SBSA LPTA Sol aug19 r1 508 7 8 20pdf.pdf

Solicitation No. 47PE0220R0016

Document: C201-SB LPTA/AUGUST 2019 (The Solicitation)

Construction Contract for Roof Replacement Sam Nunn Federal

Building

The Solicitation

The General Services Administration (GSA) is setting aside the contract under the following clause found in the Agreement:

52.219-30 Notice of Total Small Business Set Aside Women Owned

Lowest Price Technically Acceptable (LPTA

Table of Contents

I. General Information A. The Solicitation and Contract B. List of Solicitation Documents C. Authorized Representatives D. Pre-Proposal Conference E. Estimated Price Range F. FAR 52.228-1 Bid Guarantee G. FAR 52.236-27 Site Visit – Construction H. Receipt of Offers

II. Proposals

A. Proposal Contents B. Proposal Format C. Price Proposal D. Technical Proposal E. Other Information to be Submitted with Proposal F. Requirements of Joint Venture Offerors

III. General Provisions

A. Availability of Funds B. Requests for Clarification or Interpretation C. Notice to Small Business Firms D. Information Concerning the Disclosure of Solicitation Results E. Affirmative Procurement Program F. Notice Concerning Preparation of Proposals G. Contractor Performance Information H. Safeguarding Documents Designated as Sensitive But Unclassified

IV. FAR/GSAR Solicitation Provisions A. FAR 52.211-1 Availability of Specifications Listed in the GSA Index of Federal

Specifications, Standards and Commercial Item Descriptions, FPMR 101-29 B. FAR 52.211-3, Availability of Specifications Not Listed in the GSA Index of

Federal Specifications, Standards and Commercial Items Description C. FAR 52.216-1 Type Of Contract D. FAR 52.222-5 Construction Wage Rate Requirements-Secondary Site of Work E. FAR 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal

Employment Opportunity for Construction F. FAR 52.225-10 Notice of Buy American Requirement-Construction Materials G. Buy American Exceptions H. FAR 52.233-2 Service of Protest I. FAR 52.252-1 Solicitation Provisions Incorporated by Reference J. GSAR 552.102 Incorporating Provisions and Clauses by Reference K. Additional Provisions

(i) GSAR 552.236-74, Evaluation of Options (Mar 2019)

(ii) GSAR 552.236-75, Evaluation Exclusive of Options (Mar 2019)

(iii) GSAR 552.236-76 Basis of Award - Sealed Bidding Construction (Mar 2019)

(iv) GSAR Clause 552.236-77, Government’s Right to Exercise Options (Mar 2019)

L. Certified Cost or Pricing Data V. Instructions to Offerors and Clauses

A. FAR 52.215-1 Instructions to Offerors – Competitive Acquisition B. FAR 52.204-25, Prohibition on Contracting for Certain Telecommunications and

Video Surveillance Services or Equipment (AUG 2019)

C. GSAR 552.204-70, Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment. (DEVIATION I) (AUG 2019)

D. FAR 52.219-14 Limitations on Subcontracting E. FAR 52.219-18 Notice of Competition Limited to 8(a) Eligible Participants F. FAR 52.223-21, FOAMS (Jun 2016) G. FAR 52.222-62 Paid Sick Leave Under Executive Order 13706 H. Security Requirements I. Additional Clauses

(i) GSAR Clause 552.211-10 Commencement, Prosecution and Completion of Work (Mar 2019)

(ii) GSAR Clause 552.211-12, Liquidated Damages-Construction (Mar 2019)

(iii) GSAR Clause 552.211-13, Time Extensions (Mar 2019)

(iv) GSAR Clause 552.211-70, Substantial Completion

(v) GSAR Clause 552.232-5, Payment Under Fixed Price Construction

Contracts (Mar 2019)

(vi) GSAR Clause 552.236-6, Superintendence by the Contractor (Mar 2019)

(vii) GSAR Clause 552.236-11, Use and Possession Prior to Completion (Mar

2019)

(viii) GSAR Clause 552.236-15, Schedules for Construction Contracts (Mar

2019)

(ix) GSAR Clause 552.236-21, Specifications and Drawings for Construction

(Mar 2019)

(x) GSAR Clause 552.236-70, Authorities and Limitations (Mar 2019)

(xi) GSAR Clause 552.236-71, Contractor Responsibilities (Mar 2019)

(xii) GSAR Clause 552.236-72, Submittals (Mar 2019)

(xiii) GSAR Clause 552.236-73, Subcontracts (Apr 1984)

(xiv) GSAR Clause 552.243-71, Equitable Adjustments (Mar 2019)

VI. Method Of Award A. Evaluation of Offers – Lowest Price Technically Acceptable B. Lowest Price Technically Acceptable Process C. Determination of Responsibility D. Price Reasonableness/Price Realism E. Unbalanced Price F. Total Evaluated Prices G. Non Price Factors H. Evaluation of Joint Ventures

Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program.

The General Services Administration (GSA) is setting aside the contract under the following clause found in the Agreement:

52.219-30, Notice of Set-Aside for Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program

I. General Information

I.A. The Solicitation and Contract

(1) This Solicitation is set-aside for Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program. in accordance with FAR 19. This Solicitation sets forth requirements for proposals for a Contract to construct the Project described in the attached Agreement. Proposals conforming to the Solicitation requirements will be evaluated in accordance with the Method of Award set forth herein. The Government will award the Contract to the selected Offeror, subject to the conditions set forth herein.

(2) Neither the Solicitation nor any part of an Offeror's proposal shall be part of the Contract except to the extent expressly incorporated therein by the Contracting Officer.

(3) The Offeror's proposal submitted in response to this Solicitation shall constitute a firm offer.

No contract shall be formed unless and until the Contracting Officer has countersigned the SF 1442 submitted by an Offeror, and delivered to the Contractor a copy of the SF 1442 with original signatures together with the Agreement reflecting the Offeror's proposed prices.

I.B. List of Solicitation Documents

The Solicitation Documents are comprised of:

(1) The Solicitation

(2) Offeror Representations and Certifications Form

(3) Standard Form (SF) 1442 – Solicitation Offer and Award

(4) The Agreement and Attachments to the Agreement

(5) Other Forms Required For Submission with Proposals

(6) SOW’s

(7) GSA Form 527 – Contractor’s Qualifications and Financial Information

(8) Wage Rates

(9) SBU

(9) Other Attachments

I.C. Authorized Representatives

The following individuals are designated as the authorized GSA representatives under this Solicitation:

Authorized Representative Information:

Contracting Officer’s Information

Name: Michelle Mayfield

Address: 77 Forsyth Street Atlanta GA 30303

Telephone: 404-562-2578

Email: michelle.mayfield@gsa.gov

Alternate POC Information

Name: Shonda Piper-Cameron

Address: 77 Forsyth Street Atlanta, GA 30303

Telephone: (404) 331-0847

Email:Shonda.piper-cameron@gsa.gov

I.D. Pre-Proposal Conference Contractor should arrive early to allow reasonable amount of time to get through Security in the building.

Requests for Clarification. – All questions and requests for clarification should be submitted in writing By 12:00 Noon on July 27, 2020. Submit requests and inquiries to the Contracting Officer

Michelle Mayfield, michelle.mayfield@gsa.gov and PM Shonda Piper Cameron, Shonda.piper-cameron@gsa.gov.

Time: 10:00 am

Location: Sam Nunn Federal Building, 61 Forsyth Street, Atlanta GA 30303 (meet in the lobby, mask required)

Date: July, 21, 2020 (Pre- Registration is required).

I.E. Estimated Price Range

The estimated price range for the Project is between $ 500,000 and $ 1,000,000.

I.F. FAR 52.228-1 Bid Guarantee (Sep 96)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier’s check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

I.G. FAR 52.236-27 Site Visit – Construction (FEB 95)

(1) The clauses at FAR 52.236-2, Differing Site Conditions, and FAR 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, Offerors are urged and expected to inspect the site where the work will be performed.

(2) To arrange for a site visit, contact:

Name: Shonda Pipe-Cameron

Address: 77 Forsyth Street, Atlanta GA 30303

Telephone: 404-331-0847

Email:Shonda.pipe-cameron@gsa.gov http://www.acquisition.gov/far/current/html/52_233_240.html#wp1113365 http://www.acquisition.gov/far/current/html/52_233_240.html#wp1113375

(3) Pre-registration is required for all attendees to the pre-proposal Site Visit. The Site Visit shall be limited to not more than two (2) representatives from each Offeror. Offerors shall submit a Visit Authorization Request (VAR) identifying all attendees from their respective team.

Participants must have a valid, Government issued picture identification, driver’s license preferred, to gain access for the pre-proposal Site Visit. Notification of the location of entry, where attendees are required to meet, and all other requirements for the Site Visit will be issued to the Offerors. Submit the VAR to the point of contact listed below.

(2) Site visits will be held at the following date and time:

Date: Wednesday, July 21, 2020

Time: 10:00 am. (Please meet in the Lobby, Mask Required)

Contact Person: Shonda.Pipe-Cameron@gsa.gov

(3) Pre-registration is required for all attendees to the pre-proposal Site Visit. The Site Visit shall be limited to not more than two (2) representatives from each Offeror. Offerors shall submit a Visit Authorization Request (VAR) identifying all attendees from their respective team.

Participants must have a valid, Government issued picture identification, driver’s license preferred, to gain access for the pre-proposal Site Visit. Notification of the location of entry, where attendees are required to meet, and all other requirements for the Site Visit will be issued to the Offerors. Submit the VAR to the point of contact listed below.

For further information about the site visit or access requirements, please contact:

Name: Shonda Piper-Cameron

Address: 77 Forsyth Street Atlanta GA 30303

Telephone: 404-331-0847

Email: Shonda.piper-cameron@gsa.gov

I.H. Receipt of Offers

(1) In order to be considered for award, offers conforming to the requirements of the Solicitation must be received at the following office no later than 3:30 pm local time on the following date and at the following address.

Date: August 10, 2020

Address: Proposal shall be submitted by email to : Michelle.Mayfield@gsa.gov

(2) Offers sent by commercial package delivery and hand delivery shall be deemed received as of the date and time of delivery to the office designated for receipt of offers.

(3) Offers sent by United States Mail shall be deemed timely if delivered to the address of the government installation designated for receipt of offers on or before the date established for receipt of offers.

II. Proposals

II.A. Proposal Contents

Proposals shall consist of the following documents, completed and executed in accordance with this Solicitation:

1. Price Proposal

2. Technical Proposal

3. Representations and Certifications

4. Standard Form 24, Bid Bond

5. GSA Form 527 – Contractor’s Qualification and Financial Information

6. Agreement

7. SF 1442, Price Breakdown sheet

8. Past Performance Reference

9. Other Documents as Required

II.B. Proposal Format

Price Proposal on SF 1442 Price Breakdown Technical Proposal Past Performance Reference Representations and Certification of Form Bid Guarantee, using Standard Form

Offerors are required to submit proposals as described herein. Each part must be fastened or bound together. Proposals shall be submitted typed on non-educed 8 ½ x 11 sheets with 1” margins on top, bottom left and right. Forms and charts shall be labeled and included at the end of each applicable factor. All proposals received shall be evaluated for acceptability, but shall not be ranked using non/cost price factors. All resumes are not to exceed three (3) pages, for the proposed Project Manager and the Superintendent.

II.C. Price Proposal

(1) Contents

The Price Proposal shall consist of the SF 1442 and the Agreement, with prices and/or rates indicated for each price element shown on the pricing form included in Section II of the Agreement. Indicate the Base Contract Price, or if no such distinction is made, the Contract Price, in Block 17 of the SF 1442, which must be fully executed by the Offeror.

(2) Qualifications, Exclusions and Conditions

If the Offeror communicates in its proposal any qualifications, exclusions, or conditions to the proposed prices not provided for in the Contract Documents, the Contracting Officer may reject the proposal and exclude the Offeror from further discussions.

(3) Additional Proposal Requirements

II.D. Technical Proposal

The Technical Proposal shall include the information requested below for the non-price factors described in Section VI.

Factor 1: Past Performance/Similar Project (pass/fail) Factor 2: Past Experience/Similar Project (pass/fail) Factor 3: Management Approach/Key Personnel (pass/fail)

Evaluation Factors

1. Past Performance Providing Design-Build Services on Similar Projects.

This factor considers the Contractor’s performance as a firm in providing Design-Build services for three (3) similar projects completed in the last five (5) years where the

Contractor was the prime contractor. This factor will be evaluated based upon the written responses to the RFP by the Contractor and by the evaluation of responses of references recommended by the Contractor. The Government also reserves the right to use other government data available in its assessment of the Contractor’s past performance. If a completed CPARS evaluation is available for the project(s) listed under this Factor, it shall be submitted with the proposal. Contractor shall submit at least three letters of reference from clients on past projects.

“Similar projects” are defined as projects which entailed roofing system replacement and exterior repairs for commercial or federally owned or leased space with a roofing sq. ft.

replacement of at least 15,000 sq. ft. completed within the last 5 years. The SSEB will be limited to reviewing only projects of similarity.

The Government considers a project that has all of the following criteria a similar project:

Performed within the last five (5) years and at least 75% complete as of January 1, 2020.

Project in occupied building, though not necessarily occupied space of that building.

The project must involve roofing and exterior repair disciplines.

The project involved the following project delivery methods: Design-build.

Minimum requirement for this factor is providing three projects using the design-build method. The page limit for this factor is 5-double sided pages, single-spaced, Times New

Roman font (or comparable), no smaller than 10 point type-size.

In addition to the above, the Government may review any other sources of information for evaluating past performance. Other sources may include, but are not limited to, past

(CPARS) using all CAGE/DUNS numbers of team members (partnership, joint venture, teaming arrangement, or parent company/subsidiary/affiliate) identified in the

Contractor’s proposal, inquiries of owner representative(s), and any other known sources not provided by the Contractor. The Contracting Officer may also identify and analyze the past performance information of the Contractor on any other projects on which they have performed within the past five (5) years of which the Contracting Officer has knowledge or obtains knowledge.

Standard for Evaluation: The Contractor is required to provide information on at least three (3) projects meeting the criteria for past performance on similar projects as outlined above. If the Contractor’s submission for this technical factor does not meet the criteria set forth above, the submission shall be considered non-responsive.

2. Past Experience in Providing Design-Build Services on Similar Projects

The Contractor is requested to submit a detailed description of at least three (3), but no more than five (5), design-build projects performed as the prime contractor within the past five (5) years that are similar in nature to the work described in this solicitation.

Projects shall have a minimum sq. ft. of roof installed of 15,000 sq. ft. On-going project(s) must be at least 75% complete as of January 1, 2020 to be considered for evaluation. Projects submitted must demonstrate experience in roof construction and exterior repair disciplines. Previous projects may have been governmental (federal, state, or local) or private sector contracts.

“Similar projects” are defined as projects which entailed roofing system replacement and exterior repairs for commercial or federally owned or leased space with a roofing sq. ft.

replacement of at least 15,000 sq. ft. completed within the last 5 years. The SSEB will be limited to reviewing only projects of similarity. Projects using a modified bitumen

Membrane roof will receive additional consideration.

The Government considers a project that has all of the following criteria a similar project:

Performed within the last five (5) years or at least 75% complete as of January 1, 2020.

Project in occupied building.

The project must involve roofing and exterior repair disciplines, in an urban site with limited space for material storage/access, and multi-story building requiring exterior lifts.

The project involved the following project delivery methods: Design-build.

Minimum requirement for this factor is providing three projects using the design-build method.

The detailed description submitted for each project should include, as a minimum, the following information:

(1) Project title and location.

(2) Provide a brief description of the scope of the project.

(3) Type of building.

(4) Construction value and the value of major construction disciplines in the project.

(5) Date of contract start and completion. If the project is in progress, please show estimated completion percentage and projected completion date.

(6) Project delivery method (Design-build)

(7) List of subcontracted services and subcontractors used, along with estimated cost of each subcontracted service.

(8) Percentage of work self-performed by the Contractor.

(9) Name, title, address, phone number, and email of the building's owner or a representative of the owner who can attest to the quality of the services provided. It is incumbent on the Contractor to ensure this information is current and accurate. If such a person is no longer available at the organization, please provide the name, email address, and phone number of the person who has the most knowledge of the Contractor’s performance on the project.

A. Identify any problems experienced on this project as the Prime Contractor in regard to design, workmanship, or manufacturer problems. How were they overcome?

The page limit for this factor is 5-double sided pages, single-spaced, Times New Roman font (or comparable), no smaller than 10 point type-size.

Notes:

(1) Failure to provide accurate information to the above items for each project will be considered non-responsive.

(2) It is the Contractor’s responsibility to ensure points of contact, telephone numbers and email addresses are accurate.

(3) Provide required information on all entities that will be considered as part of the

Contractor’s team.

(4) Contractor to provide a separate tabular type summary of all the information

Standard for Evaluation: The Contractor is required to provide information on at least three (3), but no more than five (5), projects meeting the criteria for similar projects as outlined above. If the Contractor’s submission for this technical factor does not meet the criteria set forth above, the submission shall be considered non-responsive.

3. Management Approach /Key Personnel

The Contractor shall describe in general its approach or plan for providing the required services in the solicitation. The Contractor must demonstrate that the plan submitted reflects a comprehensive approach in terms of methodology to accommodate the

Government’s Statement of Work.

The Management Plan to accomplish work shall include:

(1) Quality Control Plan to assure the requirement of the contract will be provided as specified. Include description of quality control system, methods for identifying, correcting and preventing defects in the quality of the planning effort and the identification of authorities and responsibilities of key personnel.

(2) Draft Safety Plan for the Sam Nunn AFC project.

(3) Proposed management and administration for the Sam Nunn AFC project to include a proposed project schedule. The narrative should also discuss any significant contingency issues that could potentially delay overall progress on the project, and what actions the Contractor would propose to mitigate the impact on project completion. The project schedule is not included in the page limit for the factor.

(4) Proposed coordination plan of multiple disciplines including design team and construction team in a design-build environment. Within this plan, the contractor shall speak to the work being executed in a fully occupied building without causing disruption to the daily operation of the building and its tenants. The standard hours of the building are 7AM to 6PM unless otherwise stated. Contractor’s plan for accessing the various roof elevations and plans for working in an occupied US Federal Building.

This will need to include an explanation of how the project will be staged, plans for keeping the site clean, requirements for material storage and methodology for dealing with adverse weather events during the roof installation.

(5) Management plan requiring resumes of key personnel, at minimum, the project manager, designer, construction superintendent, and roofing foreman (if different from the construction superintendent).

Note: The Contractor will not be allowed to substitute key personnel during the course of the project without prior approval by the Contracting Officer or his/her representative. All substitutions MUST have equal or better qualifications and experience.

The page limit for this factor is 4-double sided pages, single-spaced, Times New Roman font (or comparable), no smaller than 10 point type-size. The Contractor shall provide the information identified above in a narrative style format.

Standard for Evaluation: The contractor is required to provide a Management Plan meeting the criteria for

Management Approach as outlined ab If the Contractor’s submission for this technical factor does not meet the criteria set forth above, the submission shall be considered non-responsive.

II.E. Other Information to Submit with Proposal

(1) Representations and Certifications

Offerors are reminded their SAM registration status must be “Active”, at the time their offer is submitted, to be considered for award (see 52.204-7). Offerors submitting a proposal in response to this Solicitation shall complete electronic Annual Representations and Certifications in conjunction with required Entity registration in System for Award Management (SAM), accessed via System for Award Management. Offerors shall also submit with their proposal, the Annual Representations and Certifications (FAR 52.204-8), using the attached Offeror’s Representations and Certifications (C301-SAT).

(2) Qualifications of Offerors ]

Offerors submitting a proposal in response to this Solicitation shall submit with their proposal evidence of their financial responsibility and capacity to perform the Contract. Offerors shall submit this information on GSA Form 527 – Contractor’s Qualifications and Financial Information. Where applicable, point of contact, including names and telephone numbers, are required for all contracts listed.

II.F. Requirements of Joint Venture Offerors

(1) All offers submitted by joint ventures must include a copy of an executed joint venture agreement (with original signatures) which fully discloses the legal identity of each member of the joint venture, the relationship between the members, the form of ownership of each member, and any limitations on liability or authority for each member.

https://www.sam.gov/

(2) An authorized representative of each member of the joint venture must sign the SF 1442 accompanying an offer regardless of any agency relationship established between the members.

(3) In the case of corporations that are joint venture members, the corporation secretary must certify that the corporation is authorized to participate in the joint venture, either by so certifying in the joint venture agreement, or by submitting a separate certification to the Government. The joint venture must also provide a certificate that identifies a principal representative of the joint venture with full authority to bind the joint venture.

(4) Representations and certifications, financial information, and past performance information must be submitted for each member of the joint venture.

III. General Provisions

III.A. Availability of Funds

Issuance of this Solicitation does not warrant that funds are presently available for award of a Contract. Award of the contract shall be subject to the availability of appropriated funds, and the Government shall incur no obligation under this Solicitation in advance of such time as funds are made available to the Contracting Officer for the purpose of contract award.

III.B. Requests for Clarification or Interpretation

The Government will attempt to answer all requests for clarifications or interpretations of the

Solicitation Documents prior to the date set for receipt of offers, but do not warrant that all such requests will be answered within 15 calendar days. Prospective Offerors should make such requests not less than 15 calendar days prior to the date set for receipt of offers.

III.C. Notice to Small Business Firms

A program for the purpose of assisting qualified small business concerns in obtaining certain bid, payment, or performance bonds that are otherwise not obtainable is available through the Small Business Administration (SBA) (Small Business Administration). For information concerning SBA's surety bond guarantee assistance, contact your SBA District Office.

III.D. Information Concerning the Disclosure of Solicitation Results

This acquisition is being conducted under the provisions of FAR Part 15 as a negotiated procurement. In accordance with FAR 3.104 and FAR 15.207, after receipt of proposals, no information regarding the identity of those submitting offers, the number of offers received, or the information contained in such offers will be made available until after award except as provided by FAR 15.503.

III.E. Affirmative Procurement Program

GSA has implemented an Affirmative Procurement Program (APP) intended to maximize the use of recovered materials, environmentally preferable, and bio-based products. Offerors should familiarize themselves with the requirements for using and reporting on the use of such http://www.sba.gov/ materials in performance as set forth in the Agreement. Refer to Clause FAR 52.223-10 encouraging vendors to practice waste reduction.

III.F. Notice Concerning Preparation of Proposals

Offerors are cautioned to carefully read the entire Solicitation and the Agreement to be included in the Contract contemplated by the Solicitation in order to be fully aware of all requirements and clauses in the contemplated Contract. Verify that all blanks requiring information to be supplied in an Offer have been properly filled out, that all pricing and other numerical data is accurately calculated, and that all copies of the Offer contain the same information.

III.G. Contractor Performance Information

(1) Evaluating Contractor Performance: The General Services Administration is using the Contractor Performance Assessment Reporting System (CPARS) module as the secure, confidential, information management tool to facilitate the performance evaluation process.

CPARS enables a comprehensive evaluation by capturing comments from both GSA and the contractor. The website for CPARS is Contractor Performance Assessment

Completed CPARS evaluations are sent to the Past Performance Information Retrieval System (PPIRS) which may then be used by Federal acquisition community for use in making source selection decisions. PPIRS assists acquisition officials by serving as the single source for contractor past performance data.

(2) CPARS Registration: Each award requiring an evaluation must be registered in CPARS.

The contractor will receive several automated emails. Within thirty days of award, the contractor will receive an e-mail that contains user account information, as well as the applicable contract and order number(s) assigned. Contractors will be granted one user account to access all evaluations.

(3) Contractor CPARS Training: Contractors may sign up for CPARS training. A schedule of classes will be posted to the CPARS training site (CPARS Training) and updated as needed.

(4) Contractor Representative (CR) Role: All evaluations will be sent the Contractor Representative (CR) named on your award. The CR will be able to access CPARS to review and comment on the evaluation. If your CR is not already in the CPARS system, the contracting officer will request the name and email address of the person that will be responsible for the CR role on your award.

Once an evaluation is ready to be released the CR will receive an email alerting them the evaluation is ready for their review and comment. The email will indicate the time frame the CR has to respond to the evaluation; however, the CR may return the evaluation earlier than this date.

GSA shall provide for review at a level above the contracting officer (i.e., contracting director) to consider any disagreement between GSA and the contractor regarding GSA’s evaluation of the contractor. Based on the review, the individual at a level above the contracting officer will issue the ultimate conclusion on the performance evaluation.

Copies of the evaluations, contractor responses, and review comments, if any, will be retained as part of the contract file.

III.H. Safeguarding Documents Designated as Sensitive But Unclassified http://www.cpars.gov/ https://www.cpars.gov/webtrain.htm

Certain information contained in the Solicitation Documents may have been designated as Sensitive but Unclassified (SBU) building information. With respect to such information, Offerors shall agree to the terms for receipt of such information, as set forth in the provision “Administrative Matters” in Section III of the Agreement, as a condition of receipt of such information.

IV. FAR/GSAR Solicitation Provisions

IV.A. FAR 52.211-1 Availability of Specifications Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29 (AUG 98)

(a) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to—

GSA Federal Supply Service Specifications Section, Suite 8100 470 East L’Enfant Plaza, SW Washington, DC 20407

Telephone (202) 619-8925 Facsimile (202) 619-8978

(b) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (a) of this provision. Additional copies will be issued for a fee.

IV.B. FAR 52.211-3 Availability of Specifications Not Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions (JUN 1988)

.(Applicable to solicitations that cite specifications not listed in the Index and are not furnished with the solicitation)

(a) The specifications cited in this solicitation may be obtained from: GSA Specifications Unit at (202) 755-0325. MIL Specifications may be obtained by calling (215) 697-2179.

(b) The request should identify the solicitation number and the specification required by date, title, and number as cited in the solicitation.

IV.C. FAR 52.216-1 Type of Contract (APR 84)

The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.

IV.D. FAR 52.222-5 Construction Wage Rate Requirements—Secondary Site of the Work

(MAY 14)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror’s request for a wage determination for a secondary site of the work.

IV.E. FAR 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade

Goals for Female Participation for Each Trade

21.2% 6.9%

These goals are applicable to all of the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the--

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is: [Atlanta, GA Fulton County

IV.F. FAR 52.225-10 Notice of Buy American Requirement—Construction Materials.

(MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American—Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

https://www.acquisition.gov/far/current/html/52_223_226.html#wp1169273 https://www.acquisition.gov/far/current/html/52_223_226.html#wp1169273 https://www.acquisition.gov/far/current/html/52_223_226.html#wp1169273

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

IV.G. Buy American Exceptions

For Buy American exceptions, if any, see the applicable Buy American clause in Section IV of the Agreement

IV.H. FAR 52.233-2 Service of Protest (SEP 06)

(a) Protests, as defined in section 31.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from the Contracting Officer at the address provided in the provision “Receipt of Offers” in Section I (General Information).

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

IV.I. FAR 52.252-1 Solicitation Provisions Incorporated by Reference (FEB 98)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this address:

Federal Acquisition Regulation

NUMBER TITLE DATE

52.214-34 Submission of Offers in the English Language

APR 91

52.215-16 Facilities Capital Cost of Money JUN 03

52.236-28 Preparation of Proposals - Construction OCT 97 https://www.acquisition.gov/far/current/html/FormsStandard62.html#wp1177057 https://www.acquisition.gov/far/current/html/FormsStandard62.html#wp1177057 https://www.acquisition.gov/far/current/html/52_223_226.html#wp1169273 http://www.acquisition.gov/comp/far/index.html

IV.J. GSAR Clause 552.102 Incorporating Provisions and Clauses

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

IV.K. Additional Provisions N/A

IV.L. Requiring Certified Cost or Pricing Data [15.403-4]N/A

V. Instructions and Clauses

V.A. FAR 52.215-1 Instructions to Offerors – Competitive Acquisition (Jan 2017)

(a) Definitions. As used in this provision.

“Discussions” are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer’s discretion, result in the offeror being allowed to revise its proposal.

“In writing,” “writing,” or “written” means any worded or numbered expression that can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.

“Proposal modification” is a change made to a proposal before the solicitation’s closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.

“Proposal revision” is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.

“Time,” if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.

(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).

(c) Submission, modification, revision, and withdrawal of proposals.

(1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages (i) addressed to the office specified in the solicitation, and (ii) showing the time and date specified for receipt, the solicitation number, and the name and address of the offeror. Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.

(2) The first page of the proposal must show.

(i) The solicitation number;

(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);

(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;

(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror’s behalf with the Government in connection with this solicitation; and

(v) Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent’s authority, unless that evidence has been previously furnished to the issuing office.

(3) Submission, modification, revision, and withdrawal of proposals.

(i) Offerors are responsible for submitting proposals, and any modifications or revisions, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.

(ii)(A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and.

(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or

(2) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government’s control prior to the time set for receipt of offers; or

(3) It is the only proposal received.

(B) However, a late modification of an otherwise successful proposal that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(iii) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(iv) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(v) Proposals may be withdrawn by written notice received at any time before award.

Oral proposals in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile proposals, proposals may be withdrawn via facsimile received at any time before award, subject to the conditions specified in the provision at 52.215-5, Facsimile Proposals. Proposals may be withdrawn in person by an offeror or an authorized representative, if the identity of the person requesting withdrawal is established and the person signs a receipt for the proposal before award.

(4) Unless otherwise specified in the solicitation, the offeror may propose to provide any item or combination of items.

(5) Offerors shall submit proposals in response to this solicitation in English, unless otherwise permitted by the solicitation, and in U.S. dollars, unless the provision at FAR 52.225- 17, Evaluation of Foreign Currency Offers, is included in the solicitation.

(6) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award.

(7) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer.

https://www.acquisition.gov/far/html/52_215.html#wp1144511 https://www.acquisition.gov/far/html/52_223_226.html#wp1169636 https://www.acquisition.gov/far/html/52_223_226.html#wp1169636

(8) Proposals may be withdrawn at any time before award. Withdrawals are effective upon receipt of notice by the Contracting Officer.

(d) Offer expiration date. Proposals in response to this solicitation will be valid for the number of days specified on the solicitation cover sheet (unless a different period is proposed by the offeror).

(e) Restriction on disclosure and use of data. Offerors that include in their proposals data that they do not want disclosed to the public for any purpose, or used…