Date: 05 Jun 2025

Annual Receipts: USD 45,000,000.00 Set Aside Percent: 100 Small Business Type: Small Business

FA302225R0008

Section B - Supplies or Services & Prices or Costs Additional Information/Notes

Item Supplies / Services Quantity Unit Unit Price Amount

Complete requirement IAW the attached SOW.

Product Service Code: Z2JZ

0001AA

Funding SLIN only.

Product Service Code: Z2JZ Pricing Arrangement: Firm Fixed Price

1 Job

Section C - Description/Specifications/Statement of Work

Requirements Design, furnish, and install all electrical components necessary to provide electricity and power to two (2) high volume, low speed ceiling fans in Building 995 and B450.

Section D - Packaging and Marking

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.246-12 Inspection of Construction. Aug 1996

Section F - Deliveries or Performance Overall Contract Delivery Period

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.247-29 F.o.b. Origin. Feb 2006 52.247-30 F.o.b. Origin, Contractor's Facility. Feb 2006 52.247-65 F.o.b. Origin, Prepaid Freight-Small Package Shipments. Jan 1991

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.201-7000 Contracting Officer's Representative. Dec 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018 252.236-7000 Modification Proposals--Price Breakdown. Dec 1991

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. (Jan 2023)

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) Definitions. As used in this clause-

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC F877700 Issue By DoDAAC FA3022 Admin DoDAAC FA3022 Inspect By DoDAAC F1N3BC Ship To Code N/A Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) F1N3BC Service Acceptor (DoDAAC) F1N3BC Accept at Other DoDAAC N/A LPO DoDAAC N/A DCAA Auditor DoDAAC N/A Other DoDAAC(s) N/A (*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

N/A

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section H - Special Contract Requirements

Section I - Contract Clauses

52.229-11Tax on Certain Foreign Procurements--Notice and Representation.

As prescribed in , insert the following provision: (a)29.402-3

Tax on Certain Foreign --Notice and Representation (Jun 2020) Procurements

(a)Definitions. As used in this provision--

Foreign person means any person other than a . United States person

Specified Federal procurement payment means any payment made pursuant to a contract with a foreign contracting party that is for goods, manufactured or produced, or services provided in a foreign country that is not a party to an international agreement with the . For purposes of the prior sentence, a foreign country procurement United States does not include an outlying area.

United States person as defined in (a)(30) means 26 U.S.C. 7701

(1)A citizen or resident of the ; United States

(2)A domestic partnership;

(3)A domestic corporation;

(4)Any estate (other than a foreign estate, within the meaning of (a)(31)); and 26 U.S.C. 701

(5)Any trust if-

(i)A court within the is able to exercise primary supervision over the administration of the trust; and United States

(ii)One or more have the authority to control all substantial decisions of the trust. United States persons

(b)Unless exempted, there is a 2 percent tax of the amount of a on any specified Federal procurement payment receiving such payment. See and its implementing regulations at 26 CFR 1.5000C-1 foreign person 26 U.S.C. 5000C through 1.5000C-7.

(c)Exemptions from withholding under this provision are described at 26 CFR 1.5000C-1(d)(5) through (7). The would an exemption from the withholding by using the Department of the Treasury Internal Revenue Offeror claim

Service Form W-14, Certificate of Foreign Party Receiving Federal Payments, available via Contracting Procurement the internet at . Any exemption claimed and self-certified on the IRS Form W-14 is subject to audit www.irs.gov/w14 by the IRS. Any disputes regarding the imposition and collection of the 26 U.S.C. 5000C tax are adjudicated by the

IRS as the tax is a tax matter, not a contract issue. The IRS Form W-14 is provided to the acquiring 26 U.S.C. 5000C agency rather than to the IRS.

(d)For purposes of withholding under , the represents that 26 U.S.C. 5000C Offeror

(1)It is is not a ; and foreign person

(2)If the indicates "is" in paragraph (d)(1) of this provision, then the represents that--I am claiming on Offeror Offeror the IRS Form W-14 a full exemption, or partial or no exemption [ select one] from the excise tax. Offeror shall

(e)If the represents it is a in paragraph (d)(1) of this provision, then-- Offeror foreign person

(1)The clause at FAR , Tax on Certain Foreign , will be included in any resulting contract; and 52.229-12 Procurements

FA302225R0008

https://www.acquisition.gov/far/part-29#FAR_29_402_3 https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section7701&num=0&edition=prelim https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section701&num=0&edition=prelim https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section5000C&num=0&edition=prelim https://www.irs.gov/w14 https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section5000C&num=0&edition=prelim https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section5000C&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_229_12

(2)The submit with its the IRS Form W-14. If the IRS Form W-14 is not submitted with the , Offeror shall offer offer exemptions will not be applied to any resulting contract and the Government will withhold a full 2 percent of each payment.

(f)If the selects "is" in paragraph (d)(1) and "partial or no exemption" in paragraph (d)(2) of this provision, the Offeror will be subject to withholding in accordance with the clause at FAR , Tax on Certain ForeignOfferor 52.229-12

, in any resulting contract.Procurements

(g)A taxpayer , for a fee, seek advice from the Internal Revenue Service (IRS) as to the proper tax treatment of a may transaction. This is called a private letter ruling. Also, the IRS publish a revenue ruling, which is an official may interpretation by the IRS of the Internal Revenue Code, related statutes, tax treaties, and regulations. A revenue ruling is the conclusion of the IRS on how the law is applied to a specific set of facts. For questions relating to the interpretation of the IRS regulations go to . https://www.irs.gov/help/tax-law-questions

(End of provision)

52.229-12Tax on Certain Foreign Procurements.

As prescribed in , insert the following clause: (b)29.402-3

Tax on Certain Foreign --Notice and Representation (Feb 2021) Procurements

(a)Definitions. As used in this clause--

Foreign person means any person other than a . United States person

United States person, as defined in (a)(30), means- 26 U.S.C. 7701

(1)A citizen or resident of the ; United States

(2)A domestic partnership;

(3)A domestic corporation;

(4)Any estate (other than a foreign estate, within the meaning of (a)(31)); and 26 U.S.C. 7701

(5)Any trust if-

(i)A court within the is able to exercise primary supervision over the administration of the trust; and United States

(ii)One or more have the authority to control all substantial decisions of the trust. United States persons

(b)This clause applies only to . It implements and its implementing regulations at 26 foreign persons 26 U.S.C. 5000C

CFR 1.5000C-1 through 1.5000C-7.

(c)

(1)If the Contractor is a and has only a partial or no exemption to the withholding, the Contractor foreign person shall include the Department of the Treasury Internal Revenue Service Form W-14, Certificate of Foreign Contracting

Party Receiving Federal Payments, with each voucher or submitted under this contract Procurement invoice throughout the period in which this status is applicable. The excise tax withholding is applied at the payment level, not at the contract level. The Contractor revise each IRS Form W-14 submission to reflect the exemption (if should any) that applies to that particular , such as a different exemption applying. In the absence of a completed invoice IRS Form W-14 accompanying a payment request, the default withholding percentage is 2 percent for the section 5000C withholding for that payment request. Information about IRS Form W-14 and its separate instructions is available via the internet at . www.irs.gov/w14

FA302225R0008

https://www.acquisition.gov/far/part-52#FAR_52_229_12 https://www.irs.gov/help/tax-law-questions https://www.acquisition.gov/far/part-29#FAR_29_402_3 https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section7701&num=0&edition=prelim https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section7701&num=0&edition=prelim https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section5000C&num=0&edition=prelim https://www.irs.gov/w14

(2)If the Contractor is a and has indicated in its in the provision , Tax on Certain Foreign foreign person offer 52.229-11

--Notice and Representation, that it is fully exempt from the withholding, and certified the full Procurements exemption on the IRS Form W-14, and if that full exemption no longer applies due to a change in circumstances during the performance of the contract that causes the Contractor to become subject to the withholding for the 2 percent excise tax then the Contractor - shall

(i)Notify the within 30 days of a change in circumstances that causes the Contractor to be subject Contracting Officer to the excise tax withholding under ; and 26 U.S.C. 5000C

(ii)Comply with paragraph (c)(1) of this clause.

(d)The Government will withhold a full 2 percent of each payment unless the Contractor an exemption. If the claims

Contractor enters a ratio in Line 12 of the IRS Form W-14, the result of Line 11 divided by Line 10, the Government will withhold from each payment an amount equal to 2 percent multiplied by the contract ratio. If the Contractor marks box 9 of the IRS Form W-14 (rather than completes Lines 10 through 12), the Contractor identify and must enter the specific exempt and nonexempt amounts in Line 15 of the IRS Form W-14; the Government will then withhold 2 percent only from the nonexempt amount. See the IRS Form W-14 and its instructions.

(e)Exemptions from the withholding under this clause are described at 26 CFR 1.5000C-1(d)(5) through (7). Any exemption claimed and self-certified on the IRS Form W-14 is subject to audit by the IRS. Any disputes regarding the imposition and collection of the tax are adjudicated by the IRS as the tax is a 26 U.S.C. 5000C 26 U.S.C. 5000C tax matter, not a contract issue.

(f)Taxes imposed under not be-- 26 U.S.C. 5000C may

(1)Included in the contract price; nor

(2)Reimbursed.

(g)A taxpayer , for a fee, seek advice from the Internal Revenue Service (IRS) as to the proper tax treatment of a may transaction. This is called a private letter ruling. Also, the IRS publish a revenue ruling, which is an official may interpretation by the IRS of the Internal Revenue Code, related statutes, tax treaties, and regulations. A revenue ruling is the conclusion of the IRS on how the law is applied to a specific set of facts. For questions relating to the interpretation of the IRS regulations go to . https://www.irs.gov/help/tax-law-questions

(End of clause)

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements. Jan 2017 52.204-9 Personal Identity Verification of Contractor Personnel. Jan 2011 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. Jun 2020 52.204-13 System for Award Management Maintenance. Oct 2018 52.204-18 Commercial and Government Entity Code Maintenance. Aug 2020 52.204-19 Incorporation by Reference of Representations and Certifications. Dec 2014 52.204-21 Basic Safeguarding of Covered Contractor Information Systems. Nov 2021

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities.

Dec 2023

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

Nov 2021

52.204-27 Prohibition on a ByteDance Covered Application. Jun 2023

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded

Jan 2025

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. Nov 2015 52.211-13 Time Extensions. Sep 2000 52.219-6 Notice of Total Small Business Set-Aside. Nov 2020 52.222-3 Convict Labor. Jun 2003 52.222-4 Contract Work Hours and Safety Standards -Overtime Compensation. May 2018 52.222-6 Construction Wage Rate Requirements. Aug 2018 52.222-7 Withholding of Funds. May 2014 52.222-8 Payrolls and Basic Records. Jul 2021 52.222-9 Apprentices and Trainees. Jul 2005

FA302225R0008

https://www.acquisition.gov/far/part-52#FAR_52_229_11 https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section5000C&num=0&edition=prelim https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section5000C&num=0&edition=prelim https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section5000C&num=0&edition=prelim https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title26-section5000C&num=0&edition=prelim https://www.irs.gov/help/tax-law-questions

52.222-10 Compliance with Copeland Act Requirements. Feb 1988 52.222-11 Subcontracts (Labor Standards). May 2014 52.222-12 Contract Termination-Debarment. May 2014 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations. May 2014 52.222-14 Disputes Concerning Labor Standards. Feb 1988 52.222-15 Certification of Eligibility. May 2014 52.222-35 Equal Opportunity for Veterans. Jun 2020 52.222-36 Equal Opportunity for Workers with Disabilities. Jun 2020 52.222-50 Combating Trafficking in Persons. Nov 2021 52.222-54 Employment Eligibility Verification. Jan 2025 52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026. Jan 2022 52.222-62 Paid Sick Leave Under Executive Order 13706. Jan 2022 52.223-5 Pollution Prevention and Right-to-Know Information. May 2024 52.223-21 Foams. May 2024 52.223-23 Sustainable Products and Services. May 2024 52.225-3 Buy American-Free Trade Agreements-Israeli Trade Act. Nov 2023 52.225-13 Restrictions on Certain Foreign Purchases. Feb 2021 52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving. May 2024 52.232-24 Prohibition of Assignment of Claims. May 2014 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. Oct 2018 52.232-39 Unenforceability of Unauthorized Obligations. Jun 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. Mar 2023 52.233-1 Disputes. May 2014 52.233-3 Protest after Award. Aug 1996 52.233-4 Applicable Law for Breach of Contract Claim. Oct 2004 52.236-5 Material and Workmanship. Apr 1984 52.236-7 Permits and Responsibilities. Nov 1991 52.236-16 Quantity Surveys. Apr 1984 52.236-17 Layout of Work. Apr 1984 52.242-14 Suspension of Work. Apr 1984 52.243-5 Changes and Changed Conditions. Apr 1984 52.244-6 Subcontracts for Commercial Products and Commercial Services. Jan 2025 52.247-5 Familiarization with Conditions. Apr 1984 52.247-15 Contractor Responsibility for Loading and Unloading. Apr 1984 52.247-16 Contractor Responsibility for Returning Undelivered Freight. Apr 1984 52.247-68 Report of Shipment (REPSHIP). Feb 2006 52.249-4 Termination for Convenience of the Government (Services) (Short Form). Apr 1984 52.253-1 Computer Generated Forms. Jan 1991

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. Dec 2022 252.204-7000 Disclosure of Information. Oct 2016 252.204-7003 Control of Government Personnel Work Product. Apr 1992 252.204-7004 Antiterrorism Awareness Training for Contractors. Jan 2023 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. May 2024 252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services. Jan 2023 252.204-7020 NIST SP 800-171 DoD Assessment Requirements. Nov 2023 252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials. Sep 2014 252.223-7008 Prohibition of Hexavalent Chromium. Jan 2023 252.225-7048 Export-Controlled Items. Jun 2013 252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime. Jan 2023 252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region. Jun 2023 252.232-7010 Levies on Contract Payments. Dec 2006 252.243-7001 Pricing of Contract Modifications. Dec 1991 252.244-7000 Subcontracts for Commercial Products or Commercial Services. Nov 2023 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for Military Operations. Oct 2010 252.246-7008 Sources of Electronic Parts. Jan 2023 252.247-7023 Transportation of Supplies by Sea. Oct 2024

Supplemental Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

5352.204-9002 Security Incident Reporting and Procedures Jun 2024

FAR Clauses Incorporated by Full Text

52.204-1 Approval of Contract. (Dec 1989)

Approval of Contract (Dec 1989)

This contract is subject to the written approval of ____[identify title of designated agency official here] and shall not be binding until so approved.

(End of clause)

52.209-1 Qualification Requirements. (Feb 1995)

Qualification Requirements (Feb 1995)

(a) Definition. "Qualification requirement," as used in this clause, means a Government requirement for testing or other quality assurance demonstration that must be completed before award.

(b) One or more qualification requirements apply to the supplies or services covered by this contract. For those supplies or services requiring qualification, whether the covered product or service is an end item under this contract or simply a component of an end item, the product, manufacturer, or source must have demonstrated that it meets the standards prescribed for qualification before award of this contract. The product, manufacturer, or source must be qualified at the time of award whether or not the name of the product, manufacturer, or source is actually included on a qualified products list, qualified manufacturers list, or qualified bidders list. Offerors should contact the agency activity designated below to obtain all requirements that they or their products or services, or their subcontractors or their products or services, must satisfy to become qualified and to arrange for an opportunity to demonstrate their abilities to meet the standards specified for qualification.

(Name) ____

(Address) ____

(c) If an offeror, manufacturer, source, product or service covered by a qualification requirement has already met the standards specified, the relevant information noted below should be provided.

Offeror's Name ____

Manufacturer's Name____

Source's Name ____

Item Name ____

Service Identification ____

Test Number ____ (to the extent known)

(d) Even though a product or service subject to a qualification requirement is not itself an end item under this contract, the product, manufacturer, or source must nevertheless be qualified at the time of award of this contract. This is necessary whether the Contractor or a subcontractor will ultimately provide the product or service in question. If, after award, the Contracting Officer discovers that an applicable qualification requirement was not in fact met at the time of award, the Contracting Officer may either terminate this contract for default or allow performance to continue if adequate consideration is offered and the action is determined to be otherwise in the Government's best interests.

(e) If an offeror, manufacturer, source, product or service has met the qualification requirement but is not yet on a qualified products list, qualified manufacturers list, or qualified bidders list, the offeror must submit evidence of qualification prior to award of this contract. Unless determined to be in the Government's interest, award of this contract shall not be delayed to permit an offeror to submit evidence of qualification.

(f) Any change in location or ownership of the plant where a previously qualified product or service was manufactured or performed requires reevaluation of the qualification. Similarly, any change in location or ownership of a previously qualified manufacturer or source requires reevaluation of the qualification. The reevaluation must be accomplished before the date of award.

(End of provision)

52.211-10 Commencement, Prosecution, and Completion of Work. (Apr 1984)

Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 180[Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than ____.* The time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.211-10 Commencement, Prosecution, and Completion of Work. (Alternate I) (Apr 1984) Alternate I (Apr 1984)

Alternate I (Apr 1984). If the completion date is expressed as a specific calendar date, computed on the basis of the contractor receiving the notice to proceed by a certain day, add the following paragraph to the basic clause:

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by ____[Contracting Officer insert date]. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

52.211-12 Liquidated Damages-Construction. (Sep 2000)

Liquidated Damages-Construction (Sept 2000)

If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the (a) amount of $ for each calendar day of delay until the work is completed or accepted.352.11

If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated (b) damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.213-4 Terms and Conditions-Simplified Acquisitions (Other Than Commercial Products and Commercial Services).

(Jan 2025)

Terms and Conditions-Simplified Acquisitions (Other Than Commercial Products and Commercial Services) (Jan 2025)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub.

L. 115-232).

(iv) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division R of Pub. L. 117-328), unless the agency grants an exception -see paragraph (b) of 52.204-27.

(v) 52.204-30, Federal Acquisition Supply Chain Security Act Orders-Prohibition. (Dec 2023) (Pub. L. 115-390, title II).

(vi) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

(vii) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(viii) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

(ix) 52.225-13, Restrictions on Certain Foreign Purchases (Feb 2021) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(x) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) (31 U.S.C. 3903 and 10 U.S.C. 3801).

(xi) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(xii) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Pub. L. 108-77 and 108-78 (19 U.S.C. 3805 note)).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (Apr 1984).

(ii) 52.232-8, Discounts for Prompt Payment (Feb 2002).

(iii) 52.232-11, Extras (Apr 1984).

(iv) 52.232-25, Prompt Payment (Jan 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (Jun 2013).

(vi) 52.233-1, Disputes (May 2014).

(vii) 52.244-6, Subcontracts for Commercial Products and Commercial Services (Nov 2024).

(viii) 52.253-1, Computer Generated Forms (Jan 1991).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) (41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community-see FAR 3.900(a).

(ii) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020)(Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at or above the threshold specified in FAR 4.1403(a) on the date of award of this contract).

(iii) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Feb 2024) (E.O. 13126) (Applies to contracts for supplies exceeding the micro-purchase threshold, as defined in 2.101 on the date of award of this contract).

(iv) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment., Contracts for Materials, Supplies, Articles, and Equipment (Jun 2020) (41 U.S.C. chapter

65) (Applies to supply contracts over the threshold specified in FAR 22.602 on the date of award of this contract, in the United States, Puerto Rico, or the U.S.

Virgin Islands).

(v) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(vi) 52.222-36, Equal Employment for Workers with Disabilities (Jun 2020) (29 U.S.C. 793) (Applies to contracts over the threshold specified in FAR 22.1408(a) on the date of award of this contract, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, "United States" includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vii) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(viii) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(ix)

(A) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (Mar 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(x) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (Jan 2022) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, and the outer Continental Shelf as defined in the Outer Continental Shelf Lands Act (43 U.S.C. 1331, et seq.))).

(xi) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xii) 52.223-5, Pollution Prevention and Right-to-Know Information (May 2024) (42 U.S.C. 11001-11050 and 13101-13109) (Applies to services performed on Federal facilities).

(xiii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (May 2024) (42 U.S.C. 7671, et seq.) (Applies to contracts for products as prescribed at FAR 23.109(d)(1)).

(xiv) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (May 2024) (42 U.S.C. 7671, et seq.) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xv) 52.223-20, Aerosols (May 2024) (42 U.S.C. 7671, et seq.) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (May 2024) (42 U.S.C. 7671, et seq.) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent; or contracts for construction of buildings or facilities.

(xvii) 52.223-23, Sustainable Products and Services (May 2024) (E.O. 14057, 7 U.S.C. 8102, 42 U.S.C. 6962, 42 U.S.C. 8259b, and 42 U.S.C. 7671l) (Applies to contracts when the agency identifies in the statement of work, or elsewhere in the contract, the sustainable products and services that apply to the acquisition).

(xviii)

(A) 52.225-1, Buy American-Supplies (Oct 2022) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold, as defined in 2.101 on the date of award of this contract, and the acquisition-

(1) Is set aside for small business concerns; or

(2) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $50,000).

(B) Alternate I (OCT 2022) (Applies if the Contracting Officer has filled in the domestic content threshold below, which will apply to the entire contract period of performance. Substitute the following sentence for the first sentence of paragraph (1)(ii)(A) of the definition of domestic end product in paragraph (a) of 52.225-1:

(A) The cost of its components mined, produced, or manufactured in the United States exceeds ____ percent of the cost of all its components. [ Contracting officer to insert the percentage per instructions at 13.302-5(d)(4). ])

(xix) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations., Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) (42 U.S.C.

1792) (Applies to contracts greater than the threshold specified in FAR 26.404 on the date of award of this contract, that provide for the provision, the service, or the sale of food in the United States).

(xx) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct 2013)(Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) as its source of EFT information).

(xxi) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information).

(xxii) 52.240-1, Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act-Covered Foreign Entities (Nov 2024) (Sections 1821-1826, Pub. L. 118-31, 41 U.S.C. 3901 note prec.).

(xxiii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2021) (46 U.S.C. 55305)(Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d)).

(xxiv) 52.247-69, Reporting Requirement for U.S.-Flag Air Carriers Regarding Training to Prevent Human Trafficking (Jan 2025) (49 U.S.C. 40118(g)). (Applies to contracts with a U.S.-flag carrier for the transportation by air of passengers; does not apply to contracts awarded by the Department of Defense or contracts for commercial products).

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (Nov 2021) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.)

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Nov 2021) (Applies to contracts over the threshold specified in FAR 9.405-2(b) on the date of award of this contract).

(iii) 52.211-17, Delivery of Excess Quantities (Sept 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (Feb 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (Jan 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (Feb 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

____[Insert one or more Internet addresses]

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights-

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(End of clause)

52.219-28 Postaward Small Business Program Rerepresentation. (Jan 2025)

Postaward Small Business Program Rerepresentation (Jan 2025)

(a) Definitions. As used in this clause-

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern-

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented its status as any of the small business concerns identified at 19.000(a)(3) prior to award of this contract, the…